Location via proxy:   [ UP ]  
[Report a bug]   [Manage cookies]                
Scribd Logo
Upload

Welcome to Scribd!

  • 253 views

    Subcontractor Agreement

    Uploaded by

    Seph Infante
    This subcontractor agreement outlines the terms between a general contractor and subcontractor for a construction project. It guarantees the subcontractor payment of a specified amount for labor and sets expectations for completion time and standards of work. The agreement also describes processes for resolving disputes or delays through arbitration.

    Copyright:

    © All Rights Reserved
    Download as DOC, PDF, TXT or read online from Scribd

    Subcontractor Agreement

    Uploaded by

    Seph Infante
    253 views1 page
    This subcontractor agreement outlines the terms between a general contractor and subcontractor for a construction project. It guarantees the subcontractor payment of a specified amount for labor and sets expectations for completion time and standards of work. The agreement also describes processes for resolving disputes or delays through arbitration.

    Original Description:

    Agreement

    Copyright

    © © All Rights Reserved

    Available Formats

    DOC, PDF, TXT or read online from Scribd

    Did you find this document useful?

    Is this content inappropriate?

    This subcontractor agreement outlines the terms between a general contractor and subcontractor for a construction project. It guarantees the subcontractor payment of a specified amount for labor and sets expectations for completion time and standards of work. The agreement also describes processes for resolving disputes or delays through arbitration.

    Copyright:

    © All Rights Reserved
    Download as DOC, PDF, TXT or read online from Scribd
    Download as doc, pdf, or txt
    253 views1 page

    Subcontractor Agreement

    Uploaded by

    Seph Infante
    This subcontractor agreement outlines the terms between a general contractor and subcontractor for a construction project. It guarantees the subcontractor payment of a specified amount for labor and sets expectations for completion time and standards of work. The agreement also describes processes for resolving disputes or delays through arbitration.

    Copyright:

    © All Rights Reserved
    Download as DOC, PDF, TXT or read online from Scribd
    Download as doc, pdf, or txt
    of 1

    Subcontractor Agreement

    This subcontractor agreement is made between {Subcontractor}, Subcontractor, and {General


    Contractor}, General Contractor. The agreement covers work to be done and sets expectations
    regarding that work. Violations of this agreement may lead to legal consequences.

    This agreement guarantees the Subcontractor a payment of {amount} for the work to be done. In
    cases of additional labor, the Subcontractor will be granted additional pay and will have the right
    to negotiate the amount. The total amount due will be paid upon completion of the work, with a
    deposit of {deposit} in place before the work is begun.

    The work to be performed by Subcontractor is limited in nature. It covers exactly and precisely
    the following duties: {list duties}. The method by which these duties are performed, insofar as
    the methods are safe and legal, will be at the discretion of the Subcontractor, except for the
    specific forbidden methods: {list any forbidden methods}.

    Materials for this work will be provided by {the General Contractor/the Subcontractor} and
    have been considered in the pay rate listed above. The Subcontractor will be responsible for
    providing labor and managing the project as stated above.

    It is understood that the work will be started on {date} and will be completed within
    {completion time}. If unforeseen circumstances prevent the safe and effective completion of the
    work, extensions will be discussed but are not guaranteed. If delays are not remedied within 30
    days, the General Contractor will have the right to withhold payment, unless the delays are
    caused by forces within the control of the General Contractor.

    The work performed will be of a certain standard in order to be considered acceptable. These
    standards are explicitly outlined in the description of the project provided to the Subcontractor,
    but generally include {list important requirements}. A complete description can be found
    attached to this contract. Failure to meet these requirements will result in forfeiture of {amount}
    by the Subcontractor.

    If legal disputes arise, the case must be arbitrated by an independent entity qualified for this
    position. The fees for arbitration will be paid by the party deemed in the wrong, and all charges
    will be voluntarily submitted once arbitration is complete.

    By signing this agreement, both the Subcontractor and the General Contractor are agreeing to all
    terms above.

    (Subcontractor Signature) (Date)

    (General Contractor Signature) (Date)

    You might also like