CONSTRUCTION INDUSTRY PAYMENT AND ADJUDICATION ACT (CIPAA) REMEDYING

PAYMENT ISSUES: CIDB G7 CONTRACTORS PERSPECTIVE.

Nik Mohd Dhiyafullah Nik Din and Zulhabri Ismail

Universiti Teknologi MARA (UiTM)

Abstract

Payment defaults remain chronic and prevalent issues that affecting the entire delivery chain of
construction industry. For that particular reason, Government of Malaysia have embarked serious
afford to reduce payment default issues by enacting Construction Industry Payment and
Adjudication Act (CIPAA) in 2012. Acknowledging the fact that CIPAA is relatively new to the
industry, the possibility of industrys key players to be lack of information and awareness about
CIPAA is greater. Therefore, this research aims to explore and reveal remedies offered via CIPAA as
well as the awareness and expectation of CIDB G7 contractors towards CIPAA. Hence, the research
objectives are to identify pertinent features of CIPAA in remedying payment default issues, to
investigate the perceptions and expectations of CIDB G7 contractors towards CIPAA in addressing
payment default issues and to examine the potential implications and limitations of such Act towards
current construction industry practices. This research has adopted mixed methods of questionnaire
survey and semi-structured interviews to CIDB G7 Contractors in Klang Valley area. The research
suggested that the most pertinent feature of CIPAA from contractors point of view is to streamlining
payment procedures for construction works. Apart from that, research also revealed that contractors
are optimistic that CIPAA will be able to provide legal remedy to non-payment and improve the
delivery system in construction industry. Although CIPAA will be the platform for resolving
payment disputes by means of adjudication decision and establish payment process, procedures and
timeframes, it is anticipated that CIPAA is depending on the competency and integrity of the
adjudicators. In conclusion, it is aimed that the construction industry can be benefited from the
enactment of CIPAA. Thus, the industry as a whole must collaborate and focus on their synergies to
promote effective implementation of CIPAA.

Keyword: Payment default; Construction Industry Payment and Adjudication Act (CIPAA)

Introduction

In the attempt to promote and uphold the image of construction industry, payment constantly has
been an issue and barrier that hinder such effort (Ameer Ali, 2006; Sahab and Ismail, 2011; and
Hasmori, Ismail and Said, 2012). Often, the risk of late or non-payment in construction industry could
be adversarial and disastrous and subsequently, affect the economic growth of the country (Hasmori,
Ismail and Said, 2012 and Rahman and Ye, 2010). Although there are specific provisions provided in
all standard forms of construction contract addressing the payment obligations, Judi and Muhamed
Sabli (2010) revealed that payment defaults remain substantial in the Malaysian construction
industry. As a result, cash flow problem that caused by payment defaults can severely affect the
implementation of construction projects. Consequently, Construction Industry and Payment
Adjudication Act (CIPAA) have been passed on June 18, 2012 and gazette on June 22, 2012 (Fong,
2012). Subsequent to that, the Act comes into operation effective on April 15, 2014 (Rajoo, 2014).
Acknowledging the fact that CIPAA is newly introduced to the industry, simultaneously the
possibility of industrys key players to be lack of information and awareness about CIPAA is greater.

21
Payment Defaults

Rahman and Ye (2010) and Judi and Mohamed Sabli (2010) defined payment as the sum of money
paid to contractors, consultants and suppliers after their works, service or materials has been
successfully realized or accepted. Therefore, payment always plays the significant point throughout
the completion of the project (Sin, 2006 and Saad, 2008) and the ease of cash flow is an essential
element in delivering a successful project (Karib, Shaffii, and Nor, 2008). Regular financial injection is
crucial to ensure the contractor is able to proceed work diligently (Hasmori, Ismail and Said, 2012;
Judi and Mohamd Sabli, 2010). Adversely, any payment defaults will give knocking effect on the
whole of construction business chain (Karib, Shaffii, and Nor, 2008). To add, as each and every key
player in construction industry are linked between one and another, hence, contractor is not the only
party that affected, but owner and project itself will suffer in the event of payment defaults
(Abraham, 2012). Hasmori, Ismail and Said (2012) and Fong (2007) added that, payment in
construction industry is crucial as end products of the construction industry are becoming fixture to
the ground and will not be able to remove or dismantle to recover for non-payment.
Issues of payment have plagued the construction industry for a long time. Frequently,
disputes arise from under payment, late payment and non payment to the contractor are commonly
highlighted and discussed, contributing about 56.7% in profiling of construction disputes (Abdul
Rashid et al. 2007). There are constant issues among key players of the industry, as payment defaults
would always be revolving around in construction industry (Karib, Shaffii, and Nor, 2008). As such,
contractors would be the direct and tremendous affected party due to the fact that Contractor is the
party who upfront their capitals to ensure project delivery before receives payment from client (Karib,
Shaffii, and Nor, 2008). Although there are specific provisions provided in all standard forms of
construction contract addressing the payment obligations, Judi and Mohamed Sabli (2010) revealed
that issues such as under, late or non-payment remain substantial in the Malaysian construction
industry. As a result, cash flow problem can severely affect the implementation of construction
projects and provision of the nations infrastructure and built environment. Table 1 provides brief
definition of payment defaults happened in construction industry, namely under payment, late
payment and non-payment.

Table 1: Payment defaults (Ameer Ali, 2005 in Judi and Muhamed Sabli, 2010)

No. Payment defaults Description

1 Under Payment The certified and paid amount by the Client is lower than
the value of Contractors work done.
2 Late Payment Client taking longer time than the allocated time (beyond
the period of honoring certificate) to issue/making payment
to the Contractor.
3 Non-Payment No payment is release to Contractor albeit the Contractor
has completed certain area of works

Construction Industry Payment and Adjudication Act (CIPAA)

Ameer Ali (2006), Abdullah Habib and Abdul Rashid (2006) and Sahab and Ismail (2011) are of the
opinion that Malaysia has followed the footsteps of United Kingdom, Australia, New Zealand and
Singapore in introducing the concept of statutory adjudication to construction industry. With the aim
to resolve cash flow issues, facilitate payment and expedite the dispute resolution, the facilities
offered under CIPAA provisions are said to be comprehensive to achieve such target (Ameer Ali, 2006
and Fong, 2012). In general, Clause 2, Part I of the Act provides that CIPAA applies to all construction

22
contracts made in writing carried out wholly or partly within the territory of Malaysia and giving
statutory right for unpaid parties to be paid for the work done.
There are some concerns that this new legislation may result claim culture, with the claimant
proceeding to adjudication on the slightest dispute, resulting in precious time and energy being spent
on continuous claims instead of focusing on completing the project (Fong, 2012). Contrary to that,
Rajoo (2012) contested such opinion as the adjudicator is empowered to order for adjudication costs
and fix the quantum of costs to be paid, thus it might deter any party from making frivolous payment
claims.

Lessons learnt from other countries

Certain countries have already introduced Acts and Legislations to address payment defaults issues
including United Kingdom (UK), Australia, New Zealand and Singapore (Karib, Shaffii, and Nor,
2008). Table 2 presents various Acts and Legislations from other countries together with their
functions. Generally, all of the Acts focus on remedying payment defaults and improving cash flow.
Apart from that, Table II also demonstrates the similarity in terms of function between CIPAA and
the Construction Contracts Act 2002 (New Zealand) and Construction Contracts (Security of
Payment) Act 2004 (Northern Territory, Australia).

Table 2: Payment Related Act and Functions in Other Countries (Karib, Shaffii, and Nor, 2008; Sahab
and Ismail, 2011; Ramachandra, 2013)

No. Acts and Litigations Functions

1 Housing Grants, Construction and To improve payment practices
Regeneration Act 1996 (United Kingdom,
England)
2 Building and Construction Industry Security Reduce payment delay
of Payment Act 1999 amended in 2002 (New
South Wales, Australia)
3 Building and Construction Industry Security Entitlements to progress payment
of Payment Act 2002 (Victoria, Australia)
4 The Construction Contracts Act 2002 (New Facilitate regular and timely payment,
Zealand) speedy dispute resolution, provide
remedies for non-payment
5 Building and Construction Industry of Entitlements to progress payment
Payment Act 2004 (Queensland, Australia)
6 Construction Contracts Act 2004 (Western Ensure the money flows in the contractual
Australia, Australia) chain by ensuring timely payment
7 Construction Contracts (Security of Payment) Facilitate regular and timely payment,
Act 2004 (Northern Territory, Australia) speedy dispute resolution, provide
remedies for non-payment
8 Building and Construction Industry Security Expediting payment and improving cash
of Payment Act 2004 (Singapore) flow
9 Tasmanian Security of Payment Act 2009 Reform payment behavior in the industry

23
Pertinent Features of CIPAA

Among the pertinent features of CIPAA as drawn by Clause 5 (2), Part II and Clause 35, Part IV of the
Act are outlawing the practices of Pay-When-Paid and Conditional Payment from construction
contract. As the trend of Pay-When-Paid and Conditional Payment may disrupt the chain of
business and affect other party that directly or indirectly involved, it is critical to discontinue this
practice in the industry (Judi and Muhamed Sabli, 2010). In other words, CIPAA requires payment to
be made for all work done that is practically accepted. In the event of payment default happens at any
chain point, the relevant parties must resolve it themselves but not transferring the defaults to third
parties (Abdullah Habib and Abdul Rashid, 2006).
Next, CIPAA is aimed to prevent uncertainties in payment among all parties in the
construction contract (Karib, Shaffii, and Nor, 2008). However, these statutory implied terms shall be
relevant and default mechanism in the absence of express terms in construction contract (Amer Ali,
2006; Rajoo, 2012 and Fong, 2011). Hence, Karib, Shaffii and Nor (2008) mentioned that, CIPAA will
streamline payment process and timeframes for construction contracts and provide procedures on
responses following payment claims. This pertinent feature is supported by Clause 6 of Part II as it
mentioned that non-paying party may respond in several options to claimant depending on the case
may be.
Another pertinent feature is establishing a cheaper, speedier, contemporaneous, binding,
statutorily-enabled adjudication mechanism as mentioned in Clause 7, Part II of CIPAA. As pointed
out by Karib, Ismail and Nor (2008), CIPAA have introduced new mechanism for settling
construction disputes via adjudication. Under Clause 12 (2), Part II of CIPAA, the adjudicator must
make decision on the disputes within 45 days; therefore, ensures the speedy resolution although it is
not final (Rajoo, 2012). In similar vein, Abraham (2012) and Majid (2013) have mentioned that
adjudication also provides flexibility in regards of reference to adjudication shall not hinder the
reference to other dispute resolution as stated in Clause 13, Part II of CIPAA.
Last but not least, Part IV of the CIPAA Enforcement of Adjudication Decision provides
security and remedies for the recovery of payment following a decision by the adjudicator. As such,
CIPAA allows the successful aggrieved party to recover its past debts and damages as well as avoid
incurring further future exposure (Hasmori, Ismail and Said, 2012). Under this pertinent feature, the
remedies available under the Act are interest on late payment (Clause 29, Part IV), suspension of
works (Clause 29, Part IV), direct payment from principal (Clause 30, Part IV), judgment debt
recovery (Clause 30 (4), Part IV), and other rights or remedies available in Construction Contract or
any other written law (Clause 31 (2), Part IV).

Table 3: Pertinent Features of CIPAA (Karib, Shaffii and Nor, 2008)

No. Pertinent Features of CIPAA Clauses

1 Outlawing the Practice of Pay-When-Paid and Conditional Clause 5 (2), Part II
Payment from Construction Contracts and Clause 35, Part
VI
2 Streamlining Payment Procedures for Construction Works Clause 6, Part II
3 Establishing a Cheaper, Speedier, Contemporaneous, Clause 7, Part II
Binding, Statutorily-Enabled Adjudication Mechanism
4 Providing Security and Remedies for the Recovery of Clause 29, Part IV
Payment Following a Decision by the Adjudicator and Clause 30, Part
IV

24
Expectation Towards CIPAA

The poor payment practices remain chronic problem and have affected the construction industry over
years. Therefore, Ameer Ali (2006) and Karib, Ismail and Nor (2008) disclose that the intervention of
CIPAA by way of creating a regulatory framework will provide for mechanism to remedy payment
defaults. Firstly, contractors are optimist that CIPAA will be able to offer speedy, time-bound,
cheaper, binding and contemporaneous dispute resolution (Ameer Ali, 2006). Thus, CIPAA under
Clause 7, Part II will allow swift resolution of disputes by way of adjudication, allowing projects to be
completed without wasting time and money in litigation (Karib, Shaffii, and Nor, 2008). Karib, Ismail
and Nor (2008) mentioned the next expectation towards CIPAA is to provide legal remedy to non-
payment as by way of suspend or reduce the progress of performance or direct payment from
principal. Simultaneously, contractors are looking forward that CIPAA will improve delivery system
as Clause 12, Part II of CIPAA provides quicker and cheaper disputes resolution. As a result,
inefficient dispute resolution methods which are peripheral to the core business of construction can
be avoided (Majid, 2011 and Fong, 2012).
With the primary objective to ease the cash flow of contractors, CIPAA is expected to help the
industry in sustaining the competitiveness of all parties to implement construction projects (Karib,
Shaffii, and Nor, 2008). Ameer Ali (2006) added that as the good cash flow will eliminate the
borrowing cost, it is indirectly promotes and sustains the competitiveness of Contractors offered
price. Next, it encourages professionalism and promotes integrity amongst contractors, construction
professionals, and client organizations (Karib, Shaffii, and Nor, 2008 and Ameer Ali, 2006). Apart
from that, CIPAA will also enhance the value of human capital in the construction industry (Karib,
Shaffii, and Nor, 2008). Additionally, Karib, Shaffii and Nor (2008) mentioned that CIPAA will allow
all parties to focus in completing the works effectively and efficiently since the payment is no longer
an issue to them. As a result, it will then give positive impact on the quality of construction works.

CIPAA Remedying Payment Defaults and Dispute Resolution

Remedying Payment Defaults

From construction contracts perspective, contractors are entitled to be paid upon the fulfillment of
their contractual obligations as provided under the contract (Ramachandra, 2013). The primary
objective of the enacted CIPAA is facilitating regular and timely payment. Majid (2013) has further
explained that CIPAA provides avenue for the Contractor to challenge the valuation and/or
certification of works done. Moreover, CIPAA is to address critical cash flow issues in the
construction industry (Sahab and Ismail, 2011). It should be noted that Clause 35, Part IV of CIPAA
would removed the practice of conditional payment such as pay when paid or pay if paid (Rajoo,
2012). As such, Abraham (2012) outlined that any payment defaults can be avoided and improves the
Contractors cash flow.

Dispute Resolution

The need for cheaper and speedier mechanism to resolve dispute had led to the enactment of CIPAA
as mentioned in Clause 7, Part II of the CIPAA. Thus, CIPAA will provide platform for dispute
resolution by way of statutory adjudication. As a result, it allows the project to continue the regular
activities without obstruction, whilst adjudication proceeding take place. KLRCA (n.d.) stated that
Clause 12 (5), Part II of the Act allows a party (claimant) who is owed monies to promptly obtain
payment from the non-paying party (respondent), based on assessment by industry expert known as
adjudicator. To add, adjudication proceeding is conducted privately (Clause 20, Part II) and
adjudicators decision is temporarily binding the parties (Clause 13, Part II) (KLRCA, n.d.).
Adjudication offers a faster procedure in resolving disputes among parties under the contract. Since

25
the adjudication decision is only binding but not final, it may lead the dissatisfy party to further refer
such dispute to arbitration or court litigation (Fong, 2012). The following Figure 1 and Table 4
visualizes in clearer image of the process and time taken for adjudication proceeding.

Figure 1: Adjudication Process under CIPAA (Rajoo, 2012)

Table 4: Procedure and time taken of adjudication (Shirley, 2012)

No. Item Section Requirements The Limit

1 Payment 5 To state: None
Claim (a) Amount claimed and due date
(b) Cause of action and provision in
contract relied on
(c) Description of work or services to
which payment relates
(d) Statement that it is made under
the Act
2 Payment 6 (a) May admit or dispute partly or 10 working days
Response wholly
(b) Attach payment of amount
admitted
(c) If fail to respond then it is deemed
that the entire claim is disputed
3 Notice of 7(2) and State nature and description of May serve on
Adjudication 8 dispute and remedy sought together respondent after
with supporting documents expiry of time limited
for payment response
4 Adjudication 9 State nature and description of 10 working days from
Claim dispute and remedy sought together receipt of acceptance
with supporting documents of appointment by
adjudicator under
Section 22(2) or 23(2)

26
 5 Adjudication 10 Answer the adjudication claim and 10 working days from
Response include any supporting documents. . receipt of adjudication
If not filed, claimant may proceed claim
with the adjudication after time
limited to do so
6 Adjudication 11 Reply to response and include any 5 working days from
Reply supporting documents receipt of adjudication
response

Implications and Limitations

Towards payment process and procedures

Under CIPAA provision, the unpaid party is allowed to refer any payment defaults including
payment for variation order to adjudication. Thus, from the perspective of Government, Public Works
Department (PWD) basically has taken into consideration of such provision towards current
procedures (Majid, 2013). From the foregoing, government has introduced new guidelines in order to
adhere with the provision outlined by CIPAA. Under new procedure, Majid (2013) has emphasize
that contract administrator may apply for approval in principle. Consequently, the contract sum can
be adjusted provisionally and appropriate payment of such variation order can be made accordingly.
Nevertheless, there are some limitations of CIPAA in addressing payment defaults. Firstly,
the payment default is defined as the party claims payment of a sum is not being paid in whole or in
part within specified time (Clause 5 (2) (a), Part II of the CIPAA). To address this, the paying party
may indicate the period of honouring payment that accords with its financing capability (Fong, 2012).
As such, the paying party is still having advantages as they holding discretion to specified payment
term at their convenient. In addition, Fong (2012) mentioned that reference to CIPAA can only be
made for dispute arises due to payment defaults only (Clause 7 (1), Part II). Besides, payment has also
been narrowly defined in the CIPAA to mean payment for work done or services rendered under the
express terms of the construction contract (Clause 2 and Clause 4 of Part I of CIPAA) (Fong, 2012).
Hence, it has to await judicial clarification as to what constitutes or is encompassed by work done or
services rendered under the express terms of the contract, especially whether a strict literal or
otherwise, a purposive interpretation is accorded to the meaning of express terms (Fong, 2012 and
Rajoo, 2012).

Towards disputes resolution process

Adjudication under CIPAA gives additional right to dispute resolution method conferred statutorily
and provides an aggrieved party to refer the disputes to arbitration or court proceeding at the same
time of such dispute has been referred to adjudication (Karib, Shaffii and Nor, 2008). Next, Ameer Ali
(2006); Rajoo (2012); and Fong (2012) mentioned, statutory adjudication offers flexibility to the parties
to terminate the adjudication upon agreement in writing or decision in arbitration or court. In
addition, CIPAA improves the time taken for the adjudication in making decision any dispute
proceeding (Ameer Ali, 2006 and Sahab and Ismail, 2011). Fong (2012) has further explained that
CIPAA gives ample rooms for parties as well as adjudicator to present and determine the dispute on
the merits rather than on technicalities. From the Governments perspective, Majid (2011) added that
CIPAA will improve record keeping in order protecting the Clients interest against claims from the
contractors.

27
 Even so, the effectiveness of CIPAA is critically dependent on the competency and integrity
of the adjudicators as well as the efficient and effective implementation of the CIPAA by both the
KLRCA and the High Court (Fong, 2012). Furthermore, CIPAA is differs from Housing Grants,
Construction and Regeneration Act 1996 in United Kingdom as it can only been commence when the
disputes arise due to payment defaults (Fong, 2012 and Rajoo, 2012). Rajoo (2012) pointed out, in
respect of appointing the adjudicator, the disputing parties are only at liberty to agree on the
adjudicator after the dispute has arisen. If the parties are unable to agree, the default appointing body
is the Director of KLRCA (Fong, 2012). The adjudicator is not empowered to determine and
conclusively decide on his own jurisdiction due to the absence of Kompetenz - Kompetenz provision
from CIPAA (Fong, 2012). As a result, the initial intention to resolve dispute in cheaper and quicker
mode is remain arguable.

Research Aim and Objectives

This research aims to explore and reveal remedies offered via Construction Industry Payment and
Adjudication Act (CIPAA) as well as the awareness and expectation of CIDB G7 contractors towards
CIPAA. The research objectives are as follows:

1. To identify the pertinent features of Construction Industry Payment and Adjudication Act
(CIPAA) in remedying payment default issues;

2. To investigate the perceptions and expectations of CIDB G7 contractors towards Construction

Industry Payment and Adjudication Act (CIPAA) in addressing payment default issues;

3. To examine the potential implications and limitations of Construction Industry Payment and
Adjudication Act (CIPAA) towards current construction industry practices.

Survey Result Analysis

A total of thirty (30) respondents from CIDB G7 Contractors have returned their response and
feedback by completing and duly answered sets of questionnaires. Table 5 shows the tabulation of
respondents profession.

Table 5: Tabulation according to respondents profession

No. Profession Total Percentage (%)

1 Project Manager 6 20%
2 Architect 2 7%
3 Engineer 5 17%
4 Quantity Surveyor 17 57%
5 Others 0 0%
TOTAL 30 100%

A total of five semi-structured interviews from CIDB G7 Contractors were conducted to validate and
support the former results obtained from literature review and questionnaire survey. Table 6
illustrates the details of interviewees

28
 Table 6: Tabulation according to respondents profession

Interviewee Position / Profession Years of Nature of Project Years of

ID Experience Involved Involvement
R001 Commercial Manager 25 years Public Amenities / 20 years
Infrastructure
R002 Project Manager 30 years Public Amenities / 20 years
Infrastructure
R003 Project Director 22 years Public Amenities / 25 years
Infrastructure
R004 Project Director 25 years Public Amenities 12 years
R005 Senior Project 15 years Residential / Commercial 12 years
Architect

Respondents experience in payment defaults

From the data collected, 1 respondent claimed that payment defaults are very often whilst another
13 respondents or 43% pointed out that the occurrence of payment defaults is often. Additionally,
the other 11 respondents or 37% have opted for sometimes. In contrast, 5 respondents or 17% have
claimed that such defaults are rarely happened.
Next, majority of the interviewees are of the opinion that payment default issues are still
prevalent in the construction industry. Interviewees R001, R002 and R003 were unanimous that the
payment problems have always been a dilemma within the industry while R005 stated that payment
defaults are happened occasionally to his project. On the other hand, R004 claimed that payment
issues are rarely happened to his company.

Common duration of the payment defaults listed

The subsequent element that has been outlined by questionnaire is duration taken in order to resolve
payment defaults. From the data collected, 57% or 17 respondents claimed that payment defaults are
normally took between 2 weeks to 1 month to resolve. In addition, 8 respondents (27%) indicated
payment defaults can only be resolved within 1 to 2 months whilst 3 respondents (10%) claimed that
such defaults require less than 2 weeks to be resolved. However, the remaining 2 respondents (7%)
opted for 2 4 months duration.
From the semi-structured interview conducted, R001 and R002 mentioned that payment
defaults basically took 2 to 4 weeks and 2 to 6 weeks, respectively to be resolved. In contrast, R003
indicated between 4 to 5 weeks to resolve payment defaults but in certain cases, it may prolong until 3
months. Nonetheless, R004 stated payment defaults require up to 1 to 2 weeks while R005 mentioned
that payment defaults commonly take about 1 month to be resolved. In average, any payment
defaults would require 2 to 6 weeks before it can be resolved. In short, payment defaults are critical
issues and necessary improvement should take place to address the issue effectively.

Respondents awareness about CIPAA

All of the interviewees are well-aware with the enactment of CIPAA. Despite of positive results from
semi-structured interview, questionnaire survey indicated that out of 30 numbers of respondents, 13
respondents (43%) answered Yes. In contrast, the remaining 57% or 17 respondents answered No.

29
 Table 7: Respondents awareness towards CIPAA

Awareness About CIPAA Frequency Percentage (%)

Yes 13 43%
No 17 57%
TOTAL 30 100

Objective 1 : To identify the pertinent features of Construction Industry Payment and

Adjudication Act (CIPAA) in remedying payment default issues;

This objective was achieved via mixed methods of questionnaire survey and semi-structured
interview. Table 8 tabulated the comparison between literature review, results from questionnaire
survey and semi-structured interview.

Table 8: Pertinent Features of CIPAA

No. Literature review Results from Questionnaire Results from Semi-
Survey structured Interview
1 Outlawing the practice of Establishing a Cheaper, Streamlining Payment
Pay-When-Paid and Speedier, Contemporaneous, Procedures for Construction
Conditional Payment from Binding, Statutorily-Enabled Works (Ameer Ali, 2006;
Construction Contracts Adjudication Mechanism Saad, 2008; Fong, 2011; Rajoo,
(Karib, Shaffii and Nor, 2008; (Hasmori, Ismail and said, 2012). (R001 / R002 / R004)
Judi and Muhamed Sabli, 2012; Abraham, 2012; Rajoo,
2010). 2012; Majid, 2013).
2 Streamlining Payment Streamlining Payment Establishing a Cheaper,
Procedures for Construction Procedures for Construction Speedier, Contemporaneous,
Works (Ameer Ali, 2006; Works (Ameer Ali, 2006; Binding, Statutorily-Enabled
Saad, 2008; Fong, 2011; Saad, 2008; Fong, 2011; Rajoo, Adjudication Mechanism
Rajoo, 2012). 2012). (Hasmori, Ismail and said,
2012; Abraham, 2012; Rajoo,
2012; Majid, 2013). (R003 /
R004)
3 Establishing a Cheaper, Outlawing the practice of Outlawing the practice of
Speedier, Contemporaneous, Pay-When-Paid and Pay-When-Paid and
Binding, Statutorily-Enabled Conditional Payment from Conditional Payment from
Adjudication Mechanism Construction Contracts Construction Contracts
(Hasmori, Ismail and said, (Karib, Shaffii and Nor, 2008; (Karib, Shaffii and Nor, 2008;
2012; Abraham, 2012; Rajoo, Judi and Muhamed Sabli, Judi and Muhamed Sabli,
2012; Majid, 2013). 2010). 2010). (R001)
4 Providing Security and Providing Security and Providing Security and
Remedies for the Recovery Remedies for the Recovery of Remedies for the Recovery of
of Payment Following a Payment Following a Payment Following a
Decision by the Adjudicator Decision by the Adjudicator Decision by the Adjudicator
(Hasmori, Ismail and said, (Hasmori, Ismail and said, (Hasmori, Ismail and said,
2012; Fong, 2006; Rajoo, 2012; Fong, 2006; Rajoo, 2012). 2012; Fong, 2006; Rajoo, 2012).
2012). (R005)

30
Objective 2 : To investigate the perceptions and expectations of CIDB G7 contractors towards
Construction Industry Payment and Adjudication Act (CIPAA) in addressing payment default
issues;

Likewise the first objective, this objective was achieved also via mixed methods of
questionnaire survey and semi-structured interviews. Subsequent to that, these advantages have been
listed in questionnaire survey and respondents were requested to rank such advantages based on the
most expected to the least expected. The following Table 9 is comparative analysis between literature
review and outcome from the field study. From the table, results from semi-structured interview
indicates that out of 6 variables obtained from literature review, there are only 3 variables that been
acknowledged by interviewees as primary and crucial. This situation might caused by limited
amount of semi-structured interviewees conducted for this research.

Table 9: Comparative analysis between Literature Review and Field Study Outcomes

Results from Questionnaire Results from Semi-

No. Literature review
Survey structured Interview
1 Speedy, Time-bound, Provides Legal Remedy to Improves the Delivery
Cheaper, Binding & Non-Payment (Ameer Ali, System (Ameer Ali, 2006;
Contemporaneous Dispute 2006; Karib, Shaffii and Nor, Karib, Shaffii and Nor, 2008).
Resolution (Ameer Ali, 2006; 2008). (R001 / R002 / R004, R005)
Karib, Shaffii and Nor, 2008).
2 Provides Legal Remedy to Enhances Industry Image & Speedy, Time-bound,
Non-Payment (Ameer Ali, Professionalism and Enhances Cheaper, Binding &
2006; Karib, Shaffii and Nor, Human Capital & Integrity Contemporaneous Dispute
2008). (Ameer Ali, 2006; Karib, Resolution (Ameer Ali, 2006;
Shaffii and Nor, 2008). Karib, Shaffii and Nor, 2008).
(R003 / R005)
3 Improves the Delivery Improves the Delivery System Provides Legal Remedy to
System (Ameer Ali, 2006; (Ameer Ali, 2006; Karib, Non-Payment (Ameer Ali,
Karib, Shaffii and Nor, 2008). Shaffii and Nor, 2008). 2006; Karib, Shaffii and Nor,
2008). (R004)
4 Sustains Competitiveness of Speedy, Time-bound, -
Parties (Ameer Ali, 2006; Cheaper, Binding &
Karib, Shaffii and Nor, 2008). Contemporaneous Dispute
Resolution (Ameer Ali, 2006;
Karib, Shaffii and Nor, 2008).
5 Enhances Industry Image & Enhances Construction -
Professionalism and Quality (Ameer Ali, 2006;
Enhances Human Capital & Karib, Shaffii and Nor, 2008).
Integrity (Ameer Ali, 2006;
Karib, Shaffii and Nor, 2008).
6 Enhances Construction Sustains Competitiveness of -
Quality (Ameer Ali, 2006; Parties (Ameer Ali, 2006;
Karib, Shaffii and Nor, 2008). Karib, Shaffii and Nor, 2008).

31
Objective 3 : To examine the potential implications and limitations of Construction Industry
Payment and Adjudication Act (CIPAA) towards current construction industry practices;

The third objective of the research is to examine the potential implications and limitations of
Construction Industry Payment and Adjudication Act (CIPAA) towards current construction industry
practices. Table 10 below showed the comparison of potential implications of CIPAA from
questionnaire survey and semi-structured interview. From the table, results from semi-structured
interview indicates that out of 12 variables obtained from literature review, there are only 6 variables
that been considered by interviewees as significant. Therefore, the remaining 6 variables are
considered as non-critical implications by the interviewees. As the semi-structured interview
conducted on 5 number of CIDB G7 contractors only, an increase in interviewee numbers in contrast
might give different pattern and result.
Apart from that, Table 11 demonstrates the potential limitations of CIPAA. Results from
questionnaire survey found that the absence of kompetenz-kompetenz provision, thus the
adjudicator is not empowered to determine and conclusively decide on his own jurisdiction has been
disregarded from primary potential limitations of CIPAA by the respondents. To add, semi-
structured interview discovered the absence of kompetenz-kompetenz provision, thus the
adjudicator is not empowered to determine and conclusively decide on his own jurisdiction and the
paying party having advantages as they holding discretion to specify payment term at their
convenient are non-critical potential limitations. As such, the non-critical variables from both
questionnaire survey and semi-structured interview are excluded from the table.

Table 10: Potential Implications of CIPAA

Results from Results from Semi-

No. Literature review
Questionnaire Survey structured Interview
1 Establish payment Provide positive Establish payment process,
process, procedures and adjudication decisions procedures and
timeframes for which are enforceable timeframes for
construction contracts (Fong, 2012). construction contracts
(Majid, 2013). (Majid, 2013). (R001 / R002
/ R003 / R004 / R005)
2 Introduction of approval Industry players will have CIPAA will promotes the
in principle for intended to improve in terms of good practice by making
variation orders to allow record-keeping to timely payments and
payment upon safeguard the interest for ensure accountability in
completion of such V.O and against claims (Majid, the projects involved
(Majid, 2013). 2011). (Abraham, 2012; Fong,
2012). (R001 / R002 / R003
/ R004 / R005)
3 Addressing payment CIPAA will promotes the Ensures the speedy
irregularities in the multi- good practice by making resolution of dispute
layer contractual timely payments and (Abraham, 2012;
arrangements (Majid, ensure accountability in Rajoo.2012). (R001 / R004 /
2013). the projects involved R005)
(Abraham, 2012; Fong,
2012).
4 Ensures the speedy Ensures the speedy Provide positive
resolution of dispute resolution of dispute adjudication decisions
(Abraham, 2012; (Abraham, 2012; which are enforceable
Rajoo.2012). Rajoo.2012). (Fong, 2012). (R004 / R005)

32
5 Provide positive Establish payment process, Industry players will have
adjudication decisions procedures and to improve in terms of
which are enforceable timeframes for record-keeping to
(Fong, 2012). construction contracts safeguard the interest for
(Majid, 2013). and against claims (Majid,
2011). (R004 / R005)
6 The Act applies globally CIPAA also improve the CIPAA also improve the
to construction industry time taken for the time taken for the
as it has been enacted by adjudication in making adjudication in making
the Parliament and have decision in any dispute decision in any dispute
legal jurisdiction (karib, proceeding (Ameer Ali, proceeding (Ameer Ali,
Shaffii, and Nor, 2008). 2006; Sahab and Ismail, 2006; Sahab and Ismail,
2011). 2011). (R004)
7 CIPAA allow reference to CIPAA allow reference to -
arbitration/court arbitration/court
proceeding while such proceeding while such
dispute has been referred dispute has been referred
to adjudication (karib, to adjudication (karib,
Shaffii, and Nor, 2008). Shaffii, and Nor, 2008).
8 CIPAA offers flexibility to Addressing payment -
the parties to terminate irregularities in the multi-
the adjudication upon layer contractual
agreement by both parties arrangements (Majid,
(Ameer Ali, 2006; Rajoo, 2013).
2012; Fong, 2012).
9 CIPAA also improve the CIPAA gives opportunity -
time taken for the for parties and adjudicator
adjudication in making to present and determine
decision in any dispute the dispute on the merits
proceeding (Ameer Ali, (Fong, 2012).
2006; Sahab and Ismail,
2011).
10 CIPAA gives opportunity Introduction of approval -
for parties and in principle for intended
adjudicator to present and variation orders to allow
determine the dispute on payment upon completion
the merits (Fong, 2012). of such V.O (Majid, 2013).
11 Industry players will have The Act applies globally to -
to improve in terms of construction industry as it
record-keeping to has been enacted by the
safeguard the interest for Parliament and have legal
and against claims (Majid, jurisdiction (karib, Shaffii,
2011). and Nor, 2008).
12 CIPAA will promotes the CIPAA offers flexibility to -
good practice by making the parties to terminate the
timely payments and adjudication upon
ensure accountability in agreement by both parties
the projects involved (Ameer Ali, 2006; Rajoo,
(Abraham, 2012; Fong, 2012; Fong, 2012).
2012).

33
 Table 11: Potential Limitations of CIPAA

Results from Results from Semi-

No. Literature review
Questionnaire Survey structured Interview
1 The paying party having The effectiveness of The effectiveness of CIPAA
advantages as they CIPAA is critically is critically dependent on
holding discretion to dependent on the the competency and
specified payment term competency and integrity integrity of the adjudicators
at their convenient (Fong, of the adjudicators (Rajoo, (Rajoo, 2012). (R001 / R002 /
2012). 2012). R004)
2 The paying party may The paying party may To enforce the adjudication
indicate the period of indicate the period of decision, the party may opt
honoring payment that honoring payment that for suspension or reduction
accords with their accords with their of works or direct payment
financing capability financing capability (Fong, from principal only (Fong,
(Fong, 2012). 2012). 2012; Rajoo, 2012). (R001 /
R004 / R005)
3 Reference and Reference and CIPAA never be feasible to
commencement of commencement of achieve unanimous,
adjudication under the adjudication under the voluntary adherence as the
CIPAA is limited to CIPAA is limited to opportunism of the
payment dispute only payment dispute only minority will drive the
(Fong, 2012; Rajoo, 2012). (Fong, 2012; Rajoo, 2012). entire CIPAA objective
down (Fong, 2012; Rajoo,
2012). (R003 / R005)
4 The interpretation of To enforce the The paying party may
payment as outlined by adjudication decision, the indicate the period of
CIPAA may exclude party may opt for honoring payment that
payment for variation suspension or reduction of accords with their financing
work, loss and expense, works or direct payment capability (Fong, 2012).
damages and quantum from principal only (Fong, (R003)
merits claims (Fong, 2012; Rajoo, 2012).
2012).
5 CIPAA never be feasible The paying party having Reference and
to achieve unanimous, advantages as they commencement of
voluntary adherence as holding discretion to adjudication under the
the opportunism of the specified payment term at CIPAA is limited to
minority will drive the their convenient (Fong, payment dispute only
entire CIPAA objective 2012). (Fong, 2012; Rajoo, 2012).
down (Fong, 2012; Rajoo, (R002)
2012).
6 The effectiveness of The interpretation of The interpretation of
CIPAA is critically payment as outlined by payment as outlined by
dependent on the CIPAA may exclude CIPAA may exclude
competency and integrity payment for variation payment for variation
of the adjudicators work, loss and expense, work, loss and expense,
(Rajoo, 2012). damages and quantum damages and quantum
merits claims (Fong, 2012). merits claims (Fong, 2012).
(R002)

34
 7 The absence of CIPAA never be feasible to -
Kompetenz - achieve unanimous,
Kompetenz provision, voluntary adherence as
thus the adjudicator is the opportunism of the
not empowered to minority will drive the
determine and entire CIPAA objective
conclusively decide on down (Fong, 2012; Rajoo,
his own jurisdiction 2012).
(Fong, 2012).
8 To enforce the - -
adjudication decision, the
party may opt for
suspension or reduction
of works or direct
payment from principal
only (Fong, 2012; Rajoo,
2012).

Conclusion

From the research, the literature review provides overview on the occurrence of payment default
issues in Malaysian construction industry and how to Construction Industry Payment and
Adjudication Act (CIPAA) offers remedies to the payment default issues. The research found that
payment default issues are still prevalent dilemma that lingered among the contractors in Malaysia
and to resolve or at least minimize the problem, the Parliament of Malaysia has enacted CIPAA to
address these long-plagued issues. The construction industry is optimist that CIPAA will be the best
platform to resolve payment default issues in timely manner. In spite of several pertinent features of
CIPAA that have been identified in various papers before, the research discovered the most pertinent
feature of CIPAA from contractors point of view is to streamlining payment procedures for
construction works. In addition to that, the research revealed that most of CIDB G7 contractors were
expecting the enacted CIPAA would be able to provide legal remedy to non-payment and improve
the delivery system in construction industry. Furthermore, the research discovered that most of the
CIDB G7 contractors are optimist that CIPAA will be able to provide positive adjudication decision
and establish payment procedures for construction contracts. Additionally, the research disclosed that
the major limitation of the Act is CIPAA critically dependent on the competency and integrity of the
adjudicators. Finally, despite of all barriers and limitations of CIPAA as discussed, it is aimed that the
construction industry can be benefited from the enactment of CIPAA. As such, all parties have
significant roles and must take ownership of the issues and challenges. To this end, the industry as a
whole must collaborate and focus on their synergies to promote effective implementation of CIPAA.

35
References

Abdullah Habib, S. N. H. & Abdul Rashid, K. (2006). Statutory Adjudication Appropriate Procedures and
Process for Incorporation into the Proposed Malaysian Construction Industry Payment and
Adjudication Bill. Proceeding Quantity Surveying National Convention 2006, School of
Housing, Building and Planning, USM.
Abdul Rashid, R., et al. (2007). Profiling the Construction Disputes for Strategic Construction Contract
Management. UTM. A seminar paper.
Abraham, W. (2012). Construction Industry Payment and Adjudication Act 2012- A solution or
Revolution for The Construction Industry? Zul Rafique & Partners. Retrieved on October 5,
2013.
Ameer Ali, N. A. N. (2006). A Construction Industry Payment and Adjudication Act: Reducing Payment-
Default and Increasing Dispute Resolution Efficiency in Construction.
Fong, L. C. (2007). The Malaysian Construction Industry The Present Dilemmas of the Unpaid Contractors.
International Forum Construction Industry Payment Act and Adjudication. Kuala Lumpur:
CIDB and ISM
Fong, L. C. (2011). The Malaysian PWD Form of Construction Contract 2nd Edition. Kuala Lumpur:
Sweet & Maxwell
Fong, L. C. (2012). The legal implication of CIPAA. Retrieved on October 21, 2013. Retrieved from
http://klrca.org.my/userfiles/File/The-Legal-Implication-CIPA-Conference-24_10_2012.pdf
Hasmori, M. F., Ismail, I., & Said, I. (2012). Issues of Late and Non-Payment Among Contractors in
Malaysia. 3rd International Conference on Business and Economic Research\ (3rd ICBER
2012)\) Proceeding 12-13 march 2012, Bandung, Indonesia.
Judi, S. S.,& Muhamed Sabli, N. A. (2010). A Study on Contractors Right On Late Or Non Payment.
Retrieved on October 4, 2013. Retrieved from http://eprints.uitm.edu.my/6929/
Karib, A. S., Shaffii, N., & Nor, N. M. (2008). A Report on The Proposal for a Malaysian Construction
Industry and Adjudication Act (CIPAA). Lembaga Pembangunan Industri Pembinaan Malaysia.
Retrieved on October 15, 2013. Retrieved from
https://www.cidb.gov.my/cidbv2/images/pdf/cipaa08_0.pdf
Kuala Lumpur Regional Centre for Arbitration (KLRCA) (n.d.). KLRCA, Construction industry payment
and Adjudication Act 2012. Kuala Lumpur. Malaysia.
Majid, A. M. (2011). Pengenalan Akta Pembayaran and Adjudikasi Industri Pembinaan 2011 (CIPAA).
Retrieved on October 22, 2013.
Majid, A. M. (2013). The Impact of the Construction Industry payment and Adjudication Act 2012 on
Government Contract Aministration. Retrieved on November 15, 2013.
Rahman, H. A., & Ye, K. M. (2010). Risk of Late Payment in Malaysian Construction Industry. World
Academy of science, engineering and technology 41.
Rajoo, S. (2012). Dispute Resolution for Construction Industry in Malaysia. Newletter of Kuala Lumpur
Regional Centre for Arbitration. Apr-June 2012 Issue.
Rajoo, S. (2014). The Construction Industry Payment and Adjudication Act 2012 Comes into Operation.
Press Release of Kuala Lumpur Regional Centre for Arbitration. 15 April 2014.
Ramachandra, T., (2013). Exploring Feasible Solutios to Payment Problems in the Construction Industry in
New Zealand. (Doctoral Dissertation, Auckland University of Technology, 2013). Retrieved
from http://aut.researchgateway.ac.nz/handle/10292/5554
Saad, H. (2008). Revising Contract Sum The Employer have right to set-off payment. Johor : Universiti
Teknology Malaysia.
Sahab, S., & Ismail, Z. (2011). Construction Industry Payment And Adjudication Act; Enhancing Security
Of Payment In The Malaysian Construction Industry. International Conference on Business,
Engineering and Industrial Applications - ICBEIA, 2011. 153 159. Proceeding 5-7 June 2011.
Kuala Lumpur. Malaysia.

36
Shirley, H. (2012). The Conference on the Practice and Procedure of Adjudication. MIArb Newsletter.
The Newsletter of the Malaysia Institute of Arbitrators. Retrieved on December 2, 2013.
Retrieved from http://miarb.org/userfiles/MIArb-newsletter-2012-web-res.pdf
Sin, A. S. (2006). Payment Issues The present dilemmas of Malaysian construction industry. Johor:
Universiti Teknologi Malaysia.

37
38