Government of Madhya Prdesh
Government of Madhya Prdesh
Government of Madhya Prdesh
TENDER DOCUMENT
For Percentage Rate only in works departments and other
Departments similar to work departments
(Effective from 01/01/2014)
Contract Amount
(Rs. In Figure ) Rs............................
(Rs. In Words) Rs. .........................
Stipulated Period of 8 Months Excluding Rainy Season
Completion
Page 1 of 114
TENDER DOCUMENT
Table of Contents
Annexure N to W 64-79
Page 2 of 114
SECTION – 1
Notice Inviting Tender
GOVERNMENT OF MADHYA PRDESH
PUBLIC WORKS DEPARTMENT
BRIDGE CONSTRUCTION DIVISION BHOPAL
NIT. No.- /e-tendering/2022 Dated ---------------------
Online percentage rate bids for the following works are invited from registered
contractors and Firms of repute fulfilling registration criteria:
1. Interested bidders can view the detailed NIT on the website https://mptenders.gov.in
2. The Bid Document can be purchased only online from----------------- 10:30 AM to ----------
17:30 PM.
3. Amendments to NIT, if any, would be published on website only, and not in newspaper.
Executive Engineer
PWD Bridge Division
Bhopal
Page 3 of 114
Notice Inviting Tender
GOVERNMENT OF MADHYA PRDESH
PUBLIC WORKS DEPARTMENT
OFFICE OF THE EXECUTIVE ENGINEER, P.W.D. BRIDGE DIVISION BHOPAL
First CALL
NIT.No. /e-tendering/Bhopal/2022 Dated -----------------
Online percentage rate bids for the following works are invited from registered
contractors and Firms of repute fulfilling registration criteria:
S. District (s) Probable
Earnest Money Cost of
No. Amount of Category of Period of
Name of Work Deposit (EMD) Bid
/Pkg/ Contract Contractor Completion
(In Rs.) Document
Code (Rs. in lakh)
1 2 3 4 5 6 7 8
1 Construction of Raisen Rs 215.88 Rs Rs Registered
Submersible Bridge lacks 215880.00 15000.00 Contractor 8 Months
across Davar Nalla Excluding
Near Devi Mandir
On Parwariya - Rainy
Raisen Road Distt. Season
Raisen
1. All details relating to the Bid Document(s) can be viewed and downloaded free of cost on
the website https://mptenders.gov.in
2. Bid Document can be purchased after making online payment of portal fees.
3. At the time of submission of the Bid the eligible bidder shall be required to:
i) pay the cost of Bid Document;
ii) deposit the Earnest Money;
iii) Submit a check list and
iv) Submit an affidavit.
Details can be seen in the Bid Data Sheet. The above details are to be submitted
online only.
4. ELIGIBILITY FOR BIDDERS:
(a) At the time of submission of the Bid the bidder should have valid registration with the
Government of Madhya Pradesh, PWD. However, such bidders who are not
registered with the Government of Madhya Pradesh and are eligible for registration
can also submit their bids after having applied for registration with appropriate
authority.
Page 4 of 114
(b) The bidder would be required to have valid registration at the time of signing of the
Contract.
(c) Failure to sign the contract by the selected bidder, for whatsoever reason, shall result
in forfeiture of the earnest money deposit.
5. Pre-qualification – Prequalification conditions, wherever applicable, are given in the Bid
Data Sheet.
6. Special Eligibility - Special Eligibility Conditions, if any, are given in the Bid Data
Sheet.
7. Pre Bid meeting – A pre bid meeting will be held -------------------inthe-------------------
-------
4. The Bid Document can be purchased only --------------- 10:30 AM to ------------------- 17:30
PM.
8. Amendments to NIT, if any, would be published on website only, and not in newspaper.
Executive Engineer
PWD Bridge Division
Bhopal
Page 5 of 114
SECTION 2
INSTRUCTIONS TO BIDDERS (ITB)
A. GENERAL
1. SCOPE OF BID
The detailed description of work, hereinafter referred as ‘work’, is given in the Bid Data
Sheet.
The work shall have to be executed in accordance with the technical specifications
specified in the Bid Data Sheet/Contract Data and shall have to meet high standards of
workmanship, safety and security of workmen and works.
The procedure for participation in e-tendering is given in the Bid Data Sheet.
4.1 The bidder can be an individual entity or a joint venture. The requirement of joint venture
is given in the Bid Data Sheet.
4.2 No bidder shall be entitled to submit more than one bid whether jointly or severally. If he
does so, all bids wherein the bidder has participated shall stand disqualified.
5. Cost of Bidding
The bidder shall bear all costs associated with the preparation and submission of his bid,
and no claim whatsoever for the same shall lie on the Government.
The bidder is advised to visit and inspect the Site of Works and its surroundings and
obtain for itself on its own responsibility all information that may be necessary for
preparing the bid and entering into a contract for construction of the work. All costs in
this respect shall have to be borne by the bidder.
B. BID DOCUMENTS
7. CONTENT OF BID DOCUMENTS
The Bid Document comprises of the following documents:
1. NIT with all amendments.
Page 6 of 114
2. Instructions to Bidders, bid data sheet with all Annexure
3. Conditions of Contract:
i. Part I General Conditions of Contract and Contract Data with all Annexure sand
ii. Part II Special Conditions of Contract.
4. Specifications
5. Drawings.
6. Priced Bill of Quantities
7. Technical and Financial Bid
8. Letter of Acceptance
9. Agreement and
10. Any other Document(s), as specified.
8. The bidder is expected to examine carefully all instructions, conditions of contract, the
contract data, forms, terms and specifications, bill of quantities, forms and drawings in
the Bid Document. Bidder shall be solely responsible for his failure to do so.
9. Pre-Bid Meeting (where applicable)
Wherever the Bid Data Sheet provides for pre-bid meeting:
9.1 Details of venue, date and time would be mentioned in the Bid Data Sheet. Any
change in the schedule of pre-bid meeting would be communicated on the website
only, and intimation to bidders would not be given separately.
9.2 Any prospective bidder may raise his queries and/or seek clarifications in writing
before or during the pre-bid meeting. The purpose of such meeting is to clarify
issues and answer questions on any matter that may be raised at that stage. The
Employer may, at his option, give such clarifications as are felt necessary.
9.3 Minutes of the pre-bid meeting including the gist of the questions raised and the
responses given together with any response prepared after the meeting will be
hosted on the website.
9.4 Pursuant to the pre-bid meeting if the Employer deems it necessary to amend the
Bid Document, it shall be done by issuing amendment to the online NIT.
10. Amendment of Bid Documents
10.1 Before the deadline for submission of bids, the Employer may amend or modify the Bid
Documents by publication of the same on the website.
10.2 All amendments shall form part of the Bid Document.
10.3 The Employer may, at its discretion, extend the last date for submission of bids.By
publication of the same on the website.
Page 7 of 114
C. PREPARATION OF BID
11. The bidders have to submit their bids online as per guidelinesgiven in the portal.
12. DOCUMENTS COMPRISING THE BID
The bid submitted online by the bidder shall be in the following parts:
Part 1 – This shall be known as Envelope A and would apply for all bids. Online
Envelop A shall contain the following as per details given in the Bid Data Sheet:
i) Registration number or proof of application for registration and organizational
details in format given in the bid data sheet.
ii) Payment of the cost of Bid Document;
iii) Earnest Money;and
iv) An affidavit duly notarized.
The above details are to be submitted online only.
Part 2 – This shall be known as online Envelope B and is required to be submitted only
in works where pre-qualification conditions and/or special eligibility conditions are
stipulated in the Bid Data Sheet. Online Envelop B shall contain a self-certified sheet
duly supported by documents to demonstrate fulfillment of pre-qualification conditions.
Part 3 – This shall be known as online Envelope C and would apply to all bids. Envelop
C shall contain financial offer in the format prescribed format enclosed with the Bid Data
Sheet.
13. LANGUAGE
The bid as well as all correspondence and documents relating to the bid exchanged by the
Bidder and the Employer shall be in English or Hindi. Supporting documents and printed
literature that are part of the Bid may be in another language provided they are
accompanied by an accurate translation of the relevant passages in English.In such case,
for the purposes of interpretation of the bid, such translation shallgovern.
14. TECHNICAL PROPOSAL
14.1 Only, in case of bids with pre-qualification conditions defined in the Bid Data
Sheet, the Technical Proposal shall comprise of formats and requirements given in
the Bid Data Sheet.
14.2 All the document/information enclosed with the technical proposal should be self-
attested and certified by bidder. The bidder shall be liable for forfeiture of his
earnest money deposit, if any document/information are found false/fake/untrue
before acceptance of bid. If it is found after acceptance of the bid. The bid
sanctioning authority may at his description forfeit his performance
Page 8 of 114
security/guarantee security deposit, enlistment deposit and take any other suitable
action.
17.2 The EMD shall be in the form of Fixed Deposit Receipt of a scheduled commercial bank,
issued in favour of the name given in the Bid Data Sheet. The Fixed Deposit Receipt
shall be valid for six months or more after the last date of receipt of bids. However other
form(s) of EMD may be allowed by the employer by mentioning it in the bid data sheet.
17.3 Bid not accompanied by EMD shall be liable for rejection as non-responsive.
17.4 EMD of bidders whose bids are not accepted will be returned within ten working days of
17.5 EMD of the successful Bidder will be discharged when the Bidder has signed the
17.6 Failure to sign the contract by the selected bidder, within the specified period, for
Page 9 of 114
SUBMISSION OF BID
18. The bidder is required to submit online bid duly signed digitally, and Envelop ‘A’ in physical form
also at the place prescribed in the bid data sheet.
19. PROCEDURE
19.1 Envelope ‘A’ shall be opened first online at the time and date notified and its
contents shall be checked. In cases where Envelop ‘A’ does not contain all
requisite documents, such bid shall be treated as non-responsive, and Envelop B
and/or C of such bid shall not be opened.
19.2 Wherever Envelop ‘B’ (Technical Bid) is required to be submitted, the same shall
be opened online at the time and date notified. The bidder shall have freedom to
witness opening of the Envelop ‘B’. Envelop ‘C’ (Financial Bid) of bidders who
are not qualified in Technical Bid (Envelop ‘B’) shall not be opened.
19.3 Envelope ‘C’ (Financial Bid) of bids shall be opened online at the time and date
notified. The bidder shall have freedom to witness opening of the Envelop ‘C’.
19.4 After opening Envelop ‘C’ all responsive bids shall be compared to determine the
lowest evaluated bid.
19.5 The Employer reserves the right to accept or reject any bid, and to annul the biding
process and reject all the bids at any time prior to contract award, without incurring
any liability. In all such cases reasons shall be recorded.
19.6 The Employer reserves the right of accepting the bid for the whole work or for a
distinct part of it.
20. Confidentiality
20.1 Information relating to examination, evaluation, comparison and recommendation
of contract award shall not be disclosed to bidders or any other person not
officially concerned with such process until final decision on the bid.
20.2 Any attempt by a bidder to influence the Employer in the evaluation of the bids or
contract award decisions may result in the rejection of its bid.
Page 10 of 114
E. AWARD OF CONTRACT
The Employer shall notify the successful bidder by issuing a ‘Letter of Acceptance’
(LOA) that his bid has been accepted.
22.1 Prior to signing of the Contract the bidder to whom LOA has been issued shall
have to furnish performance security of the amount, in the form and for the
duration, etc. as specified in the Bid Data Sheet.
22.2 Additional performance security, if applicable, is mentioned in the Bid Data
Sheet and shall be in the form and for the duration, etc. similar to performance
security.
23.1 The successful bidder shall have to furnish Performance security and additional
performance security, if any and sign the contract agreement within 15 days of
issue of LOA.
23.3 In the vent of failure of the successful bidder to submit Performance Security and
additional performance security, if any or sign the Contract Agreement, his EMD
shall stand forfeited without prejudice to the right of the employer for taking
action against the bidder.
i. may reject the bid for award if it determines that the bidder recommended for award
has, directly or through an agent, engaged in corrupt, fraudulent, collusive, or
coercive practices in competing for the Contract; and
ii. may debar the bidder declaring ineligible, either indefinitely or for a stated period
of time, to participate in bids, if it at any time determines that the bidder has,
Page 11 of 114
directly or through an agent, engaged in corrupt, fraudulent, collusive, or coercive
practices in competing for, or in executing, a contract.
For the purposes of this provision, the terms set forth above are defined as follows:
[End of ITB]
Page 12 of 114
Bid Data Sheet
GENERAL
SR.
PARTICULARS DATA
No.
1 Office Inviting Tender E.E PWD BRIDGE DIVISION BHOPAL
2 NIT No. /2022
3 Date of NIT ----------------
4 Bid document download ----------------- 10:30 AM to -------------- 17:30
available from date & time
PM.
Page 13 of 114
Bid Data Sheet
SECTION 2 - ITB1
ITB
CLAUS PARTICULARS DATA
E
1 Name of the ‘Work’ Construction of Submersible Bridge across
Davar Nalla Near Devi Mandir On Parwariya -
Raisen Road Distt. Raisen
2 Specifications & SOR As per 'Annexure – E'
in addition to as below:
(a) In case of Roads and Bridge works:
'SPECIFICATION FOR ROAD AND
BRIDGE WORK (fifth Revision) By
MORTH
(b) Stipulation of SOR for Road & Bridge w.e.f.
25-03-2022 and its amendments Issued upto
date of N.I.T.
(c) Stipulation of SOR for Electrical works
(w.e.f.1-08-2014 and its amendments Issued
up to date of N.I.T.
(d) Stipulation of SOR for Building work w.e.f.
01.08.2014 and its amendments Issued up to
date of N.I.T
3 Procedure for participation in e- As per 'Annexure – F'
tendering
Whether Joint Venture is allowed. NO
allowed as below:
4 (b) In case of Roads and Bridge works costing more than
Rs. Twenty five Cr.
If yes, requirement for Joint Venture As per 'Annexure – G'
Envelope-A containing : Online Only
i. Organizational details as per Rs 15000/-
'Annexure H'
ii. Cost of Bid Document
Rs 215880/-
iii. EMD Online Only
12
iv. An affidavit duly notarized as
per 'Annexure- B'
should reach in physical form in the
office of :
14 Envelope-B Technical Proposal As per 'Annexure - I' and Annexure - I (FormatI-1to I-5)
Note: The technical evaluation will be done only on
the basis of financial & physical experience details
submitted in formats ( I-1) &( I-2) requiring Annual
Turn Over & Bid Capacity. Requirement as regard
to Key technical personnel, key Lab equipments&
construction requirement as per Formats I-3, I-4 &
I-5 respectivaly shall not be part of technical
evaluation.However the non compliance on these
requirements during the currancy of the contract
may attract penalties.
Envelope-C Financial Bid As per 'Annexure - J '
15
Materials to be issued by the department As per 'Annexure - K'
16 Period of Validity of Bid 120 Days
Page 14 of 114
Bid Data Sheet
ITB
CLAUSE PARTICULARS DATA
Earnest Money Deposit Rs 215880.00
Forms of Earnest Money Deposit Online Payment Only
EMD valid for a period of --
17
FDR must be drawn in favour of MP State Electronics Development Corporation
Ltd.
Page 15 of 114
Annexure – A
(See Clause 1, 7 of Section 1 –NIT)
Page 16 of 114
Page 17 of 114
Annexure – C
(See Clouse-5 of Section 1 – NIT)
PRE-QUALIFICATIONS CRITERIA
2 Earth Work
3 Concrete work
Page 18 of 114
Annexure – D
(See Clouse-6 of Section 1 – NIT)
Note: Above criteria are indicative, subject to suitable stipulations by the departments and
specific bid.
Page 19 of 114
Annexure – E
(See Clouse-2 of Section 2-itb&
Clause 10 of GCC)
Specifications
2. Stipulation of SOR for Road & Bridge w.e.f. 25.03.2022 and its
The provisions of general / special conditions of contract, those specified elsewhere in the bid
document, as well as execution drawings and notes, or other specifications issued in writing by
the Employer shall form part of the technical specifications of this work.
Page 20 of 114
Annexure – F
(See Clouse-3 of Section 2 – ITB)
Contractors having applied under CRS shall be eligible for tendering in the designated portal
required to register themselves in this portal as per guidelines shown on the portal.
Digital Certificates:
The Bids submitted online should be signed electronically with a Class III Digital Certificate
the portal.
For purchasing the bid document, bidders are to pay online as per details given in the portal.
Bidder can withdraw and modify the bid before the bid submission end date.
Page 21 of 114
Annexure – G
(See Clouse-4 of Section 2 – ITB)
JOINT VENTURE (J.V.)
If J.V. is allowed following conditions and requirements must be fulfilled:
Bids submitted by a joint venture of two or more firms as partners shall comply with the
following requirements:
a. one of the partners shall be nominated as being Lead Partner, and this authorization
shall be evidenced by submitting a power of attorney signed by legally authorized
signatories of all the partners;
b. the bid and, in case of a successful bid, the Agreement, shall be signed so as to be
legally binding on all partners;
c. the partner in charge shall be authorized to incur liabilities and receive instructions
for and on behalf of any and all partners of the joint venture and the entire execution
of the contract, including payment, shall be done exclusively with the partner in
charge;
d. all partners of the joint venture shall be liable jointly and severally for the execution
of the contract in accordance with the contract terms, and a statement to this effect
shall be included in the authorization mentioned under [c] above, as well as in the bid
and in the Agreement [in case of a successful bid];
e. The joint venture agreement should indicate precisely the role of all members of JV
in respect of planning, design, construction equipment, key personnel, work
execution, and financing of the project. All members of JV should have active
participation in execution during the currency of the contract. This should not be
varied/modified subsequently without prior approval of the employer;
f. The joint venture agreement should be registered, so as to be legally valid and
binding on all partners; and
g. a copy of the Joint Venture Agreement entered into by the partners shall be
submitted with the bit!.
.
2. The figures for each of the partners of a joint venture shall be added together to
determine the Bidder's compliance with the minimum qualifying criteria required for
the bid. All the partners collectively must meet the criteria specified in full. Failure
to comply with this requirement will result in rejection of the joint venture's bid.
3. The performance security of a Joint Venture shall be in the name of the partner
Lead Partner/joint venture.
4. Attach the power of attorney of the partners authorizing the Bid signatory(ies) on
behalf of the joint venture
5. Attach the agreement among all partners of the joint venture [and which is legally
binding on all partners], which shows the requirements as indicated in the
Instructions to Bidders'.
Page 22 of 114
Clarification:-
1. Annexure-G (Page 24) of the bid document describes the conditions and
requirement to be applied/fulfilled in case of bidding by the joint venture (J.V.).
For the purpose of evaluation of technical bids, it is hereby clarified that in
addition to the conditions contained in Annexure-G of the bid document, the
partners of J.V. should satisfy the qualification criteria as below:-
a. The lead partner must have a share of minimum 51% in the J.V.
b. The other partner(s) must have a share of minimum 26% in the J.V.
c. The lead partner and the other partner must also meet 51% and 26% of the all
qualification criteria respectively except for the requirement of work
experience described in Annexure-I-1(A) (Page 27). However both the
partners must satisfy the full (100%) qualification criteria jointly. For this
purpose the qualification of individual partners shall be added (for Annual
Average Turn Over and for Bid Capacity only).
d. Following clarification / amendment is hereby done in requirement contained
in Annexure-I-1(A) for J.V.
i. Out of 3 similar works of value more than 20% of PAC, at least 2 works
must be done by lead partner and one work to be done by other partner,
OR
ii. Out of 2 similar works of value more than 30% of PAC, at least 1 (One)
work must be done by lead partner and 1 (One) work to be done by other
partner,
OR
iii. In case of one similar work of value more than 50% of PAC the lead
partner must satisfy the criteria. However the other partner must satisfy
the criteria in (i) above i.e. at least one work of 20% of PAC.
Page 23 of 114
Annexure – H
(See Clouse-12 of Section 2 – ITB& Clouse 4 of GCC)
ORGANIZATIONAL DETAILS
(To be contained in Envelope-A)
Page 24 of 114
Annexure –I
(See Clouse-14 of Section 2 – ITB)
No
positions
construction work
Note:
1. Technical Proposal should be uploaded duly page numbered and indexed.
2. Technical Proposal uploaded otherwise will not be considered.
Page 25 of 114
Annexure – I(Format : I-1)
(See Clouse-14 of Section 2 – ITB)
A. Financial Requirement:
The bidder should have completed either of the below:
a) three similar works each costing not less than the amount equal to 20% of the
probable amount of contract during the last 5 financial years; or
b) two similar works each costing not less than the amount equal to 30% of the
probable amount of contract during the last 5 financial years; or
c) one similar work of aggregate cost not less than the amount equal to 50% of the
probable amount of contract in anyone financial year during the last 5 financial
years;
Clarification
1- In this regard it is clarified that the requirement in Annexure-C as well as in Annexure -I are
generally for having completed similar work in last 5 financial years. However the bidders who
have executed a part of the project during last 5 financial years, and that part covers all the
major items of road construction and the value of such executed part is more than the qualified
amount mentioned in Annexure-C and / or Annexure-I shall be considered.
2- It is clarified that the experience of constructing bridges shall be considered as experience of
similar works, irrespective of it being work of rigid or flexible pavement.
3- It is clarified that works completed/executed before last date of bid submission in the current
financial year shall also be considered towards works experience requirement described in
Annexure-C and Annexure-I-1 of the document. Therefore for this purpose the works
completed/executed during current financial year up to last date of Bid submission shall be
considered in this case last 5 financial year will be counted as current financial year and 4 years
backwards.
Page 26 of 114
Existing commitments - (Value of 'C' for Bid Capacity formula)
B. Physical Requirement:
Execution of similar items of work in anyone financial year during the last 5financial years should
not be less than the minimum physical requirement fixed for the work
Page 27 of 114
Annexure – I(Format : I-2)
(See Clouse-14 of Section 2 – ITB)
Requirement:
Average annual construction turnover on the construction works not less than 50% of the
probable amount of contract during the last 5 financial years;
Note:
i. Annual turnover of construction should be certified by the Chartered Accountant.
ii. Audited balance sheet including all related notes, and income statements for the above
financialyear to be enclosed.
Clarification:-
Provisional balance sheets for financial year 2021-22 shall be considered subject to
authentication by the C.A.
Bid Capacity
Applicants who meet the minimum qualifying criteria in the evaluation as stated
above are to be evaluated further for bid capacity as under:
Thelast five years(10% weightage per year shall be given to bring the value
of work executed at present price level)
B= Proposed contract period in years.
C= Amount of work in hand at present.
Page 28 of 114
Annexure – I(Format : I-3)
(See Clouse-14 of Section 2 – ITB and clause 6 of GCC)
Qualification
Qualification
Similar work
Similar work
Key Position
Key Position
requirement
requirement
Total Work
Total Work
Experience
Experience
experience
experience
Minimum
Minimum
S. No.
S. No.
Age
Age
1 Project
Manager
2 Site
Engineer
3 Plant
Engineer
4 Quantity
Surveyor
5 Soil &
Material
Engineer
6 Supervisior
Note: It is clarified that the minimum requirement is a mandatory requirement and part of
technical bid, but the pre qualification is not to be done on the basis of this criteria.
Page 29 of 114
Annexure – I(Format : I-4)
(See Clouse-14 of Section 2 – ITB and clause 6 of GCC)
Note: It is clarified that the minimum requirement is a mandatory requirement and part of
technical bid, but the pre qualification is not to be done on the basis of this criteria.
Page 30 of 114
Annexure – I(Format : I-5)
(See Clouse-14 of Section 2 – ITB)
List of Key Equipments Machines for Construction Work
Minimum requirement Available with the bidder
S.No. Name of Equipment/ Machinery Quantity S.No. Name of Quantity
Equipment/
Machinery
1
Tipper Trucks -
2
Motor Grader -
3 Dozer -
4
Front end Loader -
5
Smooth Wheeled roller -
6
Vibratory Roller -
7
Hot mix plant with electronic control -
8
Paver finisher with electronic sensor -
9
Water tanker -
10
Bitumen Sprayer -
11
Tandem Roller -
12
Concrete mixer with Integral weigh Batching facility -
13 Slip Form Concrete paver capable of paving in
required width of carriageway in one single
pass including all appropriate accessories such
-
as, integral vibratory system and electronic
sensors ancillary equipment for applying curing
compound, joint cutting etc.
14 Concrete batching and mixing plant with automatic
control (minimum 100 cum/hour)
-
15 Pnumetictyre roller -
16 Batch Mixing plant with electronic controls (series
minimum 100-120 TPH capacity as required -
Total -
....
Note. 1. The Bidder has to either provide evidence of owning the equipments or of having made lease
arrangements for employing the required equipments as listed in the table above. Bidders can also give an
undertaking that in case he is awarded the work, he shall make suitable arrangement for providing these
equipments, prior to signing the agreement.
2. It is clarified that the minimum requirement is a mandatory requirement and part of technical bid, but the
pre qualification not to be done on the basis of this criteria.
Page 31 of 114
Annexure – J
(See Clouse-14 of Section 2 – ITB)
FINANCIAL BID
(To be Contained in Envelop-C)
NAME OF WORK : Construction of Submersible Bridge across Davar Nalla Near Devi Mandir
On Parwariya -Raisen Road Distt. Raisen
I/We hereby bid for the execution of the above work within the time specified at the
rate@...............................or at par based on the Bill of Quantities and item wise rates given
therein in all respects and in accordance with the specifications, designs, drawings and
instructions in writing in all respects in accordance with such conditions so far as applicable.
I/We have visited the site of work and am i are fully aware of all the difficulties and conditions
likely to affect carrying out the work. I/We have fully acquainted myself/ourselves about the
conditions in regard to accessibility of site and quarries/kilns, nature and the extent of ground,
working conditions including stacking of materials, installation of tools and plant conditions
effecting accommodation and movement of labour etc. required for the satisfactory execution of
contract.
Should this bid be accepted, I/We hereby agree to abide by and fulfill all the terms
and provisions of the said conditions of contract annexed hereto so far as applicable, or in
default thereof to forfeit and pay to the Governor of Madhya Pradesh or his successors in
office the sums of money mentioned in the said conditions. \
Note:
i. Only one rate of percentage above or below or at par based on the Bill of Quantities and
item wise rates given therein shall be quoted.
j. ii. Percentage shall be quoted in figures as well as in words. If any difference in figures
and words is found lower of the two shall be taken as valid and correct rate. If the
bidder is not ready to accept such valid and correct rate and declines to furnish
performance security and sign the agreement his earnest money deposit shall be
forfeited.
k. iii. In case the percentage "above" or" below" is not given by a bidder, his bid shall be
treated as non-responsive. 1
l. iv. All duties, taxes, and other levies payable by the bidder shall be included in the
percentage quoted by the bidder.
Signature of Bidder
Name of Bidder
The above bid is hereby accepted by me on behalf of the Governor of Madhya Pradesh dated
the…………..day of ………………….. 20
Page 32 of 114
Annexure – K
(See Clouse-15 of Section 2 – ITB)
………………..NIL…………………
Page 33 of 114
Annexure – L
(See Clouse-21 of Section 2 – ITB)
LETTER OF ACCEPTANCE
No.________________________ Dated ………………
To,
M/s…………………………………………. _
(Name and address of the contractor)
Subject:
-x0x-
Dear Sir (s),
Your bid for the work mentioned above has been accepted on behalf of the Governor
of Madhya Pradesh at your bided percentage …………..below/ above or at par the Bill of
Quantities and item wise rates given therein.
You are requested to submit within 15 (Fifteen) days from the date of issue of this
letter:
a. The performance security/ performance guarantee of Rs. ……………(in
figures) (Rupees…………………………………………………….in words
only). The performance security shall be in the shape of term deposit receipt
bank guarantee of any nationalized / schedule commercial bank valid up to
three months after the expiry of defects liability period.
b. Sign the contract agreement.
Please note that the time allowed for carrying out the work as entered in the bid is
_____ months including/ excluding rainy season, shall be reckoned from the date of signing the
contract agreement.
Executive Engineer,
PWD Bridge Division Bhopal
Page 34 of 114
Annexure-M
BID SECURITY (BANK GUARANTEE)
said name of the Executive Engineer the Bank itself, his successors and assigns by
these presents.
SEALED with the Common Seal of the said Bank this ______day of _______20__
(1) If after Bid opening the Bidder withdraws his bid during the period of Bid validity
OR
(2) If the Bidder having been notified to the acceptance of his bid by the name of the
above amount upon receipt of his first written demand, without the (name of the
Executive Engineer) having to substantiate his demand, provided that in his demand of
Page 35 of 114
(name of the Executive Engineer) will note that the amount claimed by him is due to him
owing to the occurrence of one or any of the two conditions, specifying the occurred
condition or conditions.
This Guarantee will remain in force up to and including the date 180 **
days after the deadline for submission of Bids as such deadline is stated in the
Engineer), notice of which extension(s) to the Bank is hereby waived. Any demand in
respect of this guarantee should reach the Bank not later than the above date.
___________________________________________________________________
* The Bidder should insert the amount of the guarantee in words and figures
denominated in Indian Rupees. This figure should be the same as shown in Bid
Page 36 of 114
Annexure – M-1
(See Clouse-22 of Section 2 – ITB)
PERFORMANCE SECURITY
To
……………………………… [name of Employer]
……………………………… [address of Employer]
AND WHEREAS it has been stipulated by you in the said Contract that the
Contractor shall furnish you with a Bank Guarantee by a recognized bank for the sum specified
therein as security for compliance with his obligation in accordance with the Contract;
AND WHEREAS we have agreed to give the Contractor such a Bank Guarantee:
NOW THEREFORE we hereby affirm that we are the Guarantor and responsible
to you on behalf of the Contractor, up to a total of ………………………[amount of guarantee]*
………………………………………………………….(in words), such sum being payable in the
types and proportions of currencies in which the Contract Price is payable, and we undertake to
pay you, upon your first written demand and without cavil or argument, any sum or sums within
the limits of ……………………………… [Amount of guarantee] as aforesaid without your
needing to prove or to show grounds or reasons for your demand for the sum specified therein.
We hereby waive the necessity of your demanding the said debt from the
contractor before presenting us with the demand.
• An amount shall be inserted by the Guarantor, representing the percentage the Contract
Price specified in the Contract including additional security for unbalanced Bids, if any and
denominated in Indian Rupees.
Page 37 of 114
SECTION 3
Conditions of Contract
Part – I General Conditions of Contract
Table of Clauses GCC
Claus
Particulars Clause
e Particulars
., No
No
A. General 21 Payments for Variations and / or Extra
Quantities
1 Definitions 22 No compensation for alterations in or
- restriction
2 Interpretations and Documents 23 of
Nowork to be
Interest carried out.
Payable
3 Language and Law 24 Recovery from Contractors
4 Communications 25 Tax
5 Subcontracting 26 Check Measurements
6 Personnel 27 Termination by Engineer in Charge
7 Force Majeure 28 Payment upon Termination
8 Contractor's Risks 29 Performance Security
9 Liability For Accidents To Person 30 Security Deposit
10 Contractor to Construct the Works 31 Price Adjustment
Mobilization and Construction Machinery
11 Discoveries 32
Advance
12 Dispute Resolution System 33 Secured Advance
B. Time Control 34 Payments Certificates
13 Programme E. Finishing the Contract
14 Extension of Time 35 Completion Certificate
15 Compensation for Delay 36 Final Account
16 Contractor's quoted percentage F. Other Conditions of Contract
C. Quality Control 37 Currencies
17 Tests 38 Labor
Correction of Defects noticed
18 39 Compliance with Labor Regulations
during the Defect Liability Period
D. Cost Control 40 Audit and Technical Examination
Variations - Change in original
19 Specifications, Designs, Drawings 41 Death or Permanent Invalidity of Contractor
etc.
20 Extra Items 42 Jurisdiction
Page 38 of 114
A. General
1. DEFINITIONS
1.1. Bill of Quantities: means the priced and completed Bill of Quantities forming part
of the Bid.
1.2. Chief Engineer: means Chief Engineer of the zone/ basin concerned.
1.3. Completion: means completion of the work as certified by the Engineer-in-Charge
in accordance with provisions of agreement.
1.4. Contract: means the Contract between the Employer and the Contractor to
execute, complete and/or maintain the work. Agreement is synonym of Contract
and carries the same meaning wherever used.
1.5. Contract Data: means the documents and other information which comprise of the
Contract.
1.6 Contractor: means a person or legal entity whose bid to carry out the work has
been accepted by the Employer.
1.7. Contractor's bid: means the completed bid document submitted by the Contractor
to the Employer.
1.8. Contract amount: means the amount of contract worked out on the basis of
accepted bid.
1.9. Completion of work: means completion of the entire contracted work. Exhaustion
of quantity of any particular item mentioned in the bid document shall not imply
completion of work or any component thereof.
1.10. Day: means the calendar day.
1.11. Defect: means any part of the work not completed in accordance with the
specifications included in the contract.
1.12. Department: means Department of the State Government viz. Water Resources
Department, Public Works Department, Public Health Engineering Department,
Rural Engineering Service and any other organization which adopts this
document.
1.13. Drawings: means drawing including calculations and other information provided
or approved by the Engineer-in-Charge.
1.14. Employer: means the party as defined in the Contract Data, who employs the
Contractor to carry out the work. The Employer may delegate any or all functions
to a person or body nominated by him for specified functions. The word Employer
/ Government / Department wherever used denote the Employer.
1.15 Engineer: means the person named in the Contract Data.
1.16 Engineer in charge: means the person named in the Contract Data.
1.17 Equipment: means the Contractor's machinery and vehicles brought temporarily to
the Site for execution of work.
1.18 Government: means Government of Madhya Pradesh.
1.19 In Writing: means communicated in written form and delivered against receipt.
1.20 Material: means all supplies, including consumables, used by the Contractor for
incorporation in the work.
Page 39 of 114
1.21. Superintending Engineer: means Superintending Engineer-in-Charge of the Circle
concerned.
1.22. Stipulated period of completion: means the period in which the Contractor is
required to complete the work. The stipulated period is specified in the Contract
Data.
1.23. Specification: means the specification of the work included in the Contract and
any modification or addition made or approved by the Engineer-in-Charge.
1.24. Start Date: means the date of signing of agreement for the work.
1.25. Sub-Contractor: means a person or corporate body who has a Contract with the
Contractor, duly authorized to carry out a part of the construction work under the
Contract.
1.26. Temporary Work: means work designed, constructed, installed, and removed by
the Contractor that are needed for construction or installation of the work.
1.27. Tender/Bid, Tender/Bidder: are the synonyms and carry the same meaning where
ever used.
1.28. Variation: means any change in the work which is instructed or approved as
variation under this contract.
1.29. Work: The expression "work" or "works" where used in these conditions shall
unless there be something either in the subject or context repugnant to such
construction, be construed and taken to mean the work by virtue of contract,
contracted to be executed, whether temporary or permanent and whether original,
altered, substituted or additional.
Page 40 of 114
3. Language and Law
The language of the Contract and the law governing the Contract are stated in the
Contract Data Sheet.
4. Communications
All certificates, notice or instruction to be given to the Contractor by Employer/Engineer
shall be sent to the address or contact details given by the Contractor in [Annexure H of
ITB]. The address and contact details for communication with the Employer/Engineer
shall be as per the details given in the Contract Data. Communication between parties that
are referred to in the conditions shall be in writing. The notice sent by facsimile (fax) or
other electronic means (email) shall also be effective on confirmation of the transmission.
The notice sent by registered post or speed post shall be effective on delivery or at the
expiry of the normal delivery period as undertaken by the postal service. In case of any
change in address for communication, the same shall be immediately notified to Engineer-
in- Charge.
5. Subcontracting
Subcontracting shall be permitted for contracts of value more than amount specified in the
Contract Data with following conditions:
a. The Contractor may subcontract up to 25 percent of the contract price with the
approval of the Employer in writing, but will not assign the Contract. Subcontracting
shall not alter the Contractor's obligations.
6. Personnel
6.1 The Contractor shall employ for the construction work and routine maintenance the
technical personnel as provided in the Annexure 1-3 of Bid Data Sheet, if applicable. If the
Contractor fails to deploy required number of technical staff, recovery as specified in the
Contract Data will be made from the Contractor.
6.2 If the Engineer asks the Contractor to remove a person who is a member of the Contractor's
staff or work force, stating the reasons, the Contractor shall ensure that the person leaves
the Site within three days and has no further connection with the Works in the Contract.
Page 41 of 114
7. Force Majeure
(b) Which such Party could not reasonably have provided against before entering into the
Contract,
(c) Which, having arisen, such Party could not reasonably have avoided or overcome,
and
Force Majeure may include, but is not limited to, exceptional events or
circumstances of the kind listed below, so long as conditions (a) to (d) above are
satisfied:
(i) War, hostilities (whether war be declared or not), invasion, act of foreign
enemies,
8. Contractor's Risks
8.1 All risks of loss or damage to physical property and of personal injury and death
which arise during and in consequence of the performance of the Contract are the
responsibility of the Contractor.
Page 42 of 114
8.2 All risks and consequences arising from the inaccuracies or falseness of the documents
and/or information submitted by the contractor shall be the responsibility of the Contractor
alone.
9. Liability for Accidents to Person
The contractor shall be deemed to have indemnified and saved harmless the
Government against all action, suits, claims, demands, costs etc. arising in
connection with injuries suffered by any persons employed by the contractor or his
subcontractor for the works whether under the General law or under workman's
compensation Act, or any other statute in force at the time of dealing with the
question of the liability of employees for the injuries suffered by employees and to
have taken steps properly to ensure against any claim there under.
10.1 The Contractor shall construct, install and maintain the Works in accordance
with the Specifications and Drawings as specified in the Contract Data.
10.2 In the case of any class of work for which there is no such specification as is
mentioned in Contract Data, such work shall be carried out in accordance with
the instructions and requirement of the Engineer-in-charge.
10.3 The contractor shall supply and take upon himself the entire responsibility of
the sufficiency of the scaffolding, timbering, machinery, tools and implements,
and generally of all means used for the fulfillment of this contract whether such
means mayor may not be approved or recommended by the Engineer.
11. Discoveries
12.1 No dispute can be raised except before the Competent Authority as defined in
Contract Data in writing giving full description and grounds of dispute. It is
clarified that merely recording protest while accepting measurement and/or
payment shall not be taken as raising a dispute.
Page 43 of 114
12.2 No dispute can be raised after 45 days of its first occurrence. Any dispute raised
after expiry of 45 days of its first occurrence shall not be entertained and the
Employer shall not be liable for claims arising out of such dispute.
12.3 The Competent Authority shall decide the matter within 45 days.
12.4 Appeal against the order of the Competent Authority can be preferred within 30
days to the Appellate Authority as defined in the Contract Data. The Appellate
Authority shall decide the dispute within 45 days.
12.5 Appeal against the order of the Appellate Authority can be preferred before the
Madhya Pradesh Arbitration Tribunal constituted under Madhya Pradesh
Madhyastham Adhikaran Adhiniyam, 1983.
12.6 The Contractor shall have to continue execution of the Works with due diligence
notwithstanding pendency of a dispute before any authority or forum.
B. Time Control
13. Programme
13.1 Within the time stated in the Contract Data, the Contractor shall submit to the
Engineer for approval a Programme showing the general methods,
arrangements,' order and timing for all the activities for the construction of
works.
13.2 The program shall be supported with all the details regarding key personnel,
equipment and machinery proposed to be deployed on the works for its
execution. The contractor shall submit the list of equipment and machinery
being brought to site, the list of key personnel being deployed, the list of
machinery/equipment being placed in field laboratory and the location of field
laboratory along with the Programme.
13.3 An update of the Programme shall be a programmes how in the actual progress
achieved on each activity and the effect of the progress achieved on the timing of
the remaining Works, including any changes to the sequence of the activities.
13.4 The Contractor shall submit to the Engineer for approval an updated Programme
at intervals no longer than the period stated in the Contract Data. If the
Contractor does not su8mit an updated Programme within this period, the
Engineer may withhold the amount stated in the Contract Data from the next
payment certificate and continue to withhold this amount until the next payment
after the date on which the overdue Programme has been submitted.
13.5 The Engineer's approval of the Programme shall not alter the Contractor's
obligations.
Page 44 of 114
14. Extension of Time
14.1 The contract is for completion of works and therefore non approval of EOT shall
not in any way invalidate the contract. The contractor will have to complete the
works.
14.2 In the event of delays attributable to the contractor, the EOT shall not be given by
the Engineer-in-Charge and the Liquidated Damages shall be levied from the
contractor in accordance with the provisions of the contract.
14.3 In the event, the delays are not attributable to the contractor the EOT may be
issued by the Engineer-in-Charge without imposition of Liquidated Damages
either suo-motto or on a written request of the contractor.
It is clarified that out of the total delays in completion of works, the EOT shall be
issued only for the part, which is not attributable to the contractor.
(Amended as per Govt. Order No. F-53-55-2018-19-Yo-1154 bhopal,dated 23-
03-2018)
15.1 The time allowed for carrying out the work, as entered in the agreement, shall be
strictly observed by the Contractor.
15.2 The time allowed for execution of the contract shall commence from the date of
signing of the agreement. It is clarified that the need for issue of work order is
dispensed with.
15.3 In the event milestones are laid down in the Contract Data for execution of the
works, the contractor shall have to ensure strict adherence to the same.
15.4 Failure of the Contractor to adhere to the timelines and/or milestones shall
attract such liquidated damages as is laid down in the Contract Data.
15.5 In the event of delay in execution of the Works as per the timelines mentioned in
the Contract Data the Engineer-in-charge shall retain from the bills of the
Contractor amount equal to the liquidated damages livable until the Contractor
makes such delays good. However, the Engineer-in-charge shall accept bankable
security in lieu of retaining such amount.
15.6 If the Contractor is given extension of time after liquidated damages have been
paid, the Engineer in Charge shall correct any over payment of liquidated
damages by the Contractor in the next payment certificate.
15.7 In the event the Contractor fails to make good the delay until completion of the
stipulated contract period (including extension of time) the sum so retained shall
be adjusted against the liquidated damages levied.
Page 45 of 114
16. Contractor's quoted percentage
The Contractor's quoted percentage rate referred to in the "Bid for works" will be
deducted/ added from/to the net amount of the bill after deducting the cost of
material-supplied by the department•.
17. Tests
17.1 The Contractor shall be responsible for:
a. Carrying out the tests prescribed in specifications, and
b. For the correctness of the test results, whether preformed in his laboratory
or elsewhere.
17.2 The contractor shall have to establish field laboratory within the time specified
and having such equipments as are specified in the Contract Data.
17.3 Failure of the Contractor to establish laboratory shall attract such penalty as is
specified in the Contract Data.
18. Correction of Defects noticed during the Defect Liability Period
18.1 The Defect Liability Period of work in the contract shall be as per the Contract
Data.
18.2 The Contractor shall promptly rectify all defects pointed out by the Engineer well
before the end of the Defect Liability Period. The Defect Liability Period shall
automatically stand extended until the defect is rectified.
18.3 If the Contractor has not corrected a Defect pertaining to the Defect Liability
Period to the satisfaction of the Engineer, within the time specified by the
Engineer, the Engineer will assess the cost of having the Defect corrected, and
the cost of correction of the Defect shall be recovered from the Performance
Security or any amount due or that may become due to the contractor and other
available securities.
D. Cost Control
19. Variations –Change in original Specifications, Designs, and Drawings etc.
19.1 The Engineer-in-charge shall have power to make any alterations, omissions or
additions to or substitutions in the original specifications, drawings, designs and
instructions, that may appear to him to be necessary during the progress of the
work and the contractor shall carry out the work in accordance with any
instructions which may be given to him in writing signed by the Engineer-in-
charge, and such alterations, omission, additions or substitutions shall not
invalidate the contract and any altered, additional or substituted work, which the
contractor may be directed to do in the manner above specified, as part of the
work, shall be carried out by the contractor on the same conditions in all respects
on which he agrees to do the main work
Page 46 of 114
19.2 The time for the completion of the work shall be extended in the proportion that the
altered, additional or substituted work bears to the original contract work and the certificate
of the Employer shall be conclusive as to such proportion.
,a. The contractor is bound to carry out the additional (Extra quantity), work at
the same rates as are specified in the contract for the work.
b. If the item is not in the priced BOO and is included in the SOR of the
department, the rate shall be arrived at by applying the quoted tender
percentage on the SOR rate.
c. If the rates for the altered or substituted work are not provided in
applicable SOR - such rates will be derived from the rates for a similar class
(type) of work as is provided in the contract (priced BOO) for the work.
d. If the rates for the altered, substituted work cannot be determined in the manner
specified in the sub clause (c) above - then the rates for such
composite work item shall be workedout on the basis of the concerned Schedule o
Rates minus/plus the percentage quoted by the contractor.
e. If rates for a particular part or parts of the item is not in the Schedule of
Rates and the rates for the altered, or substituted work item cannot be
determined in the manner specified in sub clause (b) to (d) above, the rate
for such part or parts will be determined by the Competent Authority as
defined in the Contract Data on the basis of the rate analysis derived out of
prevailing market rates when the work was done.
f. But under no circumstances, the contractor shall suspend the work on the
plea of non-acceptability of rates on items falling under sub clause (a) to (d).
Page 47 of 114
In case the contractor does not accept the rate approved by the Engineer in
Charge for a particular item, the contractor shall continue to carry out the
item at the rates determined by the Competent Authority. The decision on
the final rates payable shall be arrived at through the dispute settlement
procedure.
25.1 The rates quoted by the Contractor shall be deemed to be inclusive of the commercial
tax and other levies, duties, cases, toll, taxes of Central and State Governments, local
bodies and authorities.
25.2 The liability, if any, on account of quarry fees, royalties, octopi and any other taxes and
duties in respect of materials actually consumed on public work, shall be borne by the
Contractor.
25.3 Any changes in the taxes due to change in legislation or for any other reason shall not
be payable to the contractor.
Page 48 of 114
26. Check Measurements
26.1 The department reserves to itself the right to prescribe a scale of check
measurement of work in general or specific scale for specific works or by other
special orders.
27.1 If the Contractor fails to carry out any obligation under the Contract, the
Engineer in Charge may by notice require the Contractor to make good the
failure and to remedy it within a specified reasonable time.
27.2 The Engineer in Charge shall be entitled to terminate the Contract if the
Contractor
a. abandons the Works or otherwise plainly demonstrates the intention not to
continue performance of his obligations under the Contract;
b. the Contractor is declared as bankrupt or goes into liquidation other than for
approved reconstruction or amalgamation;
c. without reasonable excuse fails to comply with the notice to correct a particular
defect within a reasonable period of time;
d. the Contractor does not maintain a valid instrument of financial security as
prescribed;
e. the Contractor has delayed the completion of the Works by such duration for
which the maximum amount of liquidated damages is recoverable;
f. If the Contractor fails to deploy machinery and equipment or personnel or set up
a field laboratory as specified in the Contract Data;
g. If the contractor, in the judgment of the Engineer in charge has engaged in
corrupt or fraudulent practices in competing for or in executing the contract;
h. Any other fundamental breaches as specified in the Contract Data.
27.3 In any of these events or circumstances, the Engineer in Charge may, upon
giving 14 days' notice to the Contractor, terminate the Contract and expel the
Contractor from the Site. However, in the case of sub-paragraph (b) or (g) of
clause 27.2, the Engineer in Charge may terminate the Contract immediately.
27.4 Notwithstanding the above, the Engineer-in-Charge may terminate the Contract
for convenience by giving notice to the Contractor
Page 49 of 114
28. Payment upon Termination
28.1 If the contract is terminated under clause 27.3, the Engineer shall issue a
certificate for The value of the work done less Advance Payments received up
to the date of issue of the certificate, less other recoveries due in terms of the
contract, less taxes due to be deducted at source as per applicable law and less
the percentage to apply to the work not completed as indicated in the contract
Data.
(As per Amended vide Govt. memo No.F-53/ 16/2012/19/Y/6842 dt. 2.11.15)
.
28.2 Payment on termination under clause 27.4 above-
If the Contract is terminated under clause 27.4 above, the Engineer shall issue a
certificate for the value of the work done, the reasonable cost of removal of
Equipment, repatriation of the Contractor's personnel employed solely on the
Works, and the Contractor's costs of protecting and securing the Works and less
advance payments received up to the date of the certificate, less other
recoveries due in terms of the contract and less taxes due to be deducted at
source as per applicable law.
28.3 If the total amount due to the Employer exceeds any payment due to .the
Contractor, the difference shall be recovered as per clause 24 above.
30.Security Deposit- ,
30.1 Security Deposit shall be deducted from each running bill at the rate as specified
in the Contract Data. The total amount of Security Deposit so deducted shall not
exceed the percentage of Contract Price specified in the Contract Data.
30.2 The security deposit may be replaced by equivalent amount of bank guarantee or
fixed deposit receipt assigned to the Employer, with validity up to 3 (three)
months beyond the completion of Defect Liability Period/ extended Defect
Liability Period.
Page 50 of 114
31. Price Adjustment
31.1 Contract price shall be adjusted for increase or decrease in rates and price
of labour, materials, fuels and lubricants in accordance with following
principles and procedures and as per formula given in the contract data.
(a) The price adjustment shall apply for the work done from the start
date given in the contract data upto the end of the initial intended
completion date or extensions granted by the Engineer and shall not
apply to the work carried out beyond the stipulated time for reasons
attributable to the contractor.
(b) The price adjustable shall be determined during each month from
the formula given in the contract data.
(c) Following expression and meaning are assigned to the work done
during each month:
R= Total value of work during the month. It would include the
amount of secured advance granted, if any, during the
month, less the amount of secured advance recovered, if any
during the month. It will exclude value of works executed
under variations for which no price adjustment shall be
payable.
(Amended as per Govt. Order No. F-53-55-2018-19-Yo-1154 Bhopal, dated 23-03-2018) and
Amended Vide Govt memo No. F-53/16/2012/19/YO/1653 Dated 6/5/2022 (Enclosed)
31.2 To the extent that full compensation for any rise or fall in costs to the contractor is
not covered by the provisions of this or other clauses in the contract, the unit rates
and prices included in the contract shall be deemed to include amounts to cover the
contingency of such other rise or fall in costs.
(Amended as per Govt. Order No. F-53-55-2018-19-Yo-1154 Bhopal, dated 23-03-2018)
and Amended Vide Govt memo No. F-53/16/2012/19/YO/1653 Dated 6/5/2022
(Enclosed)
Page 51 of 114
compensation events, or liquidated damages.
Page 52 of 114
or be considered as an admission of the due performance of the contractor any
part thereof, in any respect or the occurring of any claim.
(j) The payment of final bill shall be governed by the provisions of clause 36 of
GCC.
36.1 The Contractor shall supply the Engineer with a detailed account of the total
amount that the Contractor considers payable for works under the Contract
within 21 days of issue of certificate of physical completion of works. The
Engineer shall issue a Defects Liability Certificate and certify any payment that is
due to the Contractor within 45 days of receiving the Contractor's account if it is
correct and complete. If the account is not correct or complete, the Engineer
shall issue within 45 days a schedule that states the scope of the corrections or
additions that are necessary. If the Account is still unsatisfactory after it has been
resubmitted, the matter shall be referred to the Competent Authority as defined
in the Contract Data, who shall decide on the amount payable to the Contractor
after hearing the Contractor and the Engineer in Charge.
36.2 In case the account is not received within 21 days of issue of Certificate of
Completion as provided in clause 32.1 above, the Engineer shall proceed to
finalize the account and issue a payment certificate within 28 days.
37. Currencies
All payments will be made in Indian Rupees.
Page 53 of 114
38. Labour
38.1 The Contractor shall, unless otherwise provided in the Contract, make his own
arrangements for the engagement of all staff and labour, local or other, and for
their payment, housing, feeding and transport.
38.2 The Contractor shall, if required by the Engineer, deliver to the Engineer a return
in detail, in such form and at such intervals as the Engineer may prescribe,
showing the staff and the numbers of the several classes of labour from time to
time employed by the Contractor on the Site and such other information as the
Engineer may require.
39. Compliance with Labour Regulations
39.1. During continuance of the Contract, the Contractor and his sub-Contractors shall
abide at all times by all existing labour enactments and rules made there under,
regulations, notifications and bye laws of the State or Central Government or local
authority and any other labour law (including rules), regulations, bye laws that may
be passed or notification that may be issued under any labour law in future either
by the State or the _Central Government or the local authority. Salient features of
some of the major labour laws that are applicable to construction industry are given
in the Contract Data. The Contractor shall keep the Employer indemnified in case
any action is taken against the Employer by the competent authority on account of
contravention of any of the provisions of any Act or rules made their under,
regulations or notifications including amendments .. If the Employer is caused to
pay or reimburse, such amounts as may be necessary to cause or observe, or for
non-observance of the provisions 'stipulated in the
notifications/byelaws/Acts/Rules/regulations including amendments, if any, on the
part of the Contractor, the Engineer/Employer shall have the right to deduct from
any money due to the Contractor including his ~amount of performance security.
The Employer/Engineer shall also have right to recover from the Contractor any
sum required or estimated to be required for making good the loss or damage
suffered by the Employer. The employees of the Contractor and the Sub-Contractor
in no case shall be treated as the employees of the Employer at any point of time.
40. Audit and Technical Examination
Government shall have the right to cause an audit and technical examination of the
Page 54 of 114
works and the final bill of the contract including all supporting vouchers, abstract
etc. to be made after payment of the final bill and if as a result of such audit and
technical examination any sum is found to have been overpaid in respect of any
work done by the contractor under the contract or any work claimed by him to have
been done under the contract and found not to, have been executed, the Contractor
shall be liable to refund the amount of overpayment and it shall be lawful for
Government to recover the same from him in the manner prescribed in clause 24
above and if it is found that the Contractor was paid less than what was due to him,
under the contract in respect of any work executed by him under it, the amount of
such under payment shall be duly paid by Government to the Contractor.
42. Jurisdiction
This contract has been entered into the State of Madhya Pradesh and its validity,
construction, interpretation and legal effect shall be subjected to the courts at the place
where this agreement is entered into. No other jurisdiction shall be applicable.
[End of GCC]
Page 55 of 114
Contract Data Sheet
A.
GCC
Particulars Data
Clause
1.14 Employer E.E PWD BRIDGE DIVISION BHOPAL
1.15 Engineer E.E PWD BRIDGE DIVISION BHOPAL
1.16 Engineer in Charge E.E PWD BRIDGE DIVISION BHOPAL
1.22 Stipulated Period of 8 Months Excluding Rainy Season
Completion (period is always excluding rainy season,
unless mentioned otherwise)
Language & Law of English & Indian Contract Act 1872
3
Contract
Address & contact details As per 'Annexure-H'
of the Contractor
4 Address & contact details E.E BRIDGE DIVISION BHOPAL
of the Employer/ Engineer 0755-2777235 eepwdbribpl@nic.in
– phone, Fax, e-mail.
Subcontracting permitted More than Rs. FiveCrores.
5
for the Contract Value
Technical Personnel to be As per 'Annexure-I' (Format I-3)
provided by the contractor
Penalty, if required Rs thirty thousand per month for each
6
Technical Personnel not Graduate Engineer and
employed Rs eighteen thousand per month for each
Diploma Engineer/ITI Surveyor
Specifications As per 'Annexure - E'
10
Drawings As per 'Annexure - N'
Competent Authority for S.E.PWD BRIDGE CIRCLE BHOPAL
deciding dispute under
Dispute Resolution System
12
Appellate Authority for C.E. PWD BRIDGE ZONE BHOPAL
deciding dispute under
Dispute Resolution System
Period for submission of (a) Every 3 months
updated construction or
program (b) at the end of every milestone,
whichever is less
13
Amount to be withheld for @ 1 % (one) percent of contract amount,
not submitting subject to a maximum of Rs. 50,000/-.
construction program in
the prescribed period
Competent Authority for Engineer-in-Charge
14 granting Time Extension (Amended as per Govt. Order No. F-53-55-
2018-19-Yo-1154 bhopal,dated 23-03-2018)
Milestones laid down for YES
15 the contract
If Yes, details of As per 'Annexure - O' or
Page 56 of 114
GCC
Particulars Data
Clause
Milestones as below, if not mentioned in Annexure -O:
Mile Stone 1:-
1/8th of the whole work before 1/4th of the
whole time allowed has elapsed,
Mile Stone 2:-
3/8th of the whole work before 1/2th of the
whole time allowed has elapsed
Mile Stone 3:-
3/4th of the whole work before 3/4th of the
whole time allowed has elapsed
Mile Stone 4:-
complete work within the stipulated time
Liquidated damage As per 'Annexure - P'
Page 57 of 114
GCC
Particulars Data
Clause
are not removed in reasonable time, the same can
be got done by the Engineer-in-Charge by way of-
(a) deploying departmental labour and material
or
(b) engaging a contractor by issuing a work order
at contract rate/SOR rate
or
(c) sanctioning supplementary work in a existing
agreement to a contractor for zonal works or
other similar work
or
(d) inviting open tender
or
(e) combination of above
The Engineer-in-Charge shall assess the cost of
such rectification which shall be recoverable from
the contractor from his Performance Security or
any amount due or that may become due to him
and from other available securities. If this amount
is not sufficient to meet the expenses incurred on
rectification, the balance amount may be
recovered as Land Revenue Arrears as per
MPLRC
(Amended vide Govt. memo No.
1400/1246/2018/19/Yo Bhopaldt.06-04-18)
21 Competent Authority for S.E. of concerned Circle
determining the rate
Any other condition for Yes as below:
breach of contract If the contractor fails to achieve 50%
financial progress in any milestoneand
27
/or
fails to achieve 75% financial progress in
two consecutive mile stones
28 Penalty (a) Penalty shall include forfeiture of Security
deposit as per clause 30 of General
Conditions of Contract and the percentage
to apply to the value of work not
completed representing the Employers
additional cost for completing the works
which shall be 20 percent and
(b) Liquidated Damages imposed as per
clause 15 or Performance Security
(Guarantee) including Additional
Performance Security (Guarantee), if any,
as per clause 29 of General Conditions of
Contract, whichever is higher
(Amended vide Govt. memo No.F-53/
16/2012/19/;ks/6842 dt. 2.11.15)
Page 58 of 114
GCC
Particulars Data
Clause
Performance guarantee The upfront Bank Guarantee against
(Security) shall be valid up Performance Security shall be taken for a
to period as mentioned below –
(a) Works having Performance Guarantee of 5
Years- Construction Period + 3 Years + 3
Months.
(b) Works having Performance Guarantee of 3
Years- Construction Period + 2 Years + 3
Months.
(c) Works having Performance Guarantee of 1
Years- Construction Period + 1 Years + 3
29 Months.
Page 59 of 114
GCC
Particulars Data
Clause
Clause 31 Weight ages of Percentage of Component
Component in the work in the work
Component B.T. Road B.T. Rigid Bridge
(Amended As per vide Construction Renewal Pavement Works
Construction
Govt. Order No. F-53-55-
Labour 10% 10% 10% 20%
2018-19-Yo-1314bhopal component-P1
dated 28-3-2018 )
Cement 5% 0% 23% 15%
component -Pc
Steel 5% 0% 12% 20%
component -Ps
Bitumen 20% 30% 0% 0%
component-Pb
POL 10% 10% 10% 10%
component -Pf
Plant & 5% 5% 5% 5%
Machinery
Spares
component -Pp
Other Materials 45% 45% 40% 30%
component-Pm
323 Clause 32.1 Mobilization and No Mobilization and Construction Machinery
Construction Machinery Advance Payable
Advance Applicable
Clause 32.2If yes, Not Applicable
Unconditional Bank
Guarantee
Clause 32.3 If yes, Rate of Not Applicable
interest chargeable on
advances
Clause 32.4 If yes, Type & Not Applicable
Amount of Advance payment
that can be paid
Clause 32.5 If yes, Recovery Not Applicable
of advance payment
33 Clause 33.1 Secured Not Applicable
Advance Applicable
Clause 33.2 if yes, Not Applicable
Unconditional Bank
Guarantee
Clause 33.2 if yes, Amount
Not Applicable
of Secured Advance
Clause 33.3 if yes, Not Applicable
Conditions for secured
advance
Clause 33.4 if yes, Recovery Not Applicable
of Secured advance
Completion Certificate –
35 after physical completion of
As per 'Annexure - U'4
Page 60 of 114
GCC
Particulars Data
Clause
the Work
Final Completion Certificate
– after final payment on As per 'Annexure- V'
completion of the Work
36 Competent Authority S.E. PWD BRIDGE CIRCLE BHOPAL
Salient features of some of
39 the major labour laws that As per 'Annexure-W'
are applicable
415 Competent Authority C.E. PWD BRIDGE ZONE BHOPAL
5
Section 3 –Contract Data
Page 61 of 114
Annexure – N
(See Clouse-10 of Section 3 – GCC)
DRAWING
List of Drawing ;-
The drawings & design for Rigid Pavement/ Flexible Pavement/Culvert/Bridges shall be
proposed & submitted by the contractor which shall be scrutinized & approved by competent
authority of department & will be issued to contractor for execution.
Page 62 of 114
Annexure – O
(See Clouse-15 of Section 3 – GCC)
DETAILS OF MILESTONES
……………………………..NA……………………………..
Page 63 of 114
Annexure – P
(See Clouse-15 of Section 3 – GCC)
If the contractor fails to achieve the milestones, and the delay in execution of work is
attributable to the contractor/the Employer shall retain an amount from the sums
payable and due to the contractor as per following scale -
ii. Slippage exceeding 25% but Up to 50% in financial target during the milestone
under consideration 5% of the work remained unexecuted in the related time
span ..
iii. Slippage exceeding 50% but Up to 75% in financial target during the milestone
under consideration -7.5% of the work remained unexecuted in the related time
span ..
iv. Slippage exceeding 75% in financial target during the milestone under
consideration -10% of the work remained unexecuted in the related time span.
Note: For arriving at the dates of completion of time span related to different milestones,
delays which are not attributable to the Contractor shall be considered. The slippage
on any milestone is if made good in subsequent milestones or at the time of
stipulated period of completion, the amount retained as above shall be refunded. In case
the work is not completed within the stipulated period of completion along with all such
extensions which are granted to the Contractor for either Employer's
default or Force Majeure, the compensation shall be levied on the contractor at the
rate of 0.05% per day of delay limited to a maximum of 10% of contract price. The
decision of Superintending Engineer shall be final and binding upon both the parties
Page 64 of 114
Annexure – Q
(See Clouse-17 of Section 3 – GCC)
Page 65 of 114
Annexure- R
PRICE ADJUSTMENT
[ Cl. 31 of Section 3- GCC ]
The formula for adjustment of prices are :
R= Value of work as defined in Clause 31.1 of Conditions of Contract
Adjustment for Labour Component
(i) Price adjustment for increase or decrease in the cost due to labour shall be paid
in accordance with the following formula.
VL = 0.85 XP1/100 XR(Li – Lo ) / Lo
VL = increase or decrease in the cost of work during the month under consideration
due to changes in rates for local Labour.
Lo= the consumer price index for industrial workers for the State on 28days preceding
the date of opening of Technical Bids as published by Labour Bureau, Ministry of
Labour, Government of India.
Li= the consumer price index for industrial workers for the State for the month under
consideration as published by Labour Bureau, Ministry of Labour component of
the work.
P1 = Percentage of Labour component of the work.
Adjustment for Cement Component
(ii) Price adjustment for increase or decrease in the cost of cement
procured by the contractor shall be paid in accordance with the
following formula:
VC= 0.85 X PC/100 X R X(C1-C0)/C0
Vc= increase or decrease in the cost of work during the month under
Consideration due to changes in rates for cement.
Co= The all India wholesale price index for Pozzolana Cement on 28 days preceding
the date of opening of Technical Bids, as published by the Economic Advisor,
DIPP, Ministry of Commerce & Industry Government of India, New Delhi.
C1= The all India average wholesale price index for cement for the month under
consideration as published by the Economic Advisor, DIPP, Ministry of
Commerce & Industry Government of India, New Delhi.
Pc= Percentage of cement component of the work
Adjustment of Steel Component
(iii) Price adjustment for increase or decrease in the cost of steel procured by the
Contractor shall be paid in accordance with the following formula:
Vs= 0.85 X PS X /100 X R X (S1-S0)/S0
Vs= Increase or decrease in the cost of work during the month under consideration
due to changes in the rates for steel.
S0= The all India wholesale price index for mild steel long products / flats on 28 days
preceding the date of opening of Technical Bids, as published by the Economic
Advisor, DIPP, Ministry of Commerce & Industry Government of India, New
Delhi.
Si = The all India average wholesale price index for mild steel long products / flats for
the month under consideration as published by the Economic Advisor, DIPP,
Ministry of Commerce & Industry Government of India, New Delhi.
Ps= Percentage of steel component of the work.
Note: For the application of this clause, index of mild steel long products / flats has
been Chosen to represent steel group. In any work only one of the indices i.e.
Page 66 of 114
either for long products or for flats shall be used as decided by the Employer/
Executing Agency.
Adjustment of Bitumen Component
(iv) Price Adjustment for increase or decrease is the cost of bitumen shall be paid in
accordance with the following formula:
Vb= 0.85 X Pb / 100XRX( Bi – Bo) / Bo
Vb= Increase or decrease in the cost of work during the month under
consideration due to changes in rates for bitumen.
Bo = The official retail price of bitumen at the IOC depot nearest to the work
site on the day 28 days prior to the date of opening ofTechnical Bids.
Bi = The official retail price of bitumen at the IOC depot nearest to the work
site for the 15th day of the month under consideration.
Pb= Percentage of bitumen component of the work.
Adjustment of POL (Fuel and Lubricant) Component
( V) Price adjustment for increase or decrease in cost of POL (Fuel and Lubricant)
shall be paid in accordance with the following formula:
Vf = 0.85 X Pf / 100 X RX ( Fi– Fo) / Fo
Vf = Increase or decrease in the cost of work during the month under
consideration due to changes in rates for fuel and lubricants.
Fo= The official retail price of High Speed Diesel (HSD) at the
existingconsumer pumps of IOC nearest to the work site on the day 28
daysprior to the date of opening of Technical Bids.
Fi = The official retail price of HSD at the existing consumer pumps of IOC
nearest to the work site for the 15th day of month under consideration.
Pf = Percentage of fuel and lubricants component of the work.
Note : For the application of this clause, the price of High Speed Diesel oil has been
chosen to represent fuel and lubricants group.
Adjustment for Plant and Machinery Spares component
( Vi) Price adjustment for increase or decrease in the cost of plant and machinery
spares procured by the Contractor shall be paid in accordance with the following
formula:
Vp= 0.85X Pp / 100XRx( Pi – Po) / Po
Vp= Increase or decrease in the cost of work during the month under
consideration due to changes in rates for plant and machinery spares.
Po= The all India wholesale price index for manufacturer of machines for
mining / quarrying and construction on 28 days preceding the date of
opening of Technical Bids, as published by the Economic Advisor, DIPP,
Ministry of Commerce & Industry Government of India, New Delhi.
Pi = The all India wholesale price index for manufacturer of machines for
mining / quarrying and construction for the month under consideration as
published by the Economic Advisor, DIPP, Ministry of Commerce &
Industry Government of India, New Delhi.
Pp = Percentage of plant and machinery spares component of the work.
Note : For the application of this clause, index of manufacturer of machines for mining /
quarrying and construction has been chosen to represent the Plant and
Machinery Spares group.
Adjustment of Other Materials Component.
( Vii) Price adjustment for increase or decrease in cost of local materials other than
cement, Steel, Bitumen and POL procured by the contractor shall be paid in
accordance with the following formula:
Page 67 of 114
Vm= 0.85X Pm / 100XRX( Mi – Mo) / Mo
Vm= Increase or decrease in the cost of work during the month under
consideration due to changes in rates for local materials other than
cement, Steel, Bitumen and POL.
Mo= The all India wholesale price index ( all commodities ) on 28 days
preceding the date of opening of Technical Bids, as published by the
Economic Advisor, DIPP, Ministry of Commerce & Industry Government
of India, New Delhi.
Mi = The all India wholesale price index( all commodities) for the month under
consideration as published by the Economic Advisor, DIPP, Ministry of
Commerce & Industry Government of India, New Delhi.
Pm = Percentage of local material component (other than Cement, Steel,
Bitumen and POL) of the work. Plant and Machinery spares component of
the work.
(Amended As per vide Govt. Order No. F-53-55-2018-19-Yo-1154
bhopal dated 23-3-2018 ) and Amended Vide Govt memo No. F-
53/16/2012/19/YO/1653 Dated 6/5/2022 (Enclosed)
The following percentages will govern the price adjustment for the entire
contract:
Note: Ordinarily the 7 components shown above are components of the civil
works. However for specific works in which some components not
included in the aforementioned 7 components, form a substantial part of
the works the same can be provided using similar formula and related
indices. In all cases the sum total of percentage of different components
shall be 100%.
Page 68 of 114
Annexure - S
(See clause 32 at Section 3 -GCC)
To,
__________ [name of Employer]
_________ [address of Employer]
__________ [name of Contractor]
This guarantee shall remain valid and in full effect from the date of the advance
payment under the Contract until ____________________________ [name of Employer)
receives full repayment of the same amount from the Contractor.
Yours truly,
An amount shall be inserted by the Bank or Financial Institution representing the amount of the
Advance Payment, and denominated in Indian Rupees.
Page 69 of 114
Annexure -T
(See clause 33 of Section 3 -GCC)
AND WHEREAS the contractor has applied to the Employer that he may be
allowed advanced on the security of materials absolutely belonging to him and brought by him to
the site of the works the subject of the said agreement for use in the construction of
such of the works as he has undertaken to executive at rates fixed for the finished work
(inclusive of the cost of materials and labour and other charges)
AND WHEREAS the Employer has agreed to advance to the Contractor the sum of
Rupees _____________________________ ______________ on the security of materials
the quantities and other particulars of which are detailed in Accounts of Secured Advance
attached to the Running account Bill for the said works signed by the Contractor on
…………………………………………. and the Employer has reserved to himself the option of
making any further advance or advances on the security of other materials brought by the
Contractor to the site of the said works.
Page 70 of 114
(1) the Contractor as aforesaid ancj all or any further sum of sums advanced as aforesaid
shall be employed by the Contractor in or towards expending the execution of the said
works and for no other purpose whatsoever.
(2) That the materials details in the said Account of Secured Advances which have been
offered to and accepted by the Employer as security are absolutely the Contractor's own
propriety and free from encumbrances of any kind and the contractor will not make any
application for or receive a further advance on the security of materials which are not
absolutely his own property and free from encumbrances of any kind and the Contractor
indemnified the Employer against all claims to any materials in respect of which an
advance has be made to him as aforesaid.
(3) That the materials detailed in the said account of Secured Advances and all other
materials on the security of which any further advance or advances may hereafter be
made as aforesaid (hereafter called the said materials) shall be used by the Contractor
solely in the execution of the said works in accordance with the directions of the
Engineer.
(4) That the Contractor shall make at his own cost all necessary and adequate arrangements
for the proper watch, safe custody and protection against all risks of the said materials
and that until used in construction as aforesaid the said materials shall remain at the site
of the said works in the Contractor's custody and on his own responsibility and shall at all
times be open to inspection by the Engineer or any officer authorized by him. In the
event of the said materials or any part thereof being stolen, destroyed or damaged or
becoming deteriorated in a greater degree than is due to reasonable use and wear thereof
the Contractor will forthwith replace the same with other materials of like quality or
repair and make good the same required by the Engineer.
(5) That the said materials shall not be removed from the site of the said works except with
the written permission of the Engineer or an officer authorized by him on that behalf.
Page 71 of 114
(6) That the advances shall be repayable in full when or before the Contract receives
payment from the Employer of the price payable to him for the said works under the
terms and provisions of the said agreement. Provided that if any intermediate payments
are made to the Contractor on account of work done than on the occasion of each such
payment the Employer will- be at liberty to make a recovery from the Contractor's bill for
such payment by deducting there from the value of the said materials than actually used
in the construction and in respect of which recovery has not been made previously, the
value for this purpose being determined in respect of each description of materials at the
rates at which the amounts of the advances made under these presents were calculated.
(7) That if the Contractor shall at any time make any default in the performance or
observance in any respect of any of the terms and provisions of the said agreement or of
these presents the total amount of the advance or advances that may still be owipg of the
Employer shall immediately on the happening of such default be re- payable by the
Contractor to be the Employer together with interest thereon at twelve percent per annum
from the date or' respective dates of such advance or advances to the date of repayment
and with all costs, charges, damages and expenses incurred by the Employer in or for the
recovery thereof or the enforcement of this security or otherwise by reason of the default
of the Contractor and the Contractor hereby covenants and agrees with the Employer to
reply and pay the same respectively to him accordingly
(8) That the Contractor hereb'fcharges all the said materials with the repayment to the
Employer of the said sum of Rupees and any further sum of sums advanced as aforesaid
and all costs, charges, damages and expenses payable under these presents PROVIDED
ALWAYS and it is hereby agreed and declared that notwithstanding anything in the said
agreement and without prejudice to the power contained therein if and whenever the
covenant for payment and repayment here-in-before contained shall become enforceable
and the money owing shall not be paid in accordance there with the Employer may at any
time thereafter adopt all or any of the following courses as he may deem best:
Page 72 of 114
(a) Seize and utilize the said materials or any part thereof in the completion of the said
works on behalf of the contractor in accordance with the provision in that behalf
contained in the said agreement debiting the contractor with the actual cost of
effecting such completion and the amount due to the contractor with the value of
work done as if he had carried it out in accordance with the said agreement and at
the rates thereby provided. If the balance is against the contractor, he is to pay same
to the Employer on demand.
(b) Remove and sell by public auction the seized materials or any part thereof and out of
the moneys arising from the sale retain all the sums aforesaid repayable or payable
to the Employer under these presents and pay over the surplus (if any) to the
Contractor.
(c) Deduct all or any part of the moneys owing out of the security deposit or any sum
due to the Contractor under the said agreement.
(9) That except in the event of such default on the part of the contractor as aforesaid interest
on the said advance shall not be payable.
(10) That in the event of any conflict between the provisions of these presents and the said
agreement the provisions of these presents shall prevail and in the event of any dispute or
difference arising over the construction or effect of these presents the settlement of which
has not been here-in-before expressly provided for the same shall be referred to the
Employer whose decision shall be final and the provision of the Indian Arbitration Act
for the time being in force shall apply to any such reference.
Page 73 of 114
Annexure - U
(See clause 35 of Section 3 -GCC)
Used M B No.…………………………
Certified that the above mentioned work was physically completed on ………….… (date) and
taken over on ……………………. (date) and that I have satisfied myself to best of myability
that the work has been done properly.
Date of issue
Executive Engineer,
PWD Bridge Division
Bhopal
Page 74 of 114
Annexure - V
Used M B No.…………………………
Certified that the above mentioned work was physically completed on ………….… (date) and
taken over on ……………………. (date)
I have satisfied myself to best of my ability that the work has been done properly.
Executive Engineer,
PWD Bridge Division
Bhopal
Page 75 of 114
Annexure - W
(See clause 39 of Section 3 -GCC)
SALIENT FEATURES OF SOME MAJOR LABOURLAWS APPLICABLE
a) Workmen Compensation Act 1923: - The Act provides for compensation in case of
injury by accident arising out of and during the course of employment.
b) Payment of Gratuity Act 1972: - Gratuity is payable to an employee under the Act on
satisfaction of certain conditions on separation if an employee has completed the
prescribed minimum years (say, five years) of service or more or on death the rate of
prescribed minimum days'(say, 15 days} wages for every completed year of service.
The Act is applicable to all establishments employing the prescribed minimum
number (say, 10) or more employees.
c) Employees P.F. and Miscellaneous Provision Act 1952: The Act Provides for monthly
contributions by the Employer plus workers at the rate prescribed (say, 10% or
8.33%). The benefits payable under the Act are:
i. Pension or family pension on retirement or death as the case may be.
ii. Deposit linked insurance on the death in harness of the worker.
III. Payment of P.F. accumulation on retirement/death etc.
d) Maternity Benefit Act 1951: - The Act provides for leave and some other benefits to
women employees in case of confinement or miscarriage etc.
e) Contract labour (Regulation &Abolition) Act 1970: - The Act provides for certain
welfare measures to be provided by the Contractor to contract labour and in case
the Contractor fails to provide, the same are required to be provided, by the
Principal Employer by Law. The principal Employer is required to take Certificate of
Registration and the Con1jactor is required to take license from the designated
Officer. The Act is applicable to the establishments or Contractor of Principal
Employer if they employ prescribed minimum (say 20) or more contract labour.
f} Minimum Wages Act 1948: - The Employer is to pay not less than the Minimum
Wages fixed by appropriate Government as per provisions of the Act if the
employment is a scheduled employment. Construction of buildings, roads, runways
is scheduled employment.
g) Payment of Wages Act 1936: - It lays down as to by what date the wages are to be
paid, when it will be paid and what deductions can be made from the wages of the
workers.
h) Equal Remuneration Act 1979: - The Act provides for payment of equal wages for
work of equal nature to male and female workers and for not making discrimination
against female employees in the matters of transfers, training and promotions etc.
Page 76 of 114
i) Payment of Bonus Act 1965: - The Act is applicable to all establishments employing
prescribed minimum (say, 20) or more workmen. The Act provides for payments of
annual bonus within the prescribed range of percentage of wages to employees
drawing up to the prescribed amount of wages, calculated in the prescribed manner.
The Act does not apply to certain establishments. The newly set-up establishments
are exempted for five years in certain circumstances. States may have different
number of employment size.
j) Industrial Disputes Act 1947: - The Act lays down the machinery and procedure for
resolution of industrial disputes, in what situations a strike or lock-out becomes
illegal and what are the requirements for laying off or retrenching the employees or
Closing down the establishment. •
I) Trade Unions Act 1926: - The Act lays down the procedure for registration of trade
unions of workmen and Employers. The Trade Unions registered under the Act have
been given certain immunities from civil and criminal liabilities.
m) Child labour (Prohibition &Regulation) Act 1986: - The Act prohibits employment
of children below 14 years of age in certain occupations and processes and provides
for regulations of employment of children in all other occupations and processes.
Employment of child labourisprohibited in building and construction industry.
Page 77 of 114
p) Factories Act 1948: - The Act lays down the procedure for approval of plans before
setting up a factory, health and safety provisions, welfare provisions, working hours,
annual earned leave and rendering information regarding accidents or dangerous
occurrences to designated authorities. It is applicable to premises employing the
prescribed minimum (say, 10) persons or more with aid of power or another
prescribed minimum (say, 20) or more persons without the aid of power engaged in
manufacturing process.
Page 78 of 114
SECTION 3
Conditions of Contract
Page 79 of 114
SECTION 4
BILL OF QUANTITIES (BOQ)
General Description of work: Construction of Submersible Bridge across Davar Nalla Near
Devi Mandir On Parwariya -Raisen Road Distt. Raisen
Probable Amount of Contract:
(Rs. In Figure) Rs 215.88 lacks
(Rs. In Words) (Rs Two Crore Fifteen Lakhs Eighty Eight Thousand Only)
~
Total Amount (Rs. In Figure)
Executive Engineer,
PWD Bridge Division
Bhopal
Page 80 of 114
SECTION 5
AGREEMENT FORM
AGREEMENT
This agreement, made on the ...................between Executive Engineer …………..name and
address of Employer) (hereinafter called " the Employer) and .................... (name and address of
contractor) hereinafter called "the Contractor" of the other part.
Whereas the Employer is desirous that the (name and identification number of Contract)
(hereinafter called "the Works") and the ,Employer has accepted the Bid by the Contractor for the
execution and completion of such Works and the remedying of any defects therein, at a cost of
Rs....................
NOW THIS AGREEMENT WITNESSED as follows:
1. In this Agreement, words and expression shall have the same meanings as are respectively
assigned to them in the conditions of contract hereinafter referred to and they shall be deemed
to form and be read and construed as part of this Agreement.
2. In consideration of the payments to be made by the Employer to the Contractor as hereinafter
mentioned, the Contractor hereby covenants with the Employer to execute and complete the
Works and remedy any defects therein in conformity in all aspects with the provisions of the
contract.
3. The Employer hereby covenants to pay the Contractor in consideration of the execution and
completion of the Works and the remedying the defects wherein Contract Price or such other
sum as may become payable under the provisions of the Contract at the times and in the
manner prescribed by the Contract.
4. The following documents shall be deemed to form and be ready and construed as part of this
Agreement viz.
i. letter of Acceptance
ii. Contractor's Bid
iii. Condition of Contract: General and Special
iv. Contract Data v. Bid Data vi. Drawings
vii. Bill of Quantities and
viii. Any other documents listed in the Contract Data as forming part of the Contract.
In witnessed whereof the parties there to have caused this Agreement to be executed the
day and year first before written.
The Common Seal of ____________________________________was hereunto affixed in
the presence of:
Signed, Sealed and Delivered by the said _________________________
_______________________________________ in the presence of:
Executive Engineer
PWD ------------------------------- Binding Signature of Contractor
Page 81 of 114
Page 82 of 114
Page 83 of 114
Page 84 of 114
Page 85 of 114
Page 86 of 114
Page 87 of 114
Page 88 of 114
Page 89 of 114
Page 90 of 114
Page 91 of 114
Page 92 of 114
Page 93 of 114
Page 94 of 114
Page 95 of 114
Page 96 of 114
Page 97 of 114
Page 98 of 114
Page 99 of 114
Page 100 of 114
Page 101 of 114
Page 102 of 114
Page 103 of 114
Page 104 of 114
Page 105 of 114
Page 106 of 114
Page 107 of 114
Page 108 of 114
Page 109 of 114
Page 110 of 114
Page 111 of 114
Page 112 of 114
Page 113 of 114
Page 114 of 114