Location via proxy:   [ UP ]  
[Report a bug]   [Manage cookies]                
Scribd Logo
Upload

Welcome to Scribd!

  • 51 views

    Agreement

    Uploaded by

    Ahmed Shah
    This letter serves as an agreement between [Your Name], the Architect, and [Client's Name], the Client, for architectural services for the [Project Name]. The Architect will provide services including design, construction documents, and administration. The Client will pay an hourly rate of $[Hourly Rate] or lump sum of $[Lump Sum Fee] according to a payment schedule, and reimburse expenses. The agreement outlines ownership of documents, confidentiality, termination terms, and dispute resolution procedures.

    Copyright:

    © All Rights Reserved
    Download as DOCX, PDF, TXT or read online from Scribd

    Agreement

    Uploaded by

    Ahmed Shah
    51 views2 pages
    This letter serves as an agreement between [Your Name], the Architect, and [Client's Name], the Client, for architectural services for the [Project Name]. The Architect will provide services including design, construction documents, and administration. The Client will pay an hourly rate of $[Hourly Rate] or lump sum of $[Lump Sum Fee] according to a payment schedule, and reimburse expenses. The agreement outlines ownership of documents, confidentiality, termination terms, and dispute resolution procedures.

    Copyright

    © © All Rights Reserved

    Available Formats

    DOCX, PDF, TXT or read online from Scribd

    Did you find this document useful?

    Is this content inappropriate?

    This letter serves as an agreement between [Your Name], the Architect, and [Client's Name], the Client, for architectural services for the [Project Name]. The Architect will provide services including design, construction documents, and administration. The Client will pay an hourly rate of $[Hourly Rate] or lump sum of $[Lump Sum Fee] according to a payment schedule, and reimburse expenses. The agreement outlines ownership of documents, confidentiality, termination terms, and dispute resolution procedures.

    Copyright:

    © All Rights Reserved
    Download as DOCX, PDF, TXT or read online from Scribd
    Download as docx, pdf, or txt
    51 views2 pages

    Agreement

    Uploaded by

    Ahmed Shah
    This letter serves as an agreement between [Your Name], the Architect, and [Client's Name], the Client, for architectural services for the [Project Name]. The Architect will provide services including design, construction documents, and administration. The Client will pay an hourly rate of $[Hourly Rate] or lump sum of $[Lump Sum Fee] according to a payment schedule, and reimburse expenses. The agreement outlines ownership of documents, confidentiality, termination terms, and dispute resolution procedures.

    Copyright:

    © All Rights Reserved
    Download as DOCX, PDF, TXT or read online from Scribd
    Download as docx, pdf, or txt
    You are on page 1of 2

    [Your Name]

    [Your Address]

    [City, State, ZIP]

    [Email Address]

    [Phone Number]

    [Date]

    [Client's Name]

    [Client's Address]

    [City, State, ZIP]

    Subject: Architectural Agreement

    Dear [Client's Name],

    This letter serves as an agreement between [Your Name], here in after referred to as the
    "Architect," and [Client's Name], hereinafter referred to as the "Client," for architectural
    services related to the [Project Name].

    1. Scope of Work: The Architect agrees to provide architectural services as outlined in the
    proposal submitted to the Client dated [Proposal Date]. The scope of work includes but
    is not limited to:
     Preliminary design and concept development
     Schematic design
     Design development
     Construction documents
     Assistance with contractor selection
     Construction administration
     Post-construction evaluation
    2. Compensation: The Client agrees to pay the Architect for the services rendered as
    follows:
     Hourly Rate: $[Hourly Rate]
     Lump Sum Fee: $[Lump Sum Fee]
     Reimbursable Expenses: The Client shall reimburse the Architect for all reasonable and
    necessary expenses incurred in connection with the project, including but not limited to
    printing costs, travel expenses, and permit fees.
    Payment shall be made according to the following schedule:
     [Payment Schedule]
    3. Project Schedule: The Architect shall provide a project schedule to the Client, indicating
    key milestones and deadlines. The Client agrees to provide all necessary information,
    documents, and approvals in a timely manner to ensure the project remains on
    schedule. The Architect will make reasonable efforts to meet the agreed-upon schedule
    but cannot be held responsible for delays caused by factors beyond their control.
    4. Ownership of Documents: The Architect retains ownership of all documents and designs
    created during the course of the project, including but not limited to drawings,
    specifications, and reports. The Client is granted a non-exclusive license to use the
    documents for the intended purpose of the project. Any use of the documents beyond
    the project's scope requires prior written consent from the Architect.
    5. Confidentiality: Both parties agree to maintain the confidentiality of all proprietary or
    sensitive information shared during the project. The Architect shall not disclose any
    confidential information to third parties without the Client's written consent, unless
    required by law.
    6. Termination: Either party may terminate this agreement with written notice in the event
    of a material breach by the other party. In the event of termination, the Client agrees to
    compensate the Architect for the services performed up to the date of termination.
    7. Dispute Resolution: Any disputes arising from this agreement shall be resolved through
    mediation or arbitration, as agreed upon by both parties. The prevailing party shall be
    entitled to recover reasonable attorney's fees and costs associated with the dispute.
    8. Governing Law: This agreement shall be governed by and construed in accordance with
    the laws of [State], without regard to its conflict of law provisions.

    You might also like