REQUISITION NO.

:
GRSE Ltd. STATEMENT OF TECHNICAL GT60051002M
REQUIREMENT FOR SUPPLY OF
YARD NO. : 3029-36 RAW MATERIAL FOR FRP SHEET : 1 OF 3
DATE: 11.02.2023 GRATING OF BOLLARD PREPARED BY: DN

1. General
1.1 Introduction

1.1.1 The document covers the technical requirements for supply of raw material for FRP Grating of
Bollard as per this specification for ASWSWC project.

1.1.2 Any clarification required regarding technical specifications/regulations should be clarified by

supplier before submission of offer. Technical offers not qualifying/complying to the SOTRs may
be eligible for rejection.

1.1.3 Deviations are to be brought out by the supplier in their compliance matrix. Onus of proving the
equivalence of alternate specifications, if any, quoted in lieu of those specified in the SOTRs,
rests with the supplier. A certificate of conformity needs to be submitted along with the bid.

1.2 Scope of Supply Per Ship

Following items are to be supplied for ASW-SWC ships, Yard Nos.3029-36.

S.No. Description Qty per Item code No.

ship
1. CHOPPED STRAND MAT (CSM 300) (TYPE 10 KG 035001010201.
APPROVED)
Specification: GSM - 300 G/M2, ISO 3374:1990 Loss
on ignition: 3.5 % moisture% < 0.20; 20 DAN Tensile
strength
2. CHOPPED STRAND MAT (CSM 450) (GSM - 450 40 KG 035001010202.
G/M2) (TYPE APPROVED)
Specification: GSM - 450 G/M2, ISO 3374:1990 Loss
on ignition: 3.5 % Moisture% < 0.20; 25 DAN Tensile
strength
3. WOVEN ROVING 610 GM /M (SQUARE) (GSM - 20 KG 660205650703
600 G/M2) (TYPE APPROVED)
Specification: GSM - 600 G/M2, ISO 3374:1990 Loss
on ignition: 3.5 % ,Moisture% < 0.20; 25 DAN
Tensile strength
4. ISOPTHALIC POLYSTER RESIN (HAND LAYUP) 200 KG 035012000100.
5. CATALYST (MEKPO) 10 KG 035013000100.
6. STYRENE BASE ACCELERATOR 2 KG 035014000100.
7. GEL COAT 30 kg 840206616010
8. PIGMENT (GREY) 4 kg 840206616011
9. ACETONE 100 kg 840206615007
 REQUISITION NO.:
GRSE Ltd. STATEMENT OF TECHNICAL GT60051002M
REQUIREMENT FOR SUPPLY OF
YARD NO. : 3029-36 RAW MATERIAL FOR FRP SHEET : 2 OF 3
DATE: 11.02.2023 GRATING OF BOLLARD PREPARED BY: DN

2. Miscellaneous Requirement

2.1 Chopped Strand Mat and Woven Roving are to be type approved. Type approval certificates
to be forwarded along with offer.

2.2 Any clarification required regarding technical specifications/regulations should be clarified by

supplier before submission of offer/pre-bid meeting.

2.3 Material Specification, condition, quality and equivalence acceptance to be as per user
department (FIB Dept, GRSE).

3.3 Vendor to confirm acceptance of material specification from user department prior
submission of Bid & final material to be supplied with complete user department satisfaction.

3.4 The relevant material test certificates to be provided along with the material supply.

3. Instructions to the Bidders

Firms must forward following documents along with their technical offer failing which the offer will be
treated as incomplete and hence, the firm shall be considered technically non-compliant. Deviation if
any is to be highlighted with justification:

i) Compliance Matrix duly filled-in as referred in Annexure – ‘A’ of SOR,

ii) Vendor must forward the sample for approval along with technical offer.
 REQUISITION NO.:
GRSE Ltd. STATEMENT OF TECHNICAL GT60051002M
REQUIREMENT FOR SUPPLY OF
YARD NO. : 3029-36 RAW MATERIAL FOR FRP SHEET : 3 OF 3
DATE: 11.02.2023 GRATING OF BOLLARD PREPARED BY: DN

ANNEXURE – ‘A’

GARDEN REACH SHIPBUILDERS & ENGINEERS LTD.

COMPLIANCE MATRIX OF SOR FOR RAW MATERIAL FOR FRP GRATING FOR ASW-SWC

OFFER REF. No. DATE:

SOR Cl. No. Bidder’s Reason for SOR CI. No. Bidder’s Reason for
Compliance Deviation, If any Compliance deviation, if any
1.1 3.1
1.2 3.2
2.1 3.3
2.2 3.4
2.3 4.
2.4

COMPANY SEAL SIGNATURE WITH DATE……………...

COMPANY NAME, ADDRESS NAME ……………………………………

FAX NO.: DESIGNATION………………………….

PH. NO.:

Note: Please indicate ACC. – For Accepted, NO. – For not accepted and DEV. – For deviation
taken by the bidder with justification for being considered for the technical bid. Enclose
separate sheet for explanation of the deviation.
1) Bidder should read the SOR thoroughly prior to filling up this acceptance format.
2) This format should be properly filled, signed and returned along with your technical bid
for considering the bid.
 ANNEXURE: III
FORMAT NO. QS/03/0019

PROFORMA OF BANK GUARANTEE TOWARDS SATISFACTORY PERFORMANCE

THIS DEED OF GUARANTEE made this …………………day of

……………………BETWEEN…………………………………………………(hereinafter called “ THE BANK ”) which expression shall
unless excluded by or repugnent to the context , be deemed to include its successors in office and assigns of
the ONE Part and GARDEN REACH SHIIPBUILDERS AND ENGINEERS LIMITED , having their Head OfficAt 43/46 ,
Garden Reach Road , Calcutta – 700024 (hereinafter called “ THE BUYERS ”) which expression shall unlesss
excluded by or repugnant to the context be deemed to include their successors in Office and assigns of the
part WHEREAS Messers ………………………………………………………….having its registered office at
……………………………………(hereinafter called “ THE SELLER ”) have accepted an Order No. ………………………………for
supply of ……………………………………from the Buyer to manufacture and deliver the same to Buyer in good
condition .

AND WHEREAS it is one of the terms of the said order that the seller shall furnish to the Buyer a
Bank Guarantee comprising …………………….……….% of the value of the order amounting to Rs. …………………….
(Rupees……………… ………………………………………………… only) for the satisfactory performance of the equipments
supplied against the said order at least for a period of ……………………………………… from the date of supply i.
e. from ………………………………………………AND WHEREAS the Buyer has agreed to accept such Bank Guarantee .

NOW THIS INDENTURE WITNESSETH THAT in consideration of the premise the Bank hereby unequivocally
undertakes and agrees with the Buyer to pay to the Buyer upon demand in writing whenever required so
by them to do and within a fortnight from date of such demand sum or sums not exceeding in the
whole of Rs. ……………………..(Rupees…………….…………………………………………………… only ) as may become payable to
the Buyer by the seller by virtue of or arising out of the Terms and Conditions of the said Order.

Provided it is hereby expressly stipulated and agreed that if any question as to whether any sum has
become payable by the seller to the buyer by virtue of or arising out of the said order, the decision of the
Buyer will be final and conclusive and the Guarantee herein contained shall not be revocable by notice or by
reason of dissolution or winding up of the business of the seller of any change in the constitution or
composition of the seller’s business and the liability of the bank under this presents shall not be impaired in
any way by any extension of time or alteration made given conceded in the conditions of the said order or any
other indulgence given by the buyer or by reasons of any failure on the part of the Buyer to enforce any of
their remedies against the sellers and / or by reasons of failure on the part of the Buyer to observe or perform
any of the stipulation contained in the said order and to be observed or performed by the sellers or by any
other dealings between the Buyer and Seller whether any of the above takes place with or without the
knowledge of the Bank and that the Guarantee herein contained shall remain in full force and virtue only . All
claims and demands of the Buyer arising out of or in connection with the said order have been fully paid and
satisfied PROVIDED ALWAYS AND IT IS HEREBY AGREED BETWEEN THE PARTIES THAT a Bank’s liability
under this Indenture shall remain in full froce from the date of issue of the Guarantee till…………………… and is
limited to a sum of Rs. ………………(Rupees………………………………………………………..)only.

NOTWITHSTANDING anything stated above our liability under the Guarantee is restricted to Rs . …………………
(Rupees………… ……………………… ………………… only ). Our Guarantee shall remain in force
upto…………………………..and unless a claim or demand in writing is made on the bank within 6 months from the
date of expiry of the Bank Guarantee the bank shall be released and discharged from all liabilities thereunder.

Date : ……………200 Signature of Bank’s Authorised

Signatories with Code No., Name,
Designation and Bank Stamp

4
FORM NO. QS/03/0020

GARDEN REACH SHIPBUILDERS & ENGINEERS LIMITED

43/46, GARDEN REACH ROAD
KOLKATA – 700 024.

FORMAT OF BANK GUARANTEE TOWARDS SECURITY DEPOSIT.

Ref : 1. BPE Notification No. BPE/G:032/78/1(4)/Adv(F)/69 dated 24.10.78.

2. F.No.0(7)/B.O.III/75 dated 2.11.77.

-------------------------------------------------------------------------------------------------------
GUARANTEE BOND
(to be used by all scheduled banks)

1. In consideration of M/s. Garden Reach Shipbuilders & Engineers Limited, 43/46, Garden Reach Road, Kolkata – 700
024(hereinafter called “The Buyer”) having agreed to exempt M/s.……………………………………………………………….
(hereinafter called “The Party”) from the demand,under the terms and conditions contained in the Tender/
Purchase order no…………………….dated …………… (hereinafter called “the said Tender/ Order”) of security deposit
for the due fulfillment by the said Party’s of the terms and conditions contained in the said Tender,on production of
a Bank Guarantee for Rs………… (Rupees…………………… ……………..only), we …………………………………… Bank
Limited (hereinafter referred to as “the Bank”) do hereby undertake to pay to the Buyer an amount not exceeding
Rs……………….. against any loss or damage caused to or suffered by the Buyer by reasn of breach by the said Party
of any of the terms or conditions contained in the said Tender.

2. We……………………………Bank do hereby undertake to pay the amounts due and payable under this Guarantee
without any demur, merely on a demand from the Buyer stating that the amount claimed is due by way of loss or
damage caused, to or would be caused to or suffered by the Buyer by reason of any breach by the said Party of
any of the terms or conditions contained in the said Tender or by reason of the Party’s failure to perform the said
Tender. Any such demand made on the Bank shall be conclusive as regards the amount due and payable by the
bank under this guarantee.

3. We………………………….Bank Limited further agree to the Guarantee herein contained shall remain in full force and
effect during the period that would be taken for the performance of the said Tender. Order and that it shall
continue to be enforceable till all the dues of the Buyer under or by virtue of the said Tender/Order have been fully
paid and its claims satisfied or discharged or till the Chairman & Managing Director, Garden Reach Shipbuilders &
Engineers Limited, certifies that the terms & conditions of the said Tender have been fully and properly carried out
by the said Party and accordingly discharges the Guarantee. Unless a demand or claim under this Guarantee is
made on us in writing on or before the……………………… we shall be discharged from all liability under this
Guarantee thereafter.

4. We…………………………………Bank Limited further agree with the Buyer that the Buyer shall have the fullest liberty
without our consent and without affecting in any manner our our obligations hereunder to vary any of the terms &
conditions of the said Tender/Order or to extended time of performance by the said party from time to time or to
postpone for any time or from time to time any of the powers exercisable by the Buyer against the said Party and
to forbear or enforce any of terms and conditions relating to the said Tender/Order and we shall not be relieved
from our liability by reason of any such variation, or extension being granted to the said Party or for any for
bearance, act or omission on the part of the Buyer or any indulgence by the Buyer to the said Party or by any such
matter of thing whatsoever which under the law relating to sureties would but for this provision have effect of so
relieving us.

5. We……………………………………..Bank Limited lastly undertake not to revoke this Guarantee during its currency
except with the previous consent of the Buyer in writing.

6. Not withstanding anything contained here in above, the liability of the Guarantor under this Guarantee is restricted
to Rs………… (Rupees…………………………… ……………….……………….only) and that this Guarantee shall remain in
force until its expiry on the ……………(date), unless a suit or action to enforce a claim under this Guarantee is made
against the Guarantor within six months from the date of expiry, all the rights of the beneficiary under the said
Guarantee shall b released and discharged from all liabilities thereof.

For ………………………………….Bank Limited.

(seal)

Dated the ………………..day of ……………………….200…..

5
 SHIPPING INSTRUCTIONS
SHIPPING MARKS:
The packing case should be marked as
GRSE LTD., KOLKATA (INDIA)
CASE NO……………………….. DIMENSION ………………
GROSS WEIGHT ………….. NET WEIGHT …………….
CONSIGNOR’S NAME ………………………………………..
PORT OF DISCHARGE ………………………………………..

SHIPPING ARRANGEMENTS (FOR SEA FREIGHT) FOB/FAS CONTRACTS

Shipping arrangements will be made by the Ministry of Shipping and
Transport (Chartering Wing), PARIVAHAN BHAWAN, 1,Parliament Street, New Delhi - 110007(Cable TRANSCHART) Fax
No.011 2371- 8614 through their respective Forwarding AGENTS/nominees as mentioned below to whom adequate notice
about the readiness of each consignment should be given by the Sellers from time to time at least six weeks in advance of
the required position, for finalizing the shipping arrangements.
SL AREA Forwarding Agents/Nominee
Ms.Tanja Heuckroth,
U.K. including Northern Ireland (also Fire) the North
Manager Sea Freight,
Continent of Europe (West Germany, Holland, Belgium,
M/s.PANALPINA WELTRANSPORT GMBH, SFEI,
A France, Norway, Sweden, Finland and Denmark) and ports
HAMBURG,GERMANY.
on the continental sea board of the Mediterranean (i.e.
Tel – 4940 23771-126 Fax: 4940 23771 342
French and Western Italian ports) and also Adriatic Ports.
E-mail : tanja.heuckroth@panelpina.com
M/s. OPT Overseas Project Transport INC.
(A Thyssen Haniel Logistic co.)
B U.S.A. & Canada 46,Sellers Street,Kearny,N.J. 07032,
Tel :(201) 998-7771
Fax: (201) 998-7833
The First Secretary (Commercial),
C Japan Embassy of India, Tokyo,Japan.
Tel: 262-2391
The Shipping Corpn. Of India Ltd.
‘Shipping House’, 245, MadameCama Egypt,
D Australia, Algeria, Bulgaria, Romania, Czechoslovakia,
G.D.R. Road, Mumbai – 400 021.
(Cable: SHIPINDIA MUMBAI) Tel: 232666, 232785.
The Secretaries, Indo-Soviet Shipping Service
C/o. The Shipping Corpn. of India Limited.
E U.S.S.R.
‘Shipping House’245, MadameCama Road, Mumbai-400 021.
(Cable: SHIPINDIA MUMBAI FOR SOVINDSHIP).
The Secretaries, Indo-Polish Shipping Service,
C/o. The shipping Corpn. Of India Ltd.,
F Poland
‘Shipping House’, 245 , Madame Cama Road, Mumbai-400021.
(Cable: SHIPINDIA MUMBAI FOR INDOPOL) Tel: 232666.
The Shipping Co-ordination officer,
Ministry of Shipping and Transport
G Other areas not specifically mentioned above
(Chartering Wing), New Delhi.
Cable: TRANSCHART,NEW DELHI.

The following additional provisions are also made in respect of imports from the undermentioned areas, respectively :

i) Shipments from Australia,Algeria,Bulgaria,Romania,Czechoslovakia, Egypt and G.D.R.

A copy of the notice about the readiness of each consignment given by The Sellers to the Shipping Corpn. of India, Mumbai
should also be endorsed to the Shipping Co-ordination officer, Ministry of Shipping and Transport (Chartering Wing), New
Delhi. (Cable: TRANSCHART,NEW DELHI)

ii) Shipments from U.S.S.R.

Shipment under this contract should be made in accordance with the agreement between the Government of the republic of
India and the Govt. of the U.S.S.R. on Merchant Shipping 1976, as amended upto date by Vessels of Indo-Soviet Shipping
service.

iii) Shipment from Poland

Shipment under this contract would be made by the National Flag Lines of The two parties and vessels of third flag
conference lines, in accordance with the Agreement between the Govt. of the Republic of India and the Govt. of Polish
People’s Republic regarding Shipping Co-operation dated 27.6.1960 as amended upto date.

iv) Shipments from Czechoslovakia

Goods under this contract would be shipped by International Flag Lines of the two parties and vessels of the third flag
conference lines, in accordance with the Agreement co-operation in Shipping between India and Czechoslovakia signed on
3.11.1978 and rectified on29.12.1079, as amended upto date.

v) The Bills of Lading should be drawn so as to show:

Shippers : The Government of India
Consignee: Garden Reach Shipbuilders & Engineers Ltd.,
43/46,Garden Reach Road,
Kolkata – 700 024.

vi) Two non-negotiable copies of the Bills of Lading including the freight amount and discount, if any allowed, should be forwarded
to the Shipping Co-ordination Officer, Ministry of Shipping & Transport(Chartering Wing), PARIVAHAN BHAWAN,1 Parliament
Street, New Delhi – 110007 after the shipment of each consignment is affected.

6
 ANNEXURE: IV
GARDEN REACH SHIPBUILDERS & ENGINEERS LTD
(A Govt. of India Undertaking)
43/46, Garden Reach Road, Calcutta- 700 024.
Fax : 033-469-8150/2020 ; Telephone : 469-8100 to 8113

STANDARD TERMS AND CONDITIONS OF SUPPLY

(INDIGENOUS EQUIPMENT / MACHINERY)

REF. NO. GRSE-STACS-PE-INDG (AUGUST, 2006)

INDEX

1. GENERAL

2. QUOTATIONS AND ORDER ACCEPTANCE TERMS

3. PACKING, SHIPPING, INSURANCE & FREIGHT DETAILS, AND DELIVERY

4. GUARANTEE / WARRANTY

5. QUALITY CERTIFICATION

6. TERMS OF PAYMENT

7. QUALITY ASSURANCE, INSPECTION, TESTING AND COMMISSIONING ASSISTANCE

8. MISCELLANEOUS

ANNEXURE:

A. STACS ACCEPTANCE FORMAT

B. EMD BANK GUARANTEE FORMAT & GUIDELINE

C. SECURITY DEPOSIT BANK GUARANTEE FORMAT & GUIDELINE

D. PERFORMANCE BANK GUARANTEE FORMAT & GUIDELINE

E. ECS FORMAT FOR BANK PARTICULARS & PAYMENT PROCEDURE

7
IN-1 GENERAL the supplied equipment. To enable this, the Purchaser’s address shall be
IN-101 The word ‘Purchaser’ refers to GARDEN REACH SHIPBUILDERS & added to the Sub-contractor’s / Supplier’s / Vendor’s mailing list or
ENGINEERS LIMITED, (GRSE), a Company registered under the database or any other document maintained for dissemination of product
Indian Companies Act 1913 and includes its successors or assigns. information and the Purchaser shall be informed of the action taken in
this regard. If such improvements / modifications are brought in by the
IN-102 The word ‘Sub-contractor / Supplier / Vendor ’ means the person / firm Sub-contractor’s / Supplier’s / Vendor’s Design Department in course of
/ Company who undertakes to manufacture and / or supply and / or manufacture of equipment ordered by the Purchaser, the Sub-contractor /
undertake work of any nature assigned by the Purchaser from time to Supplier / Vendor shall incorporate such improved versions in the
time and includes its successors or assigns. equipment without any extra cost to the Purchaser.

IN-103 The word ‘Owner’ means the person or authority with whom Garden IN-110 If the Purchaser be desirous of getting incorporated all post supply
Reach Shipbuilders & Engineers Limited (Purchaser) has contracted to modifications / improvements arising out of technological developments
carry out work in relation to which orders are placed by the Purchaser on to the original equipment supplied by the Sub-contractor / Supplier /
the Sub-contractor / Supplier / Vendor under this contract for supply or Vendor, the Sub-contractor / Supplier / Vendor, shall quote for and carry
manufacture of certain items and would include Department of Defence out all such modifications to the equipment.
Production & Supplies, Ministry of Defence, Government of India, the (a) Where the whole or a portion of the equipment has been
Indian Navy, the Coast Guard and any other specified authority. specifically developed by the Sub-contractor / Supplier / Vendor
for the Owner and the latter would, through the Purchaser, be
IN-104 The equipment / products / items to be supplied shall be strictly in bearing the entire or part of the development cost incurred by the
accordance with the Drawings / Specifications / Requirements indicated Sub-contractor / Supplier / Vendor, the design rights for the whole
in the Tender / Inquiry / Order with deviations, if any, as mutually or portion thereof, of the equipment as appropriate, shall vest in
accepted. the Owners.
(b) Prior approval of the Owner should be obtained
IN-105 The Sub-contractor / Supplier / Vendor shall not either wholly or partly before similar articles are sold / supplied to any other party other
sell, transfer, assign or otherwise dispose of the rights, liabilities and than the Owner. If such approval is given and sale is effected, the
obligations under the contract between him and the Purchaser without Sub-contractor / Supplier / Vendor shall pay to the Owner royalty
prior consent of the Purchaser in writing. at the rate mutually agreed to.

IN-106 The Sub-contractor / Supplier / Vendor shall hold harmless and keep the IN-111 Secrecy :
Purchaser indemnified against all claims arising as a result of All property (such as materials, drawings, documents etc) issued by the
infringement of any patent / copy rights on account of manufacture, sale Purchaser or any other individual or firm on behalf of the Purchaser in
or use of articles covered by the order. A clear & quite possession of connection with the contract shall remain confidential, being the
goods should take place with the passing of the title on execution of property of the Purchaser and the Sub-contractor / Supplier / Vendor
order. shall undertake to return all such property so issued and will be
responsible for any or all loss thereof and damage thereto resulting from
IN-107 Any letter, facsimile message, e-mail intimation or notice sent to the whatever causes and shall reimburse the Purchaser the full amount of
Sub-contractor / Supplier / Vendor at the last known address mentioned loss and damage.
in the offer / order shall be deemed to be valid communication for the All information given to the supplier for the execution of the
purpose of the contract. order is to be treated as SECRET / CONFIDENTIAL. The Technical
information, Drawings, Specification and other related Documents
IN-108 Governing Jurisdiction and Compliance with Laws forming part of this Enquiry /Order are the property of the Purchaser
(a) All contracts shall be deemed to have been wholly made in and shall not be used for any other purpose except for the execution of
Kolkata and all claims thereunder are payable in Kolkata City and order. Any information / drawing etc. shall not be copied, transcribed,
it is the distinct condition of the order that no suit or action for the traced or reproduced in any other form or otherwise in whole / part or
purpose of enforcing any claim in respect of the order shall be duplicated, modified, divulged and / or disclosed to a third party, not
instituted in any Court other than that situated in Kolkata City, misused, used in any other form whatsoever without Purchaser’s prior
West Bengal State, India. consent in writing except to the extent required for the execution of this
(b) The Sub-contractor/Supplier/vendor is warranted that all goods order. At the time of tendering, the tenderer has to give an undertaking
purchased against the enquiry shall conform with all applicable in favour of GRSE that in the event of any breach of the above
city, states & central laws, ordinances and regulations. Further, provisions, he would make good of any loss /cost/damage / any other
the supplier shall indemnify / defend / relieve GRSE harmless claim whatsoever preferred by anybody to GRSE in this respect.
from loss, cost of damage, by reason or any actual or alleged
violation thereof. IN-112 Preservation :
(c) GRSE shall not be liable under the workmen’s compensation Act A detailed procedure for long and short term preservation of the
of 1923, in case any employee or workmen of any contractor equipment and periodicity of preservation alongwith special
receives injury while actually serving his employer in connection preservatives, if required, prior to installation of the equipment shall be
with the latter’s work inside the compound of GRSE Ltd. furnished by the Sub-contractor / Supplier / Vendor. The detailed
(d) The existing Laws on employment of Child Labor shall be procedure for de-preservation prior to commissioning shall also be
binding for the contract. furnished.
(e) Sub-contractor/Supplier/vendor working at GRSE site , shall have Should any material require any additional preservation till
ESI and PF registration no. of their own and shall ensure its final installation / fitment on board the Ship, the materials should be
compliance with all provisions of ESI & PF act & rules, failing supplied in preserved (sealed or in cocoons) condition for long duration
which withholding / deductions from Sub- of time as per order. Detailed procedures for subsequent de-preservation
contractor/Supplier/vendor’s bills /dues as applicable or / re-preservation are to be stated by Sub-contractor / Supplier / Vendor.
termination of the contract will be effected. Sub- The preserved sealed cases / cocoons will not be opened on
contractor/Supplier/vendor working at GRSE site , are required to receipt and same will be opened when the first preservation is due or if
submit evidence showing compliance with ESI & PF formalities required on board earlier. The short fall, discrepancy or damage , if any,
in respect of employees engaged in job of GRSE viz. monthly found during the inspection after opening these cases will have to be
challan of ESI deposit, certified copy of half yearly returns replaced / made good by the supplier free of cost within reasonable
submitted to ESIC, proof of P.F. deposition etc. period.
(f) Sub-contractor/Supplier/vendor working at GRSE site are
required to comply with all statutory obligations as per Contract IN-113 The Sub-contractor / Supplier / Vendor shall render free of cost guidance
Labour (R & A) Act 1970 and Contract Labour (R & A) Central in case the Purchaser intends to set-up testing, repair / maintenance
Rules 1971 including obtainance /renewal of Labour Licence from facility to overhaul the equipment supplied by the Sub-contractor /
Regional Labour Commissioner (Central) failing which Supplier / Vendor.
deductions as applicable from bills / dues of contractor or
termination of the contract may be effected. IN-114 The Sub-contractor / Supplier / Vendor shall continue to support the
(g) All Sub-contractors/Suppliers/vendors engaged in shipbuilding equipment for a minimum period of 20 years from the date of supply by
work are required to obtain registration under the Building and making available spare parts and assemblies of the equipment supplied.
Other Construction works (RE & CS) Act 1996 & Rules and are Should the Sub-contractor / Supplier / Vendor decides to discontinue the
also required to maintain registers & records and submit returns. product, for any reason whatsoever, adequate notice shall be given to the
Purchaser / Owner to enable procurement of the requisite lifetime spares.
IN-109 The Sub-contractor / Supplier / Vendor shall unconditionally and free of
cost to the Purchaser transfer information on technological IN-115 Purchase preference in respect of equipment / product and or services of
developments / innovations / modifications which the Sub-contractor / Central Public Enterprises will be applicable for such / similar
Supplier / Vendor would evolve in future (within 3 years) in relation to

8
 equipment / product / services on tender as per extant policy (ix) Standard format for data to be provided by OEM as per ILMS
promulgated by Department of Public Enterprises, Government of India. requirement (Integrated Logistic Management System):- As
required by Indian Navy for operation of ILMS successfully at
IN-116 The Purchaser reserves the right to accept and or reject any or all tenders their end, detail information regarding ILMS compatibility as
and / or to withdraw the tender in toto without assigning any reason per format provided in SOR is to be filled in by OEMs and
whatsoever. submitted to GRSE as part of their contractual obligations and
to be included as deliverables.
IN-117 Registration as Approved Vendor :
(a) The Sub-contractor/Supplier/vendor is to confirm whether they (b) PART-II – ‘Price Bid’ - Quotes to be written in figures and
are registered with GRSE as approved Sub-contractor / Supplier / words duly authenticated / signed by the authorised person and
Vendor under 5-disit Supplier Code and indicate Product Group marked thus.
Code. If not registered, the Sub-contractor / Supplier / Vendor will
have to approach GRSE’s V R Cell for completion of all IN-203
formalities for permanent registration with GRSE immediately (a) Both these sealed envelopes-Part I and Part II, shall be put in a
after submission of any quotation/offer. Failure to comply to this third envelope duly superscribing the Tender number and Due
requirement will result in rejection of offer and restriction of Date and sealed properly and deposited as specified in the enquiry
further business. in the securely locked Tender Box kept in the concerned deptt.
(b) The bidder is to confirm whether they are registered with DGQA (b) Outstation Bidder / Tenderer shall forward their offers addressed
as approved vendor for supply of the category of item as tendered. to concerned Authority either by courier service or by speed post
If not registered, the bidder is to approach DGQA immediately for so as to reach well in advance of the due date of tender or by hand
registration after complying with all formalities like capacity delivery before due date and time of tender closing. Purchaser
assessment for supply of the required category of equipment / shall not be responsible for any postal / courier delay and it is
item within a time frame of 6 weeks from placement of attributable solely to the tenderer.
conditional order, if issued. (c) Offer in “Two Bid System” received by fax / e-mail and / or
offers received beyond due date and time of tender is liable to be
IN-118 MOU : Regular suppliers are requested to enter into Memorandum of rejected.
Understanding with GRSE as regards Commercial Terms & Conditions
contained in this STACS. IN-204
(a) The price per ‘Ship set’ shall be quoted and breakup price of
IN-119 Examination of price: Where the contract price has not been fixed in individual items of equipment and its accessories must be clearly
effective competition and the contract is not for articles whose prices are stated.
controlled, the owner reserves the right to investigate reasonableness of (b) The cost incidence against each head shall be clearly indicated
the price paid and negotiate directly with the sub- for –
contractor/supplier/vendor for reduction of price where appropriate. The - Door delivery
Owner can also ask for declaration that less basic price is not charged to - F. O. R.
other customers including Govt. and PSU. - Ex-Works - with charges for packing
and forwarding
IN-120 Individuality of contract: In the event of the offer getting converted into
an order, the said order shall be treated as an individual contract, shall (c) The offer shall indicate the discounted price, if more than one
not allow any general lien to the parties and shall not get prejudiced in shipset is ordered.
execution due to situation arising out of some other contract that the (d) The offer shall clearly indicate the Foreign Exchange content, if
supplier may have with GRSE. any, and base Exchange Rate and cut off date for Import. If any
item/s is / are required to be imported by the Sub-contractor /
IN-2. Quotations and Order Acceptance Terms: Supplier / Vendor for use in the manufacture of final product,
IN-201 Tenderer shall pay special attention to the following points. Failure to Import Licence for such product/s is to be arranged by him only.
comply with these may disqualify the tenderer. (e) The vendor/supplier/sub-contractor shall indicate the bill of
(a) Tender number and due date to be superscribed on all the materials for intended import for incorporation in order. The
envelopes. purchaser shall issue Customs Duty Exemption Certificate on
(b) Tender to be submitted on or before the due date and time. receipt of request from the vendor/supplier/sub-contractor along
(c) Offer to be as per specifications and complying with tender with the copies of bill of lading and invoice. The price advantage
conditions. for Customs Duty Exemption will be passed on to the purchaser.
(d) The envelopes to be sealed properly. (f) The purchaser reserves the right to investigate the
reasonableness of the price and ask the vendor/supplier/sub-
IN-202 Unless otherwise stated, the offers shall be in ‘Two Bid System’ only, in contractor for detail break up of their cost.
two separately sealed envelopes: -
(a) PART-I - ‘Techno-Commercial Bid’ and marked thus. In IN-205
addition, Part-I shall include- (a) The offer shall be valid for 90 days for acceptance and the prices
(i) Proforma Price Schedule blanking the prices and indicating shall remain firm and fixed until delivery of the full quantity of
‘Quoted / Not Quoted’ (as applicable against each item on the goods in the Purchaser’s Yard. If not, the Sub-contractor /
tender). Supplier / Vendor shall indicate the period during which the
(ii) Duties / Taxes, Octroi, freight charges, insurance and/or any quoted price shall remain valid for supply of the equipment /
other Statutory levies payable, specifying incidence clearly / article contracted for.
separately against each head. Should the Purchaser desire postponement of delivery of
(iii) The cost incidence against each head clearly indicating for Door the equipment / article within or beyond validity date of the
Delivery or F. O. R. or Ex-works alongwith charges for offer, the Sub-contractor / Supplier / Vendor shall indicate –
packing and forwarding. (i) The date by which such communication must be
(iv) Compliance Statement clearly highlighting deviations / received by him for deferring delivery without any
exceptions, if any, to Technical Specifications, Standard Terms financial implication to the Purchaser,
and Conditions of Supply and Specific Tender Conditions. and
Non-specifying of deviations against any or all clauses would (ii) Terms and conditions for effecting
be construed as compliance to any / all conditions of tender. postponement of delivery beyond the price
Any deviations to STACS, having financial implications, validity period.
would be considered suitably for loading the quoted price.
(STACS Acceptance Format is placed at Annexure 5). (b) Purchaser reserves the right to consider placement of Purchase
(v) Earnest Money Deposit (interest free) as stipulated in the tender Order in part or in full against the tendered quantity.
by way of D.D. / Pay Order / B.G. (as per GRSE format &
guide line at Annx.-1) issued by any scheduled Bank other IN-206 The Sub-contractor / Supplier / Vendor shall inform the Purchaser in
than Co – operative Bank to be provided by the bidder / advance in case he is unable to participate in the tender for whatsoever
tenderer in favour of GRSE as per discretion of the Purchaser. reason. Failure to comply with this will be viewed seriously and
(vi) Copy of ISO 9000 or equivalent Quality System Standards consecutive three failures on the part of Sub-contractor / Supplier /
certificate valid as of date. Vendor to do so is liable for disqualification / debarring of the Sub-
(vii) Delivery Schedule. contractor / Supplier / Vendor from all future tender enquiries and or
(viii) IIG Form regarding Codification of Defence Equipment delisting from the list of ‘Approved Registered Vendors.’
enclosed with SOR is to be filled -in and submitted. The
same is included as deliverables by the supplier. IN-207 Spares:

9
 (a) Offers for Testing and tuning / commissioning spares shall be default by the Sub-contractor / Supplier / Vendor, the Security Deposit
supplied along with the main equipment, as specified in the will be forfeited.
requisition.
(b) The Sub-contractor / Supplier / Vendors offer shall include a list IN-212 Unless otherwise specified in the ‘Statement of Requirement’ /
of manufacturer’s recommended spares together with itemised ‘Technical specifications for Procurement’, the supply shall include one
prices for set of reproducible Velographs stamped ‘Approved’ by the Inspecting
 One year uninterrupted operation – validity of Authority, micro-films, floppies / CDs and six sets of paper prints. It
offer shall be a minimum for 90 days. shall also include 15 sets each of the Operation / Maintenance Manuals,
 Five year operation – validity of offer shall be a Part Identification List, Comprehensive Part List, Test Certificates /
minimum for 180 days. (Minimum order quantity Shop Trial reports etc. of the article/s supplied.
against each item, if applicable, may also be
stated.) IN-3.0 Packing, Shipping, Insurance & Freight details and Delivery:
(c) While the spares for one year are ordered by the Purchaser, the
spares for 5 years Operation will be ordered by the Owners or IN-301 Identification of Deliverables And Penalty For Non-
Purchaser. In case of 5 years operation spares, the Sub-contractor / Compliance:
Supplier / Vendor shall indicate a base price applicable to the year
of quotation and indicate an acceptable annual escalation formula (a) The Supplier on receipt of Purchase Order and by a date not
based on which prices for future requirements could be later than 8 weeks from receipt of P.O., shall list out and confirm
established during the life cycle of the equipment in service. all deliverables including Main Equipment, Accessories, On
(d) In the event of inability to make an offer for these spares at the Board Spares, Tools, Technical Documentations and other items.
time of quoting for main equipment, the Sub-contractor / Supplier Each item shall have the firm’s part no. and break up price. The
/ Vendor shall commit a date by which such an offer can be made same is required essentially for incorporating GRSE material code
and adhere to it. Non-receipt of offer as committed will render the nos. into the Purchase Orders and computer systems. In the event
order for main equipment liable for cancellation without notice of delay in submission of the required details penalty @ ½% per
from the purchaser and without any financial implication to the week or part thereof upto the maximum of 5% of total value of all
Purchaser. deliverables, shall be levied on the Supplier.
GRSE shall issue amendment to Purchase Orders
IN-208 Tenders will be opened on the specified date and time in the concerned incorporating the details receipt from the Supplier with GRSE
department. Only authorised representatives of tenderers are permitted to Code numbers , individual prices etc. in advance of contractual
witness the Part I tender opening for Press tenders only. Tender opening delivery. While despatching the Supplier shall identify each item
shall neither be delayed nor withheld / postponed on account of absence with GRSE code no. and the firm’s part number. Packing list
of any one or more Tenderers. All the envelopes marked as ‘PRICE should indicate all deliverable items specially mentioning/
BID’ received at the time of Tender opening will be noted and held mounted on main equipment or loose items. Each item should be
unopened separately. identified with metallic or plastic tag indicating both GRSE code
no. and firm’s part no. In case of any deviation, GRSE shall not be
IN-209 Authorised representatives of only technically qualified tenderers, in in any way responsible for delay in issue of receipt inspection
case of Press Tenders only, who have submitted EMD as applicable, and report and payment.
complied with tender terms, will only be permitted to be present and All OBS are to be PIP packed. OBS and tools are to be
note the proceedings of the Price Bid - Part II opening in a manner as supplied in separate boxes with clear identification and part
directed by the tender opening officers. Qualifying tenderers not present numbers in metallic or plastic tag. Supplier’s rep. is required
during price bid opening will not be furnished with information on during receipt inspection of loose items, accessories, spares and
prices at a later date. EMD of unsuccessful tenderers will be refunded / tools for easy identification and detection of shortfall.
returned within 30 days of finalisation of order on surrendering the (b) All material shall be strongly and securely packed for shipment /
Original copy of Money Receipt and upon instruction of Purchaser. transportation as applicable in minimum cubic space in such a
EMD, if not claimed within one year from the date of notification to the manner as to prevent damage and pilferage in transit from point of
tenderer for refund, will be forfeited. shipment to final destination. Metal parts wherever necessary
shall be well slushed with preservatives to prevent rusting in
IN-210 With the acceptance of the successful bidder’s offer by the Purchaser, transit. Should it be proved that loss and damage has arisen from
which is as per the Terms and Conditions of the tender, by means of inadequate packing, the losses shall be borne by Sub-contractor /
LOA / Purchase Order, the Contract is concluded. Supplier / Vendor. Each packing shall be plainly marked and
The Sub-contractor / Supplier / Vendor shall, on receipt of the numbered upon four sides and the top thereof as directed in the
order, communicate his unconditional acceptance within two weeks of Purchase Order. Letters and numbers shall be atleast 80 mms.
from the date of mailing / receipt of the same in its entirety by returning high wherever possible. Packing should indicate Case No., Order
a copy of the Purchase Order duly signed by the authorised person and No., Gross Weight in Kgs., Nett Weight in Kgs. and outside
without any qualification. Communicating acceptance of the order dimensions LxWxH (The information on outside dimensions and
subject to any other terms and conditions of the contract on the part of weight shall be furnished to Purchaser atleast one (1) month prior
the Sub-contractor / Supplier / Vendor shall not bind the Purchaser in to shipment / despatch). No marking other than as directed shall
respect of these conditions which are less favourable to the Purchaser as be inscribed on the said packages.
compared with the conditions mutually agreed to and / or stipulated in (c) Every package shall contain a packing list in triplicate and the
the order. It shall be the responsibility of the Sub-contractor / Supplier / order number, package number, number of cases in the
Vendor to enumerate specifically any error or discrepancy in the order at consignment, description and quantity of each item packed shall
the time of acceptance. Failure to do so shall make the order binding on be clearly shown in the packing list. The description and quantity
the Sub-contractor / Supplier / Vendor in all respects. of each item shall tally with that specified in the order, wherever
Any delay in acknowledging the receipt of the Purchase Order applicable.
within the specified time limit or any qualification or modification of the
Purchase Order in the acknowledgement of the Purchase Order by the IN-302 Insurance:
Sub-contractor / Supplier / Vendor shall be a breach of the contract on IN-302.1 In cases where the Sub-contractor’s / Supplier’s / Vendor’s offers are for
the part of Sub-contractor / Supplier / Vendor. Compensation for the loss ‘Free Delivery to Purchaser’s Yard,’ transit Insurance charges shall be
caused by the breach will be recovered by the Purchaser by forfeiting the borne by the Sub-contractor / Supplier / Vendor.
Earnest Money, given by the Sub-contractor / Supplier / Vendor. If the
Sub-contractor’s / Supplier’s / Vender’s bid contains any condition and IN-302.2 In case of Ex-works / Ex-Transporter’s warehouse or Railway godown
any correspondence which are contrary to the Notice Inviting Tender offers, the Sub-contractor / Supplier / Vendor shall give details of
(NIT) then they shall be considered as superseded and void on the materials with despatch particulars and their value to Purchaser
acceptance of the bid by the Purchaser. immediately after the despatch. The Insurance Charges will be borne by
Recovery of compensation by the Purchaser from the Sub- Purchaser.
contractor / Supplier / Vendor by forfeiting the Earnest Money shall be
regarded as cancellation of the contract which has come in to existence IN-303 Storage and Demurrage will be claimed from the Sub-contractor /
on the acceptance of the offer by the Purchaser. Supplier / Vendor for all shipments that reach the purchaser without
proper despatch documentations, Lorry Receipts not accompanied by
IN-211 Security Deposit (Interest free) : packing lists, invoices etc. The Sub-contractor/ Supplier/ Vendor shall
The successful Tenderer shall submit a Security Deposit as specified in be responsible for fines due to errors or omissions in description, weight
the tender in the form of Demand Draft / Pay Order / Bank Guarantee or measurements and for increased handling charges due to improper
(as per GRSE format & guide lines at Annex-2) issued by any scheduled packing. Demurage, if any, due to wrong/non-availability of shipping
Bank other than Co-operative Banks in favour of Purchaser. The documents will borne by supplier/vendor.
Security Deposit will be returned only after the successful execution of
the order. In the event of failure to execute the order satisfactorily or

10
IN-304 Where so stipulated in the order, the Sub-contractor / Supplier / Vendor the responsibility of guarantee for the equipment / material. It will be the
shall render such reports from time to time as regards the progress of the sole responsibility of the Sub-contractor / Supplier / Vendor to ensure
contract and in such a form as may be called for by the Purchaser. The that the equipment / material supplied is complete in all respects and
Purchaser reserves the right to cancel the order forthwith without any performs to its / their designed parameters.
financial implications on either side, if on completion of 50% of the
scheduled delivery period the progress of manufacture is not to the IN-404 In the event of Sub-contractor’s / Supplier’s / Vendor’s failure to attend
satisfaction of Purchaser / Owner and failure on the part of the Sub- the Guarantee defects within a reasonable period of time, the
contractor / Supplier / Vendor to comply with the delivery schedule is Performance Bank Guarantee will be encashed by the Purchaser. The
inevitable. In such an event the Sub-contractor / Supplier / Vendor shall Purchaser’s decision shall be final and binding on Sub-contractor /
repay all the advances together with interest at prevailing bank rates Supplier / Vendor in this regard.
from the date of receipt of such advances till date of repayment. The title
of any property delivered to Purchaser will be reverted to the Sub- IN-405 Issues/Defects related to Guarantee/Warranty shall have to be liquidated
contractor / Supplier / Vendor at his cost. at the location of vessel and as desired by the Purchaser / Owner.

IN-305 The Sub-contractor / Supplier / Vendor shall arrange despatch of goods IN-5.0 Quality Certification:
by Rail / Road consigned to GRSE through GRSE nominated
transporter.. An Advance Copy of the invoice along with copies of other IN-501 Purchase preference will be considered in case the Sub-contractor /
relevant documents shall be forwarded to Purchaser sufficiently in Supplier / Vendor is accredited with ISO 9000: 2000 or equivalent
advance to avoid demurrage. In case of door delivery contracts, the International Quality System Standards in respect of equipment /
Transporter shall be directed to deliver the ordered equipment without Products and or items on tender.
insisting for consignee copy of Lorry Receipt.
However, for manufacture of Naval Ships under Cost plus IN-502 The Sub-contractor / Supplier / Vendor shall submit as proof, in Part-I of
Contracts, GRSE is acting in the capacity of an Agent since Purchase the bid documents, a copy of ISO 9000: 2000 or equivalent International
Orders are issued by GRSE on behalf of Indian Navy under MOD, Govt. Quality System Standards certificate valid as of date.
of India. Accordingly, in case of orders for supply to Naval Ships under
cost plus contract, despatch document (challan / Consignment Note etc) IN-503 The Sub-contractor / Supplier / Vendor shall preferably engage sub-
and Invoice should be marked with the words “GRSE A/C INDIAN contractors and avail supplies from suppliers with prior approval of
NAVY”. Purchaser and such sub-contractors and suppliers shall also be accredited
with ISO 9000: 2000 or equivalent International Quality System
IN-306 Standards.
(a) The binding drawings called for as per the ‘S. O. R.’ / ‘T. S. P.’
or the Purchase Order shall be supplied within stipulated time IN-504 In the event the Sub-contractor / Supplier / Vendor is not being ISO
frame as indicated in the Purchase Order, free of cost. Failure to 9000: 2000 accredited firm, the fact shall clearly be stated and the
comply may lead to cancellation of Purchase Order without any Quality Assurance / Quality Control organisation of the company be
financial implications to the Purchaser. described in detail. Pursuant to scrutiny of such statement /
(b) The drawings shall be submitted to Inspecting Authority and or documentation, the Purchaser may decide to accept the offer with pre-
DGQA / NSM / GRSE / Classification Society, as appropriate, as conditions specified for acceptance or reject the bid submitted.
specified in the Order. The onus of getting the drawings approved
within the stipulated time frame shall lie with the IN-6.0 Terms of Payment:
supplier/vendor/sub-contractor.
(c) Wherever applicable, pilot sample shall be submitted to the IN-601
authorities within the stipulated time as specified in the Order. (a) Unless or otherwise mutually agreed upon and stipulated in the
(d) In case of patternised items the vendor/supplier/sub-contractor Purchase Order, the terms of payment shall be 90% of Order value
must confirm that the relevant drawings are held by them and no within 45 days from the date of receipt inspection and acceptance
waiver of contractual terms of order shall be considered for non- of material and presentation of bill supported with complete set of
performance on this account. documents as under: -
(e) For repeat orders, unless otherwise some changes in design had
taken place, fresh approval of drawings will not be required if the (i) Seven copies of signed invoice indicating Vendor Code Number
same has already been approved. Supplier/vendor/sub-contractor and itemwise price (indicating GRSE material code no. if in
shall go ahead with manufacture of the items which are already the order) alongwith packing lists. In case of orders for
developed for same / deferment ships for Navy based on earlier supplies to Naval Ships, invoice should be marked with the
approved drawings. Immediately on receipt of order, words “GRSE A/C INDIAN NAVY” for cost plus contract,
Supplier/vendor/sub-contractor shall submit 6 copies of drawings as detailed in para IN- 305. However in case of fixed cost
for stamping and distribution. contract , Invoice will be in the name of GRSE.
(ii)Warranty Certificate in triplicate.
IN-4.0 Guarantee / Warranty (iii) 3 copies of Manufacturer’s Works Test Certificate.
(iv) 3 copies of Certificate of Inspection and approval from LRS /
IN-401 The equipment/materials are to be guaranteed/warranted for satisfactory IRS / ABS / DQA (WP) / DQAN / CQAE / WOT / GRSE
performance for the period of 12 months from the date of satisfactory (whichever is applicable).
commissioning of the vessel on which the equipment/materials/items are (v) 3 copies of GRSE’s unqualifying Inspection Cum Goods
installed OR for the period of 36 months from the date of final dispatch, Receipt Note (ICGRN)
whichever expires earlier, against improper design, defective materials (vi) Complete set of Classification / On board spares as per the
and faulty workmanship. During guarantee/warrantee period any Purchase Order.
equipment or component thereof supplied by the vendor/sub-contractor, (vii) Complete set of operation / Maintenance / Instruction
suffers due to defective material and or due to improper design and or Manuals as per the Purchase Order and also in Electronic
due to defective drawing or due to faulty workmanship the vendor/sub Medium.
contractor will assume full responsibility of rectification of such (viii) Complete set of Parts Identification List / Comprehensive
defective equipment or component thereof including direct expenses Parts List as per the Purchase Order and also in Electronic
related to removal and re-positioning of the replacement/repaired Medium.
equipment or component thereof and subsequent test & trial, incurred (ix) Complete set of “As fitted” drawing and reproducible
thereon without any financial implication to GRSE. drawings.
(x) Quotations for B & D spares for (a) 2 years operation and (b) 5
In the event Purchaser/Owner desires to have extension of years operation.
Guarantee/Warranty period beyond the stipulated period, as above, the (xi) IIG Forms duly filled in.
vendor/sub-Contractor/supplier shall quote for the same on monthly (xii) Standard Format for data provided by OEM as per ILMS
basis for the period of such extension. requirement (Integrated Logistic Management System).
All the documents shall clearly indicate the GRSE’s Purchase
IN-402 If the defects intimated during the Guarantee period are not remedied Order No. and date.
within a reasonable / stipulated time, the Purchaser may proceed to
rectify the defects at the Sub-contractor / Supplier / Vendor’s risk and (b) Balance 10% will be released after G.P. or against
cost, but without prejudice to any other rights which the Purchaser may submission of PBG for equivalent amount (as per GRSE format &
have against the Sub-contractor / Supplier / Vendor in respect of the guidelines at Annex-3) valid till G.P.
failure of the Sub-contractor / Supplier / Vendor to remedy such defects. Issue of GRN : For materials received at GRSE without
rd
Inspection report of 3 party, GRN will be issued to Local
IN-403 Inspection and approval of the equipment or material by the Inspecting supplier for their submission of bill with GRN. But for materials
Authority/ies does not absolve the Sub-contractor / Supplier / Vendor of received at GRSE with 3rd party Inspection report

11
 received from outstation suppliers, balance payment bill is to In case of orders for supplies to Naval vessels, Excise Duty
be submitted by suppliers with copy of clear & accepted ICGRN exemption certificate issued by Indian Navy will be provided on
for further linking by Corporate Finance with GRN for readiness of items for despatch & GRSE is to be intimated by supplier /
processing balance payment. vendor / sub-contractor regarding readiness of items at least a month
before despatch. Such exemption certificates shall be issued to Sub-
(c) Payment may be made to the vendors through Electronic contractors / Sub-vendors of Sub-contractor / Supplier / Vendor on
Clearing System (ECS). Vendors are to furnish requisite whom Purchaser had placed a Purchase Order.
documents / information on receipt of the order. (ECS Format
for Bank Particulars and Payment Procedure enclosed at Annex.- IN-604.1 For supplies from States outside the state of West Bengal, Declaration
6) Form “C” or “D” as applicable will be issued to the supplier for
concessional rate of Sales Tax . In case of sale within the state of West
(d) In special cases and /or for development equipment where Bengal, W.B.S.T. Form will be issued for concessional rate of Sales
advance / stage payment is specified in order, all such payments Tax.
shall be made against Bank Guarantee of equivalent amount in
GRSE format valid till receipt and acceptance of material. No IN-604.2 Declaration Form can be issued to suppliers in case of transit sale, i.e.
advance payment shall, however, be claimed without submission transfer of documents during the period of transit of the materials to
of binding drawing to Approving Authority. The advance obtain Sales Tax benefit.
payment may be released in stages depending upon the progress Invoice shall clearly indicate cost incidentals against each head,
of work and mobilization of required equipments etc. as applicable:
Basic Cost, Excise Duty, Packing & forwarding charges, Central / State
(e) All advance payments should be interest bearing. Penal Sales Tax, Service Tax, Freight, Insurance, etc.
interest is to be charged on the advance in case of delay in
delivery of supplies beyond the agreed schedule. Amount of IN-605 Payment made under one order shall not be assigned or adjusted to any
Advance & Rate of interest will be decided by the Management / other order except to the extent agreed upon in writing by the Purchaser.
TC as appropriate. During the currency of the contract, if any sum of money is payable by
the Sub-contractor / Supplier / Vendor the same shall be deducted from
(f) Where order is cancelled and advance payments already any sum then due or thereafter may become due to the Sub-contractor /
released to the contractor, the contractor shall refund all such Supplier / Vendor under the contract or any other contract with the
advance payments received to GRSE with prevailing Bank Purchaser.
interests and GRSE shall also have the right to recover the amount
from outstanding dues to the Contractor against any other IN-606 Works Contract Tax, wherever applicable, will have to be borne by Sub-
Purchase Orders placed by GRSE. contractor / Supplier / Vendor. In addition, Employees State Insurance
premium, Provident Fund, Service Tax and other statutory dues of
(g) Works Contract : In case of works contract following workers deployed at Purchaser’s premises by Sub-contractor / Supplier /
payment terms shall be followed:- Vendor will have to be borne by him. In case of Works Contract Form
58 or 59 as applicable is to be submitted by the vendor/supplier/sub-
(i) Material Portion : contractor.
75% payment against despatch document, 15%
payment against receipt & acceptance of material and IN-607 Liquidated Damages / Risk Purchase:
balance 10 % will be released after G.P. or against
PBG for equivalent amount valid till G.P. IN-607.1 In the event that-
(ii) Labour Portion :
90% payment on job completion and certification. (a) Sub-contractor / Supplier / Vendor (SELLER) fails to deliver the
Balance 10% will be released after G.P. or against equipment / product or documentation meeting the requirement of
PBG for equivalent amount valid till G.P. the Purchase Order on or before the dates specified, or
OR
Where unit rate is mentioned , 90% payment (b) the equipment / product when tested in accordance with the
progressively on job completion and Certification. performance requirement of the Purchase Order, fails to meet
Balance 10% will be released after G.P. or against those performance parameters, the buyer (Purchaser) will suffer
PBG for equivalent amount valid till G.P. damages in an amount that is not susceptible to calculation with
reasonable certainty. Therefore, any Liquidated Damages set forth
(h) If GRSE material code no. & itemised price is not in the Purchase Order represent a reasonable determination of the
incorporated in the order, supplier will submit detailed list of amount of damages that the Purchaser will suffer, and are not in
items (separately deliverables) and price break-up latest within 6 the way of penalties. Seller hereby waives any defence to
weeks of receipt of order to enable GRSE amend the order Purchaser’s recovery of such Liquidated Damages on the plea that
indicating material code no. of each item with its price. All actual damages are ascertainable or that such Liquidated Damages
Invoices, Packing list etc should invariably indicate GRSE do not represent a reasonable determination of damages suffered
material code no. against each item for recording receipt and issue by Purchaser or are penalties.
of ICGRN as well as for processing payment.
IN-607.2 Sub-contractor / Supplier / Vendor (Seller) will be liable to pay
IN-602.1 Octroi Duty at present is not applicable in West Bengal. However, Liquidated Damages for late delivery of Products, Manuals, Drawings
Octroi Duty if applicable, at a later date, will be re-imbursed by and Documentation as stated in the Purchase Order. Unless otherwise
Purchaser at actuals against submission of ‘Original Octroi paid money expressly specified, the rate of Liquidated Damages for late delivery
receipt’ and copy of Form ‘B’. Octroi receipts are to be issued in the shall be at the rate of 0.5% of the total order value per week or part
name of ‘GARDEN REACH SHIP BUILDERS & ENGINEERS LTD.’ thereof of delay upto a maximum of 5% of the total order value. Such
only. Liquidated Damages shall be deducted by the Purchaser from any
monies due to Sub-contractor / Supplier / Vendor (Seller). Payments
IN-602.2 Way Bill – In West Bengal, Way Bill is to be issued for entry of made by the Sub-contractor / Supplier / Vendor (Seller) of Liquidated
materials from outside the state. GRSE will issue the Way Bill on Damages shall be in addition to any other remedies (other than any other
submission of copy of Invoice and Consignment Note. Consignment remedy for the recovery of damages) available to the Purchaser,
Note should be in the name of GRSE. including without limitation the remedy of cancellation of Order for
In case of Transit Sale, the name of the Consignors (other than default.
seller) are to be mentioned in the P.O. and Consignment Note will be in
the name of GRSE as consignee. IN-607.3 Sub-contractor / Supplier / Vendor (Seller) will be liable to pay
Liquidated Damages for late submission of Drawings for approval as
IN-603 The Sales Tax Registration Number and Central Sales Tax Number, agreed to by Purchaser and Sub-contractor / Supplier / Vendor (Seller)
Service Tax Number, as applicable, are to be quoted on all invoices. and as stated in the Purchase Order. The amount of such damages will
Invoices shall be accompanied by a certificate to the effect that the Sub- be clearly defined in the Purchase Order and may extend upto 5% of the
contractor’s / Supplier’s / Vendor’s registration certificate was in force Order value.
on the day the sale was effected.
IN-607.3.1 Drawings submitted by the Sub-contractor / Supplier / Vendor (Seller)
IN-604 Unless otherwise stated Excise Duty, Sales Tax and any other statutory will be the property of Indian Navy.
levies will be payable extra at actuals. However, the Sub-contractor /
Supplier / Vendor shall submit the proof of having paid the duties / IN-607.4 If the equipment / article or any portion thereof be not delivered by the
levies along with the Invoices / Bills. scheduled delivery date, the Purchaser shall be at liberty, without
prejudice to the right of the Purchaser to recover Liquidated Damages /

12
 penalty as provided for in these conditions or to any other remedy for board spares (OBS) will be carried out by Quality Assurance (QA) dept.
breach of contract, to terminate the contract either wholly or to the of GRSE and thereafter, the same will be mustered & handed over to
extent of such default. Amounts advanced or part thereof corresponding ship as & when required. Joint inspection along with supplier/vendor’s
to the undelivered supply shall be recoverable from the Sub-contractor / representative shall be carried out for major items.
Supplier / Vendor at the prevailing bank rate of interest . For materials supplied with long term preservation in sealed
cases / cocoons, receipt inspection will be followed as per
IN-607.5 The Purchaser shall be at liberty to purchase, manufacture or supply PRESERVATION at Cl. IN-112 above.
from stock as it deems fit, other articles of the same or similar
description to make good such default and or in the event of the contract IN-707 The price should be inclusive of inspection/approval/certification cost to
being terminated, the balance of the articles of the remaining to be meet the relevant requirement of the technical specification. This should
delivered thereunder. Any excess over the purchase price, cost of also include the cost of furnishing shock calculations and type test
manufacture or value of any articles supplied from the stock, as the case results wherever applicable.
may be, over the contract price shall be recoverable from the Sub-
contractor / Supplier / Vendor. IN-708 The supplier/vendor/sub-contractor shall furnish all relevant Inspection
Certificates and Test & Guarantee Certificates along with each
IN-607.6 In case of unsatisfactory progress of supply at any point of time after consignment and copies of same in triplicate shall also be mailed /
placement of order GRSE reserve the right to cancel the order without forwarded to GRSE immediately on despatch of articles. The
assigning any reason and to procure the ordered material from any supplier/vendor/sub-contractor shall also provide 3 copies of weighed
alternative source at your complete risk and cost. Weight Certificate for items supplied.
GRSE also reserves the right to cancel the order forthwith without any
financial implications on either side if upon lapse of 50% of the IN-709 The decision of the inspecting authority or his agent, as the case may be,
scheduled delivery time the progress of manufacture is not up to the on any question of the intent, meaning and the scope of specifications /
satisfaction of GRSE/Owner and the failure on the part of the sub- standards shall be final, conclusive and binding on the Sub-contractor /
contractor/ supplier/vendor to conform to the delivery schedule is Supplier / Vendor.
inevitable.
IN-710 REPLACEMENT FOR REJECTION :
IN-608 Submission of Bills to SLP Section (Corporate Finance/GRSE)
The bills presently submitted to SLP Section by vendors for purchase (a) Should the articles, or any portion thereof be rejected, the
orders placed by NCM / Purchase Department in respect of “SHIP contractor shall collect the same from the purchaser’s yard within
DIVISION ONLY” will now be deposited in the Box kept at the 15 days from the date of intimation of such rejection to the
entrance of the Corporate Finance Department (in front of Pantry). All supplier/vendor/sub-contractor and replace/rectify the same on top
suppliers are requested to drop their bills in sealed cover in the Box priority basis. Before collection of rejected items the
earmarked for, effective from 01st April,2002. supplier/vendor/sub-contractor shall furnish Bank Guarantee/Bank
Computer generated acknowledgement for the bills dropped Draft of equivalent amount or accept GRSE holding back
during the previous day may be collected in the next working day from payment of their qualifying bills of equivalent amount till
the Central Despatch Section, except Saturday. deficiencies are made good. The purchaser reserve the right to
Corporate Finance (SLP Section) will forward the computer dispose off the rejected items at the end of a total period of 90
generated receipts to Central Despatch Department by 11-00 hrs. days in a manner to the best advantage to the purchaser and
everyday. recover storage charges and any consequential damages, from sale
The supplier should ensure that all the bills are kept in a separate proceeds of such disposal. Rejection of materials and also the late
envelope orderwise and also mention their vendor code number for easy delivery will affect further business with GRSE.
identification and registration. All enclosures are also be firmly fixed
with the bills and no responsibility will be taken by the SLP Section for (b) The guarantee period of replaced parts /items shall however be
alleged missing of documents. Bank Guarantee must be submitted reckoned from the date of replacement.
separately in sealed closed cover of the Bank to the SLP Section AND
NOT TO BE ENCLOSED WITH BILL. (c) If the defects are not remedied within a reasonable/stipulated
For payment through ECS, bills will be deposited in the Box time, the purchaser may proceed to rectify the defects at the
kept at the entrance of Corporate Finance Dept. as elaborated above. supplier/vendor/sub-contractor’s risk & cost but without prejudice
ECS Format of Bank particulars and Payment Procedure are enclosed at to any other rights which the purchaser may have against the
Annexure – 6 reference Clause IN 601(c) above. supplier/vendor/sub-contractor in respect of their failure to
remedy such defects.
IN-7.0 Quality Assurance, Inspection ,Testing and Commissioning
Assistance: IN-711 The services of the Sub-contractor’s / Supplier’s / Vendor’s Engineers
IN-701 The equipment will be inspected by one or more agencies indicated shall be provided free of cost till Guarantee period / extended Guarantee
below and an inspection certificate(s) shall accompany the equipment. period as required by the Purchaser to assist / supervise the installation,
Statutory : M. M. D. or N. M. D. setting to work, commissioning of the equipment supplied by the Sub-
Regulatory : Classification Society–L.R.S./A.B.S/D.N.V/ I.R.S. etc. contractor / Supplier / Vendor.
Specification: Survey, DQA(WP)/DQAN/CQAE, Classification
Society. IN-712 The Sub-contractor / Supplier / Vendor shall provide the requisite
Others: Owners, W. P. S. (KOLKATA), GRSE training for the Purchaser’s / Owner’s Personnel at Sub-contractor’s /
Supplier’s / Vendor’s/ GRSE’s premises or on board the vessel where
IN-702 The articles to be supplied shall be strictly in accordance with the the equipment is installed, in respect of the equipment received from the
drawings/specification/statement of requisition (SOR) / samples Sub-contractor / Supplier / Vendor. The cost of travelling, lodging,
indicated in the order. boarding etc. shall be borne as mutually agreed to and detailed in the
order.
IN-703 The supplier /vendor/sub-contractor shall not sell, transfer, assign or
otherwise dispose off the rights, liabilities and obligations under the IN-713 The services of the Sub-contractor’s / Supplier’s / Vendor’s Engineers
contract without the previous consent of the purchaser in writing. shall be provided free of cost as required by the Purchaser to
assist/supervise the installation, setting to work, commissioning, harbour
IN-704 The articles shall be subject to Inspection and Quality Assurance by QA and sea trials of the equipment supplied by the Sub-contractor / Supplier
Authorities or their agents (Inspecting Officer) as specified in the order. / Vendor for the periods as mutually agreed upon and as per the terms
The supplier/vendor/sub-contractor shall give 30 days’ notice for and conditions of the order.
inspection and will make necessary arrangements / provide necessary Should the Purchaser / Owner desire to avail services beyond the
facilities to inspectors / nominated agency to carry out inspection / free service periods available against the contract, the Sub-contractor /
testing during course of manufacture/final inspection and testing as Supplier / Vendor shall quote for the same on hourly / daily rate basis
required. Formal Inspection Certificates will be issued by the relevant along with other terms and conditions, if any.
QA Authorities /Agents.
IN-714 Conditions of tests and inspection requirements, if not held by the Sub-
IN-705 Immediately on receipt of order the supplier/vendor/sub-contractor shall contractor / Supplier / Vendor are to be obtained from the Inspection
get in touch with the Inspection Authority and submit Quality Assurance Authority. Any / all other technical clarifications may be obtained from
Plan. Exact scope, stages and parameters of inspection and test schedule Inspection Authority directly, under intimation to Purchaser.
shall be as per QA Plan duly approved by the QA Authority. All charges
for inspection shall be borne by the suppliers/vendors/sub-contractor. IN-715 The Sub-contractor / Supplier / Vendor shall accord all facilities to
Purchaser’s Inspectors / Nominated Agency to carry out Inspection /
IN-706 Receipt Inspection shall be carried out by GRSE/Indian Navy/Owner’s Testing during course of manufacture / final testing.
representative at GRSE yard as applicable. Receipt Inspection of on-

13
IN-8.0 Miscellaneous: Sub-contractor / Supplier / Vendor, his employees, licencees, agents or
Sub-contractor by making good such damages to the property, or
IN-801 Force Majeure (as vetted by Min. of Law) : - compensating personal injury and the total liability for such damages or
Should any force majeure circumstances arise, each of the contracting injury shall be as mutually discussed and agreed to.
party shall be excused for the non fulfilment or for the delayed
fulfilment of any of its contractual obligations, if the affected party IN-804 Use of Undue Influence / Corrupt Practices:
within 15 days of its occurrence informs the other party in writing. (a) The Sub-contractor / Supplier / Vendor should give an
Force majeure shall mean fires, floods, natural calamities or undertaking that he has not given, offered or promised to give,
other acts such as war, turmoils, strikes (as not limited to be directly or indirectly any gift, consideration, reward, commission,
establishment of the seller), sabotage, explosions, quarantine restrictions fees, brokerage or inducement to any person in service of the
beyond the control of either party. Purchaser or otherwise in procuring the contract or forbearing to
It is understood and agreed between the parties hereto that the do or for having done or forborne to do any act in relation to the
rights and obligations of the parties shall be deemed to be in suspension obtaining or execution of the Contract with the Purchaser for
during the continuance of the force majeure event as aforesaid and the showing or forbearing to show favour or disfavour to any person
said rights and obligations shall automatically revive upon the cessation in relation to the Contract or any other Contract with the
of the intervening force majeure event. The period within which the Purchaser. Any breach of the aforesaid undertaking by the Sub-
rights and obligations of the parties shall be in suspension due to force contractor / Supplier / Vendor or any one employed by him or
majeure event shall not be considered as a delay with respect to the acting on his behalf (whether with or without the knowledge of
period of delivery and / or acceptance of delivery under the contract or the Sub-contractor / Supplier / Vendor) or the commission of any
otherwise to the detriment of either party. offence by the Sub-contractor / Supplier / Vendor or any one
Notwithstanding the provisions of the immediately foregoing employed by him or acting on his behalf, as defined in Chapter IX
clauses it is further understood and agreed between the parties hereto of the Indian Penal Code, 1980 or the Prevention of Corruption
that in the event of any force majeure persisting for an uninterrupted Act, 1947 or any other Act enacted for the prevention of
period exceeding 6 (six) months, either party hereto reserves the right to corruption shall entitle the Purchaser to cancel the contract and all
terminate this contract upon giving prior written notice of 30 (thirty) or any other contracts with the Sub-contractor / Supplier / Vendor
days to the other party of the intention to terminate without any liability and recover from the Sub-contractor / Supplier / Vendor the
other than reimbursement on the terms provided in this agreement for amount of any loss arising from such cancellation. A decision of
the goods received. the Purchaser or his nominee to the effect that a breach of the
undertaking has been committed shall be final and binding on the
IN-802 Arbitration: Sub-contractor / Supplier / Vendor.
Any dispute / differences between the parties arising out of and
in connection with the contract shall be settled amicably by mutual (b) The Sub-contractor / Supplier / Vendor shall not offer or agree
negotiations. CMD/GRSE will be the Arbitrator. However Unresolved to give any person in the employment of Purchaser any gift or
disputes/ differences, if any, shall be settled by Arbitration and the consideration of any kind as “Inducement” or “reward” for doing
arbitration proceedings shall be conducted at Kolkata (India) in English or forbearing to do or for having done or foreborne to do any act
language, under the Indian Arbitration and Conciliation Act, 1996. in relation to the obtaining or execution of the contract/s. Any
If, at any time, before, during or after the contract period, breach of the aforesaid condition by the Sub-contractor / Supplier
any unsettled claim, question, dispute or difference arises between the / Vendor or any one employed by them or acting on their behalf
parties, upon or in relation to or in connection with or in any way (whether with or without the knowledge of the Sub-contractor /
touching or concerning this tender / agreement / supply order (retain Supplier / Vendor) or the commission of any offence by the Sub-
whichever is applicable) the same shall be referred to the Chairman & contractor / Supplier / Vendor or by any one employed by them or
Managing Director ( ‘CMD’ in short) or the Managing Director (‘MD’ acting on their behalf which shall be punishable under the Indian
in short), as the case may be of Garden Reach Shipbuilders & Engineers Penal Code 1980 or the Prevention of Corruption by Public
Ltd. (GRSE Ltd’ in short ) for adjudication of the said disputes or Servants, shall entitle Purchaser to cancel the contract/s and all or
differences, as Sole Arbitrator, in accordance with the provisions of the any other contracts and then to recover from the Sub-contractor /
Arbitration and Conciliation Act, 1996. Supplier / Vendor the amounts of any loss arising from such
The CMD or MD, GRSE Ltd. if he so desires, may nominate / contracts’ cancellation, including but not limited to imposition of
appoint another officer of GRSE Ltd. or a person, whom he thinks fit penal damages, forfeiture of Security Deposit, encashment of the
and competent, for adjudication of the disputes or differences, referred Bank Guarantee and refund of the amounts paid by the Purchaser.
to him as the Sole Arbitrator.
Such arbitration shall, in all respects, be conducted in (c) In case, it is found to the satisfaction of the Purchaser that the
accordance with the provisions of the Arbitration and Conciliation Act, Sub-contractor / Supplier / Vendor has engaged an Agent or paid
1996 and the rules framed thereunder or any statutory modification or commission or influenced any person to obtain the contract as
re-enactment thereof for the time being in force. described in clauses relating to Agents / Agency Commission and
The Award of the Sole Arbitrator shall be final, conclusive and use of undue Influence, the Sub-contractor / Supplier / Vendor, on
binding upon the parties. a specific request of the Purchaser shall provide necessary
In the event of the death or resignation for any reason information / inspection of the relevant financial document /
whatsoever of the said Sole Arbitrator, appointed by the said CMD or information.
MD of GRSE Ltd., the CMD or MD of GRSE Ltd., on an application
from either of the parties in this behalf, shall act himself as the Sole IN-805 Banned or de-listed Contractors:
Arbitrator or nominate / appoint, in place of the outgoing Arbitrator, The bidders shall give a declaration that they have not been banned or
another officer of GRSE Ltd. or a person whom he thinks fit and de-listed by any Government or quasi Government agencies or PSUs. If
competent to adjudicate the said disputes and differences in accordance a bidder has been banned or de-listed by any Government or quasi
with law. Government agencies or PSUs, this fact must be clearly stated and it
Also in the event of an arbitration award is set aside by a may not necessarily be a cause for disqualifying him.
competent court on an application from either party and unless otherwise
ordered by the said court, the CMD or MD of GRSE Ltd., on an IN-806
application from either party, shall himself act as Sole Arbitrator or a) As a general rule, price negotiation with L1 vendor(s) will not be
nominate / appoint another officer of GRSE Ltd. or a person whom he entered into as far as possible, unless warranted by unreasonable
thinks fit and competent to adjudicate the disputes and differences in price quoted in the opinion of GRSE.
accordance with law. b) During Technical and / or commercial negotiation in case the
The cost of the arbitration, fees of the arbitrator, remuneration of participating vendors indicate the need of submission of revised
the stenographer and clerk, stamp paper etc., as shall be decided by the price bid but the same is not acceptable by competent authority in
Sole Arbitrator, shall be shared equally by the parties. The venue of due course, GRSE reserves the right to consider such bid(s) to be
arbitration, unless otherwise decided by the parties or by the Sole disqualified on this ground under intimation to the relevant
Arbitrator himself, shall be the premises of Garden Reach Shipbuilders vendor(s) before price bid opening.
& Engineers Ltd. located at 43/46, Garden Reach Road, Kolkata 700 c) Delivery schedule as mentioned above is our essential
024. requirement. GRSE reserves the right to cancel the bid if the
delivery requirement is not met.
IN-803 Indemnification: d) Please forward your confirmation on all commercial points for
The Sub-contractor/Supplier/Vendor, his employees, licencees, agents or acceptance of your offer in tender data sheet.
Sub-Vendor / Sub-contractor, while on site of the Purchaser for the e) In case your offer is not submitted in two separate given data
purpose of this contract, shall indemnify the Purchaser against direct sheet, the same is liable to be rejected.
damage and / or injury to the property and/ or the person of the
Purchaser or that of Purchaser’s employees, agents, Sub-Contractors / **************************
Suppliers occurring and to the extent caused by the negligence of the

14
 Garden Reach Shipbuilders & Engineers Ltd.
STANDARD TERMS AND CONDITIONS OF SUPPLY
INDIGENOUS EQUIPMENT/MACHINERY.

Tender No……. Date ………….

STACS BIDDER’S STACS BIDDER’S STACS BIDDER’S STACKS BIDDER’S

CLAUSE REMARKS CLAUSE REMARKS CLAUSE REMARKS CLAUSE REMARKS
NO. N N NO.
O O
. .
IN-101 IN-203 IN-501 IN-704
IN-102 IN-204 IN-502 IN-705
IN-103 IN-205 IN-503 IN-706
IN-104 IN-206 IN-504 IN-707
IN-105 IN-207 IN-708
IN-106 IN-208 IN-601 IN-709
IN-107 IN-209 IN-602.1 IN-710
IN-108 IN-210 IN-602.2 IN-711
IN-109 IN-211 IN-603 IN-712
IN-110 IN-212 IN-604 IN-713
IN-111 IN-605 IN-714
IN-112 IN-301 IN-606 IN-715
IN-113 IN-302 IN-607.1
IN-114 IN-303 IN-607.2 IN-801
IN-115 IN-304 IN-607.3 IN-802
IN-116 IN-305 IN-607.4 IN-803
IN-117 IN-306 IN-607.5 IN-804
IN-118 IN-607.6 IN-805
IN-119 IN-401 IN-608 IN-806
IN-120 IN-402
IN-403 IN-701
IN-201 IN-404 IN-702
IN-202 IN-405 IN-703

COMPANY SEAL.
SIGNATURE ……………………….
NAME ……………………….
DESIGNATION………………………
COMPANY NAME & ADDRESS
………………………………………..
………………………………………..

NOTE:
o Bidders should read the standard terms and conditions(STACS) included in the Tender carefully
prior to filling up this acceptance format.
o This format should be proINrly filled signed and returned along with your technical bid for
considering your bid.
o Please indicate ACC- For accepted, NO – For not accepted and DEV – For deviation taken.
o Separate sheet to be attached for any deviation taken by you.
o STACS clause numbers shown in the format includes the sub clauses under them also.

15