Location via proxy:   [ UP ]  
[Report a bug]   [Manage cookies]                
Scribd Logo
Upload

Welcome to Scribd!

  • 127 views

    Contract Data Fidic MDB 2010 Const2

    Uploaded by

    muslih_mhd
    This document outlines the Particular Conditions of Contract that supplement the General Conditions of Contract for a specific project. It provides project-specific details for items like the employer and engineer's names and addresses, time for completion, defects notification period, governing law, currencies, retention amounts, insurance requirements, dispute resolution procedures, and establishes that these particular conditions shall prevail over the general conditions in cases of conflict.

    Copyright:

    © All Rights Reserved
    Download as PDF, TXT or read online from Scribd

    Contract Data Fidic MDB 2010 Const2

    Uploaded by

    muslih_mhd
    127 views2 pages
    This document outlines the Particular Conditions of Contract that supplement the General Conditions of Contract for a specific project. It provides project-specific details for items like the employer and engineer's names and addresses, time for completion, defects notification period, governing law, currencies, retention amounts, insurance requirements, dispute resolution procedures, and establishes that these particular conditions shall prevail over the general conditions in cases of conflict.

    Original Description:

    Contract Data to be fliied for Contarct Fidic MDB 2010 Red Book

    Copyright

    © © All Rights Reserved

    Available Formats

    PDF, TXT or read online from Scribd

    Did you find this document useful?

    Is this content inappropriate?

    This document outlines the Particular Conditions of Contract that supplement the General Conditions of Contract for a specific project. It provides project-specific details for items like the employer and engineer's names and addresses, time for completion, defects notification period, governing law, currencies, retention amounts, insurance requirements, dispute resolution procedures, and establishes that these particular conditions shall prevail over the general conditions in cases of conflict.

    Copyright:

    © All Rights Reserved
    Download as PDF, TXT or read online from Scribd
    Download as pdf or txt
    127 views2 pages

    Contract Data Fidic MDB 2010 Const2

    Uploaded by

    muslih_mhd
    This document outlines the Particular Conditions of Contract that supplement the General Conditions of Contract for a specific project. It provides project-specific details for items like the employer and engineer's names and addresses, time for completion, defects notification period, governing law, currencies, retention amounts, insurance requirements, dispute resolution procedures, and establishes that these particular conditions shall prevail over the general conditions in cases of conflict.

    Copyright:

    © All Rights Reserved
    Download as PDF, TXT or read online from Scribd
    Download as pdf or txt
    of 2

    Section 8 - Particular Conditions of Contract

    8-1

    Section 8 - Particular Conditions of Contract


    The following Particular Conditions of Contract (PCC) shall supplement the General Conditions of
    Contract (GCC). Whenever there is a conflict, the provisions herein shall prevail over those in the
    GCC.

    Part A Contract Data


    Conditions

    Ref. GCC

    Employers name and address

    1.1.2.2 & 1.3

    Engineers name and address

    1.1.2.4 & 1.3

    Banks name

    1.1.2.11

    Data

    Borrowers name

    1.1.2.12

    Time for Completion

    1.1.3.3

    ........... days

    Defects Notification Period

    1.1.3.7

    ........... days.

    Sections

    1.1.5.6

    .............

    Electronic transmission systems

    1.3

    .............

    Governing Law

    1.4

    .............

    Ruling language

    1.4

    Language for communications

    1.4

    .............

    Time for access to the Site

    2.1

    ........ days after Commencement Date

    Engineers Duties and Authority

    3.1(B)(ii)

    .............

    Performance Security

    4.2

    The performance security will be in the form of an


    unconditional bank guarantee in the amount of ............
    % of the Contract Price

    Normal working hours

    6.5

    .............

    Delay damages for the Works

    8.7 & 14.15(b)

    ............. % of the Contract Price per day, in the


    currencies and proportions in which the Contract Price is
    payable.

    Maximum amount of delay damages

    8.7

    ............. % of the Contract Price.

    Provisional Sums

    13.5.(b)(ii)

    ............. %

    Adjustments for Changes in Cost

    13.8

    .............

    The Contract Price

    14.1

    .............

    Total advance payment

    14.2

    .............% of the Accepted Contract Amount payable in


    the currencies and proportions in which the Accepted
    Contract Amount is payable.

    Number and timing of installment

    14.2

    .............

    Currencies and proportions

    14.2

    ............. % in
    ............. % in

    Repayment amortization of advance payment

    14.2(b)

    .............%

    Percentage of Retention

    14.3(c)

    .............%

    Limit of Retention Money

    14.3(c)

    .............% of the Accepted Contract Amount.

    Plant and Materials

    14.5(b)(i)

    If Sub-Clause 14.5 applies:


    Plant and Materials for payment when shipped en route to
    the Site : ..................
    ( list )

    ..........................................................porject.

    Contract No......................................................

    Section 8 - Particular Conditions of Contract

    14.5(c)(i)

    Materials for payment when delivered to the Site, placed


    in acceptable stockpiles, and complying with relevant
    specifications:
    .............

    ( list )

    Minimum Amount of Interim Payment


    Certificates

    14.6

    ............. % of the Accepted Contract Amount.

    Maximum total liability of the Contractor to the


    Employer

    17.6

    .............

    Periods for submission of insurance:

    18.1

    a. evidence of insurance.

    ............. days after Commencement Date

    b. relevant policies

    ............. days after Commencement Date

    Maximum amount of deductibles for

    18.2(d)

    .............

    18.3

    .............

    Date by which the DB shall be appointed

    20.2

    .............days after the Commencement

    The DB shall be comprised of

    20.2

    .............

    insurance of the Employer's risks


    Minimum amount of third party
    Insurance

    List of potential DB sole members

    20.2

    .............

    Appointment (if not agreed) to be

    20.3

    .............

    International arbitration

    20.6 (a)

    ..............

    Place of arbitration

    20.6

    .............

    made by

    ...................................................................project

    Contract No. .........................................

    You might also like