Construction contract termination and suspension:

know your rights

As Covid-19 continues to impose financial and logistical burdens on construction

projects, it has never been more important for parties to stay aware of their rights and
the risks in relation to termination and suspension of contracts.

It is increasingly important to be aware of your rights and obligations in relation to

termination and suspension because the risks, if actualised, can be detrimental. For
more detail of the contractual and non-contractual rights to terminate, see our Out-
Law guide to termination and suspension of construction contracts.

This is part of a series of guides on the impact of Covid-19 on construction projects

from the specialist infrastructure lawyers at Pinsent Masons.

How does suspension work?

The impact of Covid-19 is, we hope, temporary, which might suggest that a temporary
suspension of construction activities – in whole or in part – would be the appropriate
remedy while the impact persists.

However, there is no common law remedy of suspension. A party should only consider
suspension if there is an express contractual or statutory right to suspend, or if the
parties are prepared to agree to a suspension.

Contracts often give employers suspension rights in respect of force majeure or

emergency events. The contractor will not usually be entitled to suspend in these
circumstances, but will be entitled to relief from its obligation to complete in the form
of an extension of time – payment of costs is less common.
A party should only consider suspension if there is an express contractual or statutory
right to suspend, or if the parties are prepared to agree to a suspension.

In certain jurisdictions, contracts will also give a party a right to suspend in the event
of non-payment of a sum due. This has largely been in response to statutory
requirements. For example, in the UK, parties can suspend performance of contractual
obligations where a required payment has not been made under section 112 of the
1996 Construction Act. Parties are also entitled to payment for the reasonable costs
incurred in exercising their right to suspend performance, and to additional time
involved in suspending and re-mobilising. This statutory right expires on payment of
the required sum.

1
Likewise, in Australia, security of payment legislation entitles parties to suspend work
in multiple non-payment situations. The 1999 Building and Construction Industry
Security of Payment Act (NSW) is the cornerstone of the 'east cost model' for security
of payment legislation. If the required payment has not been received, the party due
that payment can suspend work if at least two business days have passed since giving
the required notice. A suspension right also arises where payment of an adjudicated
amount is not made within five days of the adjudication determination being received.
Similar rights exist under the 'west coast model'.

These provisions address the indirect effects of Covid-19. If the employer's business
is struggling because of the impact of the virus, it may be unable to pay the contractor.
These provisions enable the contractor to suspend work - and to limit its own costs -
in circumstances where the existence of Covid-19 may not directly provide a remedy
under the contract or statute.

How does termination work?

The longer-term impact of Covid-19 may lead to one or both of the parties to a
construction contract concluding that the contract should be terminated, perhaps
because there is no need for the project anymore.

If the parties agree, then the contract can be brought to an end on agreed commercial
terms. If there is no agreement, then the position is more complex.

Common law termination

At common law, a party can terminate the contract in the event of a breach of a
condition or an 'essential term' of the contract. The contract may specify which terms
are 'essential'.

A party may also repudiate the contract when by its words or actions it indicates that
it is no longer ready or willing to perform the contract. If this is the case, the other party
has the option to either insist on performance or to accept the repudiation and claim
damages. Repudiatory conduct is a serious matter which should not be lightly inferred.
It is tested objectively and can arise out of a single act or a course of conduct. Conduct
may not be repudiatory if it is based on a good faith interpretation of contractual rights.
The breaching party can also 'cure' conduct before repudiation is accepted.

These common law rights are based on a party being at fault. While problems caused
by Covid-19 may be considered fault free, unless the contract provides an excuse to
the contractor then the contractor will remain responsible for late progress, late supply
of materials and equipment, missed completion dates and other practical effects of the
pandemic. These 'faults' may give the employer grounds for termination.

2
Contractual termination

Given the uncertainties around common law termination, most contracts provide for
specific events and procedures. These invariably include serious breaches that would
justify common law termination but can go further, to include events which are not the
fault of a party.

Many contracts also allow the employer to terminate for convenience. This will usually
be subject to proper recompense for the contractor, and subject to an obligation to
exercise the termination right in good faith.

Contractual termination terms entitle a party to terminate where the other party fails to
perform its obligations without excusable cause. For example, an employer may
terminate where a contractor wholly suspends the work before completion without a
reasonable cause. A contractor may have an express right to terminate where the
employer fails to make payments within the time specified. The contractual provisions
typically include a timetable for 'warning notices' and periods to cure failings.

The same considerations about fault and its effects apply to contractual regimes.
However, it may be that the contract contains 'fault-free' events which would justify
termination due to prolonged Covid-19 measures. Termination for convenience could
also be used by the client - for example, if the project was no longer required.

Frustration

A contract will be frustrated, and therefore set aside, where an unforeseen event - in
this case, the pandemic – either renders contractual obligations impossible, or
radically changes the principal purpose for entering into the contract.

Frustration has a narrow application, and will not operate to provide relief for the usual
consequences of ill-advised contracts. It will not operate where there is a force
majeure clause which addresses the event impacting the project. Frustration will not
ordinarily provide relief where the event causes delay, unless the delay is for an
unreasonable time.

Conceptually, frustration may operate to terminate contracts where the impact of the
virus is such that performance of the obligations becomes impossible.

Risks of termination

Unless the parties agree, one of them will have to 'call' termination. Inevitably, that
party will cease to carry out its own obligations under the contract and refuse to

3
acknowledge its future obligations. This carries risk. A party claiming frustration can
find itself in the same position.

Termination is a binary scenario - one party is right, and the other party is wrong. A
party is either entitled to terminate or it is not. This means that:

 if the party is not entitled to terminate, the purported termination is itself a

repudiation on which the other party can rely, notwithstanding any breach by
the other party on which the terminating party may have tried to rely;

 if the party is entitled to terminate, the termination is valid notwithstanding any

prior breach by the terminating party.

Where a party acts on a mistaken conclusion that the conduct of the other party is
repudiatory, the consequences are profound. For example, in a situation where the
contractor purports to terminate because it unreasonably perceives the employer's
conduct to be repudiatory, it is the contractor who may be held to have repudiated the
contract giving rise to the employer's right to terminate. The employer may seek
damages for the extra costs of completion associated with a new contractor at a higher
price, loss of profit and additional borrowing costs.

Relationship between contract and common law

Where there are termination provisions in the construction contract, the parties need
to consider whether the contractual right excludes a common right to terminate as a
matter of construction.
In a situation where the contractor purports to terminate because it unreasonably
perceives the employer's conduct to be repudiatory, it is the contractor who may be
held to have repudiated the contract giving rise to the employer's right to terminate.

In Australia, the courts have held that a termination clause was an alternative, not a
substitution, for the common law remedies.

In the UK, the High Court in 2016 held that no general test exists as to whether parties
must comply with contractual notice clauses when terminating due to a repudiatory
breach. This will instead be determined as a matter of construction. The contractor,
Richmond, sought to rely on the common law right to terminate by reason of a
repudiatory breach, bypassing the notice and remedy requirements prescribed by the
contractual termination clause. The court found that Richmond was entitled to do so.

Conduct estopping parties from terminating

Parties can be prevented – 'estopped' – from exercising contractual rights to terminate

by representations and conduct during the performance of the conduct. An example
of such conduct could be where a party communicates that it will not insist on strict

4
performance of the contract. That party may be prevented from insisting on strict
performance at a later date.

In situations where the parties have adopted the same assumption, and proceed on
the basis of that mutual assumption, departure from that assumption in a way which
would cause detriment to one party would disentitle the other party from the right to
terminate.

Errors in termination notices

A compliant termination notice needs to be clear and unambiguous, and to make

commercial sense.

Waiver of termination rights

A party with sufficient knowledge of a breach or repudiation which displays, by

unequivocal words or conduct, that it intends to continue its performance loses the
right to terminate the contract in reliance on any breach or repudiation that had already
occurred at the time of the election.

In 2008, the Australian High Court held that estoppel and election are required to
'waive' termination rights.

Payment on termination

Contractual termination regimes provide for payment once termination occurs.

At common law, courts in the UK and Australia have approached this differently. This
difference in approach has made termination on the acceptance of repudiation a more
attractive option to contractors, particularly those in 'bad bargains'.

In the UK, on termination, a contractor will be entitled to payment for work to date
based on its contractual entitlements to that point.

In Australia, contractors were previously entitled to a 'quantum meruit' payment, or a

reasonable sum of money for the work done. This changed in 2019, with the landmark
case of Mann v Paterson Constructions Pty Ltd. As a result of this decision:

 the contractor is no longer entitled to sue on a 'quantum meruit' basis for work
carried out before the termination where it had already accrued a contractual
right to be paid at the date of repudiation;

 where no right of payment had accrued under the contract at the time of
termination for work carried out before the termination, the contractor can only

5
 recover an amount limited to the contract price for the relevant part of the works.
Previously, the claim was unlimited by the contract price; and

 where the work consists of variations requested by owners, section 38 of the

Domestic Building Contracts Act (Vic) prevents a contractor from recovering an
amount in restitution for variations that had not received approval under that
section. Instead, any quantum meruit claims need to comply with the
appropriate provisions of the Act.

The effect of this case is that a claim for quantum meruit after the termination of a
construction contract can now only be brought in very limited circumstances. This has
effectively curbed any potential 'windfall' gains by contractors attempting to recover
through quantum meruit instead of damages for the breach. It also eliminates the
incentive to terminate where there is the potential for greater recovery of money
through termination than by completing the construction works. However, valid
termination will continue to provide welcome relief to contractors on loss-making
projects.