VOL1
VOL1
VOL1
Name of Work:
VOLUME-I
(EPC CONTRACT)
Section
1 Check List
8 Section VI Appendices
2 Sufficiency of Bid 1
4 Scope of work 2
8 Supplementary requirements 5
13 Cleaning up 10
25 Land acquisitions 13
26 Use of site 14
27 Availability of Power 14
29 Modern Technology 17
Section-VI (Appendices)
10.0 Assignment 7
11.0 Liability 7
12.0 Insurance 7
13.0 Maintenance 8
15.0 Inspection 9
11
20.0 Termination or Fore Closure of the Contract
21.0 Training 11
11
22.0 O&M Manual
Note: The contents of the Bid offer document shall be legible & serially numbered.
***********
NOTICE INVITING TENDER (NIT)
OFFICE OF THE CHIEF CONSTRUCTION ENGINEER
DEO IRRIGATION PROJECT, KARANJIA, DISTRICT-MAYURBHANJ
Tel No. 06796-296144 Mail : cce.dip.dowr@gmail.com
Online tenders are invited from perspective bidders for EPC Contract for Construction of
Khairibhandan Barrage Project on river Khairibhandan at village Anlabeni, Jashipur
Block, District – Mayurbhanj, State- Odisha including hydro-mechanical works, Head
Regulator left & right, construction of aflux bund & coffer dam, dewatering during construction,
Power connectivity works to project site & colony, road connectivity, including survey,
investigation, planning, design and estimate of all components with operation and maintenance
of the project for a period of five years or five flood seasons whichever is more after successful
commissioning of the project
6 Name & address of the Chief Construction Engineer, Deo Irrigation Project,
officer inviting Bid Karanjia, District-Mayurbhanj
Sd/
Chief Construction Engineer
Deo Irrigation Project, Karanjia, District-Mayurbhan
SECTION – I
DETAILED NOTICE INVITING TENDER
(DNIT)
Section-I
2.0 Introduction 2
3.0 Invitation 2
Sub: Publication of ‘e’-procurement Notice No. 03/CCEDIP of 2023-24 (Online) for the work
“Construction of Khairibhandan Barra`ge Project on river Khairibhandan at village Anlabeni,
Jashipur Block, District – Mayurbhanj, State- Odisha including hydro-mechanical works, Head
Regulator left & right, construction of aflux bund & coffer dam, dewatering during construction, Power
connectivity works to project site & colony, road connectivity, including survey, investigation,
planning, design and estimate of all components with operation and maintenance of the project for a
period of five years or five flood seasons whichever is more after successful commissioning of the
project”
Sir
Enclosed please find herewith the ‘e’-procurement Notice No.03/CCEDIP of 2023-24 (Online)
for the above work of Chief Construction Engineer, Deo Irrigation Project, Karanjia, District-
Mayurbhanj to be published in one National English daily and one Odia daily on or before
22.09.2023. Minimum possible space may please be taken to accommodate the contents.
The complimentary copy of the advertisement may please be sent to the Superintending
Engineer, Deo Head Works Division, Karanjia under intimation to this office for confirmation.
Yours faithfully,
Encl : ‘e’-procurement Notice
No. 03/CCEDIP of 2023-24 (Online).
(both hard & soft copy) Chief Construction Engineer,
Deo Irrigation Project, Karanjia.
Memo No: ` Dated:
Copy submitted to the Additional Chief Secretary to Government, Department of Water
Resources Odisha, Rajiv Bhawan, Bhubaneswar for favour of kind information and necessary action.
Encl : ‘e’-procurement Notice
No. 03/CCEDIP of 2023-24 (Online).
Online tenders are invited from the prospective bidders for Construction of “Khairibhandan
Barrage Project on river Khairibhandan at village Anlabeni, Jashipur Block, District –
Mayurbhanj, State-Odisha” on EPC Contract.
Class/EMD/Tender Fee/Period of
Name of work
Completion
Construction of Khairibhandan Barrage Project
on river Khairibhandan at village Anlabeni, (1) Approximate value of work put to
Jashipur Block, District – Mayurbhanj, State- tender-Rs.7454.76 lakhs
Odisha including hydro-mechanical works, Head (2) Class – Super Class or equivalent
Regulator left & right, construction of aflux bund & Bidders.
coffer dam, dewatering during construction, Power (3) EMD – Rs.74,54,800/-
connectivity works to project site & colony, road (4) Tender Fee – Rs.10,000/- to be
connectivity, including survey, investigation, transferred online. (Non Refundable)
planning, design and estimate of all components (5) Period of Completion – 30 (Thirty)
with operation and maintenance of the project for calendar months including rainy
a period of five years or five flood seasons season.
whichever is more after successful commissioning
of the project.
Any addendum/ Corrigendum/ Cancellation to the above notice will be published in the Govt.
website www.tendersodisha.gov.in
***************
Sd/
Chief Construction Engineer
Deo Irrigation Project, Karanjia
SECTION – II
INSTRUCTION TO BIDDERS
SECTION – II
INSTRUCTION TO BIDDERS
INDEX
Sl. Particulars Page
No. No
1 2 3
1.0 Special Attention 1
2.0 Definitions 2
3.0 General Description of the work 5
4.0 Brief Description & Scope of work under this tender 5
5.0 Particulars provisional 7
6.0 Communication 7
7.0 General Facilities 8
8.0 Climate and working season 8
9.0 Cost of bidding 8
10.0 Language of tender 8
11.0 Bid validity 9
12.0 Method of tendering 9
13.0 Earnest money deposit( Bid Security Declaration) 9
14.0 Accompaniments to tender 10
15.0 Submission of tender 11
16.0 Opening of Technical bid 15
17.0 Opening of price bid 16
18.0 Evaluation of price bid 17
19.0 Process to be confidential 18
20.0 Award of contract 18
21.0 Initial Security deposit 18
22.0 Bid Amount 19
23.0 No sanction for foreign exchange 19
24.0 Construction Programme 20
25.0 Specific Issues 22
26.0 Corrupt or Fraudulent Practices 24
27.0 Subletting of Contract 24
SECTION-II INSTRUCTION TO BIDDERS
SECTION – II
INSTRUCTION TO BIDDERS
1.0 SPECIAL ATTENTION:
1.1 The tenders are invited on EPC contract from perspective eligible contractors/
firms who are registered as super class contractor with Govt. of Odisha.
Contractors registered in equivalent grade outside Odisha are also eligible.
However, they shall get themselves registered in super class in the State of
Odisha before signing of agreement.
1.2 All bidders are urged to submit a written/ online request immediately upon
receipt of the tender documents for the matter where clarification and/ or
additional information are desired, along with the details of work. All such
request should reach the authority inviting tender through e-mail on or before
dt.07.10.2023 up to 5.00 PM.
1.3 The bidders are advised to visit the site before quoting the bid. They should ascertain
all the required data for turnkey completion of the work.
1.4 The tender document shall be submitted as per procedure laid down in Section
-II, Para No. 15, for submission of tender.
1.5 Tender shall be opened as per procedure laid down in Section – II, Para 16.
1.6 All bidders are cautioned that bid containing any deviation from the
contractual terms and conditions, specifications or requirements shall be
rejected as non-responsive.
1.7 Conditional bid will be rejected outright. No condition shall be included in
tender.
1.8 Alternative bids are not acceptable.
1.9 Evaluation of bid will be done when tender is considered responsive as per
tender condition.
1.10 Bidder shall have to declare regarding correctness of the tenders submitted in
the prescribed format.
1.11 The Department / authority reserve the right to qualify /disqualify any bidder
without assigning any reason thereof.
1.12 Bidders shall be disqualified if they have made untrue or false representation
in the forms, statements and attachments required in the bid documents;
or
Record of poor performance either due to technical or financial or any other
reasons.
1.13 If the bidder has submitted tender fee and Bid Security Declaration on line,
the request of the bidder for not opening of bid shall not be accepted in any
circumstances.
1.14 The contractor intending to hire/lease equipment / machineries are required to
furnish proof of ownership from the company/person providing equipment
/machineries on hire/lease deed should cover the entire period of work. In the
2.22 Month: Means from the beginning of a given date of calendar month to the
end of preceding date of the next calendar month.
2.23 Week: Means seven consecutive days.
2.24 Rupees`: Means Rupees of Indian Currency.
2.25 Site: Means the lands and other places on, under, in or through which, the
works are to be executed or carried out and any other lands or places provided
by the Owner for the purposes of the contract together with such other places
as may be specifically designated in the Contract or subsequently approved as
forming part of the site.
2.26 Superintending Engineer: Means the Superintending Engineer in overall
charge of the works i.e. Engineer-in-Charge.
2.27 Temporary Works: Means all temporary works of every kind required for
performance of the Contract.
2.28 Works: Means the works to be executed in accordance with the contract.
2.29 Country: Means the Country in which the site (or most of it) is located,
where the Permanent Works are to be executed i.e., INDIA.
2.30 'Sub-Contractor' shall mean the person named in the Contract for any part of
the Works or any person to whom any part of the Contract has been subleted
by the Contractor with the consent in writing of the Engineer and will include
the legal representatives, successors and permitted assigns of such person.
2.31 'Consulting Engineer'/'Consultant' shall mean any firm or person duly
appointed as such from time to time by the Owner.
2.32 'Specification' shall mean the Technical Specifications forming a part of the
Contract and such other schedules and drawings as may be mutually agreed
upon.
2.33 The term 'Erection Portion' of the Contract Price shall mean the value of
field activities of the Contract including erection, testing and commissioning
to be performed at Site by the Contractor.
2.34 'Manufacturer's Works' or 'Contractor's Works' shall mean the place of
work used by the Manufacturer, the Contractor, their Collaborators or
Subcontractors for the performance of the Works.
2.35 'Inspector' shall mean the Owner or any person nominated by the Owner
from time to time, to inspect the equipment stores or works under the Contract
and/or the duly authorized representative of the Owner.
2.36 'Notice of Award of Contract'/'Letter of Award'/'Telex of Award' shall
mean the official notice issued by the Owner notifying the Contractor that his
proposal has been accepted.
2.37 'Date of Contract' shall mean the date on which both the parties have signed
the Contract Agreement.
2.38 'Writing' shall include any manuscript, type-written or printed statement,
under or over signature and/ or seal as the case may be.
2.39 When the words 'Approved', 'Subject to Approval', 'Satisfactory', 'Equal to',
'Proper' 'Requested', 'As Directed', 'Where Directed', 'When Directed',
'Determined By', 'Accepted', 'Permitted' or words and phrases of like import
are used, the approval, judgment, direction etc. is understood to be Ī function
of the Owner/Engineer.
2.40 "Consumer installation": means any composite electrical unit including
electric wires, fittings, motors, transformers and apparatus portable and
stationary, indoor, outdoor and underground erected and wired by or on
behalf of the consumer in one and at the same premises.
2.41 'Completion of Erection of Sub-Station' shall mean the erection of all the
equipment & accessories within boundaries of sub-station as per the scope of
work & dry test run.
2.42 'Completion of Erection of Distribution Lines' shall mean Completion of
all lines from a distribution transformer to consumer including erection of
service lines, if in scope of contractor & dry testing of the same.
2.43 'Completion of Commissioning' for electrical works shall mean the
Charging & continuous operation of the sub-station, transformers & lines for
48 hours without any interruption.
2.44 'Guarantee Period'/Maintenance Period' shall mean the period during
which the Contractor shall remain liable for repair or replacement of any
defective part of the Works performed under the Contract.
2.45 ‘Flood Seasons’ shall mean the period from 1st June to 31st October.
2.46 'Codes' of electrical works shall mean the following, including the latest
amendments, and/or replacements, if any:
(a) International Electro-technical Commission, Geneva, Switzerland i.e. IEC.
(b) Indian Electricity Act, 1905, and Rules and Regulations made there under.
(c) Indian Factory Act, 1948, and Rules and Regulations made there under.
(d) Indian Explosives Act, 1884, and Rules and Regulations made there
under.
(e) Indian Petroleum Act, 1934, and Rules and Regulations made there under.
(f) A.S.M.E. Test Codes.
(g) A.I.E.E. Test Codes.
(h) American Society of Materials Testing Codes.
(i) Bureau of Indian Standards, New Delhi.
(j) Other Internationally approved standards and/ or Rules and Regulations
touching
the subject matter of the Contract.
2.47 Words importing the singular only shall also include the plural and vice-versa
where the context so requires.
2.48 Words importing 'Person' shall include firms, companies, corporations and
associations or bodies of individuals, whether incorporated or not.
2.49 Terms and expressions not herein defined shall have the same meaning as are
assigned to them in the Indian Sale of goods Act (1930), failing that in the
Indian Contract Act (1872) and failing that in the General Clauses Act (1897).
3.0 GENERAL DESCRIPTION OF THE WORK: Construction of Barrages, weirs
and Major Check Dams ( In-stream storage structures (ISS)) across various river of
State of Odisha including hydro-mechanical works, Power connectivity works, road
connectivity, staff quarters including survey, investigation, Planning, design and
estimate of all components with operation and maintenance for a period of five years
or five flood seasons whichever is more after successful commissioning of the work,
the details of which is given below.
7.4 Electricity Supply: The Contractor shall make his own arrangement for
extension of electric connection at his own cost from the Distribution
Companies if so required by him.
7.5 Housing Facilities: Private house may not be available in the vicinity of the
work site. The Contractor shall make his own arrangement for housing the
Labourers, workers and staff at the work site.
7.6 Medical Aid: The Health Centre is available at Govt. Hospitals at the nearest
Block/Sub-Division/District head quarters. However, the Contractor shall make
first aid arrangement at his own cost in accordance with rule and regulations of
prevailing Labour Act.
7.7 Post, Telegraph & Telephones: Post, Telegraph, Telephones & Fax are
available at Block/Sub-Division/District head quarters. The site is covered by
different mobile networks.
8.0 CLIMATE AND WORKING SEASON:
8.1 Climate: The Project area has moderate climate with temperature varying from
70C to 450C. The rainy season is generally confined to four months from15th
June to 15th October.
8.2 Working Season: Since rainfall is confined mainly to the period starting from
middle of June to the middle of October, it may be necessary to close the work
of concrete during the monsoon. However, the earthwork work and power
connectivity work can be continued in dry spells during the monsoon.
9.0 COST OF BIDDING:
All costs and expenses incidental to preparation of the proposals, to attend discussion
and conferences, if any, including pre award discussion with the successful bidder,
technical and other presentation including any demonstration, etc. shall be borne by
the bidders and the Employer shall bear no liabilities whatsoever on such cost and
expenses.
10.0 LANGUAGE OF TENDER:
Tender documents shall be submitted in prescribed form in English only. All
literature or correspondence in connection with tender shall be made in English only.
11.0 BID VALIDITY:
11.1 Bids shall remain valid for a period of not less than One hundred eighty (180)
days from the last date of submission of Bids.
11.2 During the above mentioned period no plea by the Bidder for any sort of
modification of the Bid based upon or arising out of any alleged
misunderstanding of misconceptions or mistake or for any reason will be
entertained.
11.3 In exceptional circumstances, prior to expiry of the original time limit, the
Bid Inviting Officer may request the bidders to extend the period of validity
for a specified additional period. Such request to the bidders shall be made in
writing.
14.5 Scanned copy of current year solvency certificate & Credit Facility available
from any nationalized bank / scheduled bank so as to access the capability of
the bidder for execution of work.
14.6 The copy of power of attorney, if power is delegated for signing the bid to
other person by the bidder. (As per para 12 of Section-II)
14.7 Forms with Annexures shall have to be submitted in Electronic form and
where the space / window of the prescribed form are not sufficient to fill
required matter, bidder may submit the details in separate “scanned sheet”. In
online submission, the bidders have to mention relevant form number in
heading of above mentioned separate “scanned sheet”,
14.8 Other documents as mentioned in Tender Notice.
All other document mentioned in the tender documents in physical form shall also be
uploaded.
15.0 SUBMISSION OF TENDER:
15.1 The bidders shall submit their tender online only. In case of any failure,
malfunction or breakdown of electronic system used during the e-
procurement process, the tender inviting authority shall not accept any
responsibility for failure or breakdown other than in those systems strictly
within their own control.
15.2 The e-procurement applications are PKI (Public Key Infrastructure) enabled
and supports the digital Signature certificates (DSC) of appropriate class
(Class-II or Class-III) issued from a registered Certifying Authority (CA) as
stipulated by Controller of Certifying Authorities (CCA), Government of
India such as n-code, Sify, TCS, e-Mudhra etc., for signing the bids at the
time of submission by contractor. The contactor has to procure digital
Signature certificates issued by above authority as per the procedure.
Digitally signed bids are to be submitted electronically through e-
procurement, without which the tender will not be considered for opening the
price Bid.
15.3 Suitable training will be given by State Procurement Cell, Nirman Soudh,
Bhubaneswar to the bidders interested to know the procedure of bid
submission on e-procurement platform. The telephone No is 18003456765
(Toll free), 0674-2530998.
15.4 The bidders would be required to register on the e-procurement market place
www.tendersodisha.gov.in and submit their bid online. The Department will
not accept any bid submitted in the paper form. The bidders should quote
their Tender contract price at the prescribed field / place provided in the e-
market place.
15.5 The bidder may ask question online in the e-procurement portal using his/her
DSC, provided the questions are raised within the period of seeking
clarification as mentioned in the particular of tender. The officer inviting
tender will clarify queries related to the tender.
15.6 Intending bidders can contact the office of the Chief Construction Engineer,
Deo Irrigation Project, Karanjia, District-Mayurbhanj for any clarification,
and information on any working day during working hours. No clarification
will be entertained after the pre-bid meeting.
15.7 The bidders are requested to submit the bids in single stage with two covers. Cover-
1: Qualification criteria and Technical bid and Cover-2 : Financial bid in separate .
15.8 All Bidders including joint venture should submit the certified copies and
fulfill the following criteria.
a) The bid shall include all the information’s listed as below :-
(i) Copies of original documents defining the constitution or legal status, place
of registration, and principal place of business; written power of attorney of
the signatory of the Bid to commit the Bidder;
(ii) Total monetary value of construction work performed by each partner
during the last five years;
(iii) Experience in works of a similar nature and size for each partner in the last
five years, and details of works or committed contracts; and clients who
may be contacted for further information on those contracts;
(iv) Major items of construction equipment proposed to carry out the Contract;
(v) Qualifications and experience of key site management and technical
personnel proposed for the Contract;
(vi) Reports on the financial standing of the Bidder, such as profit and loss
statements and auditor’s reports for the past five years;
(vii) Evidence of adequacy of working capital for this contract (access to line (s)
of credit and availability of other financial resources);
(viii) Authority has the right to seek references from the Bidder’s bankers;
(ix) Information regarding any litigation or arbitration resulting from contracts
executed by the Bidder in the last five years or currently under execution.
The information shall include the names of the parties concerned, the
disputed amount, cause of litigation, and matter in dispute if any ;
(x) The proposed methodology and programme of construction including
Environmental Management Plan backed with equipment, materials and
manpower planning and deployment, duly supported with broad
calculations and quality control procedures proposed to be adopted,
justifying their capability of execution and completion of the work as per
technical specifications within the stipulated period of completion as per
milestones.
b) Bids from joint ventures are acceptable
Bids from joint venture of maximum two firms as partners are acceptable.
For determining the eligibility of Applicants for their qualification hereunder,
the following shall apply:
A. (a) The Applicant for qualification may be a single entity or a group of entities (the
“Joint Venture”), coming together to take part in Bid competition. However, no
applicant applying individually or as a member of a Joint Venture, as the case may
be, can be member of another Applicant. The term Applicant used herein would
apply to both a single entity and a Joint Venture.
(b) An Applicant may be a company incorporated under the Indian Companies
Act, 1956 or a combination of companies with a formal intent to enter into a Joint
Venture agreement or under an existing agreement to form a Joint Venture. A Joint
Venture shall be eligible for consideration subject to the conditions as mentioned.
(c) An Applicant shall not have a conflict of interest (the “Conflict of Interest”)
that affects the Bidding Process. Any Applicant found to have a Conflict of Interest
shall be disqualified. An Applicant shall be deemed to have a Conflict of Interest
affecting the Bidding Process, if:
(i) the Applicant, its Member or any constituent thereof and any other
Applicant, its Member or any constituent thereof have common controlling
shareholders or other ownership interest; provided that this disqualification
shall not apply in cases where the direct or indirect shareholding of an
Applicant, its Member thereof (or any shareholder thereof having a
shareholding of more than 5 per cent of the paid up and subscribed share
capital of such Applicant, Member, as the case may be), in the other
Applicant, its Member is less than 5 per cent of the subscribed and paid up
equity share capital thereof; provided further that this disqualification shall
not apply to any ownership by a bank, insurance company, pension fund or
a public financial institution referred to in section 4A of the Companies Act
1956. For the purposes of this Clause 79 (c), indirect shareholding held
through one or more intermediate persons shall be computed as follows: (aa)
where any intermediary is controlled by a person through management
control or otherwise, the entire shareholding held by such controlled
intermediary in any other person (the “Subject Person”) shall be taken into
account for computing the shareholding of such controlling person in the
Subject Person; and (bb) subject always to sub-clause (aa) above, where a
person does not exercise control over an intermediary, which has
shareholding in the Subject Person, the computation of indirect shareholding
of such person in the Subject Person shall be undertaken on a proportionate
basis; provided, however, that no such shareholding shall be reckoned under
this sub-clause (bb) if the shareholding of such person in the intermediary is
less than 26% of the subscribed and paid up equity shareholding of such
intermediary; or
(ii) a constituent of such Applicant is also a constituent of another Applicant; or
(iii) such Applicant receives or has received any direct or indirect subsidy,
grant, concessional loan or subordinated debt from any other Applicant, or
has provided any such subsidy, grant, concessional loan or subordinated
debt to any other Applicant, its Member thereof; or
(iv) such Applicant has the same legal representative for purposes of this
Application as any other Applicant; or
(v) such Applicant has a relationship with another Applicant, directly or
through common third party/ parties, that puts either or both of them in a
business for and on behalf of any and all the members of the JV during the bidding
process and, in the event the JV is awarded the Contract, during contract execution.
J. The joint venture should submit the certificates in the forms enclosed in Section-3.
K. In case of a Joint Venture, the Threshold Technical Capacity and Financial
Capacity of all the Members of Joint Venture would be taken into account for
satisfying the above conditions of eligibility, proportionately as defined in the joint
venture agreement for clause-15.8, Cover-I, File-I, Sl.1,2,3 and clause 16.5. For
avoidance of doubt it is further clarified that the Joint Venture must collectively
and individually satisfy the above qualification criteria. The Applicant shall
enclose with its application, to be submitted as per the format at Appendix-I of
Section-3, complete with its Annexes.
L. The Applicant should submit a Power of Attorney as per the format at Appendix-I
of Section-3, authorizing the signatory of the Application to commit the Applicant.
In the case of a Joint Venture, the Members should submit a Power of Attorney in
favour of the Lead Member as per format at Appendix-II of Section-3.
M. In case the Applicant is a Joint Venture, it shall comply with the following
additional requirements:
a) Number of members in a Joint Venture shall not exceed 2 (two);
b) Subject to the provisions of clause (a) above, the Application should contain
the information required for each Member of the Joint Venture;
c) the Application should include a brief description of the roles and
responsibilities of individual members, particularly with reference to financial,
technical and defect liability obligations;
d) an individual Applicant cannot at the same time be member of a Joint Venture
applying for qualification. Further, a member of a particular Applicant Joint
Venture cannot be member of any other Applicant Joint Venture applying for
qualification;
e) Members of the Joint Venture shall have entered into a binding Joint Bidding
Agreement, substantially in the form specified at Appendix-III of Section-3
(the “Jt.Bidding Agreement”), for the purpose of making the Application and
submitting a Bid in the event of being qualified. The Jt. Bidding Agreement, to
be submitted along with the application, shall, interlaid :
(i) Convey the commitment(s) of the Lead Member in accordance with this
SBD, in case the contract to undertake the Project is awarded to the Joint
Venture;
(ii) Clearly outline the proposed roles and responsibilities, if any, of each
member;
(iii) Commit the approximate share of work to be undertaken by each member;
(iv) Include a statement to the effect that all members of the Joint Venture shall
be liable jointly and severally for all obligations of the Contractor in
relation to the Project until the completion of the Project (the “Defects
Liability Period”) is achieved.
f) Except as provided under this Bidding Documents, there shall not be any
amendment to the joint venture Bidding Agreement.
N. Any entity which has been barred by the Central/State Government, or any entity
controlled by it, from participating in any project, and the bar subsists as on the
date of Application, would not be eligible to submit an application, either
individually or as member of a Joint Venture.
O. An Applicant including any member should, in the last 5(five) years, have neither
failed to perform on any contract, as evidenced by imposition of a penalty by an
arbitral or judicial authority or a judicial pronouncement or arbitration award
against the Applicant or Member, as the case may be, nor has been expelled from
any project or contract by any public entity nor have had any contract terminated
by any public entity for breach by such Applicant or Member.
P. The Applicant including any Member may provide details of all their on-going
projects along with stage of litigation, if so, against the Authority/Governments.
The Applicant including any member may also provide details of on-going process
of blacklisting if so, under any contract with Authority/Government.
Cover-1: Qualification criteria:
Technical bid: This will contain the following documents in three PDF files.
File-I
The intending bidders can submit bid as an individual.
1. The intending bidders should have satisfactorily completed (not less than 80% of the
original contract value) as a prime contractor of at least one similar work of value not
less than Rs.29.82 Crore (the amount mentioned should be 40% of the proposed
contract value) at financial year 2023-24 (Year of Invitation of Tender) price level in
last 10(ten) years prior to the FY of invitation of tender & including current
financial year i.e. from 2013-14 to 2022-23.
The self-attested copy of certificate of authenticity is to be enclosed from the
concerned Executive Engineer / Competent Officer in charge of execution. The detail
correspondence address / e-mail id of the authority issuing certificate shall be
furnished. Weightage of 10% per year shall be given on cost of the satisfactorily
completed works of previous years to bring them to the current price level.
(Weightage to be given on year-wise break up of cost component of completed work
to bring them to the current price level)
Similar work means:-
Concrete & Masonry Dams
Spillways / Barrages / Weirs,
Major Railway and Road Bridges over river,
Aqueduct / Canal Syphon / Head Regulator / Drainage Syphon / Super Passage /
Tunnel / Surplus Escape in main canals.
2. (a)The intending bidders in its name should have in the last five year (from FY
2018-19 to FY 2022-23) achieved minimum annual turnover in all types of Civil
Engineering construction work only of Rs.44.73 Crore (one and half times of the
estimated annualized cost of tender) at FY 2023-24 (i.e., FY of invitation of tender)
price level in any one financial year.
Cover-2: Financial bid: This will contain Financial Bid (Appendix-FB) &Year wise
breakup of O&M cost of Project (Appendix–F-5) shall be uploaded in two files.
File – I: The Financial Bid (Appendix–FB) shall be in intelligent Excel format. This
is to be downloaded from website, the lump sum price is to be filled up without any
change in wording & format and uploaded
File-II:
1. The year wise breakup of O&M cost of Project (Appendix–F-5) and other
information required by the Bid in connection with financial bid are to be
uploaded in PDF format.
15.9 The bidder must submit online duly filled in Forms, Schedules, i.e. of Technical bid
and Forms and Annexure of Financial bid etc. All the forms, annexure shall be
submitted duly filled in electronic form & shall be available on website.
15.10 The bidder shall fill & submit the required details / data / information in the
prescribed form of tender document i.e. Volume– I.
15.11 The bidder shall quote his/her rate only in Volume–I: Financial Bid.
15.12 Tender in off-line mode will not be accepted.
15.13 If EMD is not received with the tender as mentioned in Para.13 of Section - II, tender
shall be rejected.
15.14 The authority at his discretion can extend the last date for submission of tender by
amending the bidding document in which case all rights and obligations of the
employer and bidder will thereafter be subject to the last date as extended.
15.15 All duties, taxes, royalty and other levies payable by the contractor as per
State/Central Government rules, shall be deemed to have been included in the
contract value except GST quoted by the Bidder. The royalty charges vide Gazette
notification No.2280 dated 14.12.2016 of Odisha minor minerals concession rules-
2016shall be taken into consideration for calculation of royalty charges in their bid.
The royalty charges for the use of earth excavated from the foundation of the
structure shall not be levied. The contractor is expected to quote the bid price in lump
sum rate after careful analysis of cost involved for the performance of work complete
considering all specification and conditions of contract. In case it is noticed that the
price quoted by the Bidder is unusually high or unusually low, unless the employer is
convinced about the reasonableness of bid price on scrutiny of the analysis for such
price to be furnished by the Bidder, it will be sufficient cause for the rejection of the
bid.
15.16 The C.E. has prepared milestones for executing the work which may be referred
while bidding(in Appendix-MS).In case the bidder has alternative plan for milestone,
they should submit the indicative milestone at the time of submission of bid and
form mile stone after completion of survey and investigation. The biddershall pay
special attention as regards achieving of critical milestones on schedule, so as to
ensure final commissioning on time. The employer shall critically monitor both the
physical as well as financial targets, on monthly and quarterly basis. Shortfalls, if
any, in the monthly targets shall be immediately rectified by supplementing the
resources by the contractor leading to increase in the progress, at no extra cost to the
Employer, so as to achieve the quarterly targets as per schedule.
15.17 The contractor will be responsible for processing of permission for right of way/right
of use and land acquisition till the same is obtained. Payment of statutory charges
and cost of the land will be the responsibility of Govt. Demarcation of acquisition
area, preparation of schedules for acquisition is the responsibility of the contractor.
Similarly, preparation of all the base papers for right of way/right of use, the NOC
from different authorities/owners is the responsibility of the contractor. The
contractor should be responsible for compensation to be paid for standing crops,
trees etc. and the cost there upon will not be borne by the Govt.
16.0 OPENING OF TECHNICAL BID
16.1 The Technical Bid will be opened on 07.11.2023 onwards on website
www.tendersodisha.gov.in as mentioned in Para 3.0 (q) of NIT. Intending bidders
or their representative who wish to participate in online tender opening can log on to
www.tendersodisha.gov.in on the due date and time after online opening of the bid
by the authorized officer. The bidders who wish to remain present at Office chamber
of the Chief Construction Engineer, Deo Irrigation Project, Karanjia, District-
Mayurbhanj premise at the time of tender opening can do so. Only one representative
of each firm will be allowed to remain present. The price bid will be opened after
Government’s decision on technical bid of tender. All the statements, documents,
certificates, Bank Guarantee and technical proposals will be verified for evaluation.
The clarification on particulars, if any required from the Bidders will be obtained by
addressing the bidders. The bids will be evaluated against the specified
parameter/criteria and the qualified bidders will be identified.
16.2 If any of the Bidders is not present at the time of opening of Bids, the Bid opening
authority will be opening the Bid of the absentee Bidder, read out and record the
deficiencies if any, which shall be binding on the Bidder.
16.3 The bids not accompanying with documents as per clause No 14 of “Instruction to
Bidders” will be considered as non-responsive.
16.4 Bid capacity & the technical proposal of the bidders who have submitted the EMD &
tender fee, submitted registration certificate, Power of attorney, No relationship
Certificate, shall be scrutinized.
16.5 To qualify for award of contract each bidder who meets the minimum qualification
criteria will be qualified only if their available bid capacity is more than employer’s
estimated cost of the work. The available bid capacity will be calculated as under:
CONTRACTOR 19/27 SUPERINTENDING ENGINEER
SECTION-II INSTRUCTION TO BIDDERS
18.2 Total Cost of the bid for evaluation shall be the sum of the Bid Price quoted for
execution of work vide Item 1 of Appendix-FB and the total O&M cost for 5
years (item-2 of Financial Bid in Appendix-FB)
18.3 The tender inviting authority shall evaluate and compare the price bids of all the
responsive & qualified Bidders.
18.4. Selection of Bidder among the lowest & equally quoted Bidders will be in the
following orders:
18.4.1 The Bidder whose bid capacity is higher will be selected.
18.4.2 In case the bid capacity is also same the Bidder whose annual turnover is more
will be preferred.
18.4.3 Even if the criteria incidentally become the same, the turnover on similar works
and thereafter machinery available for the work and then the clean track record of
the firm will be considered for selection.
18.4.4 In case of any discrepancy between the overall Contract price quoted in words and
figures, the price quoted in words shall prevail.
19.0 PROCESS TO BE CONFIDENTIAL
19.1 Information relating to the examination, clarification, evaluation and comparison
of Bids and recommendations for the award of a contract shall not be disclosed to
bidders or any other persons not officially concerned with such process until the
award to the successful bidder has been announced by the Bid accepting authority.
19.2 Any effort by a Bidder to influence the processing of Bids or award decisions may
result in the rejection of his Bid.
19.3 No Bidder shall contact the bid inviting authority or any authority concerned with
finalization of Bids on any matter relating to its Bid from the time of the Bid
opening to the time the Contract is awarded.
19.4 Before recommending / accepting the Bid, the Bid recommending / accepting
authority shall verify the correctness of certificates submitted to meet the
eligibility criteria and specifically experience. The authenticated contracts of
previous works executed by the lowest Bidder shall be called for.
19.5 If the contract price quoted by a Bidder is found to be either abnormally high or
within the reasonable limits but under collusion or due to unethical practices
adopted at the time of bidding process, such Bids shall be rejected.
20.0 AWARD OF CONTRACT: The Authority after evaluation of price bid shall
recommend to the Competent Bid Accepting Authority for acceptance of the bid
to the Bidder who is found qualified as per the Bid conditions and whose price bid
is evaluated as the lowest responsive bidder.
20.1 In case of Abnormally Low bid : APS( Additional Performance Security) shall be
obtained from the bidder when the bid amount is less than estimated cost put to
tender . In such event, only the successful bidder who has quoted less bid price/
rates than the estimated cost put to tender shall have to furnish following APS in
shape of Term Deposit Receipt/Bank Guarantee pledged in favour of the
DivisionalOfficer within seven days of issue of LOA by the Divisional Officer (by
e-Mail) to the successful bidder, otherwise the bid shall be cancelled and the
security deposit shall be forfeited. Further proceeding for blacklisting shall be
initiated
CONTRACTOR 21/27 SUPERINTENDING ENGINEER
SECTION-II INSTRUCTION TO BIDDERS
against bidder. The authority shall return the APS to the contractor within 28
(Twenty Eight) days from the date of issue of completion certificate.
20.2 The Bid accepting authority reserves the right to accept or reject any Bid or all
Bids and to cancel the Bidding process, at any time prior to the award of Contract,
and shall not bear any liability for such decision and shall not have obligation to
inform the affected Bidder of the reasons.
20.3 The Bidder whose Bid has been accepted will be notified of the award of the work
by the Bid Inviting Authority, prior to expiry of the Bid validity period by
registered letter/Speed Post. This letter (hereinafter and in the Contract called
“Letter of Acceptance”) will indicate the sum that the Government will pay the
Contractor in consideration of the execution, completion, and maintenance of the
Works by the Contractor as prescribed by the Contract (hereinafter and in the
Contract called “Contract Amount”).
21.0 INITIAL SECURITY DEPOSIT
21.1 When a Bid is to be accepted the concerned Bidder shall attend the office of the
Engineer-in-Charge concerned on the date fixed in the Letter of acceptance. Upon
intimation being given by the Chief Construction Engineer, Deo Irrigation Project,
Karanjia, District-Mayurbhanj of acceptance of his Bid, the successful Bidder
shall have to pay initial security deposit (ISD)(As per OPWD guideline) and APS.
Agreements in two parts, Part-I: Work and Part-II: Operation & Maintenance of
the system shall be executed as per the Format given in Section III. The agreement
amount for Part-I: Work shall be bid amount of Sl.1 of the financial bid, Appendix
FB of Financial bid. The agreement amount for Operation & Maintenance of the
system shall be the amounts vide Item 2 of the Appendix FB of Financial bid. The
ISD @ 2% of the contract amount for each part of agreement in the shape of NSC/
Post Office Saving Account/ Post Office Time Deposit Account /KishanVikas
Patra/ unconditional and irrevocable Bank Guarantee (BG) pledged in favour of
Superintending Engineer, Deo Head Works Division, Karanjia in the standard
format on any Nationalized/ Scheduled Commercial Bank located anywhere in the
country with branches at Bhubaneswar with facility of authentication &
encashment at Bhubaneswar Branch.
21.2 The validity of the ISD for Part-I: Work Agreement shall be for a total period
not less than the stipulated period of the completion of the work in question, plus
the defects liability period plus three months.
CONTRACTOR 22/27 SUPERINTENDING ENGINEER
SECTION-II INSTRUCTION TO BIDDERS
21.3 The validity of the ISD for Part-II O & M Agreement shall be for a total period
not less than stipulated period of completion plus the period of O & M plus three
months.
21.4 The bidder shall enter into a contract in the form prescribed by the department for
the due fulfillment of the contracts. Failure to attend the Engineer-in-Charge
office on the date fixed, in the written intimation, to enter into the required
contract, they will be suspended for a period of three years. The written contract
entered into between the contractor and the Government shall be the foundation of
the rights and obligations of both the parties and the contract shall not be deemed
to be complete until the contract has first been signed by the contractor and then
by the proper officer authorized to enter into contract on behalf of the
Government.
21.5 The successful Bidder has to sign the contracts within the date specified in the
letter of acceptance. The issue of letter of acceptance shall be treated as closure of
bid process. On failure to do so his Bid will be cancelled and they will be
suspended for a period of three years without issuing any further notice and action
will be initiated for black listing the Bidder.
21.6 The date of issue of work order shall be treated as date of commencement of
work.
22 BID AMOUNT:
The bid amount to be quoted by the bidder shall be exclusive of GST but inclusive
of all statutory taxes, royalty, duties & other ancillary works mentioned in the
documents. No claim whatsoever in this connection shall be entertained under any
circumstances.
or other source shall be used in the work. In every case the material must comply
with the relevant standard specifications. Samples of materials as called for in the
standard specifications or in the Bid notice or as required by the Engineer-in-
Charge, in any case shall be submitted for the Superintending Engineer's, approval
before the supply to site of work is begun.
25.2 The Bidder’s particular attention is drawn to the sections and clauses in the
standard specifications dealing with
25.2.1 Test, Inspection and rejection of defective materials and work.
25.2.2 Carriage.
25.2.3 Construction plant.
25.2.4 Water and lighting.
25.2.5 Cleaning up during the progress and for delivery
25.2.6 Accidents.
25.2.7 Delays.
25.2.8 Particulars of payments.
25.3 The contractor should closely peruse all the specifications clauses, which govern the
bid he is bidding.
25.4 The contractor is responsible for the quality of works executed. If any defects are
noticed during execution of the work and the defect liability period after completion
of works, the contractor has to rectify at his own cost.
25.5 The contractor shall maintain the system for a period of five years covering at least
five flood seasons including the power connectivity, road connectivity, buildings,
plantation, beautification measures etc. The contractor will carry out maintenance or
repair or rectification works in case of any problem or emergency that may arise
when the system is in operation including cost of all labour, materials and
equipments. The contractor shall also prepare an operation & Maintenance Manual
and train the Govt. staffs to carry out subsequent O & M of the project.
25.6 The Bidder will quote lump sum price on the work as a whole. .
25.7 If any alteration in the contract form, the conditions of the contract, the drawings,
and specifications is found to be made by the Bidder then the Bid will be treated as
void.
25.8 A Bidder submitting a quotation which the Bid Accepting Authority considers
excessive and or indicating insufficient knowledge of current Prices or definite
attempt of profiteering will render himself liable to be debarred permanently from
Bidding or for such period as the Bid accepting authority may decide.
25.9 The Bidder should demonstrate availability (owned or leased or to be procured
against mobilization advance) of the Key and critical equipment in the shape of
list and declaration supported by ownership documents necessarily be enclosed
to the Bid on Non Judicial Stamp Paper of worth of Rs.100/- stating. "I do
hereby solemnly declare that I own -------------------------------------procured on
lease the following equipment".
25.10 A prospective bidder is expected to examine all instructions, terms & conditions,
forms and specifications in the Bid Document and fully inform himself as to all the
conditions and matters which may in any way affect the works, his bid or the cost
thereof. Further, failure of furnishing all information required by the Bid Document
or submission of incomplete offers, conditional bids containing deviations from the
bid document shall be rejected as non-responsive.
25.11 It will be imperative for each Bidder to fully inform himself of all local conditions
and factors which may have any effect on the execution of the Works covered under
the specifications and documents. In their own interest, the bidders are particularly
requested to familiarize themselves with the prevailing Income Tax Act, Companies
Act, Customs Act, prevailing Labour Laws and other related Acts and Law.
Further, the bidders are requested to comply with the Insurance Act including
Workmen's Compensation Act and third party insurance and other relevant
provisions particularly with reference to the requirements of taking insurance for
storage, Civil, Structural and Architectural Work, Erection, testing and
commissioning, operation and Maintenance, till the project is handed over to
Employer. Employer shall not entertain any request for clarification from the bidders
regarding such local conditions. It must be understood and agreed that such factors
have properly been investigated and considered by the bidders while submitting their
bids. Failure to do so will not relieve the bidders from responsibility for estimating
properly the cost of successfully performing the work and completion time required
for the Work. Employer will assume no responsibility for any understanding, or
representation concerning conditions made by any of its officers or agents prior to
award of the Contract. Neither any change in the time schedule of the contract nor
any financial adjustments arising thereof shall .be permitted by the Employer, which
arises out of lack of such clear knowledge or its effect on the cost of execution of the
contract on the part of the bidder. Employer shall not entertain any request for
clarifications from the Bidders, regarding any statutory provisions.
25.12 Being a EPC Contract, the Bidder is to take full responsibility for the survey,
Investigation, planning, Design & Engineering and execution of entire work
including commissioning, Trial run of the work complete including operation &
maintenance of the project for a period of five years or five flood seasons whichever
is more from the date of commissioning to be notified by the Employer.
25.13 Survey, Investigation, planning, Designs, Technical Specifications and Technical
Parameters shall conform to Bureau of Indian Standard Codes and/or International
Standards & practices/C.W.C. Manuals / IRC Codes/ Odisha Govt. Department
specifications / Circulars issued by Department from time to time and technical
specification of the bid documents.
25.14 It is understood that all plant, equipment, and works connected with the normal
efficient execution of the Project are covered in the scope, brought out in Bid
Documents. In case of decisions to be taken on issues relating to technical matter of
planning, design & construction, decision of Tender Inviting Authority (Chief
Construction Engineer, Deo Irrigation Project, Karanjia, District-Mayurbhanj)
is final & binding on the contractor.
25.15 While working out their price bid, the bidders are required to take into account entire
scope of the work defined in Bid documents, additional Infrastructure and other
related activities, whatsoever required.
25.16 Bidder shall also include in his price bid, cost of de-mobilization and shipping back
the construction equipment and other equipment/materials etc. from the Project Site.
Annexure – III Revised Bank Guarantee Format for Mobilization Advance Payment ............... 18
Annexure – VI (A)
Bank Certificate ................................................................................................... 21
Annexure – VI (B)
Form of Solvency Certificate by Banks .............................................................. 21
SECTION – III FORMS & ANNEXURES
FORM-A
Sir,
I / We do hereby Bid and if this Bid be accepted, under take to execute and complete the
following work: - Construction of Khairibhandan Barrage Project on river Khairibhandan at
village Anlabeni, Jashipur Block, District – Mayurbhanj, State- Odisha including hydro-
mechanical works, Head Regulator left & right, construction of aflux bund & coffer dam,
dewatering during construction, Power connectivity works to project site & colony, road
connectivity, including survey, investigation, planning, design and estimate of all components
with operation and maintenance of the project for a period of five years or five flood seasons
whichever is more after successful commissioning of the project.
1. I/We have quoted the bid in Price Bid vide Annexure – FB-I for which l/we agree to
execute the work at the quoted lump sum amount under the terms of the contract.
2. In case of any discrepancy between the bid price quoted in words and figures, the bid
price quoted in words only shall prevail.
3. I/We agree to keep the Bid validity in this Bid for a period of 180 days from the last date of
submission of bid, mentioned in the Bid notice and not to modify the whole or any part of it
for any reason within above period. If the Bid is withdrawn by me/us for any reasons
whatsoever, the earnest money paid by me/us will be forfeited to Government.
4. I/We hereby distinctly and expressly, declare and acknowledge that, before the submission
of my/our Bid I/We have carefully followed the instructions in the Bid document and have
read the technical Specification therein and the and that I/We have made such examination
of the contract documents and the plans, specifications and of the location where the said
work is to be done, and such investigation of the work required to be done, and in regard to
the equipments and material required to be furnished as to enable me/us to thoroughly
understand the intention of same and the requirements of covenant/contracts, stipulations
and restrictions contained in the contract, and in the said plans and specifications and
distinctly agree that I/We will not hereafter make any claim or demand upon the
Government based upon or arising out of any alleged misunderstanding or misconception
/or mistake on my/or our part of the said requirement of covenants/contracts, stipulations,
restrictions and conditions.
5. I/We shall not assign the contract or sublet any portion of the same. In case if it becomes
necessary I/We shall submit the same at the time of filing Bids itself or during execution,
CONTRACTOR 1/29 SUPERINTENDING ENGINEER
SECTION – III FORMS & ANNEXURES
giving the name of the sub-contractor with details of his qualification and experience and
agree to sublet with permission of Bid accepting authority only to such of the sub-
contractors who satisfies the qualification criteria in proportion to the value of work
proposed to be sublet. No part of the work shall be sub-let to other short-listed bidders.
6. If upon written intimation to me/us about acceptance my/our bid, by the Authorized
officer of Govt. of Odisha, I/We fail to attend the said office on the date herein fixed or
and if I/We fail to make the initial security deposit (ISD) to enter into the required
contract as defined in the instructions to Bidders, then I/We agree to be suspended for a
period of three years. Any notice required to be served on me/us here under shall be
deemed to have been sufficiently served on me/us if delivered to me/us personally or
forwarded to me/us by post (registered/Speed Post/ ordinary/e-mail) or left at my/our
address given herein.
7. I/We fully understand that the written contract to be entered into between me/us and
Government shall be the foundation of the rights of the both the parties and the contract
shall not be deemed to be complete until the contract has first been signed by me/us and
then by the proper officer authorized to enter into contract on behalf of Government.
8. I/We declare that I/We agree to recover the salaries of the technical staff actually engaged
on the work by the department, from the work bills, if I/We fail to employ technical staff
as per the Bid condition.
1. I/We am/are prepared to furnish detailed data in support of all my quoted rates, if and
when called upon to do so without any reservations.
2. I/We hereby declare that I/We shall not claim any price escalation except as provided in
the bidding documents.
3. I/We declare that the I/We shall take up the responsibility for processing for land
acquisition, for execution of all components of work, in the name of Department of Water
Resources, Odisha as per conditions of contract and arranging and obtaining the land for
disposal of spoil/soil not useful for construction purposes shall rest with me/us.
4. I/We hereby declare that the responsibility of processing for getting statutory clearances
of forest & environment & other department/commission/authority on behalf of the
Department of Water Resources as per Conditions of Contract for execution/completion
of work rests on me/us.
5. I/We declare that I/We will execute the work as per the mile stone programme, and if
I/We fail to complete the work as per the mile stone programme I abide by the condition
to recover liquidated damages as per the Bid conditions.
6. I/We declare that I/We will abide for settlement of disputes as per the Bid conditions.
7. I/We have not been black listed in any department in Govt. of Odisha and in any other
state/Union Govt. due to any reasons.
8. I/We have not been demoted to the next lower category for not filing the Bids after
buying the Bid schedules in a whole year and my/our registration has not been cancelled
for a similar default in two consecutive years.
9. I/We hereby certify that all the statement made and information supplied in enclosed
Forms and accompanying statements and Annexure are true and correct.
10. I/We agree to disqualify me/us for any wrong declaration in respect of the above and to
summarily reject my/our Bid.
SEAL
Form – B
ARTICLES OF CONTRACT
Whereas the Government of Odisha (herein after called the Government) are desirous
of taking up the work for Construction of Khairibhandan Barrage Project on river
Khairibhandan at village Anlabeni, Jashipur Block, District – Mayurbhanj, State- Odisha
including hydro-mechanical works, Head Regulator left & right, construction of aflux bund &
coffer dam, dewatering during construction, Power connectivity works to project site &
colony, road connectivity, including survey, investigation, planning, design and estimate of all
components with operation and maintenance of the project for a period of five years or five
flood seasons whichever is more after successful commissioning of the project
and have caused a proposal contained in Basic Project Profile, Instruction to Bidder,
Conditions of contract, Special Conditions of Contract, Conditions of Contract for O&M,
Technical Specifications and drawings describing the work to be prepared /to be done.
And whereas the said Basic Project Profile, drawings, Notice inviting Tenders
Instruction to Bidders, General condition of Contract, Special conditions & Technical
Specification, Conditions of contract for O &M & other appendices and annexures etc. of
contract documents (herein after referred as contract) as have been signed by on behalf of the
parties here to.
And whereas for the Part I: Works of Agreement, the contractor has produced
and
AND
For the Part II: O & M of Agreement the contractor has produced
And whereas the contractor has agreed that during the course of the contract period an amount
at the rate of 5.0 % (Five) of the value of work done will be withheld from the bills as
Performance Security Deposit.
And whereas the contractor has agreed to execute upon the contract, subject to the Scope of
work described in all sections and conditions & specifications forming part of the contract
(herein after referred to as the said conditions), and set forth in Annexure - FB as the Financial
bid and comply with the rate of progress noted in the conditions for a sum of rupees Rs.
(Rupees ) on lump sum basis and such other
sum as may be arrived at under the clauses of the contract documents relating to payment
And whereas the contractor has agreed to execute the subject work in two parts,
namely Part:I Works for a sum of Rs.
(Rupees ) and (Part II:O & M for a sum of
Rs (Rupees ), both
totaling to a sum of (Rupees _ ) as mentioned
in the Para above.
1. Time shall be considered as the essence of the contract and the contractor hereby
agrees to commence the work as soon as the contract is signed and agrees to
complete the work within .......................... months from the date of such signing the
contract and to show the progress as per milestone subject nevertheless to the
provisions for extension of time contained in the conditions of contract.
2. The conditions of the bid document & technical specification shall be read and
construed as forming part of this contract and the parties here to will respectfully
abide by and submit themselves to the conditions and stipulations and perform the
contract on their part, respectively.
3. Upon the terms and conditions of this contract being fulfilled and preformed to the
satisfaction of the Superintending Engineer, the security deposited by the Contractor
as herein before recited or such portion thereof as he may be entitled to under the
said condition shall be returned to the contractor as provided in the contract.
In witness thereof, the contractor M/s. duly represented by Sri
has here unto set his hand and Sri
Superintending Engineer acting on behalf of and
by the order and direction of his Excellency, the Governor of Odisha has here unto
set hishand the day and year first above written.
Signed by contractor:
SEAL
CONTRACTOR 6/29 SUPERINTENDING ENGINEER
SECTION – III FORMS & ANNEXURES
Address :
SEAL
Form- C1
Sr.
Description Remarks
No.
1 Name of bidder
[B] Date
Form – C2
DETAILS OF COST OF ISD
Sr.
Description Remarks
No.
1 Name of bidder
[B] Date
ISD Details
[A] FDR Details (In favor of the concerned Superintending Engineer only) (no
jointoperation)
Amount in
Note–Please see clause 21& its sub clause Instruction to Bidders for validity period.
Form - D
RELATIONSHIP DECLARATION
To,
The Tender Inviting Officer,
Chief Construction Engineer
Deo Irrigation Project, Karanjia, District-Mayurbhanj
Subject: (Name of the Work)
Reference: Bid Identification No.03/CCEDIP of 2023-24(Online)
Sir,
Pursuant to the ITB, it is to inform that I have relative(s) employed as an Officer in the rank of
an Assistant Engineer/Under Secretary under the WR Department. His (Their) details are
as follows.
Relationship: Name:
Designation Office
Address
Pursuant to the ITB, I am to submit herewith the names of persons who are working under
my firm having near relatives to any gazette officer in the rank of an Assistant
Engineer/Under Secretary in the Department.
Sl. Name of the my Presently Details of his relatives working in the
No employee and his working at Department
designation in the firm
Relationship
Name:
Office
Address
Relationship
Name:
Designation
Office
Address
I am also duty bound to inform the relationship of any subsequent employment with any
gazette officer in the rank of an Assistant Engineer /Under Secretary under the Department. I
am aware that any breach of this condition would render my firm liable for penal action for
suppression of facts.
I am also duty bound to inform that I have no relations with any employee working in the rank
of or above the rank of any Assistant Engineer/ Under Secretary under this Department of
Water Resources, Govt of Odisha.
Yours Sincerely,
SIGNATURE OF THE BIDDER
NB: Please strike out the Para not applicable.
Form: E
Procurement
deployment
Is it free for
Equipment
Condition
Remarks
Location
Type of
Present
Present
Year of
Owned
project
in new
Make/
Model
Sl. No
Nos.
1 2 3 4 5 6 7 8 9
Form – F
DETAILS OF WORKS IN HAND INSIDE INDIA
Amount of works to be
done during Period of
Contract (2022-23 Yr
Date of issue of work
Tendered amount in
2024-25 Yr)
completion
Remarks
Sl. No.
Crores
Place
order
to
1 2 3 4 5 6 7 8 9 10
Form - G
DETAILS OF FINANCIAL CAPABILITY
FINANCIAL CAPABILITY
NAME OF APPLICANT:
Total Assets
Current Assets
Total Liabilities
Net Worth
Working Capital
Current liabilities
Form - H
DETAILS OF PERSONNEL
Give details of key Technical and Administrative Personnel who could be assigned the
work in the following Proforma.
A) Details of the Board of Directors
1) Name of the Director
2) Address
3) Organization of the Board of Director
B) Key Technical and administrative
Personnel and Consultants
1) Project Manager (Min. 5years
experience)
2) Site Engineer
(a) Civil
(b) Mechanical
(c) Electrical
3) Supervisor
(a) Civil
(b) Mechanical
(c) Electrical
4) Technical assistants.
C) Skilled and other labour (indicate
number category wise)
1) Skilled labour
2) Other labour
SIGNATURE OF BIDDER
Form - I
ADDITIONAL INFORMATION
(A) Please add any further information which the applicant considers relevant in regard to
his capabilities.
(B) Please give a brief note indicating why applicant considers himself eligible
(C) List of works for which tender have already been submitted to the client but not
awarded.
SIGNATURE OF BIDDER
Form – J
DECLARATION BY AFFIDAVIT
(ON NON-JUDICIAL STAMP PAPER)
Annexure-I
That in the event we withdraw / modify our bid during the period of validity
Or I/we fail to execute formal contract agreement within the given timeline Or I/we
commit any breach of Tender Conditions / Contract which attracts penal action of
forfeiture of EMD and I/we will be suspended from being eligible for bidding /award
of all future contract(s) of Government of Odisha for a period of three year from the
date of committing such breach.
Name of Authorized
Signatory.................................
Company
Name.....................................................
...
Annexure – I
[Ref: - Clause 15.13 of Section – II, Volume – I of Bid Identification No. 03/CCEDIP of 2023-24(Online)]
WHEREAS _________________________________________________________________
(name and address of Contractor) (hereinafter called “the Contractor”) has to participate in the
tender for EPC Contract in respect of work ___________________ (Name of Work) invited by
the Chief Construction Engineer Deo Irrigation Project, Karanjia and submitted to the
Superintending Engineer, Deo Head Works Division, Karanjia vide e procurement Notice
No.___________________________ Tender Id. ________________________
AND WHEREAS it has been stipulated by you in the said Tender that the Bidder willl
furnish you with a Bank Guarantee from a Scheduled Bank having its Branch in Odisha in favour
of Superintending Engineer, Deo Head Works Division, Karanjia for the sum specified therein as
Bid Security / Earnest Money Deposit (EMD), for participation in the said Tender.
AND WHEREAS we have agreed to give the Contractor such a Bank Guarantee;
NOW THEREFORE we hereby affirm that we are the Guarantors and responsible to you, on
behalf of the Contractor, up to a total of Rs _________________ [amount of guarantee] Rupees
_____________________________ [in words], such sum being payable and we undertake to pay
you, upon your first written demand declaring the supplier to be in default under the contract and
without cavil or argument, any sum or sums within the limits of
Rs____________________________ [amount of guarantee] as aforesaid without your needing to
prove or to show grounds or reasons for your demand for the sum specified therein.
We hereby waive the necessity of your demanding the said debt from the Contractor
before presenting us with the demand.
We further agree that no change or addition to or other modification of the terms of the Contract
or of the Works to be performed there under or of any of the contract documents which may be
made between you and the Contractor shall in any way release us from any liability under this
guarantee, and we hereby waive notice of any such change, addition or modification.
This guarantee shall be valid up to _____________ day of __________ 20 _______ i.e.,
upto 3 (three) months beyond the Valid Period of the bid for the work.
We ______________________ (Name of Bank) hereby also undertake to have the
signature of Branch Manager issuing Bank Guarantee verified from Local Branch of the Bank in
Bhubaneswar, ______________________________ (address of Local Branch Bhubaneswar,
Odisha) for due authentication.
Our_______________________ branch at Bhubaneswar (Name & Address of the
_____________________ branch) is liable to pay the guaranteed amount depending on the filing
of claim and any part thereof under this Bank Guarantee only and only if it is served upon us by
the employer at our Bhubaneswar Branch, a written claim or demand and received by us at our
Bhubaneswar branch on or before Dt. ________________ otherwise bank shall be discharged of
all liabilities under this guarantee thereafter.
Signature of the authorized officer of the Bank)
……..………………………………………..
……..………………………………………..
Name and designation of the officer
.……..……………………………………….
Seal, name & address of the Bank and address of the Branch
Account Name :
Beneficiary Bank :
account No.
IFSC Code :
MICR Code :
Branch Address :
Bank Email Id :
Annexure – II
[Ref: - Clause 21.0 of Section – II, Volume – I of Bid Identification No. 03/CCEDIP of 2023-24(Online)]
WHEREAS (name
and address of Contractor) (herein after called “the Contractor”) has to undertake a contract, in
pursuance of Letter of acceptance No. dated of
Superintending Engineer, to execute the work of [name of
work] (herein after called “the contract”)
AND WHEREAS it has been stipulated by you in the said Contract that the Contractor
shall furnish you with a Bank Guarantee by a Nationalized/Scheduled Commercial Bank with
branches at Bhubaneswar for the sum specified therein as Initial Security, for compliance
with his obligations in accordance with the Contract;
AND WHEREAS we have agreed to give the Contractor such a Bank Guarantee;
NOW THERE FORE we hereby affirm that we are the Guarantors and responsible to you,
onbehalf of the Contractor, up to a total of Rs [amount of guarantee]
Rupees [in words], such sum being payable and we
undertake to pay you, upon your first written demand declaring the supplier to be in default
under the contract and without cavil or argument, any sum or sums within the limits of Rs
[amount of guarantee] as aforesaid without
your needing to prove or to show grounds or reasons for your demand for the sum specified
therein.
We hereby waive the necessity of your demanding the said debt from the Contractor
before presenting us with the demand.
We further agree that no change or addition to or other modification of the terms of the
Contract or of the Works to be performed there under or of any of the contract documents
which may be made between you and the Contractor shall in any way release us from any
liability under this guarantee, and we hereby waive notice of any such change, addition or
modification.
filing of claim and any part thereof under this Bank Guarantee only and only if it is served
upon us by the employer at our Bhubaneswar Branch, a written claim or demand and received
by us at our Bhubaneswar branch on or before Dt. otherwise bank shall
be discharged of all liabilities under this guarantee thereafter.
……..………………………………………..
……..………………………………………..
.……..……………………………………….
Seal, name & address of the Bank and address of the Branch
Annexure-III
Revised Bank Guarantee Format for Mobilization Advance Payment
[Ref. Clause 49.0, Section – IV, Vol – I of Bid Identification No. -03/CCEDIP of 2023-24(Online)]
THIS DEED OF GUARANTEE made on ………………… day of ……………. 20 ........... BETWEEN
……………………… Bank, a Banking Company incorporated under the Banking Companies Act, 19
……. And having its registered office at …………………. In the State of ……………………
(hereinafter called the ‘Guarantor’) of the ONE PART AND the Governor of Odisha (hereinafter
called the ‘Government’) of the OTHER PART.
WITNESS AS FOLLOWS: -
In consideration of the Governor of Odisha (hereinafter called the ‘Government’) having agreed to
advance a sum of Rs……………………. (Rupees ……………………………………………) to
…………………. (name and address of the contractor) (herein after called “the Contractor”) against
the work concerned by and under the terms and conditions upon agreement No. …………………….
dated ............................. made between the contractor and the Governor of Odisha, on production of a
bank guarantee for ` ……………………… (Rupees........................................................................ ) we
here by guarantee the payment of sums of money that may be due to the Government on account of any
breach of the terms and conditions contained in the aforesaid contract on demand with interest at 10%
per annum till payment.
1. We hereby further agree that we are aware of all the terms and conditions of the said contract
and shall abide by the decision of the Secretary to Government of Odisha, Water Resources
Department, as to whether there has been any breach of the terms and conditions of the said
contract and as to whether the supplier is liable to pay any sum as so determined.
2. Any demand made to us for payment of any sum in discharge of this guarantee shall be
conclusive proof of the fact that there has been a breach of said contract by the suppliers
which warrants the enforcement of this guarantee and is binding on the Bank without
prejudice to the claims and counter claims of the parties in the proper court of law.
3. This guarantee shall continue to be enforceable till all dues of the Government under or by
virtue of the said contract have been fully paid and its claims are satisfied or discharged or till
the Water Resources Department of the State Government certifies the terms and conditions
of the said contract have been fully and properly carried out by the said contractor and
according discharges the guarantee subject however that the Government has no right under
this bond after the expiry of contract period or the extended contract period From the date of
its execution, unless the said Government choose to further extend the said period or extended
period of guarantee by giving reasonable notice in writing to the bank on account of any
special circumstances of which the Government shall be the sole judge.
This guarantee shall be valid until the ………… day of ………………., 20
……………………. We (Name of Bank) hereby also undertake to have the signature of
Branch Manager issuing Bank Guarantee verified from Local Branch of the Bank in Bhubaneswar,
…………………………………………. (Address of Local Branch Bhubaneswar, Odisha) for
due authentication.
Our……………………………………………… branch at Bhubaneswar (Name & Address of the
………………………… branch) is liable to pay the guaranteed amount depending on the filing of
claim and any part thereof under this Bank Guarantee only and only if it is served upon us by the
employer at our Bhubaneswar Branch, a written claim or demand and received by us at our
Bhubaneswar branch on or before Dt. ……………… otherwise bank shall be discharged of all
liabilities under this guarantee thereafter.
………………………..
(Signature of the authorized officer of the Bank)
……………………………………………..
[Ref: - Clause 50 of Section – IV, Volume – I of Bid Identification No. –03/CCEDIP of 2023-24(Online)]
WHEREAS
(name and address of Contractor) (herein after called “the Contractor”) has undertaken a contract, in
pursuance of Contract No. dated of Superintending
Engineer, ............................... to execute the work of [name of work] (herein
after called the contract”)
AND WHEREAS it has been stipulated by you in the said Contract that the Contractor shall
furnish you with a Bank Guarantee by a Nationalized/Scheduled Commercial Bank with branches at
Bhubaneswar for the release of Performance Security, for compliance with his obligations in
accordance with the Contract;
AND WHEREAS we have agreed to give the Contractor such a Bank Guarantee;
NOW THEREFORE we hereby affirm that we are the Guarantors and responsible to you, on behalf of
the Contractor, up to a total of Rs [amount of guarantee]
[in words], such sum being payable and we undertake to pay you,
upon your first written demand declaring the supplier to be in default under the contract and without
cavil or argument, any sum or sums within the limits of Rs
[amount of guarantee] as aforesaid without your needing to prove or to show grounds or reasons for
your demand for the sum specified therein.
We hereby waive the necessity of your demanding the said debt from the Contractor before
presenting us with the demand.
We further agree that no change or addition to or other modification of the terms of the
Contract or of the Works to be performed there under or of any of the contract documents which may
be made between you and the Contractor shall in any way release us from any liability under this
guarantee, and we hereby waive notice of any such change, addition or modification.
……..………………………………………..
……..………………………………………..
.……..……………………………………….
Seal, name & address of the Bank and address of the Branch
ANNEXURE-V
Litigation History
Name of Applicant:
Please describe: Company’s history of litigation or arbitration from contract executed in the
last ten years or currently under execution. Please indicate for each case the year, name of
employer, cause of litigation, matter in dispute, disputed amount, and whether the award was for
or against the company.
SIGNATURE OF BIDDER.
If the contractor for the work namely “insert name of the work” is awarded to the
above firm, we shall be able to provide overdraft/ credit facilities to the extent of Rs
…………… (In words) to meet their working capital requirements for executing the above
work.
I, Managing
Director / Manager / General Manager / Agent of
bank Limited do hereby certify
that a
[here the Names and addresses of the
agency] to be solvent to the extent of [Rupees
Date:
Place:
Signature of Bank Manager
[Authorized Signatory]
APPENDIX -I
AND we hereby agree to ratify and confirm and do hereby ratify and confirm all acts, deeds
and things done or caused to be done by our said Attorney pursuant to and in exercise of the
powers conferred by this Power of Attorney and that all acts, deeds and things done by our
said Attorney in exercise of the powers hereby conferred shall and shall always be deemed
to have been done by us.
For …………………………..
Witnesses:
1.
(Notarised)
Appendix I
Page 2
Accepted
……………………………
(Signature)
Notes:
The mode of execution of the Power of Attorney should be in accordance with the
procedure, if any, laid down by the applicable law and the charter documents of the
executant(s) and when it is so required, the same should be under common seal affixed in
accordance with the required procedure.
Wherever required, the Applicant should submit for verification the extract of the charter
documents and documents such as a board or shareholders’ resolution/ power of
attorney in favour of the person executing this Power of Attorney for the delegation of
Powe hereunder on behalf of the Applican.
APPENDIX - II
FORMAT FOR POWER OF ATTORNEY FOR LEAD MEMBER
OF JOINT VENTURE
Refer Clause 79(L)
Whereas the Water Resources Department, Govt. of Odisha through the Chief
Construction Engineer, Deo Irrigation Project, Karanjia, District-Mayurbhanj (“the
Employer”) has invited applications from interested on parties for the (Name of the project to be
inserted) on Percentage rate contract (the “Project”).
Venture”) being Members of the Joint Venture are interested in bidding for the Project in accordance
with the terms and conditions of the Standard Bidding Document (SBD) and other connected
documents in respect of the Project, and
Whereas, it is necessary for the Members of the Joint Venture to designate one of them as the Lead
Member with highest share in the joint venture with all necessary power and authority to do for and
on behalf of the Joint Venture, all acts, deeds and things as may be necessary in connection with the
Joint Venture’s bid for the Project and its execution.
AND hereby agree to ratify and confirm and do hereby ratify and confirm all acts, deeds and things
done or caused to be done by our said Attorney pursuant to and in exercise of the powers conferred by
this Power of Attorney and that all acts, deeds and things done by our said Attorney in exercise of the
powers hereby conferred shall and shall always be deemed to have been done by us/ Joint Venture.
APPENDIX II
Page 2
For ……………………..
(Signature)
……………………..
For ……………………..
(Signature)
……………………..
Witnesses:
1.
2.
………………………………………
(Executants)
Notes:
The mode of execution of the Power of Attorney should be in accordance with the
procedure, if any, laid down by the applicable law and the charter documents of the
executant(s) and when it is so required, the same should be under common seal affixed in
accordance with the required procedure.
Also, wherever required, the Applicant should submit for verification the extract of the
charter documents and documents such as a board or shareholders’ resolution/ power of
attorney in favour of the person executing this Power of Attorney for the delegation of
power hereunder on behalf of the Applicant.
APPENDIX III
FORMAT FOR JOINT BIDDING AGREEMENT FOR JOINT VENTURE
Refer Clause 79(M)
(To be executed on Stamp paper of appropriate value)
THIS JOINT BIDDING AGREEMENT is entered into on this the ………… day of …………
20…
AMONGST
1. {………… Limited, a company incorporated under the Companies Act, 1956} and
having its registered office at ………… (hereinafter referred to as the “First Party”
which expression shall, unless repugnant to the context include its successors and
permitted assigns). The “First Party” is the lead partner with ..…. % share in the
joint venture.
AND
2. {………… Limited, a company incorporated under the Companies Act, 1956} and
having its registered office at ................. (hereinafter referred to as the “Second Party”
which expression shall, unless repugnant to the context include its successors and
permitted assigns).The “Second Party” is the lead partner with ..…. % share in the
joint venture..
WHEREAS,
(A) THE Water Resources Department, Govt. of Odisha represented through the Chief
Construction Engineer, Deo Irrigation Project, Karanjia, District-Mayurbhanj and
having its offices at Office ofthe Superintending Engineer, Deo Head Works Division,
Karanjia, Odisha (hereinafter referred to as the “Employer” which expression shall,
unless repugnant to the context or meaning thereof, include its administrators,
successors and assigns) has invited applications (the Applications”) by its Invitation
for Bids (IFB) with Bid Identification No. 03/CCEDIP of 2023-24 (Online) dated
……..........……(the “SBD”) for qualification of bidders (Name of the project to be
inserted) on Percentage rate Project (the “Project”) through a Percentage rate
Contract.
(B) The Parties are interested in jointly bidding for the Project as members of a Joint
Venture and in accordance with the terms and conditions of the Bid document and
other bid documents in respect of the Project, and
(C) It is a necessary condition under the Bid document that the members of the Joint
Venture shall enter into a Joint Bidding Agreement and furnish a copy thereof with the
Application.
NOW IT IS HEREBY AGREED as follows:
1. Definitions and Interpretations
In this Agreement, the capitalized terms shall, unless the context otherwise requires,
have the meaning ascribed thereto under the Bid.
2. Joint Venture
2.1 The Parties do hereby irrevocably constitute a Joint Venture (the “Joint Venture”) for
the purposes of jointly participating in the Bidding Process for the Project.
2.2 The Parties hereby undertake to participate in the Bidding Process only through this
Joint Venture and not individually and/ or through any other Joint Venture constituted
for this Project, either directly or indirectly.
APPENDIX III
Page 2
3. Covenants
The Parties hereby undertake that in the event the Joint Venture is declared the
selected Bidder and awarded the Project, it shall enter into a percentage Contract with
the Employer for performing all its obligations as the Contractor in terms of the
Contract for the Project.
4. Role of the Parties
The Parties hereby undertake to perform the roles and responsibilities as described
below:
(a) The First Party shall be the Lead member of the Joint Venture and shall have
the power of attorney from all Parties for conducting all business for and on
behalf of the Joint Venture during the Bidding Process and until the Appointed
Date under the Contract;
(b) The Second Party shall be {the Member of the Joint Venture; and}
5. Joint and Several Liability
The Parties do hereby undertake to be jointly and severally responsible for all
obligations and liabilities relating to the Project and in accordance with the terms of
the Bid and the Contract, till such time as the completion of the Project is achieved
under and in accordance with the Contract.
6. Share of work in the Project
The Parties agree that the proportion of construction in the Contract to be allocated
among the members shall be as follows:
First Party:
Second Party:
Further, the Lead Member (First Party) shall itself undertake and perform at least 51
(Fifty one) per cent or above and the Second party shall itself undertake and perform
at least 25 (Twenty five) per cent or above respectively of the total project if the
Contract is allocated to the Joint Venture.
7. Representation of the Parties
Each Party represents to the other Party as of the date of this Agreement that:
(a) Such Party is duly organized, validly existing and in good standing under the
laws of its incorporation and has all requisite power and authority to enter into
this Agreement;
(b) The execution, delivery and performance by such Party of this Agreement has
been authorized by all necessary and appropriate corporate or governmental
action and a copy of the extract of the charter documents and board resolution/
power of attorney in favour of the person executing this Agreement for the
delegation of power and authority to execute this Agreement on behalf of the
Joint Venture Member is annexed to this Agreement, and will not, to the best
of its knowledge:
(i) require any consent or approval not already obtained;
(ii) violate any Applicable Law presently in effect and having applicability
to it;
APPENDIX III
Page 3
(iii) violate the memorandum and articles of association, by-laws or other applicable
organizational documents thereof;
(iv) violate any clearance, permit, concession, grant, license or other governmental
authorization, approval, judgment, order or decree or any mortgage agreement,
indenture or any other instrument to which such Party is a party or by which such Party
or any of its properties or assets are bound or that is otherwise applicable to such Party;
or
(v) create or impose any liens, mortgages, pledges, claims, security interests, charges or
Encumbrances or obligations to create a lien, charge, pledge, security interest,
encumbrances or mortgage in or on the property of such Party, except for
encumbrances that would not, individually or in the aggregate, have a material adverse
effect on the financial condition or prospects or business of such Party so as to prevent
such Party from fulfilling its obligations under this Agreement;
(c) this Agreement is the legal and binding obligation of such Party, enforceable in
accordance with its terms against it; and
(d) there is no litigation pending or, to the best of such Party's knowledge,
threatened to which it or any of its affiliates is a party that presently affects or
which would have a material adverse effect on the financial condition or
prospects or business of such Party in the fulfillment of its obligations under
this Agreement.
8. Termination
This Agreement shall be effective from the date hereof and shall continue in full force
and effect until Project completion (the “Defects Liability Period”) is achieved under
and in accordance with the Percentage rate Contract, in case the Project is awarded to
the Joint Venture. However, in case the Joint Venture is either not qualified for the
Project or does not get selected for award of the Project, the Agreement will stand
terminated in case the Applicant is not pre-qualified or upon return of the Bid Security
by the Employer to the Bidder, as the case may be.
9. Miscellaneous
9.1 This Joint Bidding Agreement shall be governed by laws of {India/ Odisha}.
9.2 The Parties acknowledge and accept that this Agreement shall not be amended by the
Parties without the prior written consent of the Employer.
APPENDIX III
Page 4
(Signature) (Signature)
(Name) (Name)
(Designation) (Designation)
(Address) (Address)
1. 2.
Notes:
1. The mode of the execution of the Joint Bidding Agreement should be in
accordance with the procedure, if any, laid down by the Applicable Law and the
charter documents of the executants(s) and when it is so required, the same
should be under common seal affixed in accordance with the required procedure.
2. Each Joint Bidding Agreement should attach a copy of the extract of the charter
documents and documents such as resolution / power of attorney in favour of the
person executing this Agreement for the delegation of power and authority to
execute this Agreement on behalf of the Joint Venture Member.
3. Clause Deleted.
APPENDIX IV
Page 1
Statement of Legal Capacity
(To be forwarded on the letterhead of the Applicant/ Lead Member of Joint Venture)
Ref. Date:
To,
Dear Sir,
We hereby confirm that we/ our members in the Joint Venture (constitution of
which has been described in the application) satisfy the terms and conditions
laid out in the Bidding document.
We have agreed that ................................. (insert member’s name) will act as the
We have agreed that ............................... (insert individual’s name) will act as our
behalf* and has been duly authorized to submit the Bidding Document.
Thanking you,
Yours faithfully,
SECTION – IV
verify the experience of the Sub-contractor and if the Sub-contractor satisfies the qualification
criteria in proportion to the value of work proposed to be sub-let, including his past track
record of completion and quality of work, he may permit the same. The total value of works
to be awarded on sub-letting shall not exceed 50% of contract value. The extent of subletting
shall be added to the experience of the sub-contractor and to that extent deducted from that of
the main contractor. No part of the work can be sublet to other short-listed bidder of Barrage
Projects of Odisha.
6. Other Contractors:
6.1 The Contractor shall cooperate and share the Site with other contractors, Public authorities,
utilities, and the Department. The Contractor shall also provide facilities and services for
them as directed by the Engineer-in-charge.
7. Personnel:
7.1 The Contractor shall employ the required Key Personnel named in the Schedule of Key
Personnel to carry out the functions stated in the Schedule or other personnel approved by the
Engineer-in-charge. The Engineer-in-Charge will approve any proposed replacement of Key
Personnel only if their qualifications, abilities, and relevant experience are substantially equal
to or better than those of the personnel listed in the Schedule.
7.2 Failure to employ the required technical personnel including quality management staff by the
contractor, the employer would engage any quality assurance staff for implementing quality
management Plan. The amounts spent on such deployment will be recovered from the
contractor over and above the provision made in part two of schedule-A from the contractors
bills. However, this will not absolve the contractor from the responsibility of quality
management on contract works.
7.3 The technical personnel including quality assurance personnel should be on full time and
available at site whenever required by Engineer-in-Charge to take instructions.
7.4 The names of the technical personnel including quality assurance personnel to be employed
by the contractor should be furnished in the statement enclosed separately.
7.5 In case the contractor is already having more than one work on hand and has undertaken more
than one work at the same time, he should employ separate technical and quality assurance
personnel on each work.
7.6 If the contractor fails to employ technical and quality assurance personnel the work will be
suspended, department will engage technical and quality assurance personnel and recover the
cost thereof from the contractor. This will not absolve the contractor from the responsibly of
maintaining quality of work and implementing quality management plan.
7.7 If the Engineer-in-Charge asks the Contractor to remove a person who is a member of
Contractor's staff or his work force stating the reasons, the Contractor shall ensure that the
person leaves the site forthwith and has no further connection with the work in the contract.
7.8 All Contractors’ personnel employed at the plant at any time during the period covered by the
present Contract will be provided by him. The Employer is not liable for personnel in any way
and cannot be held responsible in the event of litigation of any sort between the Contractor
and members of plant personnel or their representatives
8. Contractor’s Risks:
8.1 All risks of loss or damage to physical property and of personnel injury and death, which arise
during and in consequence of the performance of the Contractor, are the responsibility of the
Contractor.
9. Insurance:
9.1 The Contractor shall provide, in the joint names of the Department and the contractor,
insurance cover from the start date to the end of the Defects Liability Period i.e., for 60
months from the date of commissioning & for maintenance period of 5 years or 5 years of
flood seasons whichever is more for the following events.
i. Loss of or damage of property in connection with the Contract; and
ii. Personal injury or death of persons employed for construction
iii. Loss of or damage to the Works, Plant and Materials
iv. Loss or damage to the Equipment.
The minimum insurance amounts shall be:
(a) For the Works, Plant and Materials: Amount fixed by insurance company for 5% of
the Contract Price.
(b) For loss or damage to Equipment: Amount fixed by insurance company for 5% of
the Contract Price.
(c) For loss or damage to property (except the Works, Plant, Materials, and Equipment)
in connection with Contract: Amount fixed by insurance company for 2% of the
Contract Price.
(d) For personal injury or death of the contractor’s employees or other people:
For death: Insurance coverage of Rs. 5.00 lakhs per occurrence
For injury: Insurance coverage of Rs. 1.00 lakh per occurrence
9.2 Policies and certificates of insurance for events i. & ii. above shall be delivered by the
Contractor to the Engineer-in-Charge at the time of concluding Contract. The policies and
certificates of insurance for the events (iii) & (iv) of above clause shall be delivered by the
contractor to Engineer-in-Charge on commencement of work & after finalization of planning
& design. All such insurance shall provide for compensation to be payable to rectify the loss
or damage incurred.
i. The contractor shall furnish insurance policy in force in accordance with proposal
furnished in the Bid and approved by-the Department for concluding the contract.
ii. The contractor shall also pay regularly the subsequent insurance premium and
produce necessary receipt to the Engineer-in-Charge, well in advance.
iii. In case of failure to act in the above said manner the department will pay the
premium and the same will be recovered from the Contractors payments.
9.3 Alterations to the terms of insurance shall not be made without the approval of the Engineer-
in-Charge.
Any amounts not insured or not recovered from the insurers shall be borne by the Contractor
in accordance with their responsibilities under Clause-9.1 above.
The Contractor shall, except if and so far as the Contract provides otherwise, indemnify the
12.2 No separate payment for bailing out sub-soil water, drainage or locked up rain water for
diversion, shoring, foundations, bailing of pumping water either from excavation of soils from
foundations or such other incidental will be paid. The bid price to be quoted by the contractor
is for the finished item of work in situ and including all the incidental charges. The borrow
pits are also to be de-watered by the contractor himself at his expense, if that should be found
necessary.
12.3 The work of diversion arrangements should be carefully planned and prepared by the
contractor and forwarded to the Engineer-in-Charge technically substantiating the proposals
and approval of the Engineer-in-Charge obtained for execution.
12.4 The contractor has to arrange for bailing out water, protection to the work in progress and the
portion of works already completed and safety measures for men and materials and all
necessary arrangements to complete the work.
12.5 All the arrangements so required should be carried out and maintained at the cost of the
contractor and no separate or additional payment is admissible.
12.6 Necessary Coffer Dams and ring bunds have to be constructed at the cost of contractor and
same are to be removed after the completion of the work. The contractor has to quote his bid
price keeping the above in view.
13. Power Supply:
13.1 The contractor shall make his own arrangements for obtaining power from the Electricity
Distribution Company (DISCOM) for carrying out construction work at his own cost. The
contractor will pay the bills of DISCOM for the cost of power consumed by him.
13.2 The contractor shall satisfy all the conditions and rules required as per Indian Electricity Act
1910 and under Rule-45(I) of the Indian Electricity Rules, 1956 as amended from time to time
and other pertinent rules.
13.3 The power shall be used for bonafide Departmental work only.
14. Temporary Diversions (Works on Highways):
14.1 The contractor shall at all time carryout work on the highway in a manner creating least
interference to the flow of traffic while consistent with the satisfactory execution of the same.
For all works involving improvements to the existing highway, the contractor shall in
accordance with the directions of the Engineer-in-Charge provide and maintain during the
execution of the work a passage for traffic, either along a part of the existing carriage way
under improvement or along a temporary diversion constructed close to the highway.
14.2 If in the opinion of the Engineer-in-Charge, it is not possible to pass the traffic on part width
of the carriage-way for any reason, a temporary diversion close to the highway shall be
constructed as directed. It shall be paved with the materials such as hard murum, gravel and
stone, metal to the specified thickness as directed by the Engineer-in-Charge. In all cases, the
alignment, gradients and surface type of the diversion including its junctions, shall be
approved by the Engineer-in-Charge before the highway is closed to traffic.
14.3 The contractor shall take all necessary measures for the safety of traffic during construction
and provide erect and maintain such barricades, including signs, markings, flags lights and
information and protection of traffic approaching or passing through the section of the
28.6 The power to grant extension of time vests with Government in Department of Water
Resources only.
29.0 Delay Ordered by the Engineer-in-Charge.
The Engineer-in-Charge may instruct the Contractor to delay the start or progress of any
activity within the Work.
30.0 Early Warning:
30.1 The contractor is to bring to the notice of the Engineer-in-Charge at the earliest opportunity of
specific likely future events or circumstances that may adversely affect the Execution of
work.
30.2 The Contractor shall cooperate with the Engineer-in-Charge in making and considering
proposals for how the effect of such an event or circumstance can be avoided or reduced by
anyone involved in the work and in carrying out any resulting instruction of the Engineer-in-
Charge.
31.0 Management Meetings:
The Engineer-in-Charge may require the Contractor to attend management meetings. The
business of a management meeting shall be to review the programme for remaining work and
to deal with matters raised in accordance with the early reporting procedure. The minutes of
the meeting shall be given in writing for follow up by the parties.
C. QUALITY CONTROL
32.0 Identifying Defects:
32.1 The Engineer-in-Charge shall check the Contractor's work and notify the Contractor of any
Defects that are found. Such checking shall not affect the Contractor's responsibilities. The
Engineer-in-Charge may instruct the Contractor to verify the Defect and to uncover and test
any work that the Engineer considers may be a Defect.
33.0 Tests:
33.1 If the Engineer-in-Charge instructs the Contractor to carry out a test not specified in the
Specification to check whether any work has a Defect, the Contractor shall promptly comply
and pay for the test and any sampling.
34.0 Action in case of improper materials and workmanship:
34.1 If in the opinion of the Engineer-in-Charge any work or part thereof is executed with
improper materials or defective workmanship the contractor(s) shall when required by the
Engineer-in-Charge, forthwith re-execute the same and substitute proper materials and
workmanship and in case of default by the contractor(s) in so doing within a week from the
date of the requisition, the Engineer-in-Charge shall have full power to employ other person
to re-execute the work and the cost thereof shall be borne by the contractor(s). Every time
notice of a Defect is given, the Contractor shall correct the notified defect within the length of
time specified by the Engineer-in-Charge's notice.
35.0 Action and compensation payable in case of bad work:
35.1 If at any time before security deposit is refunded to the contractor it shall appear to the
Engineer-in-Charge or his subordinate in charge of the work that any work has been executed
with unsound, imperfect or unskillful workmanship or with materials of inferior quality or
that any materials or article provided by him for the execution of the work are unsound or of a
quality inferior to that contracted for or otherwise not in accordance with contract, it shall be
lawful for Engineer-in-Charge to intimate this fact in writing to the contractor and then
notwithstanding the fact that the work, materials or article complained of may have been
inadvertently passed, certified and paid for, the contractor shall be bound forthwith to rectify
or remove and reconstruct the work so specified in whole or in part as the case may require or
if so required shall remove the materials or articles so specified and provide other proper and
suitable materials or articles at his own charge and cost and in the event of his failing to do so
within a period to be specified by the Engineer-in-Charge in the written intimation aforesaid,
the contractor shall be liable to pay compensation at the rate of one percent of the agreement
amount for every day not exceeding ten days during which the failure so continues and in the
event of any such failure as aforesaid, the Engineer-in-Charge may rectify or remove and re-
execute the work or remove and replace the materials or articles complained, at the cost of the
contractor. If the Engineer-in-Charge considers that such inferior work or materials as
described above may be accepted or made use of it shall be within his discretion to accept the
same at such reduced rates as he may fix therefore.
35.2 The Engineer-in-Charge shall introduce O.K. cards and prescribe the formats there of. O.K.
cards shall relate to all major components of the work. The contractor / his authorized
representative shall be required to initiate and fill in and present the O.K. card to the
construction staff who would check the respective items and send to Engineer-in-Charge or
his representative for final check and clearance / O.K. Any defects pointed out by the
supervision staff of department shall promptly be attended to by the contractors and the fact
of doing so be duly recorded on the back of O.K. card.
35.3 The Engineer-in-Charge may also introduce checklists, which shall be kept in Bound registers
by the construction supervision staff. The contractor may be required to fill up these lists in
the first instance and shall be subsequently checked by the Construction / Quality Control
Engineers.
36.0 Quality Control:
Quality control monitoring reports, test results, reports - of corrective action etc, shall be
furnished to the employer at regular intervals.
Quality Audit shall be got conducted by the Engineer-in-Charge departmentally or by other
organization and the contractor shall extend the testing facilities to them also.
The contractor shall produce the Quality records maintained by him to the department or his
authorizing agent for the quality audit.
D. COST CONTROL
37.0 Contract Price
37.1 The contract price shall be the total value of work on EPC turnkey contract as per contract
agreement including operation & maintenance of the work for five years or five flood
seasons, whichever is more from the date of commissioning of the project.
37.2 The essence of the contract is to develop optimum in-stream storage with no/minimum
submergence of private properties to make the water available for use by the public in
irrigating their land and for other domestic and commercial purpose depending on
availability. It will also facilitate recharging of ground water.
37.3 The contractor will be paid a firm contract price for completion of all works as specified
under the scope of the work under the contract.
37.4 Variation in any respect shall not be considered for compensation.
37.5 Notwithstanding anything that is stated, the contract price once accepted by the employer
shall be final and shall not be subject to any claims on any ground what so ever of the
Contractor.
37.6 The contract price of the total work is divided among different component of works as per the
percentages specified in Financial Bid- Break up of Bid amount and payments will be
regulated accordingly.
37.7 The contractor shall pay all duties and taxes in consequence of his obligations under the
contract and the contract price shall not be adjusted for such costs.
37.8 Contract price will be paid to the Contractor in Indian Rupees only.
38.0 Changes in the Quantities:
38.1 Being a lump sum contract on EPC-Turnkey basis, the contractor is bound to complete the
entire work under the contract on a firm lump sum price quoted and on a single source
responsibility basis. The Contractor shall be deemed to have satisfied himself as to the
correctness and sufficiency of the contract price. Therefore the contractor is bound to execute
all supplemental works that are found essential, incidental and inevitable for completion of
work in all respect during execution of the work and also during Operation and Maintenance
period of five years or five flood seasons whichever is more.
38.2 Entrustment of additional items:
38.2.1 Wherever additional items not contingent on the main work and outside the scope of original
contract are to be entrusted to the original contractor, entrustment of such items and the price
to be paid shall be referred to a committee consisting of serving Engineers of Department of
Water Resources approved by Government for final decision and it shall be binding on the
contactor.
38.2.2 Entrustment of the additional items contingent on the main work will be authorized by the
employer and the contactor shall be bound to execute such additional items at no extra cost to
the employer and the cost of such items shall be deemed to have been included in the contract
price quoted.
39.0 Cash Flow Forecasts:
When the program is updated, the contractor is to provide the Engineer-in-Charge with an
updated cash flow forecast.
40.0 Financial Bid & Payment Schedules:
40.1 The bidder shall quote lump sum Bid Price for the entire work and O&M in the prescribed
format given in APPENDIX -FB of Financial Bid.
40.2 The total work specified under EPC turnkey contract, except the Operation and Maintenance,
is divided into Four major components of work to facilitate payments component wise as
specified in Appendix-FB under Financial Bid. The cost of each of the above components is
to be quoted by the bidder as percentage of the Bid price.
40.3 The payment for each of the components of works shall be limited to the respective amounts
arrived on the basis of percentages specified in Appendix–F.
40.4 The components shown in Appendix-F have been further sub-divided into appropriate stages
for the purpose of stage payment as specified in Appendix-F1 to F4.
40.5 This stage payment shall be limited to the respective amounts arrived on the basis of
percentages specified in the Appendix F1 to F4.
40.6 The stage payment mentioned in F1 to F4 may be further sub divided into sub components
with amount as percentages of the stages by the contractor, which shall be duly approved by
the Chief Engineer before signing of agreement. The sub-component should have relation to
the programme of construction taking due cognizance of interdependency of various
activities. The sum of payment for each of the sub components shall be limited to the
respective stage amounts arrived on the basis of percentages specified in Appendix F1 to F4.
40.7 Payment shall be released only on the basis of completion of work of respective component /
sub-component.
40.8 The Engineer-in-Charge shall check the Contractor’s monthly statement within 7 days of
submission.
40.9 The value of work executed shall be determined by the Engineer-in-charge as per the estimate
prepared by the contractor after approval of design and sanctioned by the competent
authority.
40.10 The Engineer-in-Charge may exclude any item certified in a previous certificate or reduce
the proportion of any item previously certified in any certificate in the light of later
information.
40.11 The contractor shall be permitted to submit their work bills once in a month by 25th of every
month and payment will be made after proper check of quantity and quality within 5 days of
the receipt of the bills in proper shape.
40.12 The Competent authority is empowered to modify the percentage of components, on approval
of design and drawing based on the detailed investigation, detailed drawings and detailed
estimation done by the contractor and sanctioned by competent authority, keeping the total
price bid unaltered.
40.13 The Chief Engineer is empowered to modify the sub components stage wise keeping the
percentages of stages unaltered.
40.14 The contractor shall give “Bill of Quantities” based on the detailed estimates prepared on the
basis of approved design; drawings and items of the estimate shall be suitably clubbed or
grouped for assessment of value of work done.
41.0 Measurement & Payments:
41.1 The contractor shall execute the various components of work as per approved drawings and
specifications. The contractor shall arrange to take and record all measurements of work done
of various components of work in the Measurement Books/Level field books issued to him
and plotted in the cross section sheets and quantities arrived as per actual execution as and
when required.
41.2 In respect of works, Measurement Books/Level field books have to be issued by the Engineer-
in-Charge to Contractor duly certified and numbered for recording measurements and levels.
The Measurement Books/Level field books shall be maintained by Contractor and bills are to
be submitted to the Engineer-in-Charge by the Contractor along with a true extract of the
entire set for checking and making payment. The Engineer-in-Charge has to keep the full set
of true extract with him and return the originals to the agency for further use. The entire
original record shall be finally handed over for record to the Engineer-in-Charge by the
Contractor.
41.3 Measurements will be recorded by the contractor for the finished work only for which all tests
are conducted and work done in accordance with specifications and contract conditions by
using the materials specified in the contract.
41.4 The contractor shall prepare monthly work bills based on the measurements of work done
already recorded as stated above and submit to Engineer-in-Charge duly signed by them or
his authorized signatory for arranging payment. Only completed portions of the works will be
billed as per Break up of components & sub components by the contractor.
41.5 The Engineer-in-Charge shall exercise check to see that the bill submitted by the Contractor is
in accordance with Agreement conditions & certified by the Department quality control
authority and 3rd party quality control agency if both are deployed on the work.
41.6 The Engineer-in-Charge should check the claim with reference to the measurements recorded
to see that the percentage at which the bill is claimed is clearly traceable into the documents
on which payments are to be made. Payments shall be adjusted for recovery of advance
payments, liquidated damages in terms of agreement conditions, security deposit for due
fulfillment of the contract. Recoveries shall be effected towards royalty charges on the
material used and GST and other statutory recoveries as per State and Central Government
rules and Acts.
41.7 In case of over payments or wrong payment if any made to the contractor due to wrong
interpretation of the provisions of the contract or Contract conditions etc., such unauthorized
payment will be deducted in the subsequent bills or final bill for the work or from the bills
under any other contracts with the Government or at any time thereafter from the deposits
available with the Government.
41.8 Any recovery or recoveries advised by the Government Department either state or central, due
to non-fulfillment of any contract entered into with them by the contractor shall be recovered
from any bill or deposits of the contractor.
41.9 No claim shall be entertained, if the same is not represented in writing to the Engineer-in-
Charge within 15 days of its occurrence.
41.10 The contractor is not eligible for any compensation for inevitable delay in handing over the
site or for any other reason. In such case, suitable extensions of time will be granted after
considering the merits of the case.
41.11 The Employer shall within 28 days of receiving a Statement and supporting documents, give
to the Contractor notice of any items in the Statement with which the Engineer in charge
disagrees, with supporting particulars. Payments due shall not be withheld, except that;
a) If anything supplied or work done by the Contractor is not in accordance with the
Contract, the cost of rectification or replacement may be withheld until rectification
or replacement has been completed; and / or
b) If the Contractor was or is failing to perform any work or obligation in accordance
with the contract and as notified by the Engineer in charge, the value of this work, or
obligation may be withheld until the work or obligation has been performed.
The Employer may, in any payment, make any correction or modification that should
properly be made, to any amount previously considered due. Payment shall not be
deemed to indicate Engineer-in-Charge’s acceptance, approval, consent or
satisfaction.
41.12 All progressive payments made to the Contractor shall be reviewed on quarterly basis and
reconciled with the break-up of the schedule. Over payments/under payments made, if any,
shall be adjusted in the next interim/final payments.
41.13 Measurement shall be signed and dated by both parties on the Site. If there is any dispute in
any of the measurements a note to the effect shall be made in the measurement record against
the disputed items and such note shall be signed and dated by both parties engaged in taking
the measurements and the Parties shall discuss and resolve the same in accordance with
relevant clauses of the contract.
42.0 Interest on Money due to the Contractor:
42.1 No omission by the Engineer-in-Charge to pay the amount due upon certificates shall vitiate
or make void the contract, nor shall the contractor be entitled to interest upon any guarantee
fund or payments in arrears, nor upon any balance which may, on the final settlement of his
accounts, found to be due to him.
Price adjustment for increase or decrease in the cost of cement Procured by the contractor
shall be paid in accordance with the following formula:
Vc = 0. 85 x Pc /100 x R x (C1- C0)/C0
Vc = Increase or decrease in the cost of work during the month under the month
under consideration due to changes in the rates for cement
C0 = The all India wholesale price index for Ordinary Portland Cement (OPC) on
28 days preceding the date of opening of Bids as published by the Ministry of
Commerce and Industry, Government of India, New Delhi
C1 = The all India wholesale price index for Ordinary Portland Cement
(OPC) for the month under consideration as published by the
Ministry of Commerce and Industry, Government of India, New
Delhi.
PC = Percentage of Cement Component of the work
Note: For the application of this clause, index of (Mile Steel long products) has been chosen
to represent steel group.
46(a)(iv): Adjustment of Bitumen Component
Price adjustment for increase or decrease in the cost of bitumen shall be paid in accordance
with the following formula:
Vb= 0. 85 x Pb /100 x R x (B1-Bo)/Bo
Vb= Increase or decrease in the cost of work during the month under consideration
due to changes in the rate for bitumen.
B0 = The official retail price of bulk bitumen at the IOC / BPCL depot at nearest
center on the day 28 days prior to date of opening of Bids.
B1 = The official retail price of bulk bitumen at IOC / BPCL depot at nearest center
for the 15th day of the month under consideration.
Pb = Percentage of bitumen component of the work
46(a)(v): Adjustment towards differential cost of Pipes.
Price adjustment for increase or decrease in the cost of pipe shall be paid in accordance with
the following formula:
Vpi = 0.85 x Ppi/100 X R (Pi1- P i0)/ P i0
Vpi = Differential cost of pipe i.e. amount of increase or decrease in rupees to be paid or
recovered during the month under consideration.
Ppi = Percentage of pipe component of the work
Pi1 = All India Whole sale price index of pipe for the period under consideration as
published by the Ministry of Commerce and Industry, Government of India,
New Delhi.
Pi0 = All India Whole sale price index of pipe on 28 days preceding the date of opening
of Bids as published by the Ministry of Commerce and Industry, Government of
India, New Delhi.
46(b): Adjustment of Labour Component
Price adjustment for increase or decrease' in the cost due to labour shall be
paid in accordance with the following formula
VL = 0.85 x PL/100 x R x (L1—Lo) /Lo
VL = Increase or decrease in the cost of work during the month under
consideration due to changes in rates for local labour.
L0= The minimum wages for unskilled Iabour as Notified by Government of
Odisha as prevailed on the last stipulated date of receipt of tender including
extension, if any.
L1= The minimum wages for unskilled labour as Notified by Government of
Odisha as prevailed on the last date of the Month previous to the one under
consideration.
PL = Percentage of labour component of the work.
F0 = The official retail price of High-Speed Diesel (HSD) at the existing consumer
pumps of IOC / BPCL/ HPCL at nearest center on the day 28 days prior to
the date of opening of Bids.
F1 = the official retail price of HSD at the existing consumer pumps of IOC /
BPCL/ HPCL at nearest center for the 15th day of the month under
consideration.
Pf = percentage of fuel and lubricants component of the work
Note. For the application of this clause, the price of High-Speed Diesel oil has been chosen
to represent fuel and lubricants group.
46(d): Adjustment for Plant and Machinery Spares Component
(vi) Price adjustment for increase or decrease in the cost of plant
and machinery spares procured by the Contractor shall be paid
in accordance with the following formula:
Vp = 0.85 X Pp/100 x R x (P1-P0)/P0
Vp = Increase or decrease in the cost of work during the month under
consideration due to changes in the rates for plant and machinery
spares
P0 = The all India wholesale price index for manufacture of
machinery for mining, quarrying and construction on 28 days
preceding the date of opening of Bids as published by the
Ministry of Commerce and Industry Government of India,
New Delhi.
P1 = The all India wholesale price index for manufacture of
machinery for mining, quarrying and construction for the
month under consideration as published by the Ministry of
Commerce and Industry, Government of Indla, New Delhi.
Pp = Percentage of plant and machinery spares component of the
work
Note : For the application of this clause, index of manufacturing of machinery for
mining, quarrying and construction has been chosen to represent the Plant and
machinery Spares group.
Regarding wholesale price Index (WPI) for appropriate commodity for
payment of price adjustment, due to change of base year of WPI from 1993- 94
to 2004-05 & 2011-12, it is observed that, the commodity ‘Bars and Rod’,
‘Cement', ‘Heavy machinery and parts’ included in the list of WPI 1993-94
series are not mentioned as such in the WPI 2004-05 & 2011-12 series.
Therefore, the following items in the WPI 2004-05 & 2011-12 series shall be
considered corresponding to items in WPI 1993-94 series:
SI. Item in WPI 1993-94 Item in WPI 2004-05 Item in WPI 2011-12
No. series series series
Percentage Table
Road Works 5 5 90
R&B works (% of
1 Bridge Works 5 5 90
Component)
Building Works 5 5 90
Structural works 5 5 90
Irrigation Works (%
2 Earth, Canal &
of Component) 5 5 90
Embankment works
Structural works 5 5 90
Pipe- 70%
Pipe line work 5 5 *Machinery + Other Materials-
3 P.H Works 20%
Pipe- 70%
Sewer line 5 5 *Machinery + Other Materials-
20%
*Note:- Further breakup may be worked out considering the consumption of Cement, Steel, Bitumen,
pipe and Plant & Machinery Spare Component in the concerned works and shall be provided in the
bid document in shape of schedule of Adjustment Data as an “Appendix to Bid”. (enclosed herewith).
Appendix. to Bid
[For all works, adjustment factor for Labour and POL shall be considered @ 5o/o each. Steel,
Cement, Pipes, other Materials and Machinery shall contribute to 90% of Price Adjustment and shall
be calculated for each work separately during preparation of estimate, shall be approved by the
authority during technical sanction as a "Schedule of Adjustment Data" and shall form part of the Bid
Document]
46(a) (iii) Steel Whole sale price index for Steel (Mild Steel-
28.16%
Long Products) as published by the office of
the Economic Advisor to the Govt. of India,
Ministry of Commerce and Industry
payments to the contractor have reached 20 percent of the contract amount. The
mobilization advance along with interest shall be recovered in such a way that the full
amount is recovered, by the time 80% work is completed.
b. Each installment of mobilization advance shall be repaid by the contractor not later than
365 (Three hundred & sixty five) days from the respective date of mobilization advance
payment. The contractor shall repay each installment/phase of the advance payment on or
before the due date of repayment. The parties expressly agree that for any delay in
repayment of the mobilization advance payment, the contractor shall pay interest to the
employer for each day of delay, such interest to be calculated @ 18% (eighteen) per
annum. In the event of the contractor’s failure to make the repayment on time, the
employer shall be entitled to encash the bank guarantee for recovery of mobilization
advance along with interest.
c. If the advance payment has not been fully repaid prior to termination as per the
agreement, the whole of the balance mobilization advance, along with interest,
outstanding against the contractor shall immediately become due & payable by the
contractor to the employer. Without prejudice to the provisions of clause of termination
for contractor’s default, the advance payment along with interest @12% per annum from
the date of advance payment to the date of recovery by encashment shall be recovered
from the contractor by encashment of the bank guarantee. For the avoidance of doubt, the
aforesaid interest shall be payable on each installment/phase of the advance payment
regardless of whether the installment or any part thereof has been repaid to the employer
prior to termination.
50.0 Securities Deposit:
50.1 Performance Security Deposit:
The Department shall retain from each payment due to the contractor, 5% of gross bill
amount until completion of the works. The Performance Security shall be released only after
one year from the date of commission of the work.
50.2 All compensation, Liquidate damages or other sums or money payable by the contractor to
Government under the terms of this contract shall be deducted from or recouped by the
realization of a sufficient part of his security deposit, or from the interest arising there from or
from any sums which may due or may become due by Government to the Contractor on any
account whatsoever whether in respect of this contract, or any other contract, or otherwise. In
the event of his security deposit being reduced by reason of any such deduction or
recoupment as aforesaid, the contractor shall within ten days thereafter, make good the sum or
sums required to make good the shortfall in the amount of the security deposit.
50.3 All dues under this contract or other contract, or otherwise; shall be recovered from the
aforesaid amount of security deposit and the balance shall be refunded only after one year
from the date of completion of the work. While releasing the securities beyond the defect
liability period, the sufficiency of securities for the recovery of cost for excess energy
consumption beyond the guaranteed power consumption shall be taken into consideration.
51.0 Cost of Repairs:
Loss or damage to the Works or materials to the Works between the Start Date and the end of
the Defects Correction Periods shall be remedied by the Contractor at the Contractor's cost if
the loss or damage arises from the Contractor's acts or omissions.
b) The contractor is made bankrupt or goes into liquidation other than for a reconstruction or
amalgamation.
c) The Engineer-in-Charge gives Notice that failure to correct a particular Defect is a
fundamental breach of Contract and the Contractor fails to correct it within a reasonable
period of time determined by the Engineer-in-Charge; and
d) The Contractor does not maintain a security which is required and
e) The Contractor has delayed the completion of works by the number of days for which the
maximum amount of liquidated damages is to be paid as defined
f) If the contractor, in the judgment of the Department has engaged in corrupt or fraudulent
practices in competing for or in the executing the contract
For the purpose of this paragraph: "corrupt practice" means the offering, giving, receiving or
soliciting of anything of value to influence the action of a public official in the procurement
process or in contract execution. "Fraudulent practice" means a misrepresentation of facts in
order to influence a procurement process or the execution of a contract to the detriment of the
Government and includes collusive practice among Bidders (prior to or after Bid submission)
designed to establish Bid prices at artificial non-competitive levels and to deprive the
Government of the benefits of free and open competition.
55.2 Notwithstanding the above the Department or Engineer-in-Charge or Employer may
terminate the contract for convenience.
55.3 If the Contract is terminated, the Contractor shall stop work immediately, make the site safe
and secure, leave the site as soon as reasonably possible.
56.0 Payment upon Termination:
If the Contract is terminated because of a fundamental breach of Contract by the Contractor,
the Engineer-in-Charge shall issue a certificate for the value of the work done less advance
payments received upon the date of the issue of the certificate, less other recoveries due in
terms of the Contract, less taxes due to be deducted at source as per applicable laws and less
20 percent of the value of work not completed. If the total amount due to the Department
exceeds any payment due to the Contractor the difference shall be a debt payable to the
Department. In case of default for payment within 28 days from the date of issue of notice to
the above effect, the contractor shall be liable to pay interest at 12% per annum for the period
of delay.
57.0 Property:
All materials on the site, plant, equipment, Temporary works and works are deemed to be the
property of the Department if the Contract is terminated because of Contractor’s default.
58.0 Releases from Performance:
If the Contract is frustrated by the outbreak of war or by any other event entirely outside the
control of either the Department or the Contractor the Engineer-in-Charge shall certify that
the contract has been frustrated. The Contractor shall make the site safe and stop work as
quickly as possible after receiving this certificate and shall be paid for all works carried out
before receiving it and for any work carried out after wards to which commitment was made.
65.0 Labour:
The contractor shall, make his own arrangements for the engagement of all staff and labour,
local or other, and for their payment, housing, feeding and transport.
Labour importation and amenities to labour and contractor's staff shall be to the contractor's
account. His quoted percentage shall include the expenditure towards importation of labour
amenities to labour and staff.
The contractor shall, if required by the Engineer-in-Charge, deliver to the Engineer-in-Charge
a written in detail, is such form and at such intervals as the Engineer-in-Charge may prescribe,
showing the staff and the numbers of the several classes of labour from time to time employed
by the contractor on the Site and such information respecting Contractor's Equipment as the
Engineer-in-Charge may require.
65.1 Transportation of Labour:
The contractor shall make his own arrangement for the daily transportation of the labour and
staff from labour camps colonies to the work spot and no labour or staff of the contractor shall
stay at the work spot. No extra payment will be made to the contractor for the above
transportation of the labour and his quoted percentage to the work shall include the
transportation charges of labour from colonies to work spot and back.
The contractor will at all times duly observe the provisions of employment of children Act
XXVI of 1938 and any enactment or modification of the same and will not employ or permit
any person to do any work for the purpose under the provisions of this contract in
contravention of said Act. The contractor here by agrees to indemnify the department from and
against all claims, penalties which may be suffered by the department or any person employed
by the department by any default on the part of the contractor in the observance and
performance of the provisions of the employment of children Act. XXVI of 1938 or any
enactment or modification of the same.
The contractor shall obtain the insurance at his own cost to cover the risk on the works to
labour engaged by him during period of execution against fire and other usual risks and
produce the same to the Engineer-in-Charge concerned before commencement of work.
66.0 Safety Measures:
The contractor shall take necessary precautions for safety of the workers and preserving their
health while working in such jobs, which require special protection and precautions. The
following are some of the measures listed but they are not exhaustive and contractor shall add
to and augment these precautions on his own initiative where necessary and shall comply with
directions issued by the Engineer-in-Charge or on his behalf from time to time and at all
times.
1. Providing protective foot wear to workers situations like mixing and placing of mortar or
concrete sand in quarries and places where the work is done under much wet conditions.
2. Providing protective head wear to workers at places like underground excavations to
protect them against rock falls.
3. Providing masks to workers at granulates or at other locations where too much fine dust is
floating about and sprinkling water at frequent intervals by water hoses on all stone
crushing area and storage bins abate to dust.
4. Getting the workers in such jobs periodically examined for chest trouble due to too much
breathing in to fine dust.
5. Taking such normal precautions like fencing and lightening in excavation of trenches, not
allowing rolls and metal parts of useless timber spread around, making danger areas for
blasting providing whistles etc.
6. Supply workmen with proper belts, ropes etc., when working in precarious slopes etc.
7. Avoiding named electrical wire etc. as they would electrocute the works.
8. Taking necessary steps towards training the workers concerned on the machinery before
they are allowed to handle- them independently and taking all necessary
Precautions in around the areas where machines hoist and similar units are working.
67.0 Fair Wage Clause:
The contractor shall not employ for the purpose of this contract any person who is below the
age of eighteen (18) years and shall pay to each labourer for work done by such labourers fair
wages. PWD No.-22059 Dtd-16.08.77
Explanation – “Fair Wage” means wages, whether for time or piece work prescribed by the
state Public Works Department provided that where higher rates have been prescribed under
the Minimum Wages Act.1948 wages at such higher rates should constitute fair wages.
The Engineer-in-Charge shall have the right to enquire into and decide ant complaints
alleging that wages paid by the contractors to pay labourer for work done by such labourer is
less than the wages as per the sub-paragraph (1) above.
(b) The contractor shall not withstanding the provisions of any contract to contrary, cause to
be paid a fair wages to labourers indirectly engaged on the work including any labour
engaged by his sub contractors in connection with the said work, as if the labourers had been
immediately employed by him.
(c) In respect of all labour directly or indirectly employed in the works for the performance of
the contractor’s part of this agreement, the contractor shall comply with or cause to be
complied with all regulations made by Government in regard to payment of wages period
deductions from wages, recovery of wages not paid and deductions unauthorisedly made,
maintenance of wage register, wage cards, publications of scale of wages and other terms of
employment, inspection and submission of periodical return and all other matters of a like
nature.
(d) The Engineer-in-Charge or Sub-divisional Officer concerned shall have the right to
deduct, from the money due to the contractor, any sum required or estimated to be required
for making good the loss suffered by a worker or workers by reason of non-fulfillment of
conditions of the contract for the benefit of the workers, non-payment of wages or of
deductions made from his or their wages, which are not justified by their terms of the contract
or non-observance of the regulations. Money so deducted should be transferred to the workers
concerned.
(e) Vis-à-vis, the Government of Orissa, the contractor shall be primarily liable for all
payments to be made under and for the observance of the regulations aforesaid without
prejudice to his right to claim indemnity from his sub-contractor.
(f) The regulations aforesaid shall be deemed to be a part of this contract and ant breach
thereof shall be breach of this contract.
(g) Under the provisions of the minimum wages Act, 1948 and the minimum wages (Central
Rules 1950) the contractor is bound to allow or cause to be allowed to the labourers directly
or indirectly employed in the work one day rest for six days continuous work and pay wages
at the same rate as for duty. In the event of default the Engineer-in-Charge or Sub-divisional
Officer concerned shall have the right to deduct the sum not paid on account of wages for
weekly holiday to any labourers and pay the same to the person entitled there to from any
money due to the contractor.
(h) The contractor shall at his own expense provide or arrange for the provision of foot wear
for any labour doing cement mixing work and black topping of roads (The contractor has
undertaken to execute under this contract) to the satisfaction of the Engineer-in-Charged on
his failure to do so, Government shall be entitled to provide the same and recover the cost
from the contractor.
(i) The contractor shall submit by the 4th & 10th every month to the Engineer-in-Charge true
statement showing in respect of the Second half of the proceeding month and the First half of
the current month respectively (1) the number of labours employed by him on the work (2)
their working hours (3) the wages paid to them (4) the accident that occurred during the said
fortnight showing the circumstances under which they happened and the content of damage
injury caused by them and (5) the number of female workers who have been allowed
maternity benefit according to clause K and the amount paid to them failing which the
contractor shall be liable to pay to Government a sum not exceeding Rs.50/- for each default
to materially incorrect statement. The decision of the Engineer-in-Charge shall be final in
deducting from any bill due to contractor amount levied as fine.
(j) In respect of all labour directly or indirectly employed in the words for the performance of
the contractor’s part of this agreement, the contractor shall comply with or cause to be
complied with all the rule, framed by Government employed by the Orissa Public Works
Department and its contractors. This will apply to work places having 50 or more workers.
(b) Deductions for absence from duty, i.e. from the place or place where by the terms of his
employment he is required to work. The amount of deductions shall be in proportion to the
period for which he was absent.
(c) Deductions for damages for damage to or loss of good expressly entrusted to the employed
person for custody or for loss of money for which he is required to account where such
damage or loss is directly attributable to his neglect or default.
(d) Any other deductions, which the Orissa Government may from time to time allow.
(i) No fines shall be imposed on a worker and no deduction for damage or loss shall be made
from his wages until the worker has been given an opportunity or showing cause against such
fines or deductions.
(ii) The total amount of fines which may be imposed in any one wage period on a work shall
not exceed an amount equal to five paise in rupee of the wages payable to him in respect of
that wage period.
(iii) No fine imposed on any worker shall be recovered from him by installments, or after the
expiry of 60 days from the date on which it was imposed.
7. Register of fines, etc.
(i) The contractor shall maintain a register of fines and of all deductions for damage or loss.
Such Register shall mention the reason for which fine was imposed or deduction for damage
or loss was made.
(ii) The contractor shall maintain a list in English and in the local Indian language, clearly
defining acts and omissions for which penalty or fine can be imposed. It shall display such list
and maintain it in a clean and legible condition in conspicuous places in the work.
8. Preservation of Register
The wage register, the wage cards and the register of fines, deduction required to be
maintained under these regulations shall be preserved for 12 months after date of the last
entry made in them.
9. Power of Labour Welfare Officer to make investigation or enquiry –
The Labour Welfare Officer or any other persons authorized by the Government of Orissa on
their behalf shall have power to make enquiries with a view to ascertaining and enforcing due
and proper observance of the fair wage clauses and the provision if these of these regulations.
He shall investigate into any complaint regarding default made by the contractor, sub-
contractor in regard to such provisions.
10. Report of Labour Welfare Officers-
The Labour Welfare Officers or others authorized as aforesaid shall submit a report of the
results of his investigation or enquiry to the Engineer-in-Charge concerned, indicating the
extent, if any, to which the default has been committed with a note that necessary deduction
from the contractor’s bill be made and the wages and other dues be paid to the labourers
concerned.
11. Appeal against the decision of Labour Welfare Officers-
Any persons aggrieved by the decision and recommendation of the Labor Welfare Officer or
other person so authorized may appeal against such decision to the Labour Commissioner
within 30 days from the date of decision forwarding simultaneously a copy of his appeal to
the Engineer-in-Charge concerned but subject to such appeal, the decision of the officer shall
be final and binding upon the contractor.
12. Inspection of Registers –
The contractor shall allow inspection of the wage book and wage cards to any of his workers
or to his agent at a convenient time and place after due notice is received, or to the Labour
Commissioner or any other person authorized by the Government of Orissa on his behalf.
13. Submission of return –
The contractor shall submit periodical returns as may be specified from time to time.
14. Amendments –
The Government of Orissa may from time to time, add to or amend these regulations and on
any question as to the application, interpretation of effect of the regulations, the decision of
the Labour Commissioner or any other person authorized by the Government of Orissa in
that behalf shall be final.
67.2 Maternity benefit rules for female workers employed by Contractor.
Leave and pay during leave shall be regularized as follows.
1. Leave: i) In case of delivery: Maternity leave not exceeding 8 weeks up to an including the
day of delivery or 4th weeks following that day.
ii) In case Miscarriage: Up to 3 weeks from the date of miscarriage.
2. Pay: i) In case of delivery: Leave pay during maternity leave will be at the rate of the
women’s average daily earning calculated on the total wages earned on the days when full
time work was done during a period of three months immediately proceedings the date of
which she gives notice that the excepts to be confirmed or at the rate of twelve annas a day
whichever is greater.
ii) In case of Miscarriage: Leave pay at the rate of daily earnings calculated on the
total wages earned on the date when full time work was done during a period of 3 months
immediately proceeding the date of such miscarriage.
Condition of the Grant of Maternity Leave: No maternity leave benefit shall be admissible to
women unless she has been employed for a total period not less than 8 months immediately
proceeding the date on which proceeds on leave.
(a) Where the number of persons employed does not exceed 50.No. of seats 1.
(b) Where the number of persons employed exceeds 50 but does not exceed 100. No. of seats
3 per 100.
(c) For every additional 100, 3sets
(In particular cases the Engineer-in-Charge shall have the power to vary the scale where
necessary). Latrines and Urinal for women: If women are employed, separate latrines and
urinal for women. If women are employed, separate latrines separate from that for women
and marked in the vernacular in conspicuous letter. For women only shall be provided on
the scale laid in rule.
7. Latrines and Urinals: Except in work places provided with water flushed latrines
connection with a water borne sewerage system, all latrines shall be provided with
receiptable on dry earthen system which shall be cleaned and at least four times daily and
at least twice during working hours and kept in a strictly sanitary condition. The receipt
tables shall be tarred inside and outside at least once a year.
8. Constructions of latrines: The inside wall shall be constructed of masonry or stone
materials and shall be cement washed inside and outside at least once a year. The dates of
cement washing shall be noted in register maintained for this purpose and kept available
for inspection.
9. Disposal of Excreta: Unless otherwise arrange for by the local sanitary authorities,
arrangement for a paper disposed of excreta by incineration at the
work place shall be made by means of a suitable incidencepator approved by Asst.
director of Public Health or Municipal Medical Officer of Health as the case may be, in
whose jurisdiction the work place is situated. After natively excreta may be disposed off
putting of a layer of.
10. Night soil at the bottom of pucca tank prepared for the purpose and covering it with a
layer of waste or refuse and then covering it up with a layer of 6; layer if waste or refuse
and then covering it up with a layer of each for a fortnight (when it will turn in to
manure).
11. Provision of shelters during rest-at every work place, there shall be provided free of cost
two suitable sheds and for meals and the other for rest the use of labourers. The height of
the shelter shall not be less than 11 feet, from the floor level to the lowest of the roof.
12. Creche: (a) At every work place at which more than 50 women workers are employed,
there shall be provided only one but for the use of children under the age of 6 years,
belonging to such women and shall be used for infants games and play and their bed
room. The huts shall not be constructed on a lower standard than the following:
i) Thatched roofs
ii) Mud floors and walls
iii) Planks spared over the mud floor and covered with matting
The hut shall provided with suitable and sufficient innings for light and ventilation. There
shall be ad equates provisions for sweepers to keep the place clean. There shall be two dais
in attendance, sanitary, utensils shall be provided to the satisfaction of the Health Officer of
the area concerned. The use of the hut shall be restricted to children, their attendants and,
mothers of the children.
(b) Where the number of women workers is more than 50, the Contractor shall provide
one but and a Dai to look after the children of women workers.
(c) The size of creche shall vary according to the number of women workers.
(d) The crone shall be properly maintained and necessary equipment like toys etc. shall
be provided.
13. Canteen: A cooked food Canteen on moderate scale shall be provided for the benefits of
workers whenever it is considered expedient.
68.0 Indemnity Bond:
The contractor has to furnish the bond at the signing the Agreement.
Name of work- Construction of Barrages, weirs and major check dams(In-stream storage
structures)across various rivers of State of Odisha on EPC Contract (Turn Key
Basis)including hydro-mechanical works, Power connectivity works, road connectivity, staff
quarters including survey, investigation, Planning, design and estimate of all components with
operation and maintenance of the project for a period of five years or five flood seasons
whichever is more after successful commissioning of the project.
I contractor S/o aged
Resident of do hereby
bind myself to pay all the claims may come (a) under Workmen’s Compensation Act. 1933
with any statutory modification there of and rules there under or otherwise for or in respect of
any damage or compensation payable in connection with any accident or injury sustained (b)
under Minimum wages Act 1948 (c) under payment of wages Act.1936 (d) under the
Contractor labour (Regulation and Abolition) Act. 1970 by workmen engaged for the
performance of the business relating to the above contract i.e., failing such payment of claims
of workmen engaged in the above work, I abide in accepting for the recovery of such claims,
effected from any of my assets with the departments.
69.0 Compliance with Labour Regulations:
During continuance of the contract, the contractor and his sub contractors shall abide at all
times by all existing labour enactments and rules made there under, regulations, notifications
and bye laws of the State or Central Government or local authority and any other labour law
(including rules), regulations, bye laws that may be passed or notifications that may be issued
under any labour law in future either by the State or the Central Government or the local
authority and also applicable labour regulations, health and sanitary arrangements for
workmen, insurance and other benefits. Salient features of some of the major labour laws that
are applicable to construction industry are given below. The contractor shall keep the
Department indemnified in case any action is taken against Department by the competent
authority on account of contravention of any of the provisions of any Act or rules made there
under, regulations or notifications including amendments. If the Department is caused to pay
or reimburse, such amounts as may be necessary to cause or observe, or for non-observance of
the provision stipulated in the notifications/bye laws/Acts/Rules/regulations including
amendments, if any, on the part of the contractor, the Engineer-in-Charge/Department shall
have the right to deduct any money due to the contractor including his amount of performance
security. The Department/Engineer-in-Charge shall also have right to recover from the
contractor any sum required or estimated to be required for making good the loss or damage
suffered by the Department.
The employees of the Contractor and the Sub-contractor in no case shall be treated as the
Department of the Department at any point of time.
70.0 Salient features of some major labour laws applicable to establishment engaged in
buildings and other construction work:
a) Workmen compensation Act 1923: The Act provides for compensation in case if injury
by accident arising out of and during the course of employment.
b) Payment of Gratuity Act 1972: Gratuity is payable to an employee under the Act on
satisfaction of certain conditions on separation if any employee has completed 5 years
service or more, or on death, the rate of 15 days wages for every completed year of
service. The Act is applicable to all establishments, employing 10 or more employees.
c) Employees P.F. and Miscellaneous provision Act 1952: The Act provides for monthly
contributions by the Department plus workers @ 10% or 8.33%. The benefits payable
under the Act are:
i) Pension or family pension on retirement or death, as the case may be.
ii) Deposit linked insurance on the death in harness of the worker.
iii) Payment of P.F. accumulation on retirement/death etc.,
d) Maternity Benefit Act 1951: The Act provides for leave and some other benefits to
women employees in case of confinements or miscarriage etc.
e) Contract Labour (Regulation & Abolition) Act 1970: The Act provides for certain welfare
measures to be provided by the contractor to contract labour and in case the Contractor
fails to provide, the same are required to be provided by the Principal Department by
Law. The Principal Department is required to take certificate of Registration and the
contractor is required to take license from the designated Officer. The Act is applicable to
the establishments or Contractor of Principal Department if they employ 20 or more
contract labour.
f) Minimum wages Act 1948: The Department is supposed to pay not less than the
Minimum wages fixed by appropriate Government as per provisions of the Act if the
employment is a scheduled employment construction of Buildings, Roads, Runways are
scheduled employments.
g) Payment of wages Act 1936: It lays down as to by what date the wages are to be paid,
when it will be paid and what deductions can be made form the wages of the workers.
h) Equal Remuneration Act 1979: The Act provides for payment of equal wages for work of
equal nature to Male or Female workers and for not making discrimination against
Female employee in the matters of transfers, training and promotions etc.
i) Payment of Bonus Act 1965: The Act Is applicable to all establishments employing 20 or
more employees. The Act provides for payment of annual bonus subject to a minimum of
8.33% of wages and maximum of 20% of wages to employees drawing Rs. 3500/- per
month or less. The bonus to be paid to employees getting Rs.2500/- per months or above
and up to Rs.3500/- per month shall be worked out by taking wages as Rs.2500/- per
monthly only. The Act does not apply to certain establishments. The newly set-up
establishments are exempted for five years in certain circumstances. Some of the State
Governments have reduced the employment size from 20 to 10 for the purpose of
applicability of this Act.
j) Industrial Disputes Act 1947: The Act lays down the machinery and procedure for
resolution of Industrial disputes, in what situations a strike or lock- out becomes illegal
and what are the requirements for laying off or retrenching the employees or closing
down the establishment.
k) Industrial Employment (Standing Orders) Act 1946: It is applicable to all establishments
employing 100 or more workmen (employment size reduced by some of the State and
Central Government to 50). The Act provides for laying down rules governing the
conditions of employment by the Department on matters provided in the Act and get the
same certified by the designated Authority.
l) Trade Unions Act 1926: The Act lays down the procedure for registration of trade unions
of workmen and Departments. The Trade Unions registered under the act have been given
certain immunities from civil and criminal liabilities.
m) Child Labour (Prohibition & Regulation) Act 1986: The Act prohibits employment of
children below 14 years of age in certain occupations and processes and provides for
regulation of employment of children in all other occupations and processes, Employment
Child Labour is prohibited in Building and Construction Industry.
n) Inter-State Migrant workmen's (Regulation of Employment & Conditions of service) Act
1979: The Act applicable to an establishment, which employs 5 or more inter-state
migrant workmen through an intermediary (who has recruited workmen in one state for
employment in the establishment situated in another State). The inter State migrant
workmen, in an establishment to which this Act becomes applicable, are required to be
provided certain facilities such as housing, medical aid, traveling expenses from home
upto the establishment and back, etc.
o) The Building and Other Construction workers (regulation of Employment and conditions
of service) Act 1996 and the Cess Act of 1996: All the establishments
who carry on any building or other construction work and employs 10 or more workers are
covered under this Act. All such establishments are required to pay cess at the rate not
exceeding 2% of the cost of construction as may be modified by the Government. The
Department of the establishment is required to provide safety measures at the Building or
construction work and other welfare measures, such as Canteens, First-aid facilities,
Ambulance, Housing accommodations for workers near the work place etc. The
Department to whom the Act applies has to obtain a registration certificate from the
Registering Officer appointed by the Government.
p) Factories Act 1948: The Act lays down the procedure for approval of plans before setting
up a factory, health and safety provisions, welfare provisions, working hours, annual
earned leave and rendering information regarding accidents or dangerous occurrences to
designated authorities. It is applicable to premises employing 10 person or more with aid
of power or 20 or more persons without the aid of power engaged in manufacturing
process.
71.0 Liabilities of the Contractor:
71.1 Accident Relief and Workmen Compensation:
The contractor should make all necessary arrangements for the safety of workmen on the
occurrence of the accident, which results in the injury or death of any of the workmen
employed by the contractor, the contractor shall within 24 hours of the happenings of the
accident and such accidents should intimate in writing to the concerned Asst. Engineer / Asst.
Engineer-in-Charge of the Department the act of such accident. The contractor shall
indemnify Government against all loss or damage sustained by the Government resulting
directly or indirectly from his failure to give a intimation in the manner aforesaid including
the penalties or fines if any payable by Govt. as a consequence of Govt. failure to give notice
under workmen's compensation Act or otherwise conform to the provisions of the said Act. in
regard to such accident.
71.2 In the event of an accident in respect of which compensation may become payable under the
workmen's compensation Act VIII 23 whether by the contractor, by the Government it shall
be lawful for the Engineer-in-Charge to retain such sum of money which may in the opinion
of the Engineer-in-Charge be sufficient to meet such liability. The opinion of the Engineer-in-
Charge shall be final in regard to all matters arising under this clause.
71.3 The contractor shall at all times indemnify the Govt. of Odisha against all claims which may
be made under the workmen's compensation act or any statutory modification thereafter or
rules there under or otherwise consequent of any damage or compensation payable in
consequent of any accident or injuries sustained or death of any workmen engaged in the
performance of the business relating to the contractor.
72.0 Contractor's Staff, Representatives and Labour:
(a) The contractor shall, at all times, maintain on the works, staff of qualified Engineers, and
Supervisors of sufficient experience of similar other jobs to assure that the quality of
work turned out shall be as intended in the specifications. The contractor shall also
maintain at the works, a Work Manager or sufficient status, experience and office and
duly authorize him to deal with all aspects of the day-today work. All communications to
any commitments by the Work Manager shall be considered as binding on the
Contractor.
(b) The Contractor shall at all times submit details of skilled and unskilled labour and
equipment employed to the Engineer-in-Charge in prescribed proforma as he may require
to assess and ensure the proper progress of work.
(c) If the contractor does not employ the technical person agreed to on the work a fine of
Rs.25, 000/- will be imposed. If he does not employ for 30 days, thereafter it becomes a
fundamental breach of contract.
(d) The Contractor shall at all times, maintain on the work a staff of qualified Engineers and
Supervisors of sufficient experience of similar other jobs to ensure that the quality of
work turned out shall be as intended in these-specifications and they shall be present at
the work spot during working hours and at the time of inspection by the Department
Officers. All orders and direction given to such supervisory or other staff of the
contractor to be present on any specified inspection and the contractor shall comply with
such requisitions.
(e) The contractor shall supply to the Engineer-in-Charge details of name, qualifications and
experience in regard to all supervisory staff employed by the contractor and notify the
changes when made and satisfy the Engineer-in-Charge regarding the quality and
adequacy of staff thus employed.
(f) The Engineer-in-Charge will have the unquestionable right to ask for change in the
contractor's supervisory staff and to other removal from the work and connection
herewith of any of such staff. The contractor shall comply with such order and effect
replacement to the satisfaction of the Engineer-in-Charge.
(g) The Contractor shall not without written authorization permit entry on site of work of any
person authorized agents, engaged in connection with work.
(h) All vehicles used by the contractor shall be clearly marked with contractor's name.
73.0 Accommodation and Food:
The contractor should arrange accommodation he needs, at his own cost. The contractor shall
make his own arrangements for supply of food grains, fuel and other provision to his staff and
labourers including controlled commodities.
74.0 Relationship:
Contractor shall have to furnish information along with Bid, about the relationship he is
having with any officer of the Department Government of Odisha of the rank Assistant
Engineer and above engaged in the work and any officer of the rank of Assistant Secretary
and above of the Department of Government of Odisha.
75.0 Protection of adjoining premises:
The contractor shall protect adjoining sites against structural, decorative and other damages
that could be caused by the execution of these works and make good at his cost any such
damages.
76.0 Work during night or on Sundays and holidays:
The work can be allowed to be carried out during night, Sundays or authorised holidays in
order to enable him to meet the schedule targets and the work shall require almost round the
clock working keeping in view:
(i) The provisions of relevant labour laws being adhered to:
(ii) Adequate lighting, supervision and safety measures are established to the
satisfaction of the Engineer-in-Charge and
(iii) The construction programme given by the Contractor and agreed upon by the
Engineer-in-Charge envisages such night working or working during Sundays or
authorized holidays.
77.0 Layout of Materials Stacks:
The contractor shall deposit materials for the purpose of the work on such parts only of the
ground as may be approved by the Engineer-in-Charge before starting work. A detailed
survey, clearly indicating position and areas where materials shall be stacked and sheds built
is to be conducted by the contractor at his own cost and only after obtaining necessary
approval of the plan for use of sites by the Engineer-in-Charge, the Contractor can use the
sites accordingly.
78.0 Use of Blasting Materials:
Procurement of blasting materials and its storage is the responsibility of the contractor. The
contractor shall engage licensed blaster for blasting operation. The contractor is to act in
accordance with Indian Explosive Act and other rules prevailing, during the execution of
work. It is the responsibility of the contractor to see, that work by other agencies in the
vicinity are not hampered, in such cases if any claim is made by other agencies that should be
borne by the contractor. Carriage of blasting materials, from the magazine to the work site, is
the responsibility of the contractor.
79.0 Plant and Equipment:
79.1. The contractor shall have sufficient plant, equipment and labour and shall work such hours
and shifts as may be necessary to maintain the progress on the work as per the approval
progress schedule. The working and shifts hours shall comply with the Govt. Regulations in
force.
79.2 It is to expressly and clearly under stood that contractor shall make his own arrangements to
equip himself with all machinery and special tools and plant for the speedy and proper
execution of the work and the department does not undertake responsibility towards their
supply.
79.3 The department shall supply such of the machinery that may be available on hire basis but
their supply cannot be demanded as matter of right and no delay in progress can be attributed
to such non-supply of the plant by the department and the department cannot be made liable
for any damage to the contractor. The Contractor shall be responsible for safe custody of the
departmental machinery supplied to him (which will be delivered to contractor at the
machinery yard at site of work) and he has to make good all damages and losses if any other
than fire, wear and tear to bring it to the conditions that existed at the time of issue to the
contractor before handing over the same to the department. The hire charges for the
machinery handed over to the contractor will be recovered at the rate prevalent at the time of
supply. The contractor will have to execute supplemental contract with Engineer-in-Charge at
the time of supply of the machinery.
79.4 The acceptance of departmental machinery on hire is optional to the contractor.
80.0 Steel Forms:
Steel forms should be used for all items involving use of centering and shuttering. They shall
be such that the concrete surface obtained after removal of centering and shuttering shall be
single plane without any dents and undulations.
81.0 Inconveniences to Public:
The contractor shall not deposit materials at any site, which will cause inconvenience to
public. The Engineer-in-Charge may direct the contractor to remove such materials or may
undertake the job at the cost of the contractor.
82.0 Conflict of Interest:
Any bribe, commission, gift or advantage given, promised or offered by on behalf of contractor
or his partner, agent or servant or any one on his behalf to any officer, servant, representatives,
agents of Engineer-in-Charge, or any persons on their behalf, in relation to the obtaining or to
execution of this, or any other contract with Engineer-in-Charge shall in addition to any criminal
liability, which it may occur, subject to the cancellation of this or all other contracts and also to
payment of any loss or damage resulting from any such cancellation. Engineer-in-Charge shall
then be entitled to deduct the amount, so payable from any money, otherwise due to the
contractor under this or any other contract.
87.0 Sanitation:
The contractor shall implement the sanitary and watch and ward rules and regulations for all
forces employed under this contract and if the Contractor fails to enforce these rules, the
Engineer-in-Charge may enforce them at the expenses of the Contractor.
88.0 Training of personnel:
The contractor, shall, if and as directed by the Engineer-in-Charge provide free of any charge
adequate facilities, for vocational training of Government Officers, students, Engineers,
supervisors, foremen, skilled workmen etc. not exceeding six in number at any one time on the
contractor's work. Their salaries, allowances etc. will be borne by the Government and the
training schemes will be drawn up by the Engineer-in-Charge in consultation with the
contractor.
89.0 Ecological balance:
a) The contractor shall maintain ecological balance by preventing de-forestation, water pollution
and defacing of natural landscape. The contractor shall so conduct his construction operation
as to prevent any unnecessary destruction, scarring, or defacing of the natural surroundings in
the vicinity of the work. In respect of the ecological balance, contractor shall observe the
following instructions.
i) Where unnecessary destruction, scarring, damage or defacing may occur, as result of the
operation, the same shall be repaired replanted or otherwise corrected at the contractor’s
expense. The contractor shall adopt precautions when using explosives, which will
prevent scattering of rocks or other debris outside the work area. All work are including
borrow areas shall be smoothened and graded in a manner to conform to the natural
appearance of the landscape as directed by the Engineer-in-charge.
ii) All trees and shrubbery which are not specifically required to be cleared or removed for
construction purposes shall be preserved and shall b protected from any damage that may
be caused by the Contractor’s construction operation and equipment. The removal of
trees and shrubs will be permitted only after prior approval by the Engineer-in-Charge.
Special care shall be exercised where trees or shrubs are exposed to injuries by
construction equipment, blasting, excavating, dumping, chemical damage or other
operation and the contractor shall adequately protect such trees by use of protective
barriers or other methods approval by the Engineer-in-Charge. Trees shall not be used for
anchorages. The contractor shall be responsible for injuries to trees and shrubs caused by
his operations. The term “injury” shall include, without limitation bruising, scarring,
tearing and breaking of roots, trunks or branches. All injured trees and shrubs be restored
as nearly as practicable without delay to their original condition at the contractor’s
expense.
iii) The contractor's construction activities shall be performed by methods that will present
entrance or accidental spillage of solid matter contaminants, debris and other it
objectionable pollutants and wastage into river. Such pollutant and waste include earth
and earth products, garbage, cement concrete, sewage effluent, industrial wastes, radio-
active substances, mercury, oil and other petroleum products, aggregate processing,
mineral salts and thermal pollution. Pollutants and wastes shall be disposed off in a
manner and at sites approved by the Engineer-in-Charge.
iv) In conduct of construction activities and operation of equipments the contractor shall
utilize such practicable methods and devices as are reasonably available to control,
prevent and otherwise minimize the air pollution. The excessive omission of dust in to
the atmosphere will not be permitted during the manufacture, handling and storage of
concrete aggregates and the contractor shall use such methods and equipment as a
necessary for collection and disposal or prevention of dust during these operations. The
contractor's methods of storing and handling cement shall also include means of
eliminating atmospheric discharges of dust, equipment and vehicles that give
objectionable omission of exhaust gases shall not be operated. Burning of materials a
resulting from clearing of trees, bushes, combustible construction materials and rubbish
may be permitted only when atmospheric conditions for burning are considered
favorable.
b) Separate payment will not be made for complying with the provisions of this clause and all
cost shall be deemed to have been included in the unit rates and prices included in the contract
if any provision is not complied with within a reasonable time even after issue of a notice in
this respect, the necessary operations would be carried out by the Engineer-in-Charge at the
cost of the Contractor, Orders of the Engineer-in-Charge in this respect would be final and
binding on the contractor.
90.0 Preservation of existing vegetation:
a) The contractor will preserve and protect all existing vegetation such as trees, on or adjacent to
the site which do not unreasonably interfere with the construction as may be determined by
the Engineer-in-Charge. The contractor will be held responsible for all unauthorized cutting or
damage of trees, including damage due to careless operation of equipment, stockpiling of
materials or trekking of grass areas by equipment Care shall be taken by the Contractor in
felling tress authorized for removal to avoid any unnecessary damages to vegetation and tress
that are to remain in place and to structures under construction or in existence and to
workmen.
b) All the produce from such cutting of trees by the contractor shall remain the property of
Government and shall be properly stacked at site, approved by the Engineer-in-Charge. No
payment whatsoever shall be made for such cutting and its stacking by the Contractor. If any
produce from such cutting is not handed over to the Government by the contractor, he shall be
charged for the same at the rates to be decided by the Engineer-in-Charge. The recovery of
this amount shall be made in full from the intermediate bill that follows.
c) The contractor shall also make arrangements of fuel deposits for supply of required fuel for a
the labourer to be employed for cooking purpose at his own cost in order to prevent
destruction of vegetation growth in the surrounding area of the work site.
91.0 Possession Prior to completion:
The Engineer-in-Charge shall have the right to take possession of or use any completed part of
work or works or any part thereof under construction either temporarily or permanently. Such
possession or use shall not be deemed as an acceptance of any work either completed or not
completed in accordance with the contract with in the interest of Clause 28 of Standard
specification except where expressly otherwise specified by the Engineer-in-charge.
within seven days of the date of the receipt by him/them of the order to carry out the work,
inform the Engineer-in-Charge of the rate which he/they propose to charge for such class of
work. If the Engineer-in-Charge does not agree to this rate he shall by notice in writing be at
liberty to cancel his order to carry out such a class of work and arrange to carry it out in such
manner as he may consider it advisable. In the event of dispute the decision of the Chief
Engineer concerned shall be final. The time limit for the completion of the work shall be
extended or curtailed in the proportion to the increase or decrease in its costs. As alteration or
curtailment bears to the cost of the original contract work, the certificate of the Engineer-in-
Charge as to such proportion shall be conclusive.
98.0 Care and diversion of river / stream. :
The contractor shall submit details regarding the diversion and care of river or stream during
construction of the work along with a separate print-out of the time table showing earliest and
latest start and finish dates of various activities. He should submit a detailed labour plan with
drawings for the diversion and care of river during construction of work. The above
arrangements shall be at contractor’s cost.
99.0 Income Tax:
a) During the currency of the contract, deduction of income tax as per Income tax Rule shall be
made from the gross value of each bill of the contract.
b) The contractor's staff, personnel and labour will be liable to pay personnel income taxes in
respect of their salaries and wages as are chargeable under the laws and regulations for the
time being in force; and the contractor shall perform such duties in regard to such deductions
thereof as may be imposed on him by such laws and regulations. The quoted price shall be
deemed to be inclusive of Income Tax & no additional payment on account of Income tax
and variation in Tax structure there of shall be admissible.
100.0 ROYALTY CHARGES:
The contractor shall keep books of accounts and other documents for the purpose of levy of
royalty charges as may be necessary to clearly arrive at such amounts and shall allow
inspection of the same by a duly authorized representative of the Employer and further shall
furnish such other information/document as the Employer may require from time to time.
101.0 GST:
101.1 GST as applicable shall be deducted at source during the currency of the contract while
making payments to the contractor.
101.2 The contractor should produce a valid GST Registration Certificate before the payment of the
final bill; otherwise payment to the contractor will be withheld.
101.3 The tax structure is liable for revision as per the orders of the Government issued from time to
time and in such case, the same tax will be deducted at source at the revised rates only while
making payment to the contractor.
101.4 Excess recovery due to downward revision in sales tax rates as per orders of Government from
time to time will be reimbursed.
102.0 Labour Welfare Cess.
Labour welfare cess @ 1% of gross bill amount is to be deducted during currency of contract
subject to the amendments made by Govt. from time to time.
b. by signing the Contract, the Contractor accepts total responsibility for having foreseen all
difficulties and costs of successfully completing.
c. The Works; and the Contract Price shall not be adjusted to take account of any unforeseen
difficulties or costs.
108.0 Rights of Way and Facilities:
The Contractor shall bear all costs and charges, other than the statutory charges, for special
and/or temporary rights-of-way/right-of-use, which he may require, including those for access
to the Site. Department shall bear the statutory charges for ROW. The Contractor shall also
obtain, at his risk and cost, any additional facilities outside the site, which he may require for
the purposes of the work.
109.0 Avoidance of Interference:
The Contractor shall not interfere unnecessarily or improperly with:
a) The convenience of the public, or
b) The access to and use and occupation of all roads and footpaths, irrespective of
whether they are public or in the possession of the Employer or of others.
The Contractor shall indemnify and hold the Employer harmless against and from all-
damages, losses and expenses (including legal fees and expenses) resulting from any such
unnecessary or improper interference.
110.0 Access Route:
The Contractor shall be deemed to have been satisfied as to the suitability and availability of
access routes to the Site. The Contractor shall use reasonable efforts to prevent any road or
bridge from being damaged by the Contractor's traffic or by the Contractor's Personnel. These
efforts shall include the proper use of appropriate vehicles and routes.
Except as otherwise stated in these Conditions:
The Contractor shall (as between the Parties) be responsible for any maintenance which may
be required for his use of access routes; the Contractor shall provide all necessary signs or
directions along access routes, and shall obtain any permission which may be required from
the relevant authorities for his use of routes, signs and directions; the Employer shall not be
responsible for any claims which may arise from the use or otherwise of any access route, the
Employer does not guarantee the suitability or availability of particular access routes, and
Costs due to non-suitability or non-availability, for the use required by the Contractor, of
access routes shall be borne by the Contractor.
111.0 Transport of Goods:
a) The Contractor shall give the Employer, not less than 21 days' notice, of the date on
which any Plant or a major item of other Goods will be delivered to the Site;
b) The Contractor shall be responsible for packing, loading, transporting, receiving,
unloading, storing and protection all Goods and other things required for the Works;
and
c) The Contractor shall indemnify and hold the Employer harmless against and from all
damages, losses and expenses (including legal fees and expenses) resulting from the
transport of Goods, and shall negotiate and pay all claims arising from their transport.
112.0 Contractor's Equipment: The Contractor shall be responsible for all Contractors'
Equipment. When brought on to the Site, Contractor's Equipment shall be deemed to be
exclusively intended for the execution of the work.
1) All Constructional Plant, Temporary Works and materials provided by the Contractor
shall, when brought on to the site, be deemed to be exclusively intended for the
execution of the Works and the Contractor shall not remove the same or any part
thereof, except for the purpose of moving it from one part of the site to another,
without the consent, in writing, of the Engineer, which shall not be unreasonably
withheld.
2) Upon completion of the works the Contractor shall remove from the site all the said
Constructional Plant and Temporary Works remaining thereon and any unused
materials provided by the Contractor.
3) The Employer shall not at any time be liable for the loss of or damage to any of the
said Constructional Plant, Temporary Works or materials.
113 .0 Progress Reports:
Monthly progress reports shall be prepared by the Contractor and submitted to the Employer
in six copies. The first report shall cover the period up to the end of the first calendar month
following the Commencement Date. Reports shall be submitted monthly thereafter, each
within 5 days after the last day of the period to which it relates.
Reporting shall continue until the Contractor has completed all work. The work which is
known to be outstanding at the completion date is to be completed stated in the Taking-Over
Certificate for the Works.
Each report shall include:
a) Charts and detailed descriptions of progress, including each stage of surveys,
Investigation, design, Contractor's Documents, procurement, manufacture, delivery to
Site, construction, commissioning and trial operation;
(b) Digital photographs/videography showing the status of progress on the Site;
(c) For the manufacture of each main item of Plant and Materials, the name of the
manufacturer, manufacture location, percentage progress, and the actual or expected
dates of :
(i) Commencement of manufacture,
(ii) Contractor's inspections,
(iii) Tests, and
(iii) Shipment and arrival at the Site;
(d) The details of Contractor's Personnel and Equipment
(e) Copies of quality assurance documents, test results and certificates of Material;
(f) List of Variations, notices given
(g) Safety statistics, including details of any hazardous incidents and
Activities relating to environmental aspects and public relations; and
(h) Comparisons of actual and planned progress, with details of any events or
circumstances which may jeopardize the completion in accordance with the Contract,
and the measures being (or to be) adopted to overcome delays.
114.0 Design:
114.1 General Design Obligations:
The Contractor shall be deemed to have scrutinized, prior to the Base Data, the Employer's
Requirements (including design criteria and calculations, if any). The Contractor shall be
responsible for the Investigation planning and Design of the work and for the accuracy of such
Employer's Requirements (including design criteria and calculations), except as stated below.
The Employer shall not be responsible for any error, inaccuracy or omission of any kind in the
Employer's Requirements as originally included in the Contract and shall not be deemed to
have given any representation of accuracy or completeness of any data or information. Any
data or information received by the Contractor, from the Employer or otherwise shall not
relieve the Contractor from his responsibility for the Investigation, design and execution of
the work.
114.2 Contractors Documents:
The Contractors Documents shall comprise the technical documents specified in the
Employer's Requirements, documents required to satisfy all regulatory approvals, and the
documents.
The Contractor shall prepare all Contractors Documents, and shall also prepare any other
documents necessary to instruct the Contractors Personnel.
If the Employer's Requirements describe the Contractor's Documents which are to be
submitted to the Employer for review, they shall be submitted accordingly, together with a
notice as described below. In the following provisions of this Sub-Clause, (i) "review period"
means the period required by the Employer for review, and (ii) "Contractor's Documents"
exclude any documents which are not specified as being required to be submitted for review.
The Employers may give notice to the Contractor that a Contractor's Document fails (to the
extent stated) to comply with the Contract. If a Contractor's Document so fails to comply, it
shall be rectified, resubmitted and reviewed in accordance with this Sub-Clause, at the
Contractor's cost.
For each part of the work, and except to the extent that the Parties
otherwise agree:
(a) Execution of such part of the work shall not commence prior to the expiry of the
review periods for all the Contractor's Documents which are relevant to its design and
execution.
(b) Execution of such part of the work shall be in accordance with these Contractor's
Documents, as submitted for review; and if the Contractor; wishes to modify any
design or document which has previously been submitted for review, the Contractor
shall immediately give notice to the Employer. Thereafter, the Contractor shall submit
revised documents to the Employer in accordance with the above procedure.
(c) If the Employer's Representative instruct that further Construction Documents are
necessary for carrying the work, the Contractor shall upon receiving the Employer's
Representative Instructions prepare such construction documents and shall not be
considered as variation. Any such contract (under the preceding paragraph) or any
review (under this Sub-Clause - or otherwise) shall not relieve the Contractor from
any obligation or responsibility.
114.3 As-Built Documents:
The Contractor shall prepare, and keep up-to-date, a complete set of 'as-built' records of the
execution of the work, showing the exact as-built locations, sizes and details of the work as
executed. These records shall be kept on the Site and shall be used exclusively for the
purposes of this Sub-Clause. Two copies shall be supplied to the Employer prior to the
commencement of the quantity checks / Verification Tests on Completion.
In addition, the Contractor shall supply to the Employer as-built drawings of the work,
showing all components of the work as executed, and submit them to the Employer for review
under Sub-Clause [Contractor's Documents]. The Contractor shall obtain the consent of the
Employer as to their size, the referencing system, and other relevant details.
Prior to the issue of any Taking-Over Certificate, the Contractor shall supply to the Employer
the specified numbers and types of copies of the relevant as-built drawings, in accordance
with the Employer's Requirements. The Work shall not be considered to be completed for the
purposes of taking-over [Taking Over of the work and Sections] until the Employer has
received these documents.
114.4 Design Error:
If errors, omissions, ambiguities, inconsistencies, inadequacies or other defects are found in
the Contractor's Documents, then the work shall be corrected at the Contractor's cost,
notwithstanding any consent or approval under this Clause.
115.0 Programme:
115.1 The Contractor shall submit a work programme to the employer within 15 (fifteen) days after
the conclusion of contract / commencement date whichever is earlier and the programme shall
be based on the basic time period for completion and milestone as indicated in the Contract
Document. Contractor's programme shall be considered effective upon acceptance by the
Employer's Representative.
The Contractor shall also submit a revised work programme whenever the previous
programme is inconsistent with actual progress or with the Contractor's obligations unless
other wise stated in the contract each programme shall include:
(a) The order in which the Contractor intends to carry -out the work, including the
anticipated timing of each major stage of the works.
(b) The periods for reviews under Clause [Contractor's Documents],
(c) The sequence and timing of inspections and tests specified in the Contract, and
(d) A supporting report which includes:
(i) A general description of the methods which the Contractor intends to
adopt for the execution of each major stage of the work, and
(ii) The approximate number of each class of Contractor's Personnel and
of each type of Contractor's Equipment for each major stage.
The Contractor shall promptly give notice to the Employer of specific probable future
events or circumstances, which may adversely affect or delay the execution of the
work. In this event, or if the Employer gives notice to the Contractor that if a
programme fails (to the extent stated) to comply with the Contract or to be consistent
with actual progress and the Contractor's stated intentions, the Contractor shall submit
a revised work programme to the Employer in accordance with this Sub-Clause.
115.2 Rate of Progress:
If, at any time:
(a) Actual progress is too slow to complete within the Time for Completion, and/or
(b) Progress has fallen (or will fall) behind the current programme under
Clause 25 [Programme],
Then the Employer may instruct the Contractor to submit, under Clause 25 [Programme], a
revised programme and supporting report describing the revised methods which the
Contractor proposes to adopt in order to expedite progress and complete within the Time for
Completion of the mile stone and the work.
Unless the Employer notifies otherwise, the Contractor shall adopt these revised methods,
which may require increases in the working hours and/or in the numbers of Contractor's
Personnel and/or Goods, at the risk and cost of the Contractor.
116.0 Charge of Site
From the commencement of the work to the completion of the same, they are to be under the
contractor (s) charge. The Contractor(s) is / are to be held responsible for and to make good all
injuries, damages and repair occasioned or rendered necessary to the same by fire or other
causes and they are to hold the employer harmless from any claims for injuries to persons or
for structural employer harmless from any claims for injuries to persons or for structural
damage to property happening from any neglect, default, want of proper care or misconduct
on the part of the contractors(s) or of any one in his/their employees during the execution of
the work.
117.0 Changes in Drawing
If at any time before or after the commencement of the work the employer shall for any
reason whatsoever.
a) Cause alterations, omissions or variation in the drawings and specification involving
any curtailment of the work as originally contemplated or
b) Not required the whole of work as specified in the Bid to be carried out, the
contractor(s) shall have no claim to any payment or compensation whatsoever on
account of any profit or advantage which he/they might have derived from the
execution of the work in full as specified in the Bid but which he/they did not derive
in consequence of the curtailment of the work by reason of alterations, omissions or
variations or in consequence of the full amount of the work not having been carried
out.
118.0 “Force Majeure” means an event beyond the control of the Employer and the Contractor,
which makes it impossible or illegal for a party to perform, including but not limited to:
i) Act of God
ii) War, hostilities (whether war be declared or not), invasion, act of foreign
enemies, mobilization, requisition, or embargo;
Section-V
Special Conditions of Contract
1. GENERAL
The data and information given in the Contract Document are based on the
preliminary survey taken up by the Department. The Contractor shall therefore,
satisfy himself about the adequacy and accuracy of the said data/information and
interpretation thereof and collect fresh data/additional data/information and carry
out/conduct further investigations and studies if necessary. The Employer shall not be
responsible for the accuracy/adequacy of the data/information and interpretation
thereof by the Contractor. The contractor shall receive all the available
data/information from the department on his written request.
2. SUFFICIENCY OF BID
2.1 The Contractor shall be deemed to have visited and carefully examined the Project
site and it’s surrounding to have satisfied himself to the nature and conditions of the
means of transport and communications, whether by land or air, as available at
present and as to possible interruptions thereto including the access and regress
conditions for the Site. The Contractor is also deemed to have made enquiries,
examined and satisfied himself as to the sites source for obtaining sand, stones, bricks
and other materials, the sites for disposal of surplus materials and accommodation for
depots, colonies, workshops and other infrastructure facilities as may be necessary for
executing and completing the Works, as also the sub-soil water and variations thereof,
storms, prevailing winds, climatic conditions and all other similar matters affecting
the works including law & order.
2.2 Any neglect or omission or failure on the part of the Contractor in obtaining necessary
and reliable information upon the foregoing or any other matter affecting the Contract
shall not relieve him from any risks or liabilities or the entire responsibility for the
completion of the works in accordance with the Contract.
2.3 No verbal agreement or inference from conversation with any officer or employee of
the Employer either before or after the signing of the Contract shall in any way affect
or modify any of the terms or obligations herein contained. The Contractor shall also
be deemed to have inspected and examined the Site and to have satisfied himself,
before submitting his Bid, as to the form and nature thereof including the sub-surface
conditions and other local conditions, the hydrological, geological and climatic
conditions, the extent and nature of work and materials necessary for the completion
of the work, the means of access to the Site and the land for accommodation etc. he
may require and in general, shall be deemed to have obtained all necessary
information, as to risks, contingencies and all other circumstances which may
influence or affect his Bid.
3.1 The major components as proposed by the Employer along with the basic project
design parameters fixed by the Employer is indicated in the Information to Bidder,
Section II and Basic Project Profile, Appendix BPP, Section VI.
Basic Parameters pertaining to the work are given in the Basic Project Profile,
Appendix BPP, Section VI. The 100 year flood, 500 year flood and the pond height
(to be measured from upstream floor level of barrage) provided are fixed parameters
and cannot be changed by the bidder. Other parameters are tentative and the bidder is
to assess the correctness of the data and adequacy of the data. All additional survey,
investigation and testing data and any other data relevant to design shall be collected
by the Contractor without any financial burden to the Employer.
4. SCOPE OF WORK
4.1 General
4.1.1. The major components of the work to be executed by the contractor under this
contract shall be as described section - wise as follows. Execution of all these works
shall include all construction plant / equipment and materials indigenous or imported,
survey, investigation, survey equipment, studies and all services and facilities
required for completion of the work.
4.1.2. Any requirements of work whether requested by the Employer or otherwise and
whether specifically described in the Contract or not but are necessary or required for
the proper completion and functioning of the Works in accordance with the Contract
including remedying of any gaps and deficiencies in the Works shall not be deemed to
be considered as any change in the Scope of Work and shall not entitle the contractor
for any extra payment.
4.2.1. The scope of work under this section covers surveys and investigation requirement for
detailed planning of the work covering foundation exploration work, grid survey for
structures, their longitudinal sections and cross section, marking contours at 0.5 meter
interval along the ridges and valleys, land plan schedules and land acquisition
proposals including demarcation of land to be acquired by fixing appropriate no of
boundary stones etc; for design engineering of the Civil works related to bridge,
barrage including scouring sluices and fish ladder, pier, abutments, guide wall, guide
bunds/afflux bunds and other appurtenant works, Construction of approach road from
the nearest connectivity to the barrage site, Construction of a watchman and operator
shed near the barrage, Mechanical works like gates in barrage including Hoist and
Hoist Bridge , Power system connectivity, allied machineries and facilities for gate
operations and lighting of the bridge, hoist bridge and the barrage sites, for execution
and commissioning of the project. The Contractor shall carryout surveys and detailed
investigation required for the whole systems under this Contract as per the I.S. Codes,
IRC codes, Manuals, Standards, Guidelines, Circulars of the Department issued from
time to time. This shall not entitle the contractor to additional cost whatsoever other
than the contract price. The total scope of services shall be as per Appendix S&I and
Instruction to Bidders. Survey is to be carried as far as possible by the Total Station
instrument.
4.3.1 The present proposal is based on department’s preliminary survey and planning. The
contractor is free to change the concept and designs, keeping intact the basic purpose
of providing maximum in stream storage with no submergence, in normal
circumstances. The Contractor shall submit design of barrage, bridge, piers,
abutments, , under sluices, gates and hoists with Hoist Bridge etc. which shall be
always in conformity with the basic parameters and in accordance with the
Nationally/Internationally accepted practice and for the optimal performance of the
works as warranted under the Contract. This shall not entitle the Contractor to
additional cost, whatsoever, other than the contract price. The total scope of services
under this section shall be as per the Appendix – D&E and Instruction to Bidders.
The number of copies of the Reports and other Documents to be submitted to the
Engineer-in-Charge by the contractor is also specified in Contract Document.
The scope of work under this section detailed in Appendix-CW covers provision of all
labour, plant and materials for execution of all civil works, complete in all respect, as
described in conditions of contract and Technical Specifications of Bid Documents
including incidentals and all necessary works not shown or specified but reasonably
implied or necessary for the proper completion and functioning of the works in
accordance with the contract including any amendments thereof.
The scope of work under this section detailed in Appendix- EM includes provision of
all labour, plant and materials for supply and execution of electro-mechanical works
complete in all respect, as per Technical Specifications of Bid Documents including
incidentals and all necessary works not shown or specified but reasonably implied or
necessary for the proper completion and functioning of the works in accordance with
the contract including any amendments thereof.
5.1 The Contractor shall be required to carry out all tests in accordance with relevant
Clauses of the Conditions of contracts and the Technical Specifications and as per
I.S.Codes, IRC codes and Manuals.
to laying at site. The agency has to make arrangements from time to time for
inspection of testing of materials at wok site.
5.2.1 Where the field quality assurance plan provided for witnessing tests/inspection on
behalf of the Engineer, the Contractor shall give the Engineer-in-Charge adequate
written notice of any inspections/tests.
5.2.2 Where the Engineer or his Representative attends the tests as provided in clause 5.2.1
above, and has any objection to any works or workmanship which in his opinion is
not in accordance with the Contract he shall advise the Contractor of his objection
during tests/inspections. The Contractor shall give due consideration to such
objections and shall make modifications that may be necessary to meet the said
objective. The inspection/tests by Engineer/ Engineer’s Representative/Agency and/or
his countersigning inspection/test certificate(s) thereon shall in no way limit the
liabilities and responsibilities, of the Contractor as stipulated in the Contract. The
Contractor shall maintain and record all measurements and test results and submit the
same to the Employer after completion of such inspection/tests.
6.1 The Contractor is entitled for interim payment under various sections of the work in
accordance with Clause 41 of the General Conditions of Contract. Measurement /
verification for interim payment certificate of various items, under various sections of
the works, shall be made jointly by the Engineer-in-Charge or his Subordinate Staff
and the Contractor or his authorized representative for verifying the claims of the
Contractor’s interim payment/running bills.
6.2 All items having a financial value shall be measured in the manner as prescribed in
specification by the contractor and verified by the Engineer-in-Charge so that a
complete record is maintained of all work performed under the Contract.
6.3 Measurement shall be signed and dated by both parties on the site. If there is any
dispute in any of the measurements a note to the effect shall be made in the
measurement record against the disputed items and such note shall be signed and
dated by both parties engaged in taking the measurements and the Parties shall discuss
and resolve the same in accordance with relevant clauses of the contract.
7.1 Supply at Site of the Gates and connected Electro Mechanical Plant & Machineries,
embedded parts and spares etc., shall be made available two months in advance of the
scheduled dates of Installation/erection matching with the progress and availability of
Civil works to take care of any eventualities of hold ups/delays during transit.
7.2 If for any reason, any parts of the work of the Project are delayed, then the total
programme may be re-scheduled by mutual agreement between the Engineer-in-
Charge and the Contractor, if necessary, keeping the overall completion schedule of
the project unaltered. No extra cost whatsoever, on account of such re-scheduling
shall be payable to the contractor.
8. SUPPLEMENTARY REQUIREMENTS
8.1 General
The following parts of this Section shall be read in conjunction with the Section IV
Conditions of Contract, and Section V: Special Condition of Contract. The following
Clauses shall supplement the provisions of the corresponding clauses of Section IV
and V and whenever there is a conflict, the provisions herein shall prevail over those
in Section IV.
The Contractor shall formulate submission of proposals for all components of the
Barrage-cum-Bridge individually. The designs, drawings and estimates of barrage,
bridge, under sluices, piers, abutments, gates & hoist and hoist bridges, Road
connectivity, Electrical Connectivity, shall be furnished to the Engineer-in-Charge for
approval. All soft copies and software used for computation shall be made available to
the Engineer-in-Charge for vetting of the designs, drawings and estimates by the
competent authority. Contractor shall supply to the Engineer-in-Charge 6 (six) copies
each of the design calculations and drawings for approval. The Contractor shall
incorporate all necessary comments of the Engineer’s Representative in the above
design and drawings, if any, and shall re-submit further 6 (six) copies each of the
revised design and drawings within 10 (ten) days for final approval. The Contractor
shall thereafter submit 10 (Ten) copies each of the approved design and 10 (Ten)
copies each of the approved drawings together with one copy each of the reproducible
tracings to Engineer-in-Charge. Further design calculations and drawings shall be
submitted in sequence as per a schedule to be drawn and agreed upon mutually.
The documents and drawings shall be in sufficient detail for review. The scale of the
drawing has to be chosen in coordination with the Engineer-in-Charge. The drawings
shall be of standardized sizes and as instructed by the Engineer-in-Charge. The
drawings shall contain the following basic information in the name plate:
a) Project name
c) Contractor's name
h) Revision Number (R0 for drawing submitted initially and R1, R2, etc., for
Drawings submitted subsequently).
A blank space 90mm x 50 mm shall be provided immediately above the title block for
the approval stamp. If required by the Approving Authority, the detailed design and
the execution drawings shall be submitted by the contractor to the Approving
Authority only after verification by the Consultant(s) notified by the Engineer-in-
Charge.
The Contractor shall be responsible for preparation of working drawings and the
construction documents for works, as specified in the Contract. Drawings given are
indicative, but will form part of the contract.
The contractor shall carry out alignment studies including cost economics by
examining all possible alternatives to prepare detailed layout, designs and drawings of
all components of the work stated in scope of work. The contractor shall use
guidelines in the relevant IS codes, IRC publications and circulars issued by the
department from time to time for various components of the work.
All the studies of the work, layout drawings and modifications if required to be
prepared for taking up execution of the work, shall be prepared by the contractor and
shall be got approved from the competent authority. The contractor will have to
submit detailed drawings of each component with appropriate scales, measurements,
Reduced Levels, full dimensions, index map locations of components such as
godown, burrow area, dumping area, internal roads, etc., The contractor is expected to
organize his work to the best of his knowledge so that final draft of various types of
designs and layouts will be submitted to competent authority within stipulated time
period.
All the studies layouts, drawings, design notes, which have been submitted to the
department, shall become the absolute property of department under the copy right act
and the contractor shall not use the same in whole or part thereof elsewhere for any
purpose without explicit written permission from the department. In all difference of
opinion on technical matters between the contractor and the Engineer-in-Charge, the
decision given by the Chief Engineer shall be final and binding on the contractor.
8.3.1 Within 15 (fifteen) days from the Date of Commencement, the Contractor shall
submit to the Employer a work programme showing the sequence in which he
proposes to carry out various components for completing the works as per the Master
Control Network within the stipulated date of completion. The Master Control
Network shall indicate the sequence of various activities and highlight the critical
activities including delivery of equipment. Such work programme shall be subject to
review and revision by the Employer/Engineer-in-charge in consultation with the
Contractor from time to time in order to achieve completion of the work within the
stipulated date of completion. The contractor shall also use computer aided project
management software to generate Bar Chart based on network technique.
8.3.2 The contractor shall also submit to the Employer/Engineer-in-charge the information
on detailed methodology of carrying out investigation survey, design engineering,
detailed construction methodology along with schedule for deployment of plant &
machineries, which shall successively be adjusted in order to meet the actual
requirement to complete the work within the stipulated date of completion along with
the work programme.
8.3.3 All the survey & investigation, planning, designs, approval processes, procurement
and construction work of the project shall be taken up simultaneously; so that the
work can be completed within time for completion.
8.4 Action when the progress of any crucial item of work is unsatisfactory : If the
progress of a crucial item of work, which is important for timely completion of work
is unsatisfactory, the Engineer-in-Charge shall, not withstanding that the general
progress of work is satisfactory, in accordance with relevant clause, be entitled to take
action under this clause after giving the contractor 15 days notice in writing and the
contractor will have no claim for compensation for any loss sustained owing to such
action.
8.5.1 The works shall be executed and performed in accordance with the Master Control
Network (Work Programme) which shall clearly indicate the interlinking /
interdependencies of all the works of the Contract including relative activities of Civil
works and Electro-Mechanical works and the Power Connectivity for the project. The
Programme shall be reviewed jointly by the Employer/ Engineer and the Contractor,
at least once in a month where-in the hold ups/delays, if any, in the progress of work,
with reference to the agreed Schedule shall be given Special Attention. Necessary
modifications (updating / Revisions) of the Programme, within the overall Time for
Completion, shall be carried out by mutual agreement between the Employer/
Engineer and the Contractor.
8.5.2 If for any reason, any parts of the work of the Project are delayed, then the total
programme may be re-scheduled by mutual agreement between the Engineer-in-
Charge and the Contractor, if necessary, keeping the overall completion schedule of
the project unaltered. No extra cost whatsoever, on account of such re-scheduling
shall be payable to the contractor.
The Contractor shall submit to the Engineer, Engineer’s Representative and Engineer-
in- Charge monthly progress report by 5th. day of following months in such form and
details as prescribed by Engineer-in-Charge.
Engineer-in-Charge shall have the right to reject defective material and workmanship
or require its corrections. Rejected workmanship shall be satisfactorily replaced with
proper material without charge thereof and the contractor shall properly segregate
and remove the rejected material from the premises, if the contractor fails to
proceed at once with the replacement of the rejected material and / or the
construction of defective workmanship, the Engineer-in-Charge may replace such
material and / or correct such workmanship and charge the cost thereof to the
contractor.
The contractor shall furnish promptly without additional charge, all facilities, labour
and material necessary for the safe and convenient inspection and tests that may be
required by the Engineer-in-Charge.
All inspections and tests by the department shall be performed in such a manner as
not to unnecessarily delay the work.
The works, whether fully completed or incomplete in any project site, all the
materials, machineries, plants, tools, buildings and other things connected there with,
shall remain at the risk and in the sole charge of the contractor until whole of the
completed work scheme wise under the Contract has been handed over to the
Engineer-in-Charge. Until such delivery of the entire completed work, the contractor
shall at his own cost take all precautions reasonably to keep all the aforesaid works,
materials, machines, plants, temporary buildings and other things connected there
with free from any loss or damage and in the event of the same or any part thereof
being lost or damaged, he shall forth with reinstate and make good such loss or
damage at his own cost. The complete work shall be insured against all possible risks.
On the completion of the work the Engineer-in-Charge shall make such examination
and tests of the work as may then seem to him possible, necessary or desirable, and
the contractor shall furnish free of cost any materials, equipments and labour which
may be necessary thereof, and shall facilitate in every way all operations required by
the Engineer-in- Charge, in making examination and tests within one calendar month
from receipt of the written notice from the examine.
On the completion or part completion of the work, the fitted gates in the barrage and
sluices shall be subjected to trial run for 24 hours up-to 30 days or as decided by
Engineer-in-Charge to locate any defect and excessive leakage, if any. The trial run
shall not be deemed as commissioning of the project.
The Contractor shall have to make the work sites accessible to the departmental
officers for inspection by way of constructing/maintaining all weather
roads/approaches, the cost of which shall be borne by the Contractor.
The construction of approach road to site is within the scope of work. The Contractor
shall have to submit detailed plan to the Engineer-in-Charge showing the layout of the
work site and approach roads proposed by him, before he starts the actual work. Such
a road layout plan will be scrutinized by the Engineer-in-Charge and any
modifications suggested by him shall be binding on the contractor. However the
contractor may choose to have a separate haul road for transportation of materials and
machineries without any additional cost to employer If it is decided by the Engineer-
in-Charge to have some of the roads proposed by the Contractor as common road for
common use of department and other contractors or convenient and for compact and
planned layout of work site, the Contractor will be bound to construct them and allow
them to be used simultaneously by other Contractors and departments. In case of
disputes, the decision of the Engineer-in-Charge shall be final and the binding on the
Contractor.
The contractor shall conform to the regulations, bye-laws, any other statutory rules
made by any local Authorities or by the Government and shall protect and indemnify
Government against any claim or liability arising from or based on the violation of
any such laws, ordinance, regulations, orders, decrees, etc.,
After the completion of the work of excavation, the same will be checked and passed
by the competent authority. No masonry or concrete or back filling shall be laid
unless the foundations are so passed. No concreting shall commence, unless the
centering and the reinforcement is checked and passed by the Engineer-in-charge.
Before starting the work, and at the end before the work is covered, levels for plotting
the longitudinal sections (along the axis as decided by Engineer-in-Charge or his
authorized representative) and cross section of the portion of the work shall be taken
by authorized Engineer of the contractor in the presence of the Engineer-in-Charge or
his authorized representative and the same shall have to be got attested from the
Engineer-in-Charge or his authorized representative in token of acceptance.
If the contractor fails to take measurements and sign them, then the measurements
recorded by the Engineer-in-charge, or his authorized representative in the authorized
books shall be final and binding on the contractor. For this purpose, suitable date or
dates shall be fixed by the Engineer-in-Charge and intimated to the contractor. If the
contractor, or his duly – authorized agent fails to attend on the appointed date or dates,
the levels and measurements shall be taken in his absence and such levels and
measurements and longitudinal sections and cross sections based there on shall be
final and binding on the Contractor. The levels will be taken on such alignments and
cross sections as will be useful for reference permanently. The point of the locations
for the levels will depend upon the roughness of the area and will also be at least in
conformity with the requirement of specifications for “Excavation” as for as possible.
Similar procedure for record of measurements shall hold good for all other items and
activities involved in execution of the work. All the levels/measurements shall be
recorded by the Engineer-in-Charge or his authorized representatives in the authorized
level / measurement books.
The contractor shall produce results of quality control tests carried out on the works by
his staff and the quality audit conducted by the department or by Engineer’s
Representative on these works. If the test result do not fulfil the stipulated criteria laid
down in specifications the payment will be limited as per the provisions in the
specification(s) and if number of results fail beyond the limit of acceptance, then the
contractor shall not be paid unless he rectified all such imperfect work(s). The
decision of the Engineer-in-Charge in respect of the matters pertaining to the quality
control shall be final and binding on the Contractor.
13. CLEANING UP
a) The Contractor shall at all time keep the construction areas and his colony and
storage free from accumulation of waste or rejected materials.
b) Prior to the completion of the work, the Contractor shall remove all rubbish
from and around the premises and all tools, scaffolding equipment and
material which are not part of permanent structures executed or otherwise
asked for or as provided under any other Clauses of this contract. The
premises will be left in a manner fully satisfactory to the Engineer-in-Charge.
All communication and or notices pertaining to works and concerning matters, such
as passing and approving of foundation, reinforcement, and form work,
measurements, mark outs, etc shall not be addressed by the Contractor to an officer
not below the rank of Executive Engineer. The official language is English. All such
notices communications, etc shall be addressed in good time so as not to hold up the
work.
The contractor shall not be entitled to claim any compensation from department for
the loss suffered by him on account of delay by department in approval of alignment,
designs & drawings. However this may be considered for grant of time extension.
The Contractor shall execute the whole and every part of the work in the most
substantial and workmen like manner and both as regards materials and otherwise in
every respect in strict accordance with specifications. The Contractor shall also
confirm exactly, fully and faithfully to the designs, drawings and instructions in
writing relating to the work signed by the Engineer or Engineer-in-Charge and lodged
in his office, and to which the contractor shall be entitled to have access at such office
or on the site of the work for the purpose of inspection during office hours, and the
contractor shall, if he so requires, be entitled at his own expense to make or cause to
be made copies of specifications and of all such designs, drawings and instructions as
aforesaid.
All the Executive Engineers connected with work shall have power to make any
alterations in, or omissions from, addition to, or substitutions for the original
specifications and approved drawings, designs and instructions that may appear to
him to be necessary or advisable during the progress of the work and the contractor
shall be bound to carry out the work in accordance with any such instruction which
may be given to him in writing signed by the Executive Engineer or Engineer-in-
Charge and such alterations omissions, additions or substitutions shall not invalidate
the contract and any altered, additional or substituted work, which the contractor may
be directed to do in the manner above specified as part of the work, shall be carried
out by the contractor on the same conditions, in all respects on which he agreed to do
the main work and at the same contract cost.
Whenever any claim, against the Contractor for the payment of a sum of money arises
out of or under the Contract. Government shall be entitled to recover such sum by
appropriating, in part or whole, the Security deposit and performance security deposit
of the Contractor and to sell any Government promissory notes etc., forming the
whole or part of such security. In the event of the security being insufficient or if no
security has been taken from the Contractor, then the balance or the total sum
recoverable, as the case may be, shall be deducted from any sum then due or which at
any time thereafter may become due to the Contractor under this or any other contract
with Government. Should this sum be not sufficient to cover the full amount
recoverable from the Contractor then it shall be recovered from him as arrears of land
revenue.
The contractor shall give not less than 15(fifteen) days notice in writing to the
Engineer-in- Charge of the work, before covering up or otherwise placing beyond the
reach of measurement any work in order that the same may be verified/checked and
correct dimensions thereof be taken before the same is so covered up or placed
beyond the reach of verification/checking of any work without the consent in writing
of the Engineer-in-Charge of the work, and if any work shall be covered up or placed
beyond the reach of verification/checking without such notice having been given or
consent obtained, the same shall be uncovered at the contractor’s expense or in default
thereof, no payment or allowance shall be made for such work or materials with
which the same was executed.
The contractor shall supply at his own cost materials, plant, tools appliances,
implements, tackle, scaffolding and temporary works requisite for the proper
execution of the work, whether original, altered or substituted and whether included
in the specifications or other documents forming part of the contract or referred to in
these conditions or not, or which may be necessary for the purpose of satisfying or
complying with the requirements of the Engineer-in-Charge as to any matter as to
which under these conditions he is entitled to be satisfied, or which he is entitled to
require together with carriage to and from the work. The contractor shall also supply
without charge the requisite number of persons with the means and materials
necessary for the purpose of setting out works and counting, weighing & assisting in
the checking measurement or examinations at any time and from time to time of the
work or materials. Failing his so doing, the same may be provided by the Engineer-in-
Charge at the expense of the contractor and the expenses may be deducted from any
money due to the contractor under the contract, or from his security deposit or the
proceeds of sale thereof, or of a sufficient portion thereof. Contractor is liable for
damages arising from non provisions of lights, fencing etc., The contractor shall also
provide at his own cost, except when the contract specifically provided other wise and
except, for payment due, all necessary fencing and lights required to protect the public
from accidents, and shall be bound to bear the expenses or defence of every suit,
action or other proceedings of law that may be brought by any person for injury
sustained owing to neglect of the above precautions and to pay any damages and costs
which may be awarded in any such suit, action or proceedings, to any such persons or
which may be paid to compromise any claim by any such person.
Government shall have the right to cause any audit and technical examination of the
works and the running and final bills of the Contractor including all supporting
vouchers, abstracts etc to be made after payment of the running and final bill and if as
a result of such audit and technical examinations any sum is found to have been
overpaid in respect of any work done by the contractor under the contract or any work
claimed by him to have been done by him under the contract and found not to have
been executed, the contractor shall be liable to refund the amount of overpayment and
it shall be lawful for Government to recover the same from him in the manner
prescribed in clause “Recovery of dues from contractor” and if it is found that the
contractor was paid less than what was due to him under the contract in respect of any
work executed by him under it, the amount of such under payment shall be duly paid
by Government to the contractor.
Some component of works may interfere Railway, State Highway, Other Roads, other
pipelines etc., and as such necessary letter to grant the permission for crossing those
premises shall be issued by the respective authorities to the Engineer-in- Charge. The
contractor will have to process, follow-up and obtain timely clearance from the
concerned authorities. Statutory costs of those crossings will be paid by the
Government or will be reimbursed to the contractor if paid by him on
production of receipt.
b) For any private land, Govt. land and property, required for this work, the
process of Land and property acquisitions is to be carried out by the contractor
with the help of department. Necessary proposals/letters to concern
department will be given by the Engineer in charge, further follow-up for
timely acquisition is to be done/watched by the contractor Except cost of
temporary land acquisition or early mutually agreed acquisition of land and
crop compensation, the department shall make payments for acquiring
permanent land and property as per LA Act & Rules. The contractor shall pay
cost of temporary land acquisition and crop compensation, if any. Pursuing the
land and property acquisition cases, getting the award/approval from
competent authority, within the time shall be the whole responsibility of the
contractor, the land required for construction before award will be arranged by
the contractor to ensure timely completion of the scheme for which no claim
(c) Forest land Acquisition: During planning & Design of the barrage –cum-
bridge care shall be taken by the contractor to avoid forest land. In
unavoidable situations, the contractor shall process all forest clearance paper
works on behalf of the Department. Cost of forest land, if any to be acquired
& Cost of afforestation if any required shall be paid by the Department. All
other costs shall be borne by the contractor.
a) All land required for use of Contractor facility shall be arranged by the
Contractor from private land owner/revenue department at his own cost and no
claim on this account shall be entertained.
b) All areas of operation including those of his staff and labour colonies in case
handed over to the contractor shall be cleared and handed over back in good
condition to the Engineer-in-Charge except the areas under works constructed.
The Contractor shall make good to the satisfaction of the Engineer-in-Charge
any damage or alterations made to areas, which he has to hand over back or to
other property or land handed over to him for the purpose of this work.
c) The lands shall as herein before mentioned be handed over back to the
Engineer-in-charge immediately after completion of the work under this
contract or the termination of the contract whichever is earlier. Also no land
shall be held by the Contractor longer than the Engineer-in- Charge shall deem
necessary and the Contractor shall on due notice by the Engineer-in-Charge
vacate and returned the land which the Engineer- in-Charge may certify as no
longer required by the Contractor for the purpose of the works. In case the
lands are not handed over back to the department within the time limit
specified above, penal rent as may be decided by the Engineer-in-Charge will
be recovered from the contractor.
d) The vegetation and forest is noticeable in project area. The Contractor should
take utmost care for the preservation of this vegetation and forest. Any
damage in this vegetation and forest will have to be compensated by the
Contractor and decision of Engineer-in-Charge will be final and binding on
Contractor.
The availability of Power is indicated in the section of the Basic Project Profile
Appendix-BPP. The contractor is advised to study the provision.
The contractor shall review all the information / data available with the department
and assess the scope of surveys, investigation etc., that are to be carried out to fulfil
the obligations under the contract.
28.1 The contractors shall take this into consideration while quoting for the bid. No claims
whatsoever on this issue will be entertained during execution.
28.2 Wherever the ancillary works require shifting of H.T./L.T. power lines, towers,
Electrical poles, Telephone lines water supply lines and any other facility in way of
work etc. either permanently or temporarily the contractor shall arrange for such
shifting of power lines towers, electrical poles etc., through concerned authorities of
GRIDCO/OPTCL/WESCO/SOUTHCO and other agencies at his own cost. The
Engineer-in-Charge will process the proposals submitted by the contractor to the
authorities concerned. The price bid quoted by the Contractor is deemed to be
inclusive of such cost and no claims for separate payment will be entertained.
28.3 Contractor shall process shifting of HT/LT lines, Telephone lines & electrical and
telephone poles etc. The statutory charges required for the shifting/relocation shall be
borne by the Dept. The cost of works will be borne by the contractor. Quantum of
such works shall be assessed by the bidder.
28.4 Wherever any component of work of a scheme is crossing Railway line, the contractor
has to prepare necessary proposals for seeking permissions of Railway authorities.
The Engineer-in- Charge will process such proposals to the Railway authorities
concerned for taking up the work by them as a deposit work duly paying the amount
demanded by the railway authorities by the Dept and shall be recovered from the next
running bill of the Contractor. The Contractor shall include such cost in the bid price.
28.5 In order to check the accuracy of the investigation work the equipment, labour,
required transport and other materials etc., at site of work have to be supplied to the
Engineer’s Representative without extra cost.
28.6 No extra payment will be made to the bidder if there is any change in type of
structure, specifications, variation in quantities as per actual site conditions.
28.7 Display Boards should be displayed of size 2.00m x1.50m, wherever necessary or by
engraving on the structure with enamel painting. Boards / direction boards should also
be displayed to facilitate for inspection both at investigation and execution stages.
28.8 During soil exploration by drilling boreholes for foundations, the contractor shall take
required number of Un-disturbed Samples and normal samples and obtain soil
classification, soil properties and bearing capacity by getting them tested in the soil
testing laboratories of Government Labs/Engineering Colleges or other reputed
institutes. The contractor shall provide certain U.D. Samples and normal samples to
the Engineer-in-Charge also so as to get them tested parallel at any other lab to be
selected by the Engineer-in- Charge, if required. The cost of such testing shall be
borne by the Contractor.
28.9 The Contractor shall furnish draft reports on design Engineering, drawings, in six
copies and soft copy in CD for obtaining the approval of the competent authority.
After approval, the contractor shall furnish 11 copies of booklets and 1 soft copy in
CD for record of the department at his cost and no separate payment will be made
towards this.
28.10 The contractor shall furnish 12 (twelve) copies of Land plan schedules and Land
acquisition proposals for obtaining approval of competent authorities.
28.11 The contractor shall fix enamel-coated metallic measuring gauges both on U/s and D/s
side of all the structures and at suitable locations along with the paintings of gauge on
Piers as suggested by the Engineer-in- Charge.
28.12 The Contractor shall provide and fix chainage cum boundary stone of standard design
at an interval of 30 meter, cost thereof is deemed to be included in the quoted contract
price.
28.13 Construction of 6.5 m over all wide road with 4.3 m wide asphalt road from the
nearest connectivity.
28.14 Catch drains and drainage vents are to be provided wherever necessary to facilitate
drainage along and across the approach roads of the Barrage at no extra cost.
28.15 All the crossings of State Highways, District Roads, Village roads and all other roads/
shall be negotiated as per standards of the respective departments and as per the
permissions granted by them. The approaches to these shall be provided as per the
standard of their respective departments. The cost of these shall be deemed to have
been included in the contract price quoted.
28.16 If the proposed work is interfering with any existing irrigation canals or channels,
supply channels or Sources / Streams to Minor Irrigation tanks, roads, suitable
structures are to be provided within the quoted contract price by the contractor.
28.17 If the work is interfering oil pipe lines, gas pipe lines, water supply pipeline, or any
other pipe lines, the contractor shall provide suitable crossing in consultation with the
authorities concerned after obtaining the approval either by himself or getting them
executed by the concerned authorities as a deposit work duly depositing the requisite
amount to them. The Engineer-in-Charge will help in processing the proposals to the
authorities concerned to obtain their permission. The cost of such crossings shall be
deemed to be included in the contract price.
28.18 Diversion of streams that are interfering with the system into nearby stream(s) is not
permitted in general. However in exceptional cases, the Engineer-in-Charge may
consider such proposals depending upon their feasibility, if the distance between them
is not much (i.e., less than 200 m) and also if such diversion will not affect the
riparian rights of existing or contemplated sources on D/s side.
28.19 R.R. Masonry / CR Masonry / Brick Masonry Structures shall not be permitted
generally.
28.20 The contractor has to make his own arrangement for diversion of flow and dewatering
of foundation etc. wherever necessary within the quoted contract price.
28.21 The concrete mixes to be adopted for all the structures shall be design mixes only and
these design mixes shall be conducted in the department / reputed laboratories and got
approved by the Engineer-in-Charge before adoption.
28.22 In case of crossing works, drainage works, the contractor shall excavate necessary
approach/ Tail channels to these structures to have smooth drainage through the
structure. The cost of excavation of such channels shall be borne by the Contractor
within quoted contract price. The cost of Land Acquisition for such channels will be
borne by the department.
28.23 Plantation of selected trees with tree guards of two meter height of brick masonry at
an interval of 5 meter along the approach road and at selected places as decided by the
Engineer-in-Charge is to be done. The Contract price quoted by the Contractor shall
include all these items.
The Contractor should adopt the latest/modern methodologies and State of Art
Techniques in the investigation, planning, design, construction, operation and
maintenance and monitoring of the project.
APPENDICES
Appendices
INDEX
1 2 3
APPENDIX-S&I
SURVEYS AND INVESTIGATION
SCOPE OF SERVICES
The Contractor's Scope of Services for Survey & Investigation shall include the following
activities for the work
1.1 Review of available Data of the work and identification of Detailed survey ,
investigation and foundation exploration requirement considered necessary for fixing
alignment , planning and design of all components comprising of Civil works related
to bridge, barrage including scouring sluices and fish ladder, piers, abutments, guide
wall ,guide bunds/afflux bund and other appurtenant works., Mechanical works like
gates in barrage including sluices including Hoist and Hoist supporting structure,
Power connectivity from the nearest structure including the 11/0.43KV sub-station,
allied machineries and facilities for gate operations and lighting of the sites,
Construction of approach road from the nearest connectivity to the barrage site,
Construction of a watchman and operator shed near the barrage, preparation of
estimates on the basis of approved design, for preparation of land plan schedules and
land acquisition Proposals including property cases and execution, commissioning
and maintenance of the project. The system should as far as possible avoid Abadi,
Forest Lands, Gochars, devastanam, grave yard and permanent structures.
1.3 Preparation of work programmes for carrying out investigations and studies for the
information of the Engineer-in-Charge.
1.4 The contractor shall submit a review report after carrying out the above activities for
acceptance of the Engineer-in-Charge.
2.2 Survey for fixing permanent benchmarks with reference to levels supported by the
Department at site & subsequently to be connected with GTS Benchmark on both side
of the river and temporary bench mark along the alignment of different components.
2.4 Logging of the drill holes and preserving the logs for inspection.
2.5 The detailed investigation, foundation exploration and geo technical investigations are
to be carried out along the different alternate alignment, if feasible, and submit it for
finalisation and approval by competent authority. The conceptual plan shall be on
whole, to the part principle.
2.6 On approval of alignments, preparation of survey plans of whole work area with
contours at 0.5 m intervals, marking ridges and valleys showing clearly the river bed,
banks, road connectivity, existing nearest power connectivity, all structures etc.
2.7 Grid survey for structures, such as Nalla crossing for approach roads, afflux bund,
trial pits, core drilling for foundation investigation of structures.
2.8 Preparing land plans schedules and land acquisition proposals (Private Land,
Government Land, Forest Land if any etc.) and Property schedules such as wells,
trees, houses etc., if any and submitting same to Engineer-in-charge.
3.0 Liaison with the Employer and Employer’s Representative from the start of
investigation to actual Commissioning of the project in full.
4.0 Liaison with respective line departments of Odisha and owners of Electrical utilities,
Railways, Forest department etc. for approvals of Right of way/Right of use.
5.0 Preparation of monthly progress reports on the progress of the investigation work.
6.0 No separate payment shall be made for conducting any of the surveys, detailed
investigation and geo-technical exploration etc., indicated above and needed for the
completion of the project and shall deemed to be included in the quoted price.
APPENDIX - D&E
The Contractor's Scope of Services for Design and Engineering shall include the following
activities for the work .
1.0 Detailed Design
1.2 Review of technical and design parameters for all components of the Barrages
including Electro-mechanical works and Electrical system connectivity work.
1.3 The 500 year and 100 year flood and the pond height (to be measured from the
upstream floor) provided in salient data of Appendix BPP is binding on the
contractor. Other data provided is tentative.
1.4 Preparation of Detail Project Report(DPR) with detail hydrological and hydraulic
analysis, detail investigation taken up indicating design criteria, design parameters,
design assumptions, method of analysis on all components of the Work (bridge with a
carriage way width of 7.5m, barrage including scouring sluices and fish ladder, piers,
abutments, guide wall ,guide bunds/afflux bund with protection works and other
appurtenant works, Mechanical works like gates and stop logs, including Hoist and
hoist supporting structure, gantry crane and lifting beam, Power connectivity from the
nearest 11 KV structure,11/0.43KV substation, allied machineries and facilities for
gate operations and lighting of the sites, Construction of approach road from the
nearest connectivity to the barrage site, Construction of a two storied residential
building for watchman and operator near the barrage) .These Detail Project Report
shall be submitted to the Engineer-in-Charge for approval of Technical Advisory
Committee( TAC) before carrying out detailed design and construction drawings
1.5 On approval of DPR by TAC, detailed design shall be taken up as per Technical
Specification, relevant IS Code, IRC Code, manuals etc, for all the Civil works i.e.,
bridge with a carriage way width of 7.5m, barrage including scouring sluices and fish
ladder, piers, abutments, guide wall ,guide bunds/afflux bund with protection works
and other appurtenant works, Mechanical works like gates and stop logs, including
Hoist and hoist supporting structure, Gantry crane with lifting beam, Power
connectivity from the nearest 11KV structure,11/0.43KV substation, allied
machineries and facilities for gate operations and lighting of the sites, approach road
from the nearest connectivity to the barrage site, a two storied residential building of
about 2900 square foot built up area ,for watchman and operator ,near the barrage
including drawings required for the execution .The design calculations performed
along with the drawing shall be submitted to the Engineer-in-Charge for approval of
Competent Authority.
1.6 Processing for approval of Design & Drawing from Competent Authority.
1.7 Preparation of Detail Estimate of all components of works as per Odisha Schedule of
Rate for schedule items and Market rate / Procurement rate of EPC contractor for non-
schedule items and processing it for sanction by Competent Authority. While framing
the estimate, the items are to be clubbed as per the payment schedule to facilitate
payment.
1.8 Taking up the additional designs and modifications, as needed, during construction.
1.9 The contractor shall adopt modern methodology/State of art Techniques in design of
the components of the work.
2.0 The software and soft copies of designs shall be made available for checking of the
Designs and it will be the Property of the Department.
2.1 Submission of methodology for commissioning of entire Barrage work.
2.2 Preparation of operation and maintenance Manuals.
3.0 Project Completion Report
3.1 Preparation of as-built drawings for the Civil as well as Electro Mechanical
components of the work and a Detailed Project Completion Report.
4.0 Design liaison
4.1 Design liaison with Engineer and his representative, Consultant(s) of the Employer
and if required with Central Water Commission etc.
4.2 Preparation of Monthly Reports on the progress of the project work as a whole for
information of the Engineer-in-Charge, in respect of:
a) Investigation & Surveys.
b) Design and engineering.
c) Civil Construction.
d) Electro-Mechanical components.
e) Quality Control arrangement.
f) Technical status (Present status and future programme)
g) Project status (Time Schedule, achievement of mile-stone, slippage in time
schedule with specific reference to activities and acceleration measures proposed)
h) Financial status (Present status and future projection)
i) Deployment of Manpower, Labour, Expatriates staff and Construction Equipment
Furthermore the Report shall include necessary photographs and sketches showing the
previous month's progress.
5.0 Supply of Drawings, Reports etc.
5.1 The Contractor shall furnish to the Engineer-in-Charge the following number of
copies of drawings, reports and other technical documents:
2. Drawings for approval 6 (six) sets 1 (One) 1 (One) One hard copy shall be
returned to the Contractor with
approval or comments.
5. Review Report/ Design 3 (Three) 1 (One) copy in One hard copy shall be
Briefs/ Design Memo / CD returned to the Contractor with
sets
Design Reports (Draft) approval or comments.
5.2 Tentative list of design notes and drawings for the work to be submitted by the
contractor (civil & Electro- Mechanical component)
Sl.
Design Note Title of Drawing
No.
1 Layout Report Schematic plan ,cross section and L-section of the
work showing all controlling levels and
Arrangements
3 Barrage including scouring 1. Detail plan of the Barrage, piers, abutments, guide
sluices and fish ladder, piers, wall, afflux bund, protection works with LS and CS
abutments, guide wall ,guide of the barrage showing all components etc.
bunds/afflux bund and other 2.Details of piers, abutments, guide wall, fish ladder
appurtenant works and energy dissipation arrangement, protection
works etc.
Sl.
Design Note Title of Drawing
No.
4 Gates including Hoist and hoist 1.General arrangement drawing
bridge 2.1st stage and 2nd stage Embedded parts details
3.Gate details
4. Details of Hoist
5. Details of Hoist supporting structures.
7 Construction of a two storied 1. Layout plan with elevation and section etc.
building with about
2. Reinforcement details etc.
3000 square foot built up area
for watchman and operator shed 3.Sewerage, water supply and electrification
near the barrage detailsetc.
Note: 1.The list is indicative for design notes and drawing to be submitted by the Contractors.
Exact details will be decided as per work requirements.
5.3 No separate payment shall be made for any of the design and engineering works
indicated above and needed for the completion of the project and shall be deemed to be
included in the quoted price.
APPENDIX – CW
CIVIL WORKS
SCOPE OF SERVICES
APPENDIX- EM
SCOPE OF SERVICES
Mechanical works like gates in barrage including 1st stage and 2nd stage Embedded parts, gate
and stop logs, Hoist, Hoist supporting structure, Gantry crane and lifting beam, Power
connectivity from the nearest 11KV structure or 33/11KV substation, 11/0.43KV sub-station
including the power cable/L.T line for gate operation and lighting of the bridge along with all
machineries and facilities for gate operations and lighting of the sites.
The scope of work in this section includes, but not limited to the following:
1. Detail design of all components as per the relevant IS codes, OERC norms and
manuals.
Detailing, supply and manufacture, inspection, shop assembly, testing, painting etc as
per the approved drawing and specification of the respective components.
1 Delivery of fabricated components/equipment and transportation to site.
2 Site storage, transportation and handling, site erection, painting, testing and
commissioning including provision of labour, plant, material etc. for the above.
3 Supply and installation of all incidentals not specified but are necessary for proper
completion and satisfactory functioning of the system.
4 The Contractor shall supply the equipment, which will meet in all respects, the
requirements of Employer in regard to performance, durability and satisfactory
operation. All the equipment supplied shall conform to the relevant Indian Standards.
APPENDIX- BPP
CONSTRUCTON OF BARRAGE
BASIC PROJECT PROFILE
1.0 Introduction : Government of Odisha proposes to build an integrated ISS across river
Khairibhandan at Anlabeni in Mayurbhanj District to enhance in-stream storage for
water conservation for improving recharge of ground water, availability for drinking
water supply, augmentation of lift irrigation and flow irrigation wherever feasible and
availability for supply to industrial & commercial establishments in the area.
1.1 The 500 year, 100 year flood and the pond height (to be measured from the upstream
floor) provided in the salient features in Appendix BPP are binding on the contractor.
Other data provided are tentative. The hydrological data of the sites will be made
available based on availability with the department.
1.2 The main components of the work will be a) Barrage including energy dissipation
arrangement, fish ladder ,piers and abutment with guide wall (b) Scouring Sluices on
both sides (d) Hydraulic gates with mechanically and electrically operated hoists
including hoist supporting structure (e) afflux bund and bank protection works (f)
Bridge with carriage way width of 7.5m over the barrage (g) Electrical connectivity to
the barrage site from the nearest 11 KV structure with 11/0.43KV substation and
cables for hoist operation and lighting of sites, bridge and hoist bridge (i)Construction
of 1600 sqft of site office with Boundary wall (j)Approach Road to the barrage site
from the nearest connectivity and (k)other ancillary works.
Electrical systems as per the work specifications provided in the bid documents, and
commissioning of the project on turnkey basis followed by operation and maintenance
of the entire work for a period of five years or five flood seasons whichever is more.
4.1. Survey & Investigation: Survey and Investigation shall include but not limited to
following activities,
b) Fixing of permanent & temporary benchmark stones and transferring the values
of the levels to them. The permanent bench mark is to be placed near the
bridge-barrage abutments on both sides and at other places of importance.
c) Preparation of site survey plans for all crossing to the roads, drain, railway
lines existing water, gas & oil pipes etc.
d) Preparation of land schedule for acquisition of land from private owners &
processing it for acquisition till completion of the process. Preparation and
processing of proposal and arranging for having clearance for use of land for
the Barrage cum Bridge work in forest area wherever required. Processing for
obtaining right of way / right of use permission from different Govt., Semi
Govt. and private authority.
4.2 Design:
a) Preparation of separate plan for the Barrage including scouring sluices and fish
ladder, piers, abutments, guide wall, guide bunds/afflux bunds and other
appurtenant works, approach road from the nearest connectivity to the barrage
site. Watchman and operator shed near the barrage, Power connectivity from the
nearest 11KV structure.
c) Processing for approval of all the designs & drawings from competent
authorities and getting it approved.
c) Procurement of the embedded parts of the gates, gates, hoist machineries and
equipments, electrical materials and equipments required for the work as per
the drawing and specifications of the agreement.
4.4 Works:
c) Mechanical works like gates in Barrage including Hoist and Hoist Bridge.
4.1 Operation and Maintenance of the system for five years or five flood seasons
whichever is more.
4.2 Capacity building of O& M staff of Government for O&M of the work.
The scope also includes necessary co-ordination and management to obtain consent or
permission from affected bodies/ authority/ parties whose damage to property is
involved in construction of all the components. The contractor will be responsible for
processing all the papers required for permission for right way/right of use from Govt.
Semi Govt. and private parties etc. All statutory charges required to be paid for this
shall be borne by the Govt. The department will sign the necessary documents
required for permissions/ clearances/land acquisition. Required co-ordination for
sanction from the concerned authority & NOC from the concerned authority / field
owner for satisfactory completion shall be provided by the bidder. For Acquisition of
land from private land owners, the contractor is to prepare the land acquisition
schedules & other schedules prescribed by Govt. & process the acquisition as per the
prevailing land acquisition Act of Govt. Odisha. The Department will sign all the
documents required for this purpose. The cost of the land & property as per the Govt.
rules in force will be born by the Govt. Processing of the proposal for alienation of
Govt. land is also the responsibility of the contractor.
The salient features of the work based on the Department’s study are given in Table in
page 13/13. However the bidder has to make its own assessment by site visits,
preliminary surveys and study of relevant maps and documents for the data before
bidding.
* *
the
upstream
floor)
*
1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17
Construction
of Khairib Lat:21°57’
1 Khairibhanda handan
n Barrage 58.57’’ N
Project on & Long
river :86°03’35. Mayurbha
Khairibhanda 51’’E Anlabeni Jashipur 588 2360 396.31 394.00 - -
nj 2007 - - -
n at village
Anlabeni,
Jashipur
Block, District
– Mayurbhanj,
State- Odisha.
NOTE:
1. The level indicated above is with reference to the Bench Mark level to be supplied by the Engineer-in-Charge.
2. Maximum permissible Afflux: - As per design permissibility.
3. 100 years return flood discharge is to be considered for design of all components of the barrage except Affluxbund.
4. 500 years return flood discharge is to be considered for design of Afflux bund only
5. Gates: Vertical lift type gate with electro-mechanical hoisting arrangement for operation. Arrangement for manual operation also to be
provided.
6. Values marked *in above table are fixed & binding for design & execution.
CONTRACTOR
CONTRACTOR 13/13 EXECUTIVE
13/13 ENGINEER SUPERINTENDING ENGINEER
SECTION-VII
8.0 Vehicle 6
10.0 Assignment 7
11.0 Liability 7
12.0 Insurance 7
13.0 Maintenance 8
15.0 Inspection 9
11
19.0 Taxes, Licenses, Permits and Fees
11
20.0 Termination or Fore Closure of the Contract
21.0 Training 11
11
23.0 Handing over of the work
SECTION - VII CONDITIONS OF CONTRACT FOR O&M
Section-VII
CONDITIONS OF CONTRACT FOR OPERATION & MAINTENANCE
1.0 Introduction :
The contract is for Construction of Khairibhandan Barrage Project on river Khairibhandan at
village Anlabeni, Jashipur Block, District – Mayurbhanj, State- Odisha including hydro-
mechanical works, Head Regulator left & right, construction of afflux bund & coffer dam,
dewatering during construction, Power connectivity works to project site & colony, road
connectivity, including survey, investigation, planning, design and estimate of all components
with operation and maintenance of the project for a period of five years or five flood seasons
whichever is more after successful commissioning of the project in Bid Identification No
03/CCEDIP of 2023-24(Online). The completion of work will be considered for
commissioning of the project. After completion and commissioning of the work the Contractor
shall be responsible for the operation and maintenance of the work for a period of five years or
five flood seasons whichever is more from the date of notification of commissioning of the work,
under the Agreement for O & M of the barrage work. The Contractor shall be responsible for the
operation & maintenance of all components of the project including associated works in
accordance with prudent utility practice. The O & M contract will run concurrently with defect
liability periodfrom the date of commissioning of the work.
2.0 ADMINISTRATIVE PROVISIONS: The following additional clauses shall apply only
during the Operation & Maintenance period.
DEFINITIONS
In this Agreement the following words and expressions shall have the meanings hereby
assigned to them, except where the context otherwise requires:
1. “Operation and Maintenance” shall mean O&M of all the components of the
Construction of Khairibhandan Barrage Project on river Khairibhandan at village
Anlabeni, Jashipur Block, District – Mayurbhanj, State- Odisha including hydro-
mechanical works, Head Regulator left & right, construction of afflux bund & coffer dam,
dewatering during construction, Power connectivity works to project site & colony, road
connectivity, including survey, investigation, planning, design and estimate of all
components with operation and maintenance of the project for a period of five years or
five flood seasons whichever is more after successful commissioning of the project.
2. “Operation and Maintenance period” shall mean five years or five flood seasons
whichever is more from the notified date of commissioning of the work.
3. “Contract” shall mean the agreement between the Employer and the Contractor along
with all documents incorporated therein by reference and all documents incorporated
by these Conditions of Contract.
4. “Contractor’s Equipment” shall mean all equipment, instruments, tools, machineries
and other appliances and things of whatsoever nature required for the fulfillment of
the Contract or of the Contractor’s Obligations, but not including those items which
are intended to form, or which form part of the Facility.
5. “Contractor's Obligations” shall mean the obligation to execute the Project in its
entirety and shall, without limitation, include the Operation and Maintenance.
6. “Date of Taking Over” shall mean the date of Successful Completion of operation &
maintenance period as per agreement clause and taking over of the entire work &
process by Department.
CONTRACTOR 16/11 SUPERINTENDING ENGINEER
SECTION - VII CONDITIONS OF CONTRACT FOR O&M
7. “Defects Liability Period” shall mean the Defects Liability Period of five years
for all works, commencing on and from Date of commissioning of project including
satisfactorily passing tests on completion during which the Contractor shall undertake
the responsibilities, and have the liability for the facility.
8. “Facility” shall mean the entire system to be designed and constructed in accordance
with the provisions hereof, including the buildings, structures ,ramps, pits, pipes,
fencing, lighting, testing and analysis equipment, tools, computers, software
programs, safety equipment, plant machinery, supplies, instruments and inventory
incorporated therein, as well as all open areas within the site, and including any
additions, modifications, alterations, replacement and repairs as may be made thereto
from time to time.
9. “Governmental Authority" shall mean any Indian entity, authority or body exercising
executive, legislative, judicial, regulatory or administrative functions, including,
without limitation, any government authority, agency, department, board, commission
or instrumentality of Indian or any political subdivision thereof, court and tribunal.
10. “Law” shall mean and include all the provisions of all Indian statutes, regulations,
ordinances, codes, official or other standards, administrative or other rules, zoning and
other plans and restrictions, building and other permits, judgments awards and decrees
of, or agreements with any Governmental, semi- Governmental or quasi-
Governmental Authority as currently in effect or as may be in effect from time to time
and /or as may be amended or supplemented from time to time.
11. “Maintenance Standard” shall mean the requirements for operating, maintaining,
repairing, and renewing the Facility:
i. As set forth in the O & M Manual; bidder shall furnish this before commissioning
of work.
ii. Required pursuant to applicable Law;
iii. As may be necessary for keeping the facility in a satisfactory condition such that
the Facility will continuously, comply with the Operation Standard; and
iv. As may be necessary to ensure that the Facility shall continuously be in an
optimum condition and state in relation with the lifetime of the Facility.
12. “O & M Manual” shall mean the final Manual for the Operation and
Maintenance of the entire system, to be prepared in accordance with the Bid
Documents.
13. “Operation and Maintenance Obligations” shall mean the obligation of the
Contractor pursuant to the Agreement to operate and maintain the Facility on and
from the Date of commissioning of the work until the date of completion of this
Agreement.
14. “Operation and Maintenance Price” shall mean the amount payable by the
Employer to the Contractor, for the fulfillment of the Contractor’s Operation and
Maintenance obligations. This price is the price quoted by the bidder for O & M
of the work vide item number 2 in the Price Bid ( APPENDIX PB)
15. “Operation Standard” shall mean : a) The Performance Guarantees; b) All
applicable Laws; c) All of the requirements, policies and procedures set forth in
the O & M Manual d) All other operational requirements set forth in this
Agreement.
16. “Site” shall mean that specific area specified in the Bid Documents and shall
include any other places as may be specifically designated by the Employer from
time to time as forming part of the Site.
2.1 Scope of Services
The scope of services during defects liability period of five years after the notified
date of commissioning of the work.
2.1.1 During the defect liability period, the contractor will have to bear
additional responsibility in addition to normal O & M as defined under
clause 2.2 below.
2.1.2 The responsibility of the contractor during defect liability period will be
at par with other general contracts.
2.1.3 During the defect liability period the soundness, longevity, performance
and defects will be under scrutiny and observation & any defects noticed
will be repaired, replaced and brought to perfect running condition by
the contractor at his own cost as per the direction of the Engineer-in-
charge. This responsibility will be in addition to the O & M operation as
envisaged in the agreement.
2.2 The duties and responsibility of the contractor under the O & M agreement will be as
under.
2.2.1 To maintain all the components of the Barrage cum bridge work as per
the scope of the work described under different sections of the Bid
document.
2.2.2 To provide all services necessary to maintain the project efficiently,
maximize the availability of the project, optimize the useful life of the
project etc.
2.2.3 To provide requisite numbers of qualified (and if required licensed)
personnel to perform the services including security of the work.
2.2.4 To carry out any maintenance or repairs or rectification or replacement
work in case of any problem or emergency that may arise while all the
components of the work is in-operation during the maintenance period of
five years or five flood seasons whichever is more as directed by the
employer/ Engineer-in-Charge.
ii. Preparation of training manual for training of the staff of the Department to be
furnished prior to commissioning of the work.
iii. List of equipments, tools & plant required for smooth Operation &
Maintenance to be furnished along with the Bid.
The Contractor shall take full responsibility for the care of the Facility and
materials and Plant from the date of commissioning of the work until the date of
completion of the Operation and Maintenance period of five years or five flood
seasons whichever is more, when the responsibility for the care shall pass to the
Employer.
If any loss or damage happens to the Facility, or any part thereof, or materials or
Plant for incorporation therein, during the period for which the Contractor is
responsible for the care thereof, from any cause whatsoever, other than the risks
defined in Sub-Clause of Risks and obligation of the employer, the Contractor
shall, at his own cost, rectify such loss or damage so that the Facility conform in
every respect with the provisions of the Contract to the satisfaction of the
Employer. The Contractor shall also be liable for any loss or damage to the work
occasioned by him in the course of any operations carried out by him for the
purpose of complying with his obligation under Sub-Clause Risks and Obligation
of the Contractor.
4.0 COMMENCEMENT AND DURATION OF O & M:
On completion of the work, the trial & commissioning of the work shall be taken up
as per relevant conditions of contract.
Extension of the O & M Period would involve a negotiated revision to the Terms
and Conditions of the Agreement. Curtailment of O&M period would require
revision of O&M cost proportionately. The decision of the Government / department
shall be final whether to curtail/extend or not the O & M period.
5.0 Maintenance Personnel
The Contractor shall deploy experienced personnel for maintenance of the Barrage-
cum-Bridge work. The deployment schedule indicating the number of the Managers,
Supervisors, Operators, Helpers/Fitters, Mechanics, Electrician & other support staff
etc. for O&M of work, responsibility assigned to each of them should be furnished
along with the bid. For effective O&M, local people of the nearby villages may be
selected by the contractor who is to be trained during the construction stage for their
deployment during the O&M period. The bio-data of all O&M personnel shall be
provided to Engineer-in-charge before commencement of operation and maintenance
for approval.
Additional staff required for smooth and efficient operation of the work is to be
deployed by the contractor as per requirement for which no extra payment will be
admissible.
All Contractors’ personnel employed at the work at any time during the period
covered by the present Contract will be provided by him. The Employer is not
liable for personnel in any way and cannot be held responsible in the event of
litigation of any sort between the Contractor and deployed personnel or their
representatives.
All decisions related to staff numbers and qualifications should be approved by the
Employer. The Contractor undertakes to comply with applicable legislation and the
code of labour law on matters of health, hygiene and safety, and shall assume
responsibility for works required in the event of any change in applicable
regulations.
6.0 Right to Perform upon Contractor’s Default
It anytime, the Contractor fails to perform and such failure is likely to cause injury to
any person or damage to the project, the Employer may, but shall have no obligation
to, perform any such obligation of the contractor. The cost to the Employer of
affecting such performance would be deducted from the payment due to the
Contractor.
No additional payment shall be made for operation and maintenance services during
the maintenance period of five years and shall be deemed to be included in the
quoted contract price.
The Contactor shall also make available the proof that maintenance / of total system
was carried out during operation & maintenance period in accordance with the
maintenance schedule and O & M manual.
8.0. VEHICLE
The contractor has to deploy 4 wheeler of model after 2022 in working condition for
smooth operation and maintenance. The vehicle such as Mahindra Jeep (Bolero) /
Tata Sumo is to be deployed for O & M period. All expenditure is to be born by the
contractor. The vehicle is to be deployed for minimum 150 days in each year.
9.0 FORCE MAJEURE
“Force Majeure” means an event beyond the control of the Employer and the
Contractor, which makes it impossible or illegal for a party to perform, including but not
limited to:
i) act of God.
ii) war, hostilities (whether war be declared or not), invasion, act of foreign enemies,
mobilization, requisition, or embargo;
iii) Rebellion, revolution, insurrection, or military or usurped power, or civil work.
iv) contamination by radioactivity from any nuclear fuel, or from any nuclear waste
from the combustion of nuclear fuel, radioactive toxic explosive, or other
hazardous properties of any explosive nuclear assembly or nuclear component of
such assembly.
v) riot, commotion or disorder, unless solely restricted to employees of the
Contractor or of his Subcontractors.
If either party is prevented from or delayed in performing any of his obligations under
the Contract by any circumstances of Force Majeure, then he shall notify the other party
thereof within seven days, and specify how these circumstances are detrimental in the
performance of the Contract.
13.0 MAINTENANCE
The Contractor shall be responsible for corrective maintenance of civil, hydraulic,
mechanical, electrical and computing equipment as well as miscellaneous equipment
as described in Clause below.
The Contractor shall be responsible for carrying out regular servicing and
The Contractor shall ensure that measurement systems operate correctly at all times.
The Contractor is responsible for the maintenance of the landscaped areas inside the
Employer plant fences.
The Contractor shall be responsible for maintenance of civil structures including
gates, quarters, roads etc. within the limits of his scope of work, under this Contract.
14.0 CONSUMABLES AND UTILITIES SERVICES - SPARE PARTS & STORES
14.1 Consumables and Utilities Services
Unless stipulated otherwise elsewhere in the document, for the duration of the
O & M period, the Contractor will be responsible for the supply and control of
lubricants, spare parts and consumable materials excluding electrical power,
necessary for the continuous operation of the works.
The Contractor will manage the consumables and utilities services to ensure their
most economic consumption and to minimize wastage.
The quantities of all the unutilized spare parts and consumable materials will be
fully handed-over to the Employer at the end of the O&M period.
The Contractor is also responsible for providing spare parts and material required for
the operation and maintenance during the operation period, and shall bear the cost
for the same, including the cost of storing and safeguarding.
The Contractor will make all necessary arrangements to ensure the continuous
supply of spare parts and material for the works and the rate of supply of these
materials shall be in such quantities and amounts as would ensure uninterrupted
operation.
Any spare parts used during the O&M period shall be replaced by purchasing new
spare parts and total set of spare parts shall be handed over to the employer after
completion of five years maintenance period / extended O & M period if any.
A report shall be drawn up to record the opinions of both parties. The Employer
reserves the right to call in equipment manufacturers or specialized technicians for
these visits.
These visits shall provide an opportunity for examining maintenance programs and
operating procedures and improvements requiring additional investments.
Report of visits by persons other than those of the Employer and the Contractor to
the Facility shall be kept at site.
The Contractor shall also indicate any significant modifications to the set-up
characteristics of the installation, shut-downs, anomalies or incidents that have
occurred with respect to operation.
16.2 Invoicing
The Contractor shall prepare and submit to the Employer an invoice at the end of
every month of O & M with all documents supporting its calculations for the
preceding month. The invoice shall be submitted between 1st & 5th day of every
month.
The Employer shall have ten (10) calendar days from receipt of such invoice to
notify in writing to the Contractor its acceptance thereof or the grounds for disputing
such invoice. The Employer shall pay to the Contractor all accepted amounts.
VENDOR LIST
SECTION-VIII VENDOR LIST
SECTION - VIII
VENDOR LIST
A. LIST OF STANDARD MAKES OF EQUIPMENT / MATERIAL
SL.
Product Name of Manufacturer
No.
1. Welding Electrodes Advani Oerlikon, Indian Oxygen,
ESAB, Modi Electrodes, M/s D H Welding Electrodes Pvt.
Ltd.
2. Ordinary Portland A.C.C, KONARK, ULTRATECH, AMBUJA, LAFARGE
Cement
3. HYSD Bars (TMT) SAIL , TATA & JINDAL
4. M.S. Plate / H.R. Coil Tata, SAIL, TISCO, Jindal conforming to IS 2062
B. LIST OF APPROVED MAKES OF MECHANICAL EQUIPMENTS &
COMPONENTS
Sr. No. Mechanical Equipment Name of Manufacturer
1 Tools TAPARIA ,RECORD
LEADER,EVEREST,
GEDOR,JHALANI,MEKASTER
2 Worm Reducers PREMIUM,ELECON,SHANTI
GEAR,NEW ALLENBURY
3 Gear Coupling ALLFLEX,LOVE-
JOY,FLEXOCON,ELECON
4 E M Brake STERLING CONTROLS,SPEEDO
CONTROL,ELECTROMAG,BCW
C. LIST OF APPROVED MAKES OF ELECTRICAL EQUIPMENTS &
COMPONENTS
Sl. No. Electrical Equipment Name of Manufacturer
1. Distribution Transformers ALFA,TESLA,ODISHA
TRANSFORMERS,SYNERGY
TRANSFORMERS,UNITED
ELECTRICAL,ODISHA INDUSTRIAL
ENGINEERING PVT.LTD,BRITE
TRANSFORMERS
2 LT Cables CCI/NICCO,FINOLEX,AVOCAB
TORRENT,GLOSTER,GEMS CAB
POLYCAB
3 Flexible wire(FRLS) FINOLEX,ANCHOR,HAVELLS,RR
CABLE
4 PHILIPS,BAJAJ,CROMPTON,HAVEL
Lighting fixture LS
FINANCIAL BID
&
MILE STONE
SECTION – IX
FINANCIAL BID & MILE STONES
1 Financial Bid 1
2 Appendix- FB 2
3 Appendix-F 5
4 Appendix-F1 6
5 Appendix –F2 7
6 Appendix – F 3 8
7 Appendix – F 4 9
8 Appendix – F 5 10
9 Appendix – MS 11
SECTION-IX FINANCIAL BID & MILE STONES
FINANCIAL BID
1.0 General
Details of the Financial Bid has been described under Section IV clause-40.The work,
excluding O&M, has been broadly divided into four components as given in APPENDIX
F. The bidder has to assign a value to these components in terms of percentage of Bid
amount of Item 1 of Appendix FB of Financial Bid. In case of any
deviation/alterations/modifications of methodology leading to change in components or its
quantity or incorporation of new items of work after approval of Detailed design and
estimates, the competent authority shall have full powers to revise the percentage breakup
of components keeping the contract price same as quoted by the bidder. Each component
is further sub-divided into four stages as given below.
Evaluation of Bid shall be carried out as per Clause 18 of Section II: Instruction to Bidder.
Tender Inviting Authority- Chief Construction Engineer, Deo Irrigation Project, Karanjia
Bid Identification No. 03/CCEDIP of 2023-24 (Online)
Construction of Barrage
SCHEDULE OF WORKS
(This BOQ template must not be modified/replaced by the bidder& the same should be uploaded after filling the relevant columns,
else the bidder is liable to be rejected for this tender. Bidders are allowed to enter Bidder name & values only)
Item. Rate in figures to be enter by the
No.
Description of item
Bidder
Amount
In figures In words
Rs. P.
Rs. P.
1. Construction of Khairibhandan Barrage Project on river
Khairibhandan at village Anlabeni, Jashipur Block, District
– Mayurbhanj, State- Odisha including hydro-mechanical
works, Head Regulator left & right, construction of afflux
bund & coffer dam, dewatering during construction, Power
connectivity works to project site & colony, road
connectivity, including survey, investigation, planning,
design and estimate of all components as per with
operation and maintenance of the project for a period of
five years or five flood seasons whichever is more after
successful commissioning of the project as per relevant
clauses of the agreement, Technical Specification,
relevant IS codes, IRC codes, MoRTH specification, CWC
& CBIP manuals etc. as per relevant clauses of the
agreement etc. complete as per specification and direction
of Engineer in charge.
Total Bid Amount in figure
SECTION-IX FINANCIAL BID & MILE STONES
APPENDIX – F 1
PAYMENT SCHEDULE FOR
Barrage including scouring sluices, fish ladder, abutments and guide walls, Piers, Pier cap etc.
complete in all respect as per the Technical specification and approved drawing.
Percentage of
Sl.
PARTICULARS OF THE COMPONENT Component
No.
Amount
1 2 3
1. After detail survey, investigation, foundation exploration for fixing
alignment of Weir, etc, as per relevant IS codes, IRC codes, MoRTH
specification and circulars, issued by department from time to time,
planning and design of all components, Preparation of detail estimate
as per Schedule of Rates of Odisha on the basis of approved design- 2
drawing, clubbing of items for record of measurement and basis of
payment, getting approval from competent authorities. Processing of
land acquisition, forest clearance and Right of Way, if required &
getting approval from competent authorities.
TOTAL 100
Note: “A”=0.93(Bid value for the work executed ÷ the sanctioned estimate amount for the
work executed)
APPENDIX – F 2
Bridge deck including parapet, expansion joint, wearing coat and bearing etc. complete in all
respect as per Technical Specification and approved drawing.
Percentage of
Sl.
PARTICULARS OF THE COMPONENT Component
No.
Amount
1 2 3
1. After Detail survey, investigation, foundation exploration for fixing
alignment of barrage and bridge, etc, as per relevant IS codes, IRC
codes, MoRTH specification and circulars, issued by department
from time to time, planning and design of all components,
Preparation of detail estimate as per Schedule of Rates of Odisha on
2
the basis of approved design-drawing, clubbing of items for record of
measurement and basis of payment, getting approval from competent
authorities. Processing of land acquisition, forest clearance and
Right of Way, if required & getting approval from competent
authorities.
TOTAL 100
Note: “A”=0.93(Bid value for the work executed ÷ the sanctioned estimate amount for the
work executed)
APPENDIX – F 3
Gates, stop logs & hoists including hoist bridge, gantry crane and lifting beam, embedded parts,
Power connectivity including all structural works, cables for operation of hoist and lighting of the
barrage area and bridge etc. complete in all respect as per the relevant Technical Specification and
approved drawing.
Percentage of
Sl.
PARTICULARS OF THE COMPONENT Component
No.
Amount
1 2 3
1. After Detail survey, investigation, foundation exploration for fixing
alignment of barrage, bridge, Power connectivity etc, as per relevant
IS codes ,IRC codes, MoRTH specification, OERC norms and
circulars, issued by department from time to time, planning and
2
design of all components, preparation of detail estimate as per
Schedule of Rates of Odisha on the basis of approved design-
drawing, clubbing of items for record of measurement and basis of
payment, getting approval from competent authorities.
TOTAL 100
Note: “A”=0.93(Bid value for the work executed ÷ the sanctioned estimate amount for the
work executed)
APPENDIX – F 4
PAYMENT SCHEDULE FOR
Guide banks/Afflux Bund including all ancillary works, Approach roads including all cross
drainage works & watchman and operator quarter includes electrification, water supply and
sewerage system as per Technical Specification and approved drawing.
Percentage of
Sl.
PARTICULARS OF THE COMPONENT Component
No.
Amount
1 2 3
1. After Detail survey, investigation, foundation exploration for fixing
alignment of Guide banks/Afflux Bund to avoid any type of
submergence , Approach roads & staff quarters , etc, as per relevant
IS codes ,IRC codes, MoRTH specification and circulars, issued by
department from time to time, planning and design of all
components, Preparation of detail estimate as per Schedule of Rates 1
of Odisha on the basis of approved design-drawing, clubbing of
items for record of measurement and basis of payment, getting
approval from competent authorities, processing of land acquisition,
forest clearance and Right of Way ,if required & getting approval
from competent authorities.
2. After construction of the Guide banks/Afflux Bund, up to the Pond
level of the barrage, Approach roads up to the sub-base level and
staff quarters up to roof level as per approved design-drawing,
specifications, IS codes, IRC codes, MOST Manual etc Running
70
Bills will be paid as detailed below: - Amount of running Bill = Bill
amount as per actual quantity of work executed based on Sanctioned
estimates and by clubbing of items as approved by the competent
authorities x “A” Where “A” is defined in the note below.
3. After completion of construction of Guide banks/Afflux Bund
complete up to the design level, Approach roads and staff quarters
complete in all respect including all finishing work as per approved
design-drawing, specifications, IS codes, IRC codes, MOST Manual
etc. Running Bills will be paid as detailed below: - Amount of 24
running Bill = Bill amount as per actual quantity of work executed
based on Sanctioned estimates and by clubbing of items as approved
by the competent authorities x “A” Where “A” is defined in the note
below.
4. After commissioning of weir, approach road, quarters etc. & after
defect liability period is over. 5
TOTAL 100
Note: “A”=0.93(Bid value for the work executed ÷ the sanctioned estimate amount for the
work executed)
APPENDIX F-5
Total
APPENDIX – MS
MILESTONES
Time in month
Milestone to
for achieving
be achieved as
milestone from
MS Particular physical % of
No. the
respective
commencement
item
of work
Total -----