SCLHK037
SCLHK037
SCLHK037
by
Keith Pickavance
Keith Pickavance2
INTRODUCTION
This paper is about proving a reasonable time to complete in the absence of a completion date. Rarely does
one come across a contractors claim without finding in it somewhere the allegation that time is at large
and the employer is not entitled to any liquidated damages.
Generally, provided that there is a contract completion date, a power under the contract to extend time, and
the contract administrator (CA) properly exercises that power, a new date for completion can be enforced.
This is usually calculated by adding to the initial date for completion the additional time required for the
effect of the employers time risk event.3 However, if, for reasons within the employers control, the
contractor is prevented from completing by the date for completion and there is no right to extend time for
performance (or it is not properly extended) the employer can no longer insist upon the completion date. It
is then left without a firm date from which liquidated damages might be calculated. Time is then said to be
at large as a result of the effect of what is known as the prevention principle, which has been described
as being based upon:
(i) a rule of law: some broad notion of justice as that a man should not be allowed to recover
damages for what he himself has caused4, or
(ii) an implied term: as a matter of fairness or policy5.
The expression time at large is thus usually used to indicate that the claimant believes that, for one reason
or another, there is no enforceable date for completion of the works. Hence, because there is then no date
from which they can be calculated, the employers right to liquidated damages is defeated. If that argument
succeeds, the contractors obligation is to complete within a reasonable time. If it does not then the
employer may recover its losses as general damages at common law.
There is some doubt as to whether, when the employer has lost its right to liquidated damages, the fixed
sum specified remains in limbo, as it were, to act as a cap on recoverable losses as is sometimes thought6 or,
whether it is void ab initio and hence of no effect at all. The logical result of the alternative is that the
employer is then entitled to recover provable losses in excess of what, at the time the contract was entered
into, were agreed to be a limit on the employers right to recovery.7 However, we are not concerned here
1
Based on the paper given by Keith Pickavance and Wendy MacLaughlin to the Society of Construction Law, London on 4 October 2005.
2
Keith Pickavance is an architect, chairman of Pickavance Consulting Limited, London and Hong Kong, and author of Delay and Disruption in
Construction Contracts (3rd edition 2005).
3
Balfour Beatty Buildings Ltd v Chestermount Properties Ltd (1993) 62 BLR 1, QB (Comm Crt), Colman J, at page 29.
4
SMK Cabinets v Hili Modern Electrics Pty Ltd [1984] VR 391, Supreme Court of Victoria, at page 395; 1 Const LJ 159.
5
See note 3.
6
See for example, I. N. Duncan Wallace QC, Hudsons Building and Engineering Contracts, 11th edition, 1995, Sweet & Maxwell, at para 10-
002; Stephen Furst QC and Vivian Ramsey QC, Keating on Building Contracts, 7th edition, 2001, Sweet & Maxwell, at para 9-26; and John
Dorter and John Sharkey, Building and Construction Contracts in Australia, 2nd edition, 1990, at page 4749.
7
Adrian Baron, Damages in the shadow of a penalty clause tripping over policy in the search for logic and legal principle, Society of
Construction Law (paper no 101), April 2002 and Hamish Lal, The doctrine of penalties and the absurd paradox: does it really matter in
2003? Society of Construction Law (paper no 113), May 2003; both available at www.scl.org.uk.
1
Keith Pickavance
with the financial consequences of time at large. This paper is concerned only with the circumstances in
which the employer might find itself without an enforceable completion date and the practical problem of
then determining how a reasonable time to complete might fairly be calculated.
Whether time has become at large is a matter of law dependant upon the terms of the contract and the facts
that are alleged to defeat the applicability of the liquidated damages provisions. What is a reasonable time
to complete once time has become at large is a matter of fact depending upon the circumstances as to how
time has become at large, the date on which time became at large, and the materials available from which
such a calculation could properly be made. It follows that the law and facts are inextricably bound and it is
not possible to deal with one aspect satisfactorily without also dealing with the other.
So, before passing on to consider how a reasonable time to complete might be calculated, it is helpful to
consider how the parties might have come to be without an enforceable completion date in the first place. In
principle, there are at least two possibilities as to how this might have happened.
First, there may be a contract completion date together with a number of employers time risk events for
which the contract makes provision for the CA to extend time but which have not been operated because
the power to extend time:
(i) has been wrongfully exercised; or
(ii) has not been exercised at all; or
(iii) has become inoperable; or
(iv) does not apply to the occurrence in question; or
it cannot be applied because the parties have failed to specify a completion date to which the power to
extend time can be applied. Whilst unusual, this latter possibility may occur if no date for completion is
written into the contract or, under the engineering forms, there is no period for completion stipulated by
either party.
On the other hand, of course, there may not be a contract completion date simply because there was no
contract in the first place.
8
Rapid Building Group Ltd v Ealing Family Housing Association Ltd (1984) 29 BLR 10, CA; at page 14.
9
Northern Regional Health Authority v Derek Crouch Construction Co Ltd [1984] QB 644; 26 BLR 1, CA; Browne-Wilkinson LJ at page 29.
10
Standard Form of Building Contract with Contractors Design, 1998 edition, Joint Contracts Tribunal (JCT WCD 98) and Conditions of
Contract for Plant and Design-Build, 1995 edition, International Federation of Consulting Engineers (FIDIC Yellow Book).
11
ICE Design and Construct Conditions of Contract, 2nd edition, September 2001, Institution of Civil Engineers.
2
A Little of Time at Large
expressly or impliedly required that the extension of time awarded to the contractor is fair and reasonable in
all the circumstances.
In most modern standard forms of contract a perverse award by the CA will not have the effect of defeating
the employers right to liquidated damages and set time at large simply because, by the terms of most of the
standard forms, the parties agree to refer their disputes to a tribunal that has the power to open up, review
and revise any certificate so as to determine afresh the parties rights under the contract.12 The tribunal may
then correct a perverse decision by the CA awarding a fair and reasonable extension of time to the
contractor and liquidated damages to the employer for any delay in excess of that relieved by the extension
of time.
On the other hand that may not always be so, particularly with bespoke forms of contract that do not
contain the same power to open up, review and revise. In Peak v McKinney13 for example, it appears that
the dispute was first decided by an Official Referee. On appeal, the Court of Appeal unanimously held that
the Judges assessment of the cause of the delay to piling repairs was so perverse that it did not amount to a
decision on the facts, and they overturned it. In that case, the Court of Appeal held that there had been
delays caused by the employer for which the contract provided no power to extend time. However,
Salmon LJ clearly thought, obiter, that even if the contract had have contained a power to extend time for
the cause of delay, the failure to award an appropriate extension of time under the circumstances would also
have left the employer without an enforceable completion date, which would also have defeated the
liquidated damages provisions.14
12
See for example ICE Conditions of Contract, 7th edition, September 1999, Institution of Civil Engineers, (ICE 7th), clause 66(11).
13
Peak Construction (Liverpool) Ltd v McKinney Foundations Ltd (1970) 1 BLR 111, CA; at page 111.
14
See note 13, at page 122.
15
See note 13.
3
Keith Pickavance
16
See note 13, at page 121.
17
See note 8.
18
Standard Form of Building Contract, 1963 edition, Joint Contracts Tribunal.
19
Contract for Building and Civil Engineering Works, 1998 edition, PACE, (GC/Works/1), clause 36(2)(b).
20
Form of Contract for Lump Sum Contracts, 4th edition, 2001, Institute of Chemical Engineers, (IChemE Red Book), clause 44.1(d).
21
Standard Form of Management Contract, 1998 edition, The Joint Contracts Tribunal Ltd, clause 2.13.2.
22
See note 12, clause 44(1)(e).
23
ACA Form of Building Agreement, 3rd edition, 1998, Association of Consultant Architects, clause 11.5(e).
24
Conditions of Contract for Construction, International Federation of Consulting Engineers, 1999 edition (the Red Book), clause 8.4(e).
25
NEC3 Engineering and Construction Contract, 2005 edition, Institution of Civil Engineers, (ECC3), clause 60.1(18).
26
Hong Kong Standard Form of Building Contract, 2005.
27
Government of Hong Kong S.A.R. General Conditions of Contract for Civil Engineering Works , (1999 Edn).
4
A Little of Time at Large
28
See note 4.
29
See (2005) 21 Const LJ 321 for the award on the preliminary issue, which usefully discusses the results of other arbitrations on similar facts.
30
See for example Standard Form of Building Contract, Private with Quantities, 1998 edition, The Joint Contracts Tribunal Ltd (JCT 98), clause
25.3.1
31
Gaymark Investments Pty Ltd v Walter Construction Group Ltd (1999) NTSC 143, (1999) 16 BCL 449.
32
Known as NPWC3.
33
See for example I. N. Duncan Wallace QC, Prevention and Liquidated Damages: a Theory Too Far? (2002) 18 Building and Construction
Law 82 and Hamish Lal, Extensions of time: the conflict between the prevention principle and notice requirements as a condition precedent,
Society of Construction Law (paper no 103), April 2002; available at www.scl.org.uk.
34
The evil which Vinelott J sought to avoid by rejecting an implied term in JCT 63 to the same effect in London Borough of Merton v Stanley
Hugh Leach Ltd 32 BLR 51, (1986) 2 ConstLJ 189, ChD.
5
Keith Pickavance
Court of Victoria in SMK Cabinets v Hili35. The Supreme Court of New South Wales has also declined to
accept that a failure by the contractor to give notice in a contract that rendered notice a condition precedent
to entitlement would automatically deprive the employer of liquidated damages. In the case of Turner
Corporation v Austotel, Cole J rejected this contention saying:
If the Builder, having a right to claim an extension of time fails to do so, it cannot claim
that the act of prevention which would have entitled it to an extension of time for
Practical Completion resulted in its inability to complete by that time. A party to a
contract cannot rely upon preventing conduct of the party where it failed to exercise a
36
contractual right which would have negated the effect of that preventing conduct.
Turner v Austotel was also referred to by the New South Wales Court of Appeal in the case of Peninsula
Balmain v Abigroup, in which it was observed obiter that:
in the absence of the supervising officers power to extend time even if a claim had
not been made within time, the contractor would be precluded from the benefit of an
extension of time and liable for liquidated damages, even if delay had been caused by
variations required by Peninsula [the employer] and thus within the so called
prevention principle. 37
There should be nothing in the employers control that could permit the employer to require the contractor
to take more time to complete, whilst at the same time taking liquidated damages for the contractors failure
to complete on time. However, there is something intuitively disturbing about the concept of the
contractors failure to comply with a condition precedent to an extension of time interfering with the
employers entitlement to liquidated damages so as to render the contractor better off by not complying
with the contract than it would have been if it had.
This is not a subject that has yet come before the English or Hong Kong courts. It can though be expected
to occur sooner or later under a number of UK and international standard forms of contact. For example:
(i) PPC2000 states that the employer may only grant an extension of time if there is a breach of
contract by the employer or any consultant of which the Constructor has given Early
Warning;38
(ii) NEC3 states: if the contractor does not notify a compensation event within eight weeks of
becoming aware of an event, he is not entitled to a change in the prices, the completion date or
a key date unless the project manager should have notified the event to the contractor but did
not;39
(iii) and the 1999 editions of the FIDIC forms also provide, perhaps less enigmatically, that: if the
contractor fails to give notice of a claim within 28 days, the time for completion shall not be
extended, the contractor shall not be entitled to additional payment, and the employer shall be
discharged from all liability in connection with the claim.40
35
See note 4, Brooking J, at page 395.
36
Turner Corporation Ltd v Austotel Pty Ltd (1997) 13 Building and Construction Law 378, Supreme Court of New South Wales; at pages
384-385.
37
Abigroup Contractors Pty Ltd v Peninsula Balmain Pty Ltd [2002] NSWCA 211, (2002) Building and Construction Law 322, New South
Wales Court of Appeal; at para [78].
38
Standard Form of Contract for Project Partnering (PPC 2000), Association of Consultant Architects and Trowers + Hamlin, at clause 18.3(xiv).
39
See note 25, Clause 61.3.
40
See note 24, clause 20.1
6
A Little of Time at Large
41
British Steel Corporation v Cleveland Bridge and Engineering Company Ltd [1984] 1 All ER 504, QBD.
42
See note 41, at page 511b.
43
J & J Fee Ltd v The Express Lift Company Ltd (1993) 34 Con LR 147, QBD (OR).
44
See note 43.
7
Keith Pickavance
long it would take him to perform 45. In other words, having identified a date by which the contract
works were to be completed, the reasonable time to complete can be calculated from that baseline.
There are then two positions to consider: whether the time risk structure under the contract subsists
notwithstanding the absence of a completion date or, whether the time risk structure falls with the absence
of a completion date.
45
Astea (UK) Ltd v Time Group Ltd [2003] EWHC 725, TCC; at para 144.
46
See note 6 Hudson, at para 9.031.
47
See note 12; Phillimore LJ, at page 127.
48
See note 18.
49
See note 8, at page 19.
50
See note 4.
8
A Little of Time at Large
Where this approach is appropriate, the calculation of a reasonable time to complete is exactly the same as
if the contract period had been properly extended. The burden of proving a reasonable time then falls on the
contractor to show what time (additional to that which it initially contracted for) it reasonably needs to
cover the delaying effect of both the employers breach and those employers risks under the contract.
In these circumstances, the only difference between a properly extended time for completion under the
contract and a reasonable time to complete outside the contract, is that after the former the employer is
entitled to liquidated damages for delay. After the latter, on the other hand, it is no longer entitled to
liquidated damages but must prove its actual losses and, in the SMK Cabinets v Hili case51, only the actual
losses flowing from the breach.
51
See note 4.
9
Keith Pickavance
(i) carried out the work with adequate materials goods and workmanship which did not prove
defective;
(ii) arranged deliveries so that materials, goods, plant and other resources were available when
needed;
(iii) expressly or impliedly warranted its ability to maintain progress in a particular situation or at a
particular speed;
(iv) had adequate site organisation, labour force, plant and materials; and
(v) remained responsible for acts or omissions within the control of the contractors subcontractors
and suppliers, notwithstanding that they may not have been within the direct control of the
contractor.
Whilst the Court of Appeal did not express a view on what would be a reasonable time to complete, and no
view was expressed upon whether the risk structure should remain, in Peak v McKinney Salmon LJ
appeared to take the view that the principal issue was how much delay had been caused by the employers
breach.52 In other words, how much the contractor could demonstrate should be added on to its contract
period. On the other hand, whilst accepting that was a consideration, Edmund Davies LJ seemed to think
that the time taken up by those matters within the contractors control was a relevant consideration, saying:
But, just as the plaintiffs must themselves be absolved from contributing to any delay, so
also must the defendants, save in respect of that for which inevitably flowed from their
original default. 53 [emphasis added]
Relieving the contractor from the effect of everything other than that which is within the contractors
control is also the route that the courts appear to have taken in a few cases of time at large in fields other
than construction. For example, take the shipping case of Pantland Hick v Raymond & Reid54. The
consignee of a cargo was in breach of a contractual obligation to discharge the relevant vessel within a
reasonable time. There was a single cause of delay, namely a strike of dockworkers, over which the
consignee had no control and the effect of which, while it lasted, was totally to prevent performance of the
contract. The appellants case was that the appropriate period was the additional time that would have been
required for the effect of the strike, over and above the contract period. But the respondents argued that the
question was not what time would have been reasonable under ordinary circumstances, but what time was
reasonable under the circumstances as they then were, absent any fault on the part of the respondents. The
issues were rationalised by Lord Herschell as follows:
My Lords, there appears to me to be no direct authority upon the point, ... I would
observe, in the first place, that there is of course no such thing as a reasonable time in
the abstract. It must always depend upon circumstances. Upon the ordinary
circumstances say the learned counsel for the appellant. But what may without
impropriety be termed the ordinary circumstances differ in particular ports at different
times of the year. It appears to me that the appellants contention would involve
constant difficulty and dispute, and that the only sound principle is that the reasonable
time should depend on the circumstances which actually exist. If the cargo has been
taken with all reasonable despatch under those circumstances I think the obligation of
52
See note 13, at page 120.
53
See note 13, Edmund Davies LJ, at page 124.
54
Pantland Hick v Raymond & Reid [1893] AC 22, HL.
10
A Little of Time at Large
the consignee has been fulfilled. When I say the circumstances which actually exist, I, of
course, imply that those circumstances, in so far as they involve delay, have not been
caused or contributed to by the consignee. 55
In the same case, Lord Watson took the view that, by analogy, the contractor would only be disentitled to
more time with regard to events that were both beyond the contractors control and were neither negligent
nor unreasonable.56
In Astea v Time Group, a case which involved the development of computer software, HH Judge Seymour
explained the decision in Pantland, saying:
What it seems to me the application of the test formulated by the House of Lords in
Pantland Hick v Raymond & Reid involves in a case such as the present is a broad
consideration, with the benefit of hindsight, and viewed from the time as at which one
party contends that a reasonable time for performance has been exceeded, of what
would, in all the circumstances which are by then known to have happened, have been a
reasonable time for performance. 57
On the broad considerations of fairness and reasonableness as being the foundation of the prevention
principle (enunciated by Brooking J in SMK Cabinets v Hili58), it thus seems wrong to deprive the
contractor of a right to relief in time as a result of the employers breach, which otherwise the contractor
would have enjoyed under the risk provisions of the contract. The better view, it seems, is that a reasonable
time to complete should not so much be based upon circumstances beyond the contractors control but
along the line taken by Lord Herschell in Pantland Hick59 and Judge Seymour in Astea v Time Group60.
That is, by subtracting from the time actually taken to execute circumstances expressly or impliedly within
the contractors control that have caused or contributed to the delay to completion. Accordingly, if the risk
structure falls, then it would appear to be appropriate that the onus of proving a reasonable period to
complete should lie with the employer.
55
See note 54, Lord Herschell, at page 29.
56
See note 54, at pages 32 and 33.
57
See note 45, at para 144.
58
See note 4.
59
See note 54.
60
See note 45.
11
Keith Pickavance
61
John Barker Construction Ltd v London Portman Hotel Ltd (1996) 83 BLR 31, TCC.
62
A contingency that rightly renders this method unsuitable where as-built records are available. See for example, Great Eastern Hotel
Company Ltd v John Laing Construction Ltd [2005] EWHC 181, TCC, at para 184.
63
Delay and Disruption Protocol, Society of Construction Law, October 2002, available at www.eotprotocol.com.
64
Balfour Beatty Construction Ltd v London Borough of Lambeth [2002] 1 BLR 288, TCC; at page 302.
65
Royal Brompton Hospital NHS Trust v Frederick A Hammond (No 1) [2000] EWHC Technology 39; at [32].
12
A Little of Time at Large
In the absence of a contract period from which to start, a reasonable time to complete can only properly be
calculated by the As-Built But-For method (see below), on the basis of the actual effect of each breach by
the contractor as it impacted the contractors contemporaneous critical path to completion. This is one of
the methods recognised by the SCL Delay and Disruption Protocol as being an appropriate method of
calculating an extension of time in the absence of a competent planned programme. Provided the materials
are available from which to calculate it, this method takes as a base line the programme of the work as it
was actually carried out, and subtracts from the critical path those actual periods of time for which the
contractor is liable. In so far as, in the absence of those time periods, the critical path shortens, then the
resultant completion date can be said to be the completion date that reasonably could have been achieved in
all the circumstances then existing, save for the contractors culpable delay.
One of the essential characteristics of a tort is that it arises out of mans actual conduct rather than out of an
agreement for future conduct from which a planned intent can be deduced. This method therefore also tends
to be the most likely method available for calculating an appropriate time to complete where the claim is
based upon a tortious relationship, for example, in nuisance.
A WORKED EXAMPLE
This example is of the calculation of a reasonable time in an action in the tort of nuisance. However, the
method used to calculate the period that would have been necessary but for the unreasonable delay on the
part of the defendant in this case is the same method as would be adopted in a contractual dispute in which
there was no contract period from which to start.
On 27 May 1997, the party responsible for the repair of a building became aware of spalling concrete
cladding panels. A protective fan scaffold was erected in October 1997 and remained in place until 18 April
1999, when it was dismantled and replaced to enable the necessary works to be carried out. The claimants
case was that the erection and maintenance of the scaffolding exceeded the period which was necessary for
the purposes of carrying out the works required and that, as a result of the nuisance caused, it lost profits
between October 1997 and April 1999.
The dispute related to the actual length of time the scaffolding remained in place outside the claimants
place of business whilst investigation and repairs were carried out.
The necessity for the repairs was unplanned and there could never have been a planned programme for the
incident or its investigation prior to the letting of the repair contract. There were, however, documents
available giving an historical record of the sequence of occurrences from the date the claimant was notified
of the spalling concrete, to the date the repair contract was awarded. An appropriate method of analysis
would thus be one that used the actual sequence of works as the baseline.
The measurement of unnecessary delay was made by reference to what would have been the completion
date but-for any delaying event (deduced from the re-created history of occurrences in the form of a
dynamic programme). This form of analysis is called an As-Built But-For (ABBF) analysis or a collapsed
as-built. It requires the logic by which the works were procured to be deduced from the sequence that the
activities actually followed.
The method of creating the factual baseline was as follows:
(i) build the programme from the documents, creating milestone activities which indicate start or
completion of an activity;
(ii) identify the actual time periods for each activity;
13
Keith Pickavance
(iii) link the actual time periods represented by the activities with their perceived logical
predecessors and successors;
(iv) identify the activities that represent periods of time that were unnecessary to the process and
code the difference between a reasonable duration and the actual duration as delaying events.
The ABBF method is as follows:
(i) for the purposes of collapsing, take the baseline as-built programme and copy it to a new
programme file for the ABBF analysis;
(ii) calculate the critical path to completion (this is done automatically by the software when the
command to re-sequence is given);
(iii) for the identified delaying events on the programme attribute the duration of zero days in place
of their actual duration;
(iv) recalculate the critical path and identify the date the completion date would have occurred but
for the delaying events.
When the duration of the delaying event is reduced to zero days, if any delaying event was found to be at
any point in its duration on or near the critical path, the completion date would be brought forward. The
difference between (i) the completion date with the actual duration of the delaying event and (ii) that as a
result of the collapse of the critical path with the duration of the event set to zero days is the delay to the
completion date actually caused by the delaying events.
A number of the delaying events were found to have occurred over the same time frame, in whole or in
part, and were thus parallel causes of the same delay to progress. The ABBF analysis demonstrated that the
earliest date on which repair works could have been started but for all the delaying events when taken
together was 23 January 1998. However, the repair works were not actually commenced until 18 April 1999.
Accordingly, the unnecessary delay in commencing the repair works amounts to 450 calendar days. For this
period, liability was, of course, to be established. For example, the repairer may not ultimately be held to be
responsible for the effect of delay to progress caused by the owner or the inaction of the planning authority
and to that extent, the period against which the claimants losses may be calculated will be something less
than the total avoidable delay caused.
Although this is an example of how the effect of Lord Herschells ratio66 might reasonably be put into
practice in determining a reasonable time to complete in relation to a claim in tort, provided the materials
are available from which the factual matrix can be inferred, it is equally applicable to construction disputes
in which there is no contract or, if a contract, no programme which might usefully serve as a baseline.
KEITH PICKAVANCE
November 2005
The views expressed in this paper are those of the author alone, and do not necessarily represent the views of the Society of
Construction Law Hong Kong.
66
See Note 54.
14
A Little of Time at Large
NOTES
15
Keith Pickavance
NOTES
16