NIT 36 Tender Document

File No.
TTD-67024(31)/89/2022-DEE I SEC - TTD
Tirumala Tirupati Devasthanams :: Tirupati
ENGINEERING DEPARTMENT
e-Tendering
STANDARD BID DOCUMENT
INDEX
NO DETAILS Page No.
1. NOTICE INVITING TENDER (NIT)
2. INSTRUCTIONS TO TENDERERS.
A. General.
B. Tender Document
C. Preparation of Tenders
D. Submission of Tenders
E. Tender Opening and Evaluation.
F. Award of Contract.
3. Declaration
À Checklist to Accompany the Tender
4. CONDITIONS OF CONTRACT.
File No.TTD-67024(31)/89/2022-DEE I SEC - TTD
TENDER
A) General
B) Time for completion.
C) Quality Control
D) Cost Control
E) Finishing the Contract
F) Special conditions.
5. TECHNICAL SPECIFICATIONS
6. BILL OF QUANTITIES
7. DRAWINGS
8. SCHEDULE-A
TIRUMALA TIRUPATI DEVASTHANAMS

ENGINEERING DEPARTMENT
*** *** ***
NOTICE INVITING TENDERS (NIT) – Adv.No. 49/D3/CE/TTD/2022-23 dt: 20-11-2022
1. DEPARTMENT NAME : TIRUMALA TIRUPATI DEVASTHANAMS

– Engineering
2. CIRCLE : SE(Elec), TTD, TIRUPATI
3. NIT NUMBER : 36/SE(Elec)/TTD/TPT/2022-23
4. NAME OF WORK : Providing base structure for erection of
temporary lighting along with connecting cables
& street lighting at Sri Kodanda Rama swamy vari
Kalyanavedika in Vontimitta, Kadapa district.
5. ESTIMATE CONTRACT : Rs 80,45,796-86

VALUE
6. PERIOD OF COMPLETION : Three Months with 5 years defect liability
period
7. FORM OF CONTRACT : Lump Sum
8. BIDDING TYPE : Open
9. BID CALL NO. : …1…
10 TYPE OF QUOTATION : PERCENTAGE
11 TRANSACTION FEE : Rs 2,849/- (0.03% of ECV + 18% GST)

PAYABLE TO APTS,
VIJAYAWADA (INR)
12 PROCESSING FEE : ……
13 PROCESSING FEE DD : ……
PAYABLE TO
14 EMD/BID SECURITY : Rs 80,500-00
15 EMD / BID SECURITY BY : Executive Officer, TTD, Tirupati.
WAY OF ON-LINE
PAYMENT / BG on or after 20-
11-2022
16 BID DOCUMENT : 24-11-2022 at 5.00 p.m
DOWNLOADING START
DATE
17 BID DOCUMENT : 09-12-2022 up to 1.00 p.m
DOWNLOADING END DATE
18 LAST DATE AND TIME FOR : 09-12-2022 up to 3.00 p.m
RECEIPT OF BIDS
19 BID VALIDITY : 90 days
20 TENDER OPENING DATE : 09-12-2022 at 3.01 p.m
21 OFFICER INVITING BIDS : Chief Engineer, TTD, Tirupati
22 BID OPENING AUTHORITY : Superintending Engineer (Elec), TTD, Tirupati
23 ADDRESS : O/o Superintending Engineer(Elec), Room
No.15, Ground floor, T.T.D.Administrative
Buildings, K.T.road, Tirupati, Chittoor(Dist), A.P,
India
24 CONTACT DETAILS : 0877-226 4999
Procedure for bid submission:
1.Bids shall be submitted online on www.apeprocurement.gov.in platform
2.The participating bidders in the tender should register themselves free of cost on e-
procurement platform www.apeprocurement.gov.in.
3. Bidders can log-in to e-procurement platform in Secure mode only by signing with the
Digital certificates. Digital Certificates can be obtained from Andhra Pradesh Technology
Services, Vijayawada.
4. The bidders who are desirous of participating in e-procurement shall submit their bids as
per the standard formats available at the e market place.
5. The bidders should scan and upload copies of Registration document and Online payment
receipt / BG towards EMD. The bidders shall sign on all the documents, uploaded by him,
owning responsibility for their correctness/ authenticity.
6. After uploading the documents the attested copies (to be attested by a Gazetted Officer)
of the uploaded documents (except the Price bid / offer) are to be submitted by the
successful bidder either in person or through by courier or post to the Tender Inviting
Authority, before entering into agreement, within the stipulated time. The department will
not take any responsibility for any delay receipt / non-receipt of attested certificates /
documents, from the successful bidder before the stipulated time. If any successful bidder
fails to submit the attested hard copies of uploaded certificates / documents, within the
stipulated time or if any variations is noticed between the uploaded documents and the hard
copies submitted by the bidder, the successful bidder will be suspended from participating
in the tenders on e-procurement platform for a period of 3 years. Besides this, the
department will invoke all processes of law including criminal prosecution of such
defaulting bidder as an act of extreme deterrence to avoid delays in the tender process.
7. The TTD will not hold any risk and responsibility non-visibility of the scanned and
uploaded documents.
8. If the lowest bidder backs out at the time of agreement, penalty of forfeiture of EMD will
be imposed and business of the agency will be suspended for period of three years with all
the Departments in A.P in respect of conventional tenders also vide G.O.Ms.No.259 of T,
R&B (R.V) dept., dated 6.9.2008.
General Terms & Conditions
1. Transaction fee: All the participating bidders shall pay a

transaction fee (non-refundable) for Rs 2,849/- (0.03% of estimate
contract value + 18% service tax) in favour of APTS, Vijayawada.
2. All the participating bidders have to pay the E.M.D. of (@1% of

ECV/TCV ) Rs 80,500-00 by way of BG / On-line payment through e-
procurement portal only. The EMD paid through NEFT / RTGS
mode or through DD will be summarily rejected.
Name of Account holder: EO, TTD - EMD, TTD EMD Account

No.013110100031399, UNION BANK OF INDIA, IFSC Code:
UBIN0801313, MICR No. 517026071. (Online payments to any
other accounts & EMD paid through Demand draft will be

summarily rejected).
The EMD online payment is to be made through e-procurement

portal only.
The EMD Account details furnished is for obtaining Bank

Guarantee only. The EMD paid through NEFT / RTGS mode or
through Demand Draft will be summarily rejected.
3. The successful bidder has to pay the balance EMD @ 1.5% of

ECV/TCV whichever is higher at the time of conclusion of
Agreement in shape of crossed DD / BG in favour of E.O, TTD,
Tirupati.
If, the tenderer submits 1% EMD in the form of BG at the time of

tender and successful, the total EMD of 2½% is to be paid in the
form of DD / BG (valid for contract period i.e. of Three (3) Months
+ Defect liability period of SIXTY (60) months + 28 days).
4. Class of contractor Eligible: Class-I Electrical contractors in

TTD/Govt. having A Grade license. The eligible intending bidders
would be required to enroll themselves on the e-procurement
market place www.eprocurement.gov.in and submit their bids
online.
5. Any other condition regarding receipt of tenders in conventional

method appearing in the tender documents may please be treated
as not applicable.
6. The successful bidder shall pay 0.04% of estimate contract value

towards e-procurement corpus fund by on-line payment in favour
of Managing Director, Andhra Pradesh Technology Services,
Vijayawada at the time of conclusion of agreement which is
enabled on e-procurement platform in the name of accepted
bidder.
7. “The bidder shall authenticate the bid with his digital certifcate
for submitting the bid electronically on e-procurement platform
and the bids not authenticated by digital certifcate of the bidder
will not be accepted on the e-procurement platform.”
(G.O.Ms.No.6, dt: 28/02/2005 of IT & C Dept., Govt. of AP).
8. As per the G.O.Ms 174, I&CAD (PW-REFORMS) Department dated

01-09-2008, if the successful bidder is found defaulting in
submission of hard copies of uploaded certifcates / documents,
within the stipulated time, i.e., before concluding the agreement
or if any variations is noticed between the uploaded documents
and the hard copies submitted by the successful bidder, the
successful bidder will be suspended from participating in the
tenders on e-procurement platform for a period of 3 years.
9. Tenders with an excess of above 5% of the estimated contract

value shall not be allowed to quote in online and the tender

percentage to be quoted should be inclusive of all taxes excluding
GST.
10. Taxes & Duties.

(i) The rates mentioned in the BOQ are basic rates excluding GST
and applicable GST will be reimbursed / paid as per actuals on
production of proof.
(ii) The bidders are requested to quote the Tender percentage

excluding GST.
(iii) Statutory deductions will be made as per norms, if applicable.

Any modalities imposed on GST by the Government from time to
time, the same will be implemented
11. Single tender received in 1st call is liable for cancellation.
TENDER
Date: ……………
To
The Executive Officer,
T.T.Devasthanams,
Tirupati.
Sir,
I / We do hereby tender and if this tender be accepted, under take to execute the following
work viz.……………………………………………..……………………………………………
…………………………………………………………………….…………………………………………
…………………………………………..…………………………….. as shown in the drawings and
described in the specifications deposited in the office of the Executive Engineer / Superintending
Engineer, ____________________________________________________ with such variations by
way of alterations or additions to, and commissions from the said works and method of payment as
provided for in the “conditions of the contract” for the sum of Rupees
…………………………………………………………………………………………………. …………………
……………………………………………… or such other sum as may be arrived under the clause of the
standard preliminary specifications relating to “Payment on lump-sum basis or by final measurement at
unit rates”
I/WE have also quoted percentage excess or less on E.C.V. ., in the website
www.apeprocurement.gov.in for which I/We agree to execute the work when the lump sum
payment under the terms of the agreement is varied by payment on measurement quantities.
I/WE agreed to keep the offer in this tender valid a period of Three month(s) mentioned in the
tender notice and not to modify the whole or any part of it for any reason within above period. If the
tender is withdrawn by me/us for any reasons whatsoever, the earnest money paid by me/us will be
forfeited to T.T.D.
I/WE hereby distinctly and expressly, declare and acknowledge that, before the submission of
my/our tender I/We have carefully followed the instructions in the tender notice and have read the
A.P.S.S. and the preliminary specifications therein and the A.P.S.S. addenda volume and that I/We
have made such examination of the contract documents and the plans, specifications and quantities
and of the location where the said work is to be done, and such investigation of the work required to
be done, and in regard to the material required to be furnished as to enable me/us to thoroughly
understand the intention of same and the requirements, covenants, agreements, stipulations and
restrictions contained in the contract, and in the said plans and specifications and distinctly agree that
I/We will not hereafter make any claim or demand upon the Government based upon or arising out of
any alleged misunderstanding or misconception /or mistake on my/or our part of the said requirement,
covenants, agreements, stipulations, restrictions and conditions.
I/WE enclosed to my/our application for tender schedule a Online payment receipt /
BG (No…………………………………………………..dated:…………………..) for
Rs……………………………..as earnest money not to bear interest.
I/WE shall not assign the contractor or sublet any portion of the same. In case if it becomes
necessary such subletting with the permission of the Executive Engineer shall be limited to (1) Labour
contract, (2) Material contract, (3) Transport contract and (4) Engaging specialists for special item of
work enjoined in A.P.S.S.
IF MY/OUR tender is not accepted the sum shall be returned to me/us on application when
intimation is sent to me/us of rejection or at the expiration of three months from last date of receipt of
this tender, whichever is earlier. If my/our tender is accepted the earnest money shall be retained by
the T.T.D. as security for the due fulfillment of this contract. If upon written intimation to me/us by the
Superintending / Executive Engineer’s Office, I/We fail to attend the said office on the date herein fixed
or if upon intimation being given to me/us by the Superintending /Executive Engineer or acceptance of
my/our tender, and if I/We fail to make the additional security deposit or to enter into the required
agreement, then I/We agree the forfeiture of the earnest money. Any notice required to be served on
me/us here under shall be sufficiently served on me/us if delivered to me/us personally or forwarded to
me/us by post to (registered or ordinary) or left at my/our address given herein. Such notice shall if
sent by post be deemed to have been served on me/us at the time whenin due course of post it would
be delivered at the address to which it is sent.
I/WE fully understand that the written agreement to be entered into between me/us and T.T.D.
shall be the foundation of the rights of the both the parties and the contract shall not be deemed to be
complete until the agreement has first been signed by me/us and then by the proper officer authorised
to enter into contract on behalf of T.T.D.
I AM/WE ARE professionally qualified an my/our qualifications are given below:

Name Qualified
I/WE will employ the following technical staff for supervising the work and will see that one of
them is always at site during working hours, personally checking all items of works and paint extra
attention to such works as required special attention (eg) Reinforced concrete work.
Name of members of technical staff proposed to be employed Qualification.

I / WE declare that I/WE agree to recover the salaries of the technical staff actually engaged
on the work by the department, from the work bills, if I/We fail to employ technical staff as per the
tender condition.
TENDERERS / CONTRACTOR’S CERTIFICATE.

1. I/WE hereby declare that I/We have perused in detail and examined closely the Andhra
Pradesh Standard Specifications, all clauses of the preliminary specifications with all
amendments and have either examined all the standards specifications or will examine all the
standard specifications for items for which I/We tender, before I/We submit such tender and
agree to be bound and comply with all such specifications for this agreement which I/We
execute in the Irrigation & Command Area Development Department.
2. I/WE certify that I/We have inspected the site of the work before quoting my Percentage
excess or less on ECV, I /We have satisfied about the quality, availability and transport
facilities for stones sand and other materials.
3. I/WE am/are prepared to furnish detailed data in support of all my quoted rates, if and when
called upon to do so without any reservations.
4. I/WE hereby declare that I/We will pay an additional security deposit if required as per Tender
conditions.
5. I/WE hereby declare that I am/we are accepting to reject my tender in terms of tender
conditions.
6. I/WE hereby declare that I/We will not claim any price escalation.
7. I/WE hereby declare that I am/We are accepting for the defect liability period as 60 months
instead of 6 months under clause 28 of APSS.
8. a) I/WE declare that I/WE will procure the required construction materials including earth and
use for the work after approval of the Engineer-in-Charge. The responsibility for arranging and
obtaining the land for borrowing or exploitation in any other way shall rest with me/us for the
materials for construction, I/WE shall ensure smooth and un-interrupted supply of materials.
b. I/WE declare that the responsibility for arranging and obtaining the land for disposal of
spoil/soil not useful for construction purposes shall rest with me/us.
c. I/WE declare that I/WE shall not claim any compensation or any payment for the land so
arranged for disposal of soil and the land for borrow area. My/our quoted percentage excess
or less ECV., are inclusive of the land so arranged and I/We will hand over the land so
arranged for disposal of soil to; the department after completion of work. - DELETED
d. I/WE declare that I/WE will not claim any extra amount towards any material used for the work
other than the quoted works for respective schedule ‘A’ items.
9. I/WE declare that I/WE will execute the work as per the mile stone programme, and if I/WE fail
to complete the work as per the mile stone programme I abide by the condition to recover
liquidated damages as per the tender conditions.
10.I / WE declare that I/WE will abide for settlement of disputes as per the tender conditions.
DECLARATION OF THE TENDERER.
1. I/WE have not been black listed in any department in Andhra Pradesh due to any reasons.
2. I/WE have not been demoted to the next lower category for not filing the tenders after buying
the tender schedules in a whole year and my/our registration has not been cancelled for a
similar default in two consecutive years.
3. I/WE agree to disqualify me/us for any wrong declaration in respect of the above and to
summarily reject my/our tender.
Address of the Tenderer :

Phone No.: Fax No.:

CONTRACTOR.
INSTRUCTIONS TO TENDERERS
A-GENERAL
Name of work: Providing base structure for erection of temporary lighting

along with connecting cables & street lighting at Sri Kodanda Rama swamy
vari Kalyanavedika in Vontimitta, Kadapa district.
1. Scope of work:
Give brief description and location of work : The work consists of providing base
structure for temporary lighting with UG Cables at Sri Kodanda Rama swamy vari
Kalyanavedika in Vontimitta.
TTD has decided to take up the work of : Providing base structure for erection of
temporary lighting along with connecting cables & street lighting at Sri
Kodanda Rama swamy vari Kalyanavedika in Vontimitta, Kadapa district.
List out Principal Components of the work : SITC of Pillar boxes = 13

Nos., 9Mtrs octagonal poles = 47 Nos., Timer box = 3 Nos., supply of
50sqmm Cable = 1190mtrs, S&F of 120W LED street light fittings= 32
Nos.
a. ECV Put to tender : Rs 80,45,796.86

b. Give breakup of cost of major items covered in the ECV :
c. Period of completion : 03 (Three) Months with 5 years defect liability
period
d. SSR adopted : Civil SSR 2022-23, CSSR 2022-23 &
previous approved rates
e. Rates adopted for
f. Cement : ----
g. Steel : ----
h. Details of provisions included in the ECV put to Tender.
i) LA & LI at : -----
i. Seigniorage charges : -----
ii. Other allowances : Contractors profit & overhead charges @ 13.365% added on SSR
Items
iii.
g. Reimbursable Provisions.
i) Technical Personnel : ----
ii. Insurance Premium : ----
iii. GST : As specified in clause 84
of Conditions of contract
1.1 The Superintending Engineer(Elec), TTD, Tirupati invites tenders for the above work
vide Adv.No. 49/D3/CE/TTD/TPT/2022-23 dt: 20-11-2022
1.2 Online bids for the above work will be received from Class-I Electrical contractors in
TTD/Govt. having A Grade license. The eligible Contractors / Firms shall submit bids online on
www.apeprocurement.gov.in before the date and time stipulated in Notice Inviting Tender
[NIT].
The online bids will be opened by the Superintending Engineer (Elec), TTD or his nominee at
his office, on the dates mentioned in NIT. If the Office happens to be closed on the dates, the
opening of tenders gets automatically postponed to the next working date, the time being
unaltered, unless extended by a notification published in News papers or sent through Fax /
telegrams to all those who purchased the tender documents.
1.3 The successful tenderer is expected to complete the work within the time period
specified in the NIT.
2. Firms Eligible to Tender:
2.1 The Firms who
i) possess the valid Proof mentioned in the NIT and satisfy all the
conditions therein .
ii) are not blacklisted or debarred or suspended by the Government for
what ever the reason, prohibiting them not to continue in the contracting
business
iii) have complied with the eligibility criteria specified in the
NIT.
are the eligible tenderers.
2.2 Firms Ineligible to Tender:

i) A retired officer of the Govt. of AP or Govt. of India executing works is
disqualified from tendering for a period of two years from the date of retirement
without the prior permission of the Government.
ii) The Tenderer who has employed any retired officer as mentioned above
shall be considered as an ineligible tenderer.
iii) The contractor himself or any of his employees is found to be Gazetted
Officer who retired from Government Service and had not obtained permission from
the Government for accepting the contractor’s employment within a period of 2 years
from the date of his retirement.
iv) The Contractor or any of his employees is found at any time after award of
contract, to be such a person who had not obtained the permission of the Government
as aforesaid before submission of the tender or engagement in the Contractor’s
service.
v) Contractor shall not be eligible to tender for works in the division / circle
where any of his near relatives are employed in the rank of Assistant Engineer or
Assistant Executive Engineers and above on the Engineering side and Divisional
Accounts Officer and above on the administrative side. The Contractor shall intimate
the names of persons who are working with him in any capacity or are subsequently
employed. He shall also furnish a list of Gazetted /Non-Gazetted, State Government
Employees related to him. Failure to furnish such information tenderer is liable to be
removed from the list of approved contractors and his contract is liable for
cancellation.
Note: Near relatives include

1. Sons, step sons, daughters, and step daughters.
2. Son-in-law, and daughter-in-law.
3. Brother-in-law, and sister-in-law.
4. Brothers and Sisters.
5. Father and Mother.
6. Wife / Husband.
7. Father-in-law and Mother-in-law
8. Nephews, nieces, uncle and aunties
9. Cousins and
10. Any person residing with or dependent on the contractor.
3. Qualification data of the Tenderers
3.1 The tenderer shall furnish the following particulars in the formats enclosed,
supported by documentary evidence as specified in the formats.
a) Check List to accompany the tender (in Annexure-I).
b) Attested copies of documents relating to the Registration of the firm, Partnership
deed, Articles of Association, Commercial Tax / Registration, Latest Income Tax
Clearance certificate, Commercial Tax clearance certificate etc.
Note: The Partnership firms, which are registered as Contractors shall intimate the
change in partnership deed, if any, as per GO Ms No.58, I & CAD, dt.23.4.2002 within
one month of such change. Failure to notify the change to the registration authority in
time will entail the firms to forfeit their registration and their tender will be rejected.
The intimation of change of partners if any and the acceptance by the Registration
authority may be enclosed.
c. Value of similar works executed every year during the last five financial years
(i.e., from 2017-2018 to 2021-2022) in Statement – I.
d. details of similar works completed in the name of the tenderer as Prime
Contractor during the last five financial years i.e., from 2017-2018 to 2021-
2022 showing year wise break up of value of work executed in Statement – II.
e. Year wise specified quantities executed by the tenderer during the last five
financial years in Statement-III

f. Details of the existing commitments i.e., works on hand and works for which
tenders are submitted in Statement – IV
g. availability of key personnel for administration / site management and
execution viz., technical personnel required for the work;
Graduate Engineer (Elec) … 1 No.
Diploma Holder (Elec) … 1 No.
h. information regarding any litigation, with Government during the last five
years, in which the Tenderer is involved in (Statement – V)
i. Availability of working capital for the work [Liquid assets, credit facility and
availability of other financial resources such as solvency etc];
j) the proposed methodology and program of construction, backed with equipment

planning and deployment, duly supported with broad calculations, justifying their capability
of execution and completion of the work as per technical specifications within the
stipulated period of completion as per milestones.
k) The particulars of quality control testing Lab owned, OR tie up with established
quality control testing laboratories.
3.2 Tenders from Joint Ventures are not acceptable unless specifically stated otherwise.
3.3 QUALIFICATION CRITERIA FOR OPENING OF THE PRICE BID.
A) To qualify for opening the Price Bid each contractor / firm in its name,
should have, during the last five financial years from 2017-2018 to 2021-2022
(specify the financial years; those immediately preceding the financial year in which
the tenders are invited).
(i) Satisfactorily completed as a PRIME CONTRACTOR, similar works of

value not less than Rs 1,60,92,000-00 [at current price level] in any one year.
Note:- The cost of completed works of previous years shall be given weightage of
10% per year to bring them to current price level, (the financial year in which bids are
invited).
B) The tenderer should have executed the following minimum quantities in any
one financial year during the last five financial years i.e., from 2017-2018 to 2021-
2022.
Sl.No. Description of work Quantity

1) SITC of Pillar boxes / Panel boards 26 Nos
2) Supply of UG Cable 700 Mtrs
C. Each bidder should further demonstrate:
(i) Availability (either owned or leased or to be procured against mobilisation advance of

the following key and critical equipment for this work.)
S.No. Equipment Type and Characteristics Minimum No. required.
-- ---- ----
Note: The major equipment to attain the completion of works in accordance with the
prescribed construction schedule, is to be shown in the above table.
(ii) Liquid assets and / or credit facilities of not less than Rs 80,46,000-00
(Credit facility / letter of credits / Solvency certificates from Banks etc).
(D) Bid capacity.
The tenderer who meets the above qualification criteria and whose available bid capacity is
more than the estimated contract value will be qualified for opening of Price bid. The available
bid capacity will be calculated as under:
Available Bid Capacity : 2AN-B > Rs 80,45,796.86
Where,
A= Maximum value of works executed in its name in any one financial year during
the last five financial years (updated to current Price level) taking into account the
works completed as well as works in progress.
N= Number of years prescribed for completion of the work for which Tenders are
invited [months / 12].
B = Updated value (at current Price level), of all existing Commitments i.e.,
ongoing works, works likely to be awarded to be executed during the 2022-2023 year.
(Period of completion for which Tenders are invited).
Annual turnover, cost of completed works and balance works on hand etc., shall be
updated by giving weightage of 10% per year to bring them to current price
level.
No relaxation will be given to any of the qualification criteria.
Note: a) Sub-contractor’s experience, in his name will be taken in to account in

determining the Tenderer’s compliance to the Qualification criteria, if it is as per GO
Ms No.8, dt. 8.1.2003.
b) The experience gained in a registered JV firm to the extent of the
tenderer’s share shall be considered if the tenderer happens to be the lead partner,
for similar works criteria also.
3.4 Even though the tenderers meet the above qualifying criteria, they are liable to be
disqualified / debarred / suspended / blacklisted if they have
• Furnished false / fabricated particulars in the forms, statements and /

annexures submitted in proof of the qualification requirements and/or
• Not turned up for entering into agreement, when called upon.
• record of poor progress such as abandoning the work, not properly
completing the contract, inordinate delays in completion, litigation
history or financial failures etc. and/or
• participated in the previous bidding for the same work and had quoted
unreasonably high tender percentage and
• even while execution of the work, if found that the work was awarded
to the Contractor based on false / fake certificates of experience, the
Contractor will be blacklisted and work will be taken over invoking
clause 61 of PS to APSS.
3.5 Tenders with an excess of above 5% of the estimated contract value shall not
be allowed to quote in online.
3.6 For tenders up to 25% less than the estimated contract value of work, no additional
security deposit is required. But for tenders less than 25% of the estimated Contract Value of
work, the difference between the tendered amount and 75% of the estimated contract value,
shall be paid by the successful tenderer at the time of concluding agreement as an additional
security to fulfill the contract through a Demand Draft on a Nationalized Bank / Scheduled
bank.
3.7 a) If the percentage quoted by a tenderer is found to be either
abnormally high or within the permissible ceiling limits prescribed but under collusion
or due to unethical practices adopted at the time of tendering process, such tenders
shall be rejected.
b) A tenderer submitting a Tender which the tender accepting authority

considers excessive and or indicative of insufficient knowledge of current prices or
definite attempt of profiteering will render himself liable to be debarred permanently
from tendering or for such period as the tender accepting authority may decide. The
tenderer overall percentage should be based on the controlled prices for the materials,
if any, fixed by the Government or the reasonable prices permissible for the tenderer
to charge a private purchaser under the provisions of clause-6 of the hoarding and
profiteering prevention ordinance of 1943 as amended from time to time and on similar
principle in regard to labour supervision on the construction .
4. One Tender per Tenderer:

4.1 Each Tenderer shall submit only one Tender for the work. A Tenderer who submits
more than one Tender will cause dis-qualification of all the Tenders submitted by the
Tenderer.
5. Cost of Tendering
5.1 The Tenderer shall bear all costs associated with the preparation and submission of
his Tender and the tender inviting authority will in no case be responsible and liable for those
costs.
6. Site Visit.
6.1 The Tenderer, at the Tenderer’s own responsibility and risk is advised to visit and
examine the Site of Work and its surroundings and obtain all information that may be
necessary for preparing the Tender for entering into a contract, for construction of the work.
The costs of visiting the site shall be at the Tenderer’s own expense.
B. TENDER DOCUMENT
7. Contents of Tender document.
7.1 One set of Tender document, comprises of the following:
Technical bid
1) Notice Inviting Tenders (NIT)
2) Instruction to Tenderers
3. Qualification information
4) Conditions of Contract.
5) Specifications.
6) Forms of Securities. i.e., EMD, Additional Security etc.
Price bid
Bill of Quantities and Price bid.
8. Clarification on Tender Documents

8.1 A prospective Tenderer requiring any clarification on Tender documents may
contact the Tender Inviting Officer at the address indicated in the NIT. The Tender Inviting
Officer will also respond to any request for clarification, received through post .
9. Pre Bid Meeting
9.1 The details presented in this Bidding Document have been compiled with all
reasonable care. However, it is the Bidder’s responsibility to ensure that the information
provided is adequate, clearly understood and it includes all documents as per the Index.
9.2 Bidder shall examine the Bidding Document thoroughly in all respects and if any
conflict, discrepancy, error or omission is observed, Bidder may request clarification in the pre-
bid meeting.
9.3 Pre-bid Meeting will be held at 3.00 PM IST on ___________ in the chamber of the
Chief Engineer, TTD, Tirupati. Bidders can send their queries to the S.E(Elec), TTD
Administrative Building, K.T. Road Tirupati-517501 Only. The queries received 2 days
prior to the Pre Bid Meeting will be answered. The entry to the Pre-Bid Meeting will
be limited to One person per bidder and they should carry valid authorization letter
on company’s letter head.
9.4 Only queries reaching TTD within 2 working days (before 17:00 hrs) prior to
Pre-Bid Conference will be taken for consideration.
9.5 Queries shall be sent to O/o the Superintending Engineer-Elec., TTD Administrative
Building, K.T. Road Tirupati-517501. The clarifications for queries received by the TTD
up to specified time will be up-loaded as corrigendum on
https://tender.apeprocurement.gov.in.
9.6 The response to queries/ clarifications of the bidders shall not form part of Bidding
Document unless issued as an Amendment/Addendum.
9.7 The bidder shall sign the copy of the Minutes of the Pre-bid meeting and scan and
enclose along with all other documents. Clarifications furnished in the pre-bid meeting shall be
the part of the bid document. Not attending the meeting, does not relieve the tenderers from
the decisions taken at the pre-bid meeting. Failure to comply the same, such tenders are liable
for rejection. DELETED
10. Amendment to Tender Documents

10.1 Before the last date for submission of tenders, the tender inviting officer may modify
the contents of the Tender Notice, Tender documents by issuing amendment / addendum.
10.2 Any addendum/amendments issued by the Tender Inviting Officer shall be part of the
Tender Document and it shall either be communicated in writing to all the purchasers of the
Tender documents or notified in the News Papers/ e-Procurement site in which NIT was
published.
10.3 To give prospective Tenderers reasonable time to take an addendum into account in
preparing their bids, the Tender Inviting Officer may extend if necessary, the last date for
submission of tenders.
C. PREPARATION OF TENDERS.
11. Language of the Tender.
11.1 All documents relating to the tender shall be in the English Language only.
12. Bid Offer:
12.1 Bill of Quantities called Schedule “A” and the bid offer accompanies the tender
document as Volume - II. It shall be explicitly understood that the Tender Inviting Officer does
not accept any responsibility for the correctness or completeness of this schedule ‘A’ and this
schedule ‘A’ is liable to alterations by omissions, deductions or additions at the discretion of
the Superintending Engineer or as set forth in the conditions of the contract. The
Schedule “A” shall contain the items of work indicated as part– I and LS provisions as part–II.
The percentage quoted by the contractor shall be applicable only to part –I. However, the
provisions contained in the part–II will be operable basing on the conditions provided in the
Tender Document. The tenderers will have to state clearly their willingness to execute the
work at certain specific percentage of excess or less or at par of the ECV indicated in Part-I at
the space provided therein in Schedule ‘A’. The L.S. amounts indicated in part-II are
maximum reimbursable amounts. The tenderer should however quote his lump sum tender
based on this schedule of quantities. He should quote his offer as a overall tender
percentage. The over all tender percentage should be written both in words and figures.
12.2 The Schedule –A (or Price-bid) contains not only the quantities but also the rates
worked out by the Department and the amount for each item and total value of the estimated
contract. The tenderer should workout his own rates keeping in view the work, site conditions
and quote his overall tender percentage with which he intends to execute the work .
12.3 The bid offer shall be for the whole work and not for individual items / part of the
work.
12.4 All duties, taxes, and other levies payable by the contractor as per State / Central
Government rules, shall be included in the tender percentage / rate quoted by the tenderer,
however keeping in view the maximum reimbursable amounts specified in Part.II of Price bid
12.5 The tendered contract amount as computed based on overall tender percentage is
subject to variation during the performance of the Contract in accordance with variation in
quantities etc.
12.6 Charges payable to APTS:
The successful bidder will pay further fee @ 0.04% of ECV (Estimated contract value )
i.e., payable to APTS.
Once the L1 bidder is finalized, the system automatically generates the e-Procurement fund
(corpus fund) to be paid. The option for payment of e-Procurement fund (Corpus fund) is
enabled to bidders/contractors in their login.
(The ceiling amount of Transaction fee for works costing ECV up to Rs 50.00 Crores is
Rs10,000.00 and for works costing with ECV above Rs 50.00 Crores the ceiling amount of
transaction fee is Rs 23,000/-) to create e procurement corpus fund to be administered by
APTS. The above fee is payable by the successful bidder through online payment only which
is enabled on e-procurement platform in the name of accepted bidder at the time of conclusion
for the agreement.
13. Validity of Tenders:

13.1 Tenders shall remain valid for a period of not less than three months from the last
date for receipt of Tender specified in NIT.
13.2 During the above mentioned period no plea by the tenderer for any sort of
modification of the tender based upon or arising out of any alleged misunderstanding of
misconceptions or mistake or for any reason will be entertained .
13.3 In exceptional circumstances, prior to expiry of the original time limit, the Tender
Inviting Officer may request the bidders to extend the period of validity for a specified
additional period. Such request to the Tenderers shall be made in writing. A Tenderer may
refuse the request without forfeiting his E.M.D. A Tenderer agreeing to the request will not be
permitted to modify his Tender, but will be required to extend the validity of his E.M.D. for a
period of the extension.
14. Earnest Money Deposit
14.1 The Tenderer shall furnish, Earnest Money Deposit as specified in NIT. The Tenderers
are requested to pay by way of On-Line payment / BG only.
14.2 The DD furnished towards EMD for BIDDING the tender shall be valid for a period of
six months from the date of tender notice.
14.3 The EMD of Tenderers will be returned no sooner the tenders are finalised or end
date of the Tender validity period which ever is earlier.
14.4 The earnest money deposited by the successful tenderer will not carry any interest
and it will be dealt with as provided in the conditions stipulated in the tender.
14.5 The Successful tenderer has to pay the Balance EMD @ 1.5 % of ECV / TCV whichever
is higher at the time of conclusion of the Agreement
14.6 The E.M.D. shall be forfeited.
(a) if the Tenderer withdraws the Tender during the validity period of Tender.
(b) in the case of a successful Tenderer, if he fails to sign the Agreement for whatever the
reason.
14.7 In consideration of the Executive Engineer / Superintending Engineer /Chief Engineer,
T.T.Devasthanams undertaking to investigate and to take into account each tender and in consideration
of the work thereby involved, all earnest monies deposited by the tenderer will be forfeited to the
T.T.Devasthanams in the event of such tenderer either modifying or with-drawing his tender at his
instance within the said validity period of three months.
D. SUBMISSION OF TENDERS.
15. Submission of Tenders:
15.1 The tenderer shall invariably ensure that the scanned copies of the following documents are
uploaded and attached online:
As per the Annexure-I Check list
15.2 Bids submitted in offline sealed cover system shall not be considered for evaluation.
16. Last date / time for Submission of the Tenders.
16.1 Tenders must be submitted not later than the date and time specified in NIT.
16.2 The Superintending Engineer / Chief Engineer, TTDs, may extend the dates for Bid submission
/ Price bid opening of Tenders by issuing an amendment in which case all rights and obligations of the
Superintending Engineer/Chief Engineer will remain same as previously.
17. Modification to the Tender.
17.1 Tenderers may modify their bid submitted online before the last date / time prescribed in NIT.
E. TENDER OPENING AND EVALUATION
18. Tender opening
18.1 The Tender opening authority shall open the bids online on the stipulated date and
time of opening specified in NIT.
19. Price Bid Opening:
19.1 At the specified date and time, the price bids of the will be opened online by the Tender
receiving authority or his nominee and the result will be displayed on the ‘e’ market place which can be
seen by all the bidders who participated in the Tenders.
19.2 Tenders shall be scrutinized in accordance with the conditions stipulated in the Tender
document. In case of any discrepancy of non-adherence Conditions the Tender accepting authority shall
communicate the same which will be binding both on the tender Opening authority and the Tenderer. In
case of any ambiguity or dispute, the decision taken by the Tender Accepting Authority on tenders shall
be final.
20. Evaluation and Comparison of Price Bids
20.1 The Superintending Engineer will evaluate and compare the price bids of all the qualified
Tenderers. Because of this both percentage and item value system the L1 will be finalized by taking in to
amount of combined value for both portions (i.e both percentage and open tender value).
20.2 Negotiations at any level are strictly prohibited. However, good gesture rebate, if offered by the
lowest tenderer prior to finalization of tenders may be accepted by the tender accepting authority.
20.3 Selection of Tenderer among the lowest & equally quoted tenderers will be in the following orders:
a) The tenderer whose bid capacity is higher will be selected.
b) In case the bid capacity is also same the tenderer whose annual turnover is more will be
preferred.
c) Even if the criteria incidentally become the same, the turnover on similar works and thereafter
machinery available for the work and then the clean track record will be considered for selection.
21. Process to be Confidential.

21.1 Information relating to the examination, clarification, evaluation and comparison of Tenders
and recommendations for the award of a contract shall not be disclosed to Tenderers or any other
persons not officially concerned with such process until the award to the successful Tenderer has been
announced by the tender accepting authority. Any effort by a Tenderer to influence the processing of
Tenders or award decisions may result in the rejection of his Tender.
21.2 No Tenderer shall contact the Superintending Engineer or any authority concerned with
finalization of tenders on any matter relating to its Tender from the time of the Tender opening to the time
the Contract is awarded. If the Tenderer wishes to bring additional information to the notice of the
Superintending Engineer, It should be done so in writing.
21.3 Before recommending / accepting the tender, the tender recommending / accepting authority
shall verify the correctness of certificates submitted to meet the eligibility criteria and specifically
experience. The authenticated agreements of previous works executed by the lowest tenderer shall be
called for.
21.4 Tenders will be finalized by the Executive Engineers / Superintending Engineers / Chief
Engineer / Executive Officer / TTD Board according to the powers vested with them.
F. AWARD OF CONTRACT
22. Award Criteria
22.1 The Executive Engineer / Superintending Engineer / Chief Engineer will award or recommend
to the Competent tender accepting authority for award of the contract to the Tenderer who is found
Technically qualified as per the Tender conditions and whose price bid is lowest.
22.2 The tender accepting authority reserves the right to accept or reject any Tender or all tenders
and to cancel the Tendering process, at any time prior to the award of Contract, without thereby incurring
any liability to the affected Tenderer or Tenderers or any obligation to inform the affected Tenderer or
Tenderers of the reasons for such action.
23. Notification of Award and Signing of Agreement.
23.1 The Tenderer whose Tender has been accepted will be notified of the award of the work by the
Executive Engineer / Superintending Engineer / Chief Engineer, prior to expiration of the Tender validity
period by registered letter. This letter (hereinafter and in the Conditions of Contract called “Letter of
Acceptance”) will indicate the sum that the T.T.Devasthanams will pay the Contractor in consideration of
the execution, completion, and maintenance of the Works by the Contractor as prescribed by the
Contract (hereinafter and in the Contract called the “Contract Amount”).
23.2 When a tender is to be accepted the concerned tenderer shall attend the office of the Executive
Engineer / Superintending Engineer concerned on the date fixed in the Letter of acceptance. Upon
intimation being given by the Executive Engineer / Superintending Engineer / Chief Engineer, of
acceptance of his tender, the tenderers shall make payment of the balance E.M.D., and additional
security deposit wherever needed by way of Demand Draft or unconditional and irrevocable Bank
Guarantee obtained from a Nationalized / Scheduled Bank with a validity period of months, and sign an
agreement in the form prescribed by the department for the due fulfillment of the contract. Failure to
attend the Executive Engineer / Superintending Engineer’s office on the date fixed, in the written
intimation, to enter into the required agreement shall entail forfeiture of the Earnest Money deposited.
The written agreement to be entered into between the contractor and the T.T.Devasthanams shall be the
foundation of the rights and obligations of both the parties and the contract shall not be deemed to be
complete until the agreement has first been signed by the contractor and then by the proper officer
authorized to enter into contract on behalf of the T.T.Devasthanams.
23.3 The successful tenderer has to sign an agreement within a period of 15 days from the date of
receipt of communication of acceptance of his tender. On failure to do so his tender will be cancelled
duly forfeiting the E.M.D., paid by him without issuing any further notice and action will be initiated for
black listing the tenderer.
23.4 If the lowest bidder backs out at the time of agreement, penalty of forfeiture of EMD will be
imposed and business of the agency will be suspended for THREE years with all the Departments in A.P
in respect of conventional tenders also vide G.O.Ms.No. 259 of T, R&B (R.V) dept., dt. 6.9.2008.
24. Corrupt or Fraudulent Practices
24.1 The Government require that the bidders / suppliers / contractors under Government financed
contracts, observe the highest standard of ethics during the procurement and execution of such
contracts. In pursuance of this policy, the T.T.Devasthanams.
(a) Define for the purposes of the provision, the terms set forth below as follows:
(i) “Corrupt practices” means the offering, giving, receiving or soliciting of any thing of value
to influence the action of a T.T.Devasthanams official in procurement process or in contract
execution: and
(ii) “Fraudulent practice” means a misrepresentation of facts in order to influence a
procurement process or the execution of a contract to the detriment of the T.T.Devasthanams
and includes collusive practice among Tenderers (prior to or after Tender submission) designed
to establish in Tender prices at artificial non-competitive levels and to deprive the
T.T.Devasthanams of the benefits of free and open competition.
(b) Will reject a proposal for award if it determines that the Tenderer recommended for award
has engaged in corrupt or fraudulent practices in competing for the contract in question.
(c) Will blacklist / or debar a firm, either indefinitely or for a stated period of time, if at any time
determines that the firm has engaged in corrupt or fraudulent practices in competing for, or in
executing a T.T.Devasthanams Contract.
(d) Further more, Tenderers shall be aware of the provisions stated in the General Conditions of
Contract.
FORMS OF TENDER
QUALIFICATION INFORMATION
Annexure –I
CHECKLIST TO ACOMPANY THE TENDER
Page No.
S. Submitted in
Description (see Note
No Cover ‘A’
below)
1 2 3 4
1 Proof of Class-I Electrical contractors in TTD/Govt. having A Mandatory
Grade license
2 EMD for Rs 80,500-00 by way of On-Line payment / BG Mandatory

only.
3 Income tax / PAN Card Mandatory

4 Copy of GST registration Mandatory
5 The bidder has to scan the declaration towards not Mandatory
blacklisted typed in their letter head with signature
6 Evidence of satisfactorily completed similar works in any one Mandatory

financial year during last five years i.e., 2017-18 to 2021-22
for Rs 1,60,92,000-00.
7 Credit facility / letter of credits / Solvency certificates from Mandatory

Banks for Rs 80,46,000-00 (Not older than one year)
8 The Bidder has to scan / furnish the details as per Mandatory
Statement-I to Statement-VI & Bid capacity
9 The bidder has to scan experience certificates having Mandatory
execution of minimum quantities as mentioned at Clause
No.3.3 (B) in Instructions to tenderers in any one financial
year during last five years i.e., 2017-18 to 2021-22
DECLARATION
I / WE ………………………………………………………………. have gone through carefully all the

Tender conditions and solemnly declare that I / we will abide by any penal action such as
disqualification or black listing or determination of contract or any other action deemed fit, taken by,
the Department against us, if it is found that the statements, documents, certificates produced by us
are false / fabricated.
I / WE hereby declare that, I / WE have not been blacklisted / debarred / Suspended / demoted in any
department in Andhra Pradesh or in any State due to any reasons.
Signature of the Tenderer

STATEMENT – I
Details of value of similar works executed in each year during the last five financial years by
the Tenderer.
Sl. No. Financial Year Value in Rs.

1.
2.
3.
4.
5.
a. Certificate from Chartered Accountant supported with Annual Balance

Sheet tallying with I.T. Clearance certificate.
STATEMENT – II
Details of similar works completed in the Name of the Tenderer during the last five financial
years.
Name of the Address of Agt. Concluding Agreement No. & Value of

Sl. No
work Authority dated. Contract
1 2 3 4 5
Value of work done year wise during the Total value of

Stipulated period of Actual date of last ‘five’ years. work done.
completion completion 1st 2nd 3rd 4th 5th
Year Year Year Year Year
6 7 8 9 10 11 12 13
Attach certificates issued by the concerned and showing work wise / year wise value of work
done and date of completion.
STATEMENT – III
Physical quantities executed by the Tenderer in any one financial year during the last five
financial years.
Quantities executed / Year wise.
Agt.
Sl. No. Financial Year Name of work Any other items.
No.
1 2 3 4 5 6 7 8 9 10
1
2
3
4
5
Attach certificates in support of the quantities mentioned in the Schedule issued by the
Executive Engineer concerned and countersigned by the concerned Superintending Engineer duly
showing the quantities executed year wise.
STATEMENT – IV
Details of Existing Commitments
Details of works on hand and, yet to be completed as on the date of submission of the Tender and
works for which Tenders have been awarded as on the date of submission of Tender are to be
furnished.
A. Existing Commitments on ongoing works:

Sl. Name Address of Agt. Value of Stipul-ated Value Balance Antici-pated Updated
of work Value of value of

of Agt. conclu- No. period of date of comp-
No cont-ract done works to be balance
work ding authority & Date comp-letion letion
so far. comple-ted work
1 2 3 4 5 6 7 8 9 10
B. Details of works for which Tenders are submitted [awarded /

likely to be awarded]
Address of Agt. Date on which

Sl. Name of Estimated Stipulated period Present stage
concluding tender was
No. work value of work of completion of Tender.
authority submitted
1 2 3 4 5 6 7
STATEMENT – V
Availability of Key personnel
Qualification and experience of key personnel to be deployed for executed of the contract.
S. No Name Designation Qualification Total Experience Working with the Tender since
1 2 3 4 5 6
STATEMENT – VI
Information on litigation history in which Tenderer is the Petitioner.
S. Case No. / Court where Subject Matter / Prayer in the Respondents i.e., SE / Present
No Year filed. case. CE Stage.
1 2 3 4 5 6

BID CAPACITY
(To be filled by the Tenderer)
1) Name of the work :
2) Due on :
3) Name of the Tenderer :
A Maximum value of similar works executed in its name in any one financial year :
: during the last five financial years (updated to current price level) taking into
account the works completed as well as works in progress.
N: Number of years prescribed for completion of work for which Tenders are :
invited (Months / 12)
B: Updated value (at current price level), of all existing commitments i.e., ongoing :
works, works likely to be awarded to be executed.
(Period of completion for which Tenders are invited).
(Supported by necessary certificate).
4) Estimate value (put to Tender) :
2AN – B :
Certified that the particulars noted above are correct to the best of my
knowledge

CONDITIONS OF CONTRACT
A. GENERAL
1. Interpretation:
1.1 In interpreting these Conditions of Contract, singular also means plural, male also
means female, and vice-versa. Headings have no significance. Works have their normal
meaning under the language of the contract unless specifically defined. The Engineers-in-
charge will provide instructions clarifying queries about the conditions of Contract.
1.2 The documents forming the Contract shall be interpreted in the following order of
priority:
1) Agreement
2) Letter of Acceptance, notice to proceed with the works
3) Contractor’s Tender (Technical bid)
4) Conditions of contract
5) Specifications
6) Drawings
7) Bill of quantities (Price-bid)
8) Any other document listed as forming part of the Contract .
2. Engineer-in-Charge’s Decisions:
2.1 Except where otherwise specifically stated, the Engineer-in-charge will decide the
contractual matters between the Department and the Contractor in the role representing the
Department.
3. Delegation:
3.1 The Engineer-in-charge may delegate any of his duties and responsibilities to other
officers and may Cancel any delegation by an official order issued.
4. Communications:
4.1 Communications between parties, which are referred to in the conditions, are effective
only when in writing. A notice shall be effective only when it is delivered (in terms of Indian
Contract Act)
5. Sub-contracting:
5.1 If the prime contractor desires to sub-let a part of the work, he should submit the
same at the time of filing tenders itself or during execution, giving the name of the proposed
Sub-contractor, along with details of his qualification and experience. The Tender Accepting
Authority should verify the experience of the Sub-contractor and if the Sub-contractor satisfies
the qualification criteria in proportion to the value of work proposed to be sub-let, he may
permit the same. The total value of works to be awarded on sub-letting shall not exceed 50%
of contract value. The extent of subletting shall be added to the experience of the sub-
contractor and to that extent deducted from that of the main contractor.
6. Other Contractors:
6.1 The Contractor shall cooperate and share the Site with other contractors, Public
authorities, utilities, and the Department. The Contractor shall also provide facilities and
services for them as directed by the Engineer-in-charge.
7. Personnel:
7.1 The Contractor shall employ the required Key Personnel named in the Schedule of
Key Personnel to carry out the functions stated in the Schedule or other personnel approved
by the Engineer-in-charge. The Engineer-in-charge will approve any proposed replacement of
Key Personnel only if their qualifications, abilities, and relevant experience are substantially
equal to or better than those of the personnel listed in the Schedule.
7.2 Failure to employ the following minimum required technical personnel by the
contractor the following amounts will be recovered from the contractor over and above the
provision made in part two of schedule-A from the contractors bills.
S.No Contract value of Technical staff to be employed For non-employment of the technical
works to be executed. staff, rates of recovery per month
1 More than Rs.15.00 One Graduate Engineer (Elec) Rs 58,500/-
Lakhs. & one Diploma Holder (Elec)
7.3 The technical personnel should be on full time and available at site whenever
required by Engineer in Charge to take instructions.
7.4 The names of the technical personnel to be employed by the contractor should be
furnished in the statement enclosed separately.
7.5 In case the contractor is already having more than one work on hand and has
undertaken more than one work at the same time, he should employ separate technical
personnel on each work.
7.6 If the contractor fails to employ technical personnel the work will be suspended or
department will engage a technical personnel and recover the cost thereof from the contractor.
7.7 If the Engineer-in-charge asks the Contractor to remove a person who is a member
of Contractor’s staff or his work force stating the reasons the Contractor shall ensure that the
person leaves the site forthwith and has no further connection with the work in the contract.
8. Contractor’s Risks:
8.1 All risks of loss of or damage to physical property and of personnel injury and death,
which arise during and in consequence of the performance of the Contract are the
responsibility of the Contractor.
9. Insurance:
Insurance is totally at the risk and responsibility of the Contractor from the Start Date to the
end of the Defects Liability period i.e., 60 months after completion of the work for all the
events.
10.Site Inspections:
The contractor should inspect the site and also proposed quarries of choice for materials
source of water and quote his percentage including quarrying, conveyance and all other
charges etc.
The responsibility for arranging the land for borrow area rests with the Contractor and no
separate payment will be made for procurement or otherwise. The contractor’s quoted
percentage will be inclusive of land cost.
11. Contractor to Construct the Works:

11.1 The Contractor shall construct and Commission the Work in accordance with the
specifications and Drawings.
12. Diversion of streams / Vagus / Drains.
The contractor shall at all times carry out construction of cross drainage works in a manner
creating least interference to the natural flow of water while consistent with the satisfactory
execution of work. A temporary diversion shall be formed by the contractor at his cost where
necessary. No extra payment shall be made for this work.
12.1 No separate payment for bailing out sub-soils, water drainage or locked up rain
water for diversion, shoring, foundations, bailing of pumping water either from excavation of
soils from foundations or such other incidental will be paid. The percentage to be quoted by
the contractor are for the finished item of work in situ and including all the incidental charges.
The borrow pits are also to be de-watered by the contractor himself at his expense, if that
should be found necessary.
12.2 The work of diversion arrangements should be carefully planned and prepared by the
contractor and forwarded to the Executive Engineer technically substantiating the proposals
and approval of the Executive Engineer obtained for execution.
12.3 The contractor has to arrange for bailing out water, protection to the work in progress
and the portion of works already completed and safety measures for men and materials and
all necessary arrangements to complete the work.
12.4 All the arrangements so required should be carried out and maintained at the cost of
the contractor and no separate or additional payments is admissible..
13.1 Coffer Dams.

Necessary cofferdams and ring bunds have to be constructed at the cost of contractor and
same are to be removed after the completion of the work. The contractor has to quote his
percentage keeping the above in view.
14.1 Temporary Diversions (Works on Highways)

The contractor shall at all times carryout work on the highway in a manner creating least
interference to the flow of traffic while consistent with the satisfactory execution of the same.
For all works involving improvements to the existing highway, the contractor shall in
accordance with the directions of the Engineer-in-charge provide and maintain during the
execution of the work a passage for traffic, either along a part of the existing carriage way
under improvement or along a temporary diversion constructed close to the highway.
14.2 If in the opinion of the Engineer-in-Charge, it is not possible to pass the traffic on part
width of the carriage-way for any reason, a temporary diversion close to the highway shall be
constructed as directed. It shall be paved with the materials such as hard morum, gravel and
stone, metal to the specified thickness as directed by the Engineer-in-Charge. In all cases,
the alignment, gradients and surface type of the diversion including its junctions, shall be
approved by the Engineer-in-charge before the highway is closed to traffic.
14.3 The contractor shall take all necessary measures for the safety of traffic during
construction and provide erect and maintain such barricades, including signs, markings, flags
lights and information and protection of traffic approaching or passing through the section of
the highway under improvement. Before taking up any construction, an agreed phased
programme for the diversion of traffic on the highway shall be drawn up in consultation with
the Engineer-in-charge.
14.4 The barricades erected on either side of the carriage way portion of the carriage way
closed to traffic, shall be of strong design to resist violation and painted with alternative black
and white stripe. Red lanterens or warnings lights of similar type shall be mounted on the
barricades at night and kept lit throughout from sunset to sunrise.
15.1 Ramps:
Ramps required during execution may be formed wherever necessary and same are to be
removed after completion of the work. No separate payment will be made for this purpose.
16.1 Monsoon Damages:

Damages due to rain or flood either in cutting or in banks shall have to be made good by the
contractor till the work is handed over to the Department. The responsibility of de-silting and
making good the damages due to rain or flood rests with the contractor. No extra payment is
payable for such operations and the contractor shall therefore, have to take all necessary
precautions to protect the work done during the construction period.
16.2 The works to be Completed by the Intended Completion Date:

The Contractor may commence execution of the Works on the Start Date and shall carry out
the Works in accordance with the programme submitted by the Contractor, as updated with
the approval of the Engineer-in-Charge, and complete the work by the Intended Completion
Date.
17.1 Safety:
The Contractor shall be responsible for the safety of all activities on the Site.
18.1 Discoveries:
Anything of historical or other interest or of significant value unexpectedly discovered on the
Site is the property of the Government / T.T. Devasthanams. The Contractor is to notify the
Engineer-in-charge of such discoveries and carry out the Engineer-in-Charge’s instructions for
dealing with them.
19.1 Possession of the Site.

The Department shall give possession of the site to the Contractor. If possession of a part site
is given, the Department will ensure that the part site so handed over is amenable to carryout
the work at site by the Contractor.
20.1 Access to the Site:

The Contractor shall provide the Engineer-in-Charge and any person authorised by the
Engineer-in-Charge, access to the site and to any place where work in connection with the
Contract is being carried out or is intended to be carried out.
21.1 Instructions:
The Contractor shall carry out all instructions of the Engineer-in-charge and comply with all
the applicable local laws where the Site is located.
22.1 Settlement of disputes:

If any dispute of difference of any kind whatsoever arises between the department and the
Contractor in connection with, or arising out of the Contract, whether during the progress of
the works or after their completion and whether before or after the termination, abandonment
or breach of the Contract, it shall in the first place, be referred to and settled by the Engineer-
in-charge who shall, within a period of thirty days after being requested by the Contractor to
do so, give written notice of his decision to the Contractor. Upon receipt of the written notice of
the decision of the Engineer-in-Charge the Contractor shall promptly proceed without delay to
comply with such notice of decision.
22.2 If the Engineer-in-Charge fails to give notice of his decision in writing within a period of
thirty days after being requested or if the Contractor is dissatisfied with the notice of the
decision of the Engineer-in-Charge, the Contractor may within thirty days after receiving the
notice of decision appeal to the Department who shall offer an opportunity to the contractor to
be heard and to offer evidence in support of his appeal, the Department shall give notice of his
decision within a period of thirty days after the Contractor has given the said evidence in
support of his appeal, subject to arbitration, as hereinafter provided. Such decision of the
Department in respect of every matter so referred shall be final and binding upon the
Contractor and shall forthwith be given effect to by the Contractor, who shall proceed with the
execution of the works with all due diligence whether he requires arbitration as hereinafter
provided, or not. If the Department has given written notice of his decision to the Contractor
and no claim to arbitration, has been communicated to him by the Contractor within a period of
thirty days from receipt of such notice the said decision shall remain final and binding upon the
Contractor. If the Department fail to give notice of his decision, as aforesaid within a period of
thirty days after being requested as aforesaid, or if the Contractor be dissatisfied with any
such decision, then and in any such case the contractor within thirty days after the expiration
of the first named period of thirty days as the case may be, require that the matter or matters
in dispute be referred to arbitration as detailed below:-
23.1 Settlement of Claims:

1. Any dispute arising out of this Agreement up to Rs.1,00,00,000/- has to be settled by way
of negotiation and conciliation between the TTD (Concerned Authority) and the Contractor. If
there is no cordial settlement between the parties, then the matter shall be referred to an In-
house Arbitration for settlement of several small claims as mentioned below in order to save
money and time of both parties:
(a): Claims up to the value of Rs.10,00,000/-

Superintending Engineer (of another circle working in TTD as decided by the Executive
Officer, TTD)
(b): Claims from Rs.10,00,001/- up to Rs.1,00,00,000/-

Chief Engineer (other than the person working in TTD and any other person working in
Government Department of AP) as decided by the Executive Officer, TTD.
The Sole Arbitrator appointed as above shall conduct the proceedings as per the
provisions of Arbitration and Conciliation Act 1996 and amendments thereon, from time to
time. The place of Arbitration is at Tirupati. The Arbitration proceedings shall be conducted in
English Language. The Arbitrator is entitled the fee as per the Fourth Schedule of Arbitration
and Conciliation Act, 1996 and amendments thereon, from time to time. Both parties shall
bear the fee of the Arbitrator and expenses for conducting Arbitration Proceedings equally.
The Arbitrator shall dispose off the proceedings strictly within the time as stipulated
in Arbitration and Conciliation Act, 1996 and amendments thereon, from time to time.
2: Claims above Rs.1,00,00,000/-
All the claims above Rs.1,00,00,000/- have to be settled by approaching the Civil Court
only by filing a civil suit, but not by way of Arbitration. The Arbitration clauses mentioned
under sub-clause 1(a) & (b) above, are nothing to do relating to the claims more than
Rs.1,00,00,000/-.
The Courts at Tirupati, Chittoor District, Andhra Pradesh shall alone have jurisdiction to
entertain any such suit arising under this Agreement.
23.2 JURISDICTION:
For the purpose of this agreement all the transactions shall be deemed to have taken place
within the state of ANDHRA PRADESH and the courts in Tirupati, Chittoor district, AP shall
have jurisdiction over the matters arising under or out of this agreement.
B. TIME FOR COMPLETION

24 Program:
24.1 The total period of completion is Three (03) Months with 5 years defect liability
period from the date of entering with agreement to proceed including rainy season. The work
should be programmed such as to achieve the mile-stones as in “Rate of progress statement”
enclosed, in clause 24.4
24.2 The attention of the tenderer is directed to the contract requirement at the time of
beginning of the work, the rate of progress and the dates for the whole work and its several
parts as per milestones. The following rate of progress and proportionate value of work done
from time to time as will be indicated by the Executive Engineer’s Certificate for the value of
work done and completion of mile-stones will be required. Date of commencement of their
programme will be the date for concluding agreement.
24.3 After signing the agreement, the contractor shall forthwith begin the work, shall
regularly and continuously proceed with them.
24.4 Rate of progress:

h. Work programme of achieving the milestones.
Sl.No. Period after date of handing over of % of work to be completed (Based on contract lump-sum
site. amount)
1 Up to end of 1st Month 35 %

2 Up to end of 2nd Month 70 %
3 Up to end of 3rd Month 100 %
ii) Site Schedule of programme of handing over site to the contractor. (in case of piece mail
handing over of site)
24.5 The contractor shall commence the works on site within the period specified under
condition 24.1 to 24.4 above after the receipt by him of a written order to this effect from the
Executive Engineer / Superintending Engineer and shall proceed with the same with due
expedition and without delay, except as may be expressly sanctioned or ordered by the
Executive Engineer / Superintending Engineer, or be wholly beyond the contractor’s control.
24.6 Save in so far as the contractor may prescribe, the extent of portions of the site of
which the contractor is to be given possession from time to time and the order in which such
portions shall be made available to him and, Subject to any requirement in the contract as to
the order in which the works shall be executed, the Executive Engineer / Superintending
Engineer will, with the Executive Engineer’s written order to commence the works, give to the
contractor possession of so much of the site as may be required to enable the contractor to
commence proceed with the execution of the works in accordance with the programme if any,
and otherwise in accordance with such reasonable proposals of the contractor as he shall by
written notice to the Executive Engineer / Superintending Engineer, make and will from time to
time as the works proceed, give to the contractor possession of such further portions of the
site as may be required to enable the contractor to proceed with the execution of the works
with due dispatch in accordance with the said programme or proposals as the case maybe ; if
the contractor suffers delay or incurs cost from failure on the part of the Executive Engineer /
Superintending Engineer to give possession in accordance with the terms of this clause, the
Competent authority shall grant an extension of time for the completion of works.
24.7 The contractor shall bear all costs and charges for special or temporary way leases
required by him in connection with access to the site. The contractor shall also provide at his
own cost any additional accommodation outside the site required by him for the purposes of
the work.
24.8 Subject to any requirement in the contract as to completion of any section of the
works before completion of the whole of the works shall be completed in accordance with
provisions of clauses in the Schedule within the time stated in the contract calculated from the
last day of the period named in the statement to the tender as that within which the works are
to be commenced or such extended time as may be allowed.
24.9 Delays and extension of time:

No claim for compensation on account of delays or hindrances to the work from any cause
whatever shall lie, except as hereafter defined. Reasonable extension of time will be allowed
by the Executive Engineer or by the officers competent to sanction the extension, for
unavoidable delays, such as may result from causes, which in the opinion of the Executive
Engineer, are undoubtedly beyond the control of the contractor. The Executive Engineer shall
assess the period of delay or hindrance caused by any written instructions issued by him, at
twenty five per cent in excess or the actual working period so lost.
In the event of the Executive Engineer failing to issue necessary instructions and thereby
causing delay and hindrance to the contractor, the latter shall have the right to claim an
assessment of such delay by the Superintending Engineer of the Circle whose decision will be
final and binding. The contractor shall lodge in writing with the Executive Engineer a
statement of claim for any delay or hindrance referred to above, within fourteen days from its
commencement, otherwise no extension of time will be allowed.
Whenever authorized alterations or additions made during the progress of the work are of
such a nature in the opinion of the Executive Engineer as to justify an extension of time in
consequence thereof, such extension will be granted in writing by the Executive Engineer or
other competent authority when ordering such alterations or additions.
25. Construction Programme:

25.1 The Contractor shall furnish within one month of the order of the work a programme
showing the sequence in which he proposed to carry out the work, monthly progress expected
to be achieved, also indicating date of procurement of materials plant and machinery. The
schedule should be such that it is practicable to achieve completion of the whole work within
the time limit fixed and in keeping with the Mile stone programme specified and shall obtain
the approval of the Engineer-in-charge. Further rate of the progress as in the program shall
be kept up to date. In case it is subsequently found necessary to alter this program, the
contractor shall submit sufficiently in advance the revised program incorporating necessary
modifications and get the same approved by the Engineer-in-charge. No revised program
shall be operative with out approval of Engineer-in-charge.
25.2 The Superintending Engineer shall have all times the right, without any way violating
this contract, or forming grounds for any claim, to alter the order of progress of the works or
any part thereof and the contractor shall after receiving such directions proceed in the order
directed. The contractor shall also report the progress to the Superintending Engineer within 7
days of the Executive Engineer’s direction to alter the order of progress of works.
25.3 The Contractor shall give written notice to the Engineer-in-Charge whenever planning
or progress of the works is likely to be delayed or disrupted unless any further drawings or
order including a direction, instruction or approval is issued by the Engineer-in-Charge within a
reasonable time. The notice shall include details of the drawing or order required and of why
and by when it is required and of any delay or disruption likely to be suffered if it is late.
26. Speed of Work:

26.1 The Contractor shall at all times maintain the progress of work to conform to the latest
operative progress schedule approved by the Engineer-in-Charge. The contractor should
furnish progress report indicating the programme and progress once in a month. The
Engineer-in-Charge may at any time in writing direct the contractor to slow down any part or
whole of the work for any reason (which shall not be questioned) whatsoever, and the
contractor shall comply with such orders of the Engineer-in-Charge. The compliance of such
orders shall not entitle the contractor to any claim of compensation. Such orders of the
Engineer-in-Charge for slowing down the work will however be duly taken into account while
granting extension of time if asked by the contractor for which no extra payment will be
entertained.
26.2 Delays in Commencement or progress or neglect of work and forfeiture of earnest

money, Security deposit and withheld amounts:
If, at any time, the Engineer-in-Charge shall be of the opinion that the Contractor is delaying
Commencement of the work or violating any of the provisions of the Contractor is neglecting
or delaying the progress of the work as defined by the tabular statement. “Rate of progress” in
the Articles of Agreement”, he shall so advise the Contractors in writing and at the same time
demand compliance in accordance with conditions of Tender notice. If the Contractor
neglects to comply with such demand within seven days after receipt of such notice, it shall
then or at any time there after, be lawful for the Engineer-in-Charge to take suitable action in
accordance with Clause.60 of APSS.
27 Suspension of works by the Contractor:

27.1 If the Contractor shall suspend the works, or sublet the work without sanction of the
Engineer-in-Charge, or in the opinion of the Engineer-in-Charge shall neglect or fail to proceed
with due diligence in the performance of his part of the Contract as laid down in the Schedule
rate of progress, or if he shall continue to default or repeat such default in the respects
mentioned in clause.27 of the APSS Engineer-in-Charge shall take action in accordance with
Clause 61 of APSS.
27.2 If the Contractor stops work for 28 days and the Stoppage has not been authorised by
the Engineer-in-Charge the Contract will be terminated under Clause 61 of APSS.
27.3 If the Contractor has delayed the completion of works the Contract will be Terminated
under Clause.61 of APSS.
28. Extension of the Intended Completion Date:

28.1 The Engineer-in-Charge shall extend or recommend for extension, in accordance with
the Government orders in force, the Intended Completion Date if a Variation is issued which
makes it impossible for Completion to be achieved by the Intended Completion Date.
28.2 The Engineer-in-Charge shall decide whether and by how much to extend the
Intended Completion Date within 21 days of the Contractor asking the Engineer for a decision
upon the effect of a Variation and submitting full supporting information. If the Contractor has
failed to give early warning of a delay or has failed to cooperate in dealing with a delay, the
delay by this failure shall not be considered in assessing the new Intended Completion Date.
29. Delays Ordered by the Engineer-in-Charge:

29.1 The Engineer-in-Charge may instruct the Contractor to delay the start or progress of
any activity within the Work.
30. Early Warning:

30.1 The contractor is to warn the Engineer-in-Charge at the earliest opportunity of specific
likely future events or circumstances that may adversely affect the Execution of Works.
30.2 The Contractor shall cooperate with the Engineer-in-Charge in making and
considering proposals for how the effect of such an event or circumstance can be avoided or
reduced by anyone involved in the work and in carrying out any resulting instruction of the
Engineer-in-Charge.
31. Management Meetings:

31.1 The Engineer-in-Charge may require the Contractor to attend a management
meeting. The business of a management meeting shall be to review the programme for
remaining work and to deal with matters raised in accordance with the early warning
procedure.
C. Quality Control
32. Identifying Defects:
32.1 The Engineer-in-Charge shall check the Contractor’s work and notify the Contractor of
any Defects that are found. Such checking shall not affect the Contractor’s responsibilities.
The Engineer-in-Charge may instruct the Contractor to verify the Defect and to uncover and
test any work that the Engineer considers may be a Defect.
33 Tests:
33.1 If the Engineer-in-Charge instructs the Contractor to carry out a test not specified in
the Specification to check whether any work has a Defect and the Contractor shall pay for the
test and any samples.
34. Correction of Defects:

34.1 The Engineer-in-Charge shall give notice to the Contractor of any Defects before the
end of the Defects Liability Period, which begins on Completion. The defects liability period
shall be extended for as long as defects remain to be corrected by the Contractor.
34.2 Every time notice of a Defect is given, the Contractor shall correct the notified defect
within the length of time specified by the Engineer-in-Charge’s notice.
35. Uncorrected Defects:

35.1 If the contractor has not corrected the defect within the time specified in the Engineer-
in-Charge’s notice, the Engineer-in-Charge will assess the cost of having the defect corrected
and the contractor will pay this amount.
35.2 The Engineer-in-Charge shall introduce O.K. cards and prescribed the formats there
of. O.K. cards shall relate to all major components of the work. The contractor / his
authorised representative shall be required to initiate and fill in and present the O.K. card to
the construction staff who would check the respective items and send to the quality control
staff for final check and clearance / O.K. Any defects pointed out by the construction
supervision staff or by the Quality Control staff shall promptly be attended to by the
contractors and the fact of doing so be duly recorded on the back of O.K. card.
35.3 The Engineer-in-Charge may also introduce checklists, which shall be kept in Bound
registers by the construction supervision staff. The contractor may be required to fill up these
lists in the first instance and shall be subsequently checked by the Construction / Quality
Control engineers.
36. Quality Control:

In addition to the normal inspection by the regular staff in-charge of the Construction of work,
the work will also be inspected by the Executive Engineer Quality control staff and any other
authorized external Agency if any sub-standard work or excess payments are noticed with
reference to measurement books etc., during inspection, action will be taken based on their
observations and these will be effected by the Engineer-in-Charge of the execution of the
work.
For all works costing more than Rs.2.00 Crores the Contractor shall submit quality plan and
also show proof of owning quality lab or tie-up with an established quality lab.
D. Cost Control
37. Bill of Quantities:
37.1 The Bill Quantities shall contain items for the construction work to be done by the
Contractor.
37.2 The Contractor is paid for the quantity of the work done at the estimate rate in the Bill
of Quantities for each item plus or minus Tender percentage.
38. Changes in the Quantities:

38.1 The contractor is bound to execute all supplemental works that are found essential,
incidental and inevitable during execution of main work.
38.2 The payment of rates for such supplemental items of work will be regulated as under;
38.3 Supplemental items directly deducible from similar items in the original agreement.
38.4 The rates shall be derived by adding to or subtracting from the agreement rate of such
similar item the cost of the difference in the quantity of materials, labour between the new
items and similar items in the agreement worked out with reference to the Standard Schedule
of Rates adopted in the sanctioned estimate with which the tenders are accepted plus or
minus over all tender percentage.
38.5
(a) Similar items but the rates of which cannot be directly deduced from the original
agreement.
(b) Purely new items which do not correspond to any item in the agreement.
The rates of all such items shall be Estimated Rates plus or minus overall Tender premium.
39. Extra Items:

39.1 Extra items of work shall not vitiate the contract. The contractor shall be bound to
execute extra items of work as directed by the Engineer-in-Charge. The rates for extra items
shall be worked out by the Executive Engineer as per the conditions of the Contract and the
same are binding on the Contractor.
39.2 The contractor shall before the 15th day of each month, submit in writing to the
Executive Engineer a statement of extra items if any that they have executed during the
preceding month failing which the contractor shall not be entitled to claim any.
40 Entrustment of additional items:

40.1 Where ever additional items not contingent on the main work and outside the scope of
original agreement are to be entrusted to the original contractor dispensing with bids and if the
value of such items exceeds the limits up to which the officer is empowered to entrust works
initially to contractor without calling for tenders, approval of next higher authority shall be
obtained. Entrustment of such items on nomination shall be at rates not exceeding the
estimated rates.
40.2 Entrustment of the additional items contingent on the main work will be authorized by
the officers up to the monetary limits up to which they themselves are competent to accept
items in the original agreement so long as the total amounts up to which they are competent to
accept in an original agreement rates for such items shall be worked out in accordance with
the procedure (I) For all items of work in excess of the quantities shown in the Bill of
Quantities of the Tenders, the rate payable for such items shall be estimate rates for the items
(+) or (-) over all tender percentage accepted by the competent authority.
40.3 Entrustment of either the additional or supplemental items shall be subject to the
provisions of the agreement entered into by a Competent Authority after the tender is
accepted. The Chief Engineer being the authority next higher to the Superintending Engineer,
who entered into the agreement approves the rate for the items / variation in quantity in the
current agreement. The items shall not be ordered by an officer on his own responsibility if
the revised estimate or deviation statement providing for the same requires the sanction of
higher authority.
Note: It may be noted that the term Estimate Rate used above means the rate in the
sanctioned estimate with which the tenders are accepted, or if no such rates is available in the
estimate, the rate derived will be with reference to the Standard Schedule of Rates adopted in
the sanctioned estimate with which tenders are accepted.
41. Cash flow forecasts:

41.1 When the program is updated, the contractor is to provide the Engineer-in-charge with
an updated cash flow forecast.
42 Payment Certificates:
42.1 The Contractor shall submit to the Engineer-in-charge monthly statements of the
estimated value of the work completed less the cumulative amount certified previously.
42.2 The Engineer-in-charge shall check the Contractor’s monthly statement within 14 days.
42.3 The value of work executed shall be determined by the Engineer-in-charge.
42.4 The value of work executed shall comprise the value of the quantities of the items in
the Bill of Quantities completed.
42.5 The Engineer-in-charge may exclude any item certified in a previous certificate or
reduce the proportion of any item previously certified in any certificate in the light of later
information.
43 Payments:
43.1 Payment for the work done by the contractor will be made for the finished work based
on the measurements recorded in measurement books by any officer of the department not
lower in rank than a Assistant Engineer and check measured by any officer not lower in rank
than a Deputy Executive Engineer. The measurement shall be recorded at various stages of
the work done and also after work is completed. The contractor shall be present at the time of
recording of each set of measurement and their check measurement and accept them then
and there so as to avoid disputes at a later stage. If the contractor is not available at the
workspot at the time of recording measurements or check measurements the particulars of
measurements shall be signed by the authorised agent of contractor based on which the
contractor shall accept the set of measurements without any further dispute. If for any reason
the contractor’s authorised agent is also not available at site when the department decides to
suspend the work recording of measurements in the absence of the contractor or his
authorised representative the department shall not entertain any claim from the contractor for
any loss incurred by him on this account. The Contractor shall however note that the
Department cannot indefinitely wait for recording the measurement due to the absence of the
Contractor and his authorised agent and check measure them even in the absence of the
contractor.
Deposits will be refunded within two weeks from the date of receipt of request from the
contractor, subject to fulfilling the agreement conditions.
43.2Payments and Certificates:

43.2.1 Payments shall be adjusted for recovery of advance payments, liquidated damages in
terms of tender conditions and security deposit for the due fulfillment of the contract. Payment
will be made to the Contractor under the certificate to be issued at reasonably frequent
intervals by the Engineer-in-Charge, and intermediate payment will be the sum equal to 92½%
of the value of work done as so certified and balance of 7½% will be withheld and retained as
security for the due fulfillment of the contractor under the certificate to be issued by the
Engineer-in-Charge.
43.2.2 On completion of the entire works the contractor will receive the final payment of all
the money due or payable to him under or by virtue of the contract except retention money of
a sum equal to 7½ percent of the total value of the work done. The EMD of 2.5% and withheld
amount of 7.5% from the final bill will be retained under deposits. Out of these retained
deposits, 25% security deposit will be released after expiry of 12 months from the date of
completion of work and on satisfactory attending of the defects during the said period, next
25% of the security deposit will be released after expiry of 36 months from the date of
completion of work and on satisfactory attending of the defects during the said period and
remaining 50% of the security deposit will be released after expiry of 60 months from the date
of completion of work and on satisfactory performance during defect liability period.
43.2.3 Defects liability period shall be taken as SIXTY (60) months from the date of
completion of the work for building as a whole, wherein all the defects shall be rectified by the
contractor at his own cost.
43.2.4 Defects of serious nature causing inconvenience such as leakage, reverse floor
slopes affecting the drainage (ponding of water), warping and opening of joints in doors and
window shutters etc., shall be undertaken by the contractor immediately on receipt of the
complaint but not exceeding one week time, failing which the defects will be got removed at
his risk and cost plus 25% as supervision and establishment charges.
43.2.5 All other defects notified to the contractor during the DLP shall be rectified to the
entire satisfaction of Engineer-in-Charge or item replaced as soon as possible but not later
than one month in any case. Failure to do so in a reasonable period the Engineer-in-Charge
shall get it done at his cost plus 25% as supervision and establishment charges after final
notice of 10 days. The decision of Engineer-in-Charge regarding a defect being of serious
nature or otherwise shall be final and binding.
43.2.6 The major scope of the defect liability will be as under. However, the DLP is not
limited to these items and all the works executed shall be maintained during DLP of 60
months.
S Description Defect Liability

l
.
N
o
.
1 Replacement/Repairs of Pillar boxes, Timer poles, poles, UG cables, LED street
. light fittings etc., and other items as per BOQ.
Note:
(i) The above list is illustrative and not exhaustive.
(ii)The rectification includes all electrical and all other works including internal and
external services without any exclusion.
43.2.7 In case of over payments or wrong payment if any made to the contractor due to
wrong interpretation of the provisions of the contract, APSS or Contract conditions etc., such
unauthorised payment will be deducted in the subsequent bills or final bill for the work or from
the bills under any other contracts with the T.T.Devasthanams / Government or at any time
thereafter from the deposits available with the Government / T.T. Devasthanams.
43.2.8 Any recovery or recoveries advised by the Government Department either state or
central, due to non-fulfillment of any contract entered into with them by the contractor shall be
recovered from any bill or deposits of the contractor.
43.2.9 No claim shall be entertained, if the same is not represented in writing to the
Engineer-in-Charge within 15 days of its occurrence.
43.2.10 The contractor is not eligible for any compensation for inevitable delay in handing
over the site or for any other reason. In such case, suitable extensions of time will be granted
after considering the merits of the case.
43.3 Intermediate Payments:

43.3.1 For intermediate Stage of work, only part rates as fixed by the Engineer-in-Charge will
be paid.
43.3.2 Part rates shall be worked out for the work done portion based on the actual
operations involved keeping in view the value of the balance work to be done, to avoid
unintended benefit to the Contractor in initial Stage.
43.3.3 Full rate shall be paid when the work is completed to the full profile as noted in the
drawings.
43.3.4 For earthwork in cutting, 10% of the quantity will be with-held for intermediate
payments and the same will be released after completing the work to the profiles as per
drawings and disposal of the spoil material at the specified places and handing over the
balance useful stone. For this purpose a length of 25 mts. will be taken as a Unit.
43.3.5 For earthwork, embankment formation work, 10% of the quantity will be withheld for
intermediate payments and the same will be released after completing the bund to the profiles
as per drawings including trimming of side slopes and all other works contingent to the bund
profile. For this purpose, 25 mts of length will be taken as a Unit.
43.3.6 For the structure works either with masonry or concrete where the height of structure
is more than three meters, the quantities executed in the lower level will be withheld at the rate
of one percent for every three meters height, if the balance height o the structure work is more
than three meters in being over the executed level and the same will be released only after the
entire work is completed as certified by the Engineer-in-Charge.
43.3.7 For C.M. & C.D. works and for lining works, spread over more than 2 Km. In length 5
percent of the concrete and Masonry quantities will be with held and the same will be released
after completion of all C.M. & C.D. works and lining for the entire length certified by the
Engineer-in-Charge.
43.3.8 Where payment is intended for aggregates by Bill of Quantities item based on stack
measurements, 10% of the quantity measured will be withheld. No payment or advance will
be made for unfixed materials when the rates are for finished work in site.
- DELETED
44. Interest on Money due to the Contractor:
44.1 No omission by the Executive Engineer or the sub-divisional officer to pay the amount
due upon certificates shall vitiate or make void the contract, nor shall the contractor be entitled
to interest upon any guarantee fund or payments in arrear, nor upon any balance which may,
on the final settlement of his accounts, found to be due to him.
45. Certificate of Completion of works:

45.1 Certificate of Completion of works:
45.1.1 When the whole of the work has been completed and has satisfactory passed any
final test that may be prescribed by the Contract, the Contractor may give a notice to that
effect to the Engineer-in-Charge accompanied by an undertaking to carryout any rectification
work during the period of maintenance, such notice and undertaking shall be in writing and
shall be deemed to be request by the Contractor for the Engineer-in-Charge to issue a
Certificate of completion in respect of the Works. The Engineer-in-Charge shall, within twenty
one days of the date of delivery of such notice either issue to the Contractor, a certificate of
completion stating the date on which, in his opinion, the works were completed in accordance
with the Contract or give instructions in writing to the Contractor specifying all the Works
which, in the Engineer-in-Charge'’ opinion, required to be done by the Contractor before the
issue of such Certificate. The Engineer-in-Charge shall also notify the Contractor of any
defects in the Works affecting completion that may appear after such instructions and before
completion of the Works specified there in. The Contractor shall be entitled to receive such
Certificate of the Completion within twenty one days of completion to the satisfaction of the
Engineer-in-Charge of the Works so specified and making good of any defects so notified.
45.1.2 Similarly, the Contractor may request and the Engineer-in-Charge shall issue a
Certificate of Completion in respect of:
45.1.3 Any section of the Permanent works in respect of which a separate time for
completion is provided in the Contract, and
Any substantial part of the Permanent Works which has been both completed to the
satisfaction of the Engineer-in-Charge and occupied or used by the Department.
45.1.4. If any part of the Permanent Works shall have been completed and shall have
satisfactorily passed any final test that may be prescribed by the Contract, the Engineer-in-
Charge may issue such certificate, and the Contractor shall be deemed to have undertaken to
complete any outstanding work in that part of the Works during the period of Maintenance.
46 Taxes included in the bid:

46.1 The percentage quoted by the contractor shall be deemed to be exclusive of GST
but including other Taxes on all materials that the contractor will have to purchase for
performance of this contract.
46.2 Any central or state sales and other taxes on completed item of works of this
contract (other than clause 102) as may be levied and paid by the contractor are to be borne
by himself /herself.
47. Retention:
47.1 The department shall retain from each payment due to the contractor @ the rate of
7.5% of bill amount until completion of the whole of the Works.
47.2 On completion of the entire works the contractor will receive the final payment of all
the money due or payable to him under or by virtue of the contract except retention money of
a sum equal to 7½ percent of the total value of the work done. The EMD of 2.5% and withheld
amount of 7.5% from the final bill will be retained under deposits. Out of these retained
deposits, 25% security deposit will be released after expiry of 12 months from the date of
completion of work and on satisfactory attending of the defects during the said period, next
25% of the security deposit will be released after expiry of 36 months from the date of
completion of work and on satisfactory attending of the defects during the said period and
remaining 50% of the security deposit will be released after expiry of 60 months from the date
of completion of work and on satisfactory performance during defect liability period.
47.3 On completion of work and after payment of final bill, the contractor can substitute
the Retention amounts with Bank guarantees of equivalent amounts at 25% of the amount
shall be with BG valid for 12 months from the date of completion of work, another 25% of the
amount shall be with BG valid for 36 months from the date of completion of work and
remaining 50% the amount shall be with BG valid for 60 months from the date of completion of
the work (from a Nationalized bank / Scheduled Bank in the prescribed proforma).
48.1 Liquidated Damages:

48.2 If for any reason, which does not entitle the contractor to an extension of item, the rate
of progress of works, or any section is at any time, in the opinion of the Superintending
Engineer too slow to ensure completion by the prescribed time or extended time for
completion Superintending Engineer shall so notify the contractor in writing and the contractor
shall there upon take such steps as are necessary and the Superintending Engineer may
approve to expedite progress so as to complete the works or such section by the prescribed
time or extended time. The contractor shall not be entitled to any additional payment for taking
such steps. If as a result of any notice given by the Superintending Engineer under this
clause the contractor shall seek the Superintending Engineers permission to do any work at
night or on Sundays, if locally recognized as days or rest, or their locally recognized
equivalent, such permission shall not be unreasonably refused.
48.3 If the contractor fails to complete whole of the works or any part thereof or section of
the works within the stipulated periods of individual mile stones (including any bonafide
extensions allowed by the competent authority without levying liquidated damages), the
Superintending Engineer may without prejudice to any other method of recovery will deduct
one tenth of one percent of contract value per calendar day or part of the day for the period of
delays subject to a maximum of 10% of the contract value not as a penalty from any monies in
his hands due or which may become due to the contractor. The payment or deductions of
such damages shall not relieve the contractor from his obligation to complete the works, or
from any other of his obligations and liabilities under the contract.
48.4 The maximum amount of liquidated damages for the whole of the works is ten percent
of final contract price.
49 Mobilization Advance:
No advance whatsoever either for mobilization of machinery and materials of the execution of
work will be given under any circumstances. The tender received with such conditions will be
summarily rejected.
50.0 Securities:
50.1 The Earnest Money Deposit and Additional Security (for discount tender percentage
beyond 25%) shall be provided to the Department not later than the date specified in the
Letter of Acceptance and shall be issued in an amount and form and by a bank acceptable to
the Department. The Earnest Money shall be valid until a date 28 days from the date of expiry
of Defects Liability Period and the additional security shall be valid until a date 28 days from
the date of issue of the certificate of completion.
51.1 Cost of Repairs:

51.2 Loss or damage to the Works or materials to the Works between the Start Date and
the end of the Defects Correction Periods shall be remedied by the Contractor at the
Contractor’s cost if the loss or damage arises from the Contractor’s acts or omissions.
E. Finishing the Contract
52.1 Completion:
52.2 The Contractor shall request the Engineer-in-Charge to issue a Certificate of
completion of the Works and the Engineer-in-Charge will do so upon deciding that the work is
completed.
53.1 Taking Over:

53.2 The Department shall takes over the Site and the Works within seven days of the
Engineer-in-Charge issuing a certificate of Completion.
54.1 Final Account:

54.2 The Contractor shall supply to the Engineer-in-Charge a detailed account of the total
amount that the Contractor considers payable under the Contract before the end of the
Defects Liability Period. The Engineer-in-Charge shall issue a Defects Liability Certificate and
certify any final payment that is due to the Contractor within56 days of receiving the
Contractor’s account if it is correct and complete. If it is not, the Engineer-in-Charge shall
issue within 56 days a schedule that states the scope of the corrections or additions that are
necessary. If the final Account is still unsatisfactory after it has been resubmitted, the
Engineer-in-Charge shall decide on the amount payable to the Contractor and issue a
payment certificate with in 56 days of receiving the Contractor’s revised account.
55.1 Termination:
55.2 The Department may terminate the Contract if the contractor causes a fundamental
breach of the Contract.
55.3 Fundamental breaches of Contract include, but shall not be limited to the following.
a) The Contractor stops work for 28 days when no stoppage of work is shown on the current
program and the stoppage has not been authorised by the Engineer-in-Charge.
b) The Contractor is made bankrupt or goes into liquidation other than for a reconstruction or
amalgamation.
c) The Engineer-in-Charge gives Notice that failure to correct a particular Defect is a

fundamental breach of Contract and the Contractor fails to correct it within a reasonable
period of time determined by the Engineer-in-Charge; and
d) The Contractor does not maintain a security which is required and
e) The Contractor has delayed the completion of works by the number of days for which the
maximum amount of liquidated damages can be paid as defined.
f) If the contractor, in the judgement of the Department has engaged in corrupt or fraudulent
practices in competing for or in the executing the contract.
For the purpose of this paragraph: “corrupt practice” means the offering, giving,
receiving or soliciting of any thing of value to influence the action of a public official in the
procurement process or in contract execution. “Fraudulent practice” means a
misrepresentation of facts in order to influence a procurement process or the execution of a
contract to the detriment o the Government and includes collusive practice among Tenderers
(prior to or after Tender submission) designed to establish Tender prices at artificial non-
competitive levels and to deprive the Government of the benefits of free and open competition.
55.4 Notwithstanding the above the Department may terminate the contract for
convenience.
55.5 If the Contract is terminated, the Contractor shall stop work immediately, make the
Site safe and secured leave the Site as soon as reasonably possible.
56.1 Payment upon Termination:

56.2 If the Contract is terminated because of a fundamental breach of Contract by the
Contractor, the Engineer-in-Charge shall issue a certificate for the value of the work done less
advance payments received upon the date of the issue of the certificate, less other recoveries
due in terms of the Contract, less taxes due to be deducted at source as per applicable law
and less the percentage to apply to the work not completed. Additional Liquidated Damages
shall not apply. If the total amount due to the Department exceeds any payment due to the
Contractor the difference shall be a debt payable to the Department.
57.1 Property:
57.2 All materials on the Site, Plant, Equipment, Temporary Works and Works are deemed
to be the property of the Department if the Contract is terminated because of Contractor’s
default.
58.1 Release from Performance:

58.2 If the Contract is frustrated by the outbreak of war or by any other event entirely
outside the control of either the Department or the Contractor the Engineer-in-Charge shall
certify that the contract has been frustrated. The Contractor shall make the site safe and stop
work as quickly as possible after receiving this certificate and shall be paid for all works
carried out before receiving it and for any work carried out after wards to which commitment
was made.
F. Special Conditions
59 Labour:
The contractor shall, make his own arrangements for the engagement of all staff and labour,
local or other, and for their payment, housing, feeding and transport.
Labour importation and amenities to labour and contractor’s staff shall be to the contractor’s
account. His quoted percentage shall include the expenditure towards importation of labour
amenities to labour and staff;
The contractor shall, if required by the Engineer-in-Charge, deliver to the Engineer-in-Charge

a written in detail, is such form and at such intervals as the Engineer-in-Charge may prescribe,
showing the staff and the numbers of the several classes of labour from time to time employed
by the contractor on the Site and such information respecting Contractor’s Equipment as the
Engineer-in-Charge may require.
60.1 Transportation of Labour:

I The contractor shall make his own arrangement for the daily transportation of the
labour and staff from labour camps colonies to the work spot and no labour or staff of the
contractor shall stay at the work spot. No extra payment will be made to the contractor for the
above transportation of the labour and his quoted percentage to the work shall include the
transportation charges of labour from colonies to work spot and back.
II The contractor will at all times duly observe the provisions of employment of children
Act XXVI of 1938 and any enactment or modification of the same and will not employ or permit
any person to do any work for the purpose under the provisions of this agreement in
contravention of said Act. The contractor here by agrees to indemnify the department from
and against all claims, penalties which may be suffered by the department or any person
employed by the department by any default on the part of the contractor in the observance
and performance of the provisions of the employment of children Act. XXVI of 1938 or any
enactment or modification of the same.
III As per Govt. memo No.721/Gr.(1)/81-35, dt:17.11.87. The contractor shall obtain the
insurance at his own cost to cover the risk on the works to labour engaged by him during
period of execution against fire and other usual risks and produce the same to the Executive
Engineer concerned before commencement of work.
61 Safety Measures:
1 The contractor shall take necessary precautions for safety of the workers and preserving
their health while working in such jobs, which require special protection and precautions. The
following are some of the measures listed but they are not exhaustive and contractor shall add
to and augment these precautions on his own initiative where necessary and shall comply with
directions issued by the Executive Engineer or on his behalf from time to time and at all times.
2 Providing protective foot wear to workers situations like mixing and placing of mortar or
concrete sand in quarries and places where the work is done under much wet conditions.
3 Providing protective head wear to workers at places like under ground excavations to
protect them against rock falls.
4 Providing masks to workers at granulates or at other locations where too much fine dust is
floating about and sprinkling water at frequent intervals by water hoses on all stone crushing
area and storage bins abate to dust.
5 Getting the workers in such jobs periodically examined for chest trouble due to too much
breathing in to fine dust.
6 Taking such normal precautions like fencing and lightening in excavation of trenches, not
allowing rolls and metal parts of useless timber spread around, making danger areas for
blasting providing whistles etc.
7 Supply work men with proper belts, ropes etc., when working in precarious slopes etc.
8 Avoiding named electrical wire etc., as they would electrocute the works.
9. Taking necessary steps towards training the workers concerned on the machinery before
they are allowed to handle them independently and taking all necessary precautions in around
the areas where machines hoists and similar units are working.
62 Fair Wage Clause:

1. The contractor shall pay not less than fair wages to laborers engaged by him on the work.
2. “Fair” wages means wages whether for time of piecework notified by the Government from
time in the area in which the work is situated.
3. The contractor shall not with-standing the revisions of any contract to the contrary cause to
be paid to the labour, in directly engaged on the work including any labour engaged by the
sub-contractor in connection with the said work, as if the labourers had been directly
employed by him.
4 In respect of labour directly or indirectly employed in the works for the purpose of the
contractors part of the agreement the contractor shall comply with the rules and regulations on
the maintenance of suitable records prescribed for this purpose from time to time by the
Government. He shall maintain his accounts and vouchers on the payment of wages to the
labourers to the satisfaction of the Executive Engineer.
5 The Executive Engineer shall have the right to call for such record as required to satisfy
himself on the payment of fair wages to the labourers and shall have the right to deduct from
the contract amount a suitable amount for making good the loss suffered by the worker or
workers by reason of the “fair wages” clause to the workers.
6 The contractor shall be primarily liable for all payments to be made and for the observance
of the regulations framed by the Govt. from time to time without prejudice to his right to claim
indemnity from his sub-contractors.
7 As per contract labour (Regulation and abolition) Act. 1970 the contractor has to produce
the license obtained from the licensing officers of the labour department along with the tender
or at the time of agreement.
8. Any violation of the conditions above shall be deemed to be a breach of his contract.
9 Equal wages are to be paid for both men and women if the nature of work is same and
similar.
10 The contractor shall arrange for the recruitment of skilled and unskilled labour local and
imported to the extent necessary to complete the work within the agreed period as directed by
the Executive Engineer in writing.
63 Indemnity Bond:
Name of work: ……………………..
I _____________________contractor Resident of ____________________ do hereby bind
myself to pay all the claims may come (a) under Workmen’s Compensation Act. 1933 with any
statutory modification there of and rules there under or otherwise for or in respect of any
damage or compensation payable in connection with any accident or injury sustained (b)
under Minimum wages Act 1948 (c) under payment of wages Act.1936 (d) under the
Contractor labour (Regulation and Abolition) Act. 1970 by workmen engaged for the
performance of the business relating to the above contract ie., Failing such payment of claims
of workmen engaged in the above work, I abide in accepting for the recovery of such claims,
effected from any of my assets with the departments.
64. Compliance with Labour Regulations:

During continuance of the contract, the contractor and his sub contractors shall abide at all
times by all existing labour enactments and rules made there under, regulations, notifications
and bye laws of the State or Central Government or local authority and any other labour law
(including rules), regulations, bye laws that may be passed or notifications that may be issued
under any labour law in future either by the State or the Central Government or the local
authority and also applicable labour regulations, health and sanitary arrangements for
workmen, insurance and other benefits. Salient features of some of the major labour laws that
are applicable to construction industry are given below. The contractor shall keep the
Department indemnified in case any action is taken against Department by the competent
authority on account of contravention of any of the provisions of any Act or rules made
thereunder, regulations or notifications including
amendments. If the Department is caused to pay or reimburse, such amounts as may be
necessary to cause or observe, or for non-observance of the provision stipulated in the
notifications/bye laws/Acts/Rules/regulations including amendments, if any, on the part of the
contractor, the Engineer-in-charge /Department shall have the right to deduct any money due
to the contractor including his amount of performance security. The Department/Engineer-in-
Charge shall also have right to recover from the contractor any sum required or estimated to
be required for making good the loss or damage suffered by the Department.
The employees of the Contractor and the Sub-contractor in no case shall be treated as the
Department of the Department at any point of time.
65 Salient features of some major labour laws applicable to establishment engaged

in buildings and other construction work:
(a) Workmen compensation Act 1923: The Act provides for compensation in
case if injury by accident arising out of and during the course of employment.
(B) Payment of Gratuity Act 1972: Gratuity is payable to an employee under the Act
on satisfaction of certain conditions on separation if any employee has completed 5
years service or more, or on death, the rate of 15 days wages for every completed
year of service. The Act is applicable to all establishments, employing 10 or more
employees.
(c) Employees P.F. and Miscellaneous provision Act 1952: The Act provides for
monthly contributions by the Department plus workers @ 10% or 8.33%. The benefits
payable under the Act are:
Pension or family pension on retirement or death, as the case may be.
Deposit linked insurance on the death in harness of the worker.
Payment of P.F. accumulation on retirement/death etc.,
(d) Maternity Benefit Act 1951: The Act provides for leave and some other
benefits to women employees in case of confinements or miscarriage etc.
(e) Contract Labour (Regulation & Abolition) Act 1970: The Act provides for
certain welfare measures to be provided by the contractor to contract labour and in
case the Contractor fails to provide, the same are required to be provided by the
Principal Department by Law. The Principal Department is required to take certificate
of Registration and the contractor is required to take license from the designated
Officer. The Act is applicable to the establishments or Contractor of Principal
Department if they employ 20 or more contract labour.
(f) Minimum wages Act 1948: The Department is supposed to pay not less
than the Minimum wages fixed by appropriate Government as per provisions of the
Act if the employment is a scheduled employment construction of Buildings, Roads,
Runways are scheduled employments.
(g) Payment of wages Act 1936: It lays down as to by what date the wages are to
be paid, when it will be paid and what deductions can be made form the wages of the
workers.
(h) Equal Remuneration Act 1979: The Act provides for payment of equal wages
for work of equal nature to Male or Female workers and for not making discrimination
against Female employee in the matters of transfers, training and promotions etc.
(i) Payment of Bonus Act 1965: The Act Is applicable to all establishments
employing 20 or more employees. The Act provides for payment of annual bonus
subject to a minimum of 8.33% of wages and maximum of 20% of wages to
employees drawing Rs. 3500/- per month or less. The bonus to be paid to employees
getting Rs.2500/- per months or above and upto Rs.3500/- per month shall be worked
out by taking wages as Rs.2500/- per monthly only. The Act does not apply to certain
establishments. The newly set-up establishments are exempted for five years in
certain circumstances. Some of the State Governments have reduced the
employment size from 20 to 10 for the purpose of applicability of this Act.
(j) Industrial Disputes Act 1947: The Act lays down the machinery and
procedure for resolution of Industrial disputes, in what situations a strike or lock- out
becomes illegal and what are the requirements for laying off or retrenching the
employees or closing down the establishment.
(k) Industrial Employment (Standing Orders) Act 1946: It is applicable to all
establishments employing 100 or more workmen (employment size reduced by some
of the State and Central Government to 50). The Act provides for laying down rules
governing the conditions of employment by the Department on matters provided in the
Act and get the same certified by the designated Authority.
(l) Trade Unions Act 1926: The Act lays down the procedure for registration of
trade unions of workmen and Departments. The Trade Unions registered under the
act have been given certain immunities from civil and criminal liabilities.
(m) Child Labour (Prohibition & Regulation) Act 1986: The Act prohibits
employment of children below 14 years of age in certain occupations and processes
and provides for regulation of employment of children in all other occupations and
processes, Employment Child Labour is prohibited in Building and Construction
Industry.
(n) Inter-State Migrant workmen’s (Regulation of Employment & Conditions of
service) Act 1979:The Act applicable to an establishment, which employs 5 or more
inter-state migrant workmen through an intermediary (who has recruited workmen in
one state for employment in the establishment situated in another State). The inter
State migrant workmen, in an establishment to which this Act becomes applicable, are
required to be provided certain facilities such as housing, medical aid, travelling
expenses from home upto the establishment and back, etc.
(o) The Building and Other Construction workers (regulation of Employment and
conditions of service) Act 1996 and the Cess Act of 1996: All the establishments who
carryon any building or other construction work and employs 10 or more workers are
covered under this Act. All such establishments are required to pay cess at the rate
not exceeding 2% of the cost of construction as may be modified by the Government.
The Department of the establishment is required to provide safety measures at the
Building or construction work and other welfare measures, such as Canteens, First-
aid facilities, Ambulance, Housing accommodations for workers near the work place
etc. The Department to whom the Act applies has to obtain a registration certificate
from the Registering Officer appointed by the Government.
(p) Factories Act 1948: The Act lays down the procedure for approval of plans
before setting up a factory, health and safety provisions, welfare provisions, working
hours, annual earned leave and rendering information regarding accidents or
dangerous occurrences to designated authorities. It is applicable to premises
employing 10 person or more with aid of power or 20 or more persons without the aid
of power engaged in manufacturing process.
66 Liabilities of the Contractor:

66.1 Accident Relief and workmen compensation:
The contractor should make all necessary arrangements for the safety of workmen on the
occurrence of the accident, which results in the injury or death of any of the workmen
employed by the contractor, the contractor shall within 24 hours of the happenings of the
accident and such accidents should intimate in writing to the concerned Asst. Engineer / Asst.
Executive Engineer of the Department the act of such accident. The contractor shall
indemnify Government against all loss or damage sustained by the Government resulting
directly or indirectly from his failure to give intimation in the manner aforesaid including the
penalties or fines if any payable by Govt. as a consequence of Govt. failure to give notice
under workmen’s compensation Act or otherwise conform to the provisions of the said Act. In
regard to such accident.
66.2 In the event of an accident in respect of which compensation may become payable
under the workmen’s compensation Act VIII 23 whether by the contractor, by the Government
it shall be lawful for the Executive Engineer to retain such sum of money which may in the
opinion of the Executive Engineer be sufficient to meet such liability. The opinion of the
Executive Engineer shall be final in regard to all matters arising under this clause.
66.3 The contractor shall at all times indemnify the Govt. of A.P. against all claims which
may be made under the workmen’s compensation act or any statutory modification thereafter
or rules thereunder or otherwise consequent of any damage or compensation payable in
consequent of any accident or injuries sustained or death of any workmen engaged in the
performance of the business relating to the contractor.
67 Contractor’s Staff, Representatives and Labour:

(a) The contractor shall, at all times, maintain on the works, staff of qualified
Engineers, and Supervisors of sufficient experience of similar other jobs to assure that
the quality of work turned out shall be as intended in the specifications. The
contractor shall also maintain at the works, a Work Manager or sufficient status,
experience and office and duly authorise him to deal with all aspects of the day-today
work. All communications to any commitments by the Work Manager shall be
considered as binding on the Contractor.
(b) The Contractor shall at all times submit details of skilled and unskilled labour
and equipment employed to the Engineer-in-Charge in prescribed proforma as he
may require to assess and ensure the proper progress of work.
For the work costing more than 10.00 Lakhs, if the contractor does not employ the
technical person agreed to on the work a fine of Rs. 25, 000/- will be imposed. If he
does not employ for 30 days, thereafter it becomes a fundamental breach of contract.
(c) For the work costing less than 10.00 Lakhs the Executive Engineer has to
imposed on suitable fine of Rs. 5,000/- for non-employment of technical person. If he
does not employ for 30 days, thereafter it becomes a fundamental breach of contract.
68. Accommodation and food:

The contractor should arrange accommodation he needs, at his own cost. The contractor
shall make his own arrangements for supply of food grains, fuel and other provision to his staff
and labourers including controlled commodities.
69. Relationship:
Contractor shall have to furnish information along with tender, about the relationship he is
having with any officer of the Department, Government of Andhra Pradesh of the rank
Assistant Engineer and above engaged in the work and any officer of the rank of Assistant
Secretary and above of the Department of Government of Andhra Pradesh.
70. Protection of adjoining premises:

The contractor shall protect adjoining sites against structural, decorative and other damages
that could be caused by the execution of these works and make good at his cost any such
damages.
71. Work during night or on Sundays and holidays:

The works can be allowed to be carried out during night, Sundays or authorised holidays in
order to enable him to meet the schedule targets and the work shall require almost round the
clock working keeping in view:
I) The provisions of relevant labour laws being adhered to:
II) Adequate lighting, supervision and safety measures are established to the satisfaction of
the Engineer-in-Charge and
III) The construction programme given by the Contractor and agreed upon by the Engineer-in-
Charge envisages such night working or working during Sundays or authorised holidays.
72 Plant and Equipment:

72.1 The contractor shall have sufficient plant, equipment and labour and shall work such
hours and shifts as may be necessary to maintain the progress on the work as per the
approval progress schedule. The working and shifts hours shall comply with the Govt.
Regulations in force.
72.2 It is to expressly and clearly understood that contractor shall make his own
arrangements to equip himself with all machinery and special tools and plant for the speedy
and proper execution of the work and the department does not undertake responsibility
towards their supply.
73 Conflict of interest:
Any bribe, commission, gift or advantage given, promised or offered by on behalf of contractor
or his partner, agent or servant or any one on his behalf to any officer, servant,
representatives, agents of Engineer-in-Charge, or any persons on their behalf, in relation to
the obtaining or to execution of this, or any other contract with Engineer-in-Charge shall in
addition to any criminal liability, which it may occur, subject to the cancellation of this or all
other contracts and also to payment of any loss or damage resulting from any such
cancellation. Engineer-in-Charge shall then be entitled to deduct the amount, so payable from
any money, otherwise due to the contractor under this or any other contract.
74 Contract documents and materials to be treated as confidential:

All documents, correspondences, decisions and orders, concerning the contract shall be
considered as confidential and/or restricted in nature by the contractor and he shall not divulge
or allow access to them by any unauthorised person.
75 General obligations of Contractor:

75.1 The contractor shall, subject to the provision of the contract and with due care and
diligence, execute and maintain the works in accordance with specifications and drawings.
75.2 The contractor shall promptly inform the Department and the Engineer-in-Charge of
any error, omission, fault and toerh defect in the design of or specifications for the works
which are discovered when reviewing the contract documents or in the process of execution of
the works.
75.3 If Contractor believes that a decision taken by the Engineer-in-Charge was either
outside the authority given to the Engineer-in-Charge by the Contract or that the decision was
wrongly taken, the decision shall be referred to the technical expert within 14 days of the
notification of the Engineer-in-Charge’s decisions.
75.4 Pending finalisation of disputes, the contractor shall proceed with execution of work
with all due diligence.
76. Security measures:

a) Security requirements for the work shall be in accordance with the Government’s
general requirements including provisions of this clause and the Contractor shall
conform to such requirements and shall be held responsible for the actions of all his
staff, employees and the staff and employees of his sub-contractors.
b) All contractors’ employees, representatives and sub-contractor’s employees shall

wear identifications badges provided by the contractor. Badges shall identify the
contractor, showing and employee’s number and shall be worn at all times while at the
site. Individual labour will not be required to wear identification badges.
c) All vehicles used by the contractor shall be clearly marked with contractor’s name.
d) The contractor shall be responsible for the security of the works for the duration of
the contract and shall provide and maintain continuously adequate security personnel to
fulfill these obligations. The requirements of security measures shall include, but not
limited to maintenance of order on the site, provision of all lighting, fencing, guard
flagmen and all other measures necessary for the protection of the works within the
colonies, camps and elsewhere on the site, all materials delivered to the site, all
persons employed in connection with the works continuously throughout working and
non working period including nights, Sundays and holidays for duration of the contract.
e) Other contractors working on the site concurrently with the contractor will provide
security for their own plant and materials. However, their security provisions shall in no
way relieve the contractor of his responsibilities in this respect
f) Separate payment will not be made for provision of security services.
77 Training of personnel:
The contractor, shall, if and as directed by the Engineer-in-Charge provide free of any charge
adequate facilities, for vocational training of Government Officers, students, Engineers,
supervisors, foremen, skilled workmen etc. not exceeding six in number at any one time on
the contractor’s work. Their salaries, allowances etc. will be borne by the Government and the
training schemes will be drawn up by the Engineer-in-Charge in consultation with the
contractor.
78 Payment upon termination:

If the contract is terminated because of a fundamental breach of contract by the contractor,
the Engineer-in-Charge shall issue a certificate for the value of the work done less advance
payment received upon the date of the issue of the certificate and less the percentage to apply
to the work not completed as indicated in the contract data. Additional liquidated damages
shall not apply. If the total amount due to the Department exceeds any payment due to the
contractor the difference shall be a debt payable to the Department. In case of default for
payment within 28 days from the date of issue of notice to the above effect, the contractor
shall be liable to pay interest at 12% per annum for the period of delay.
79 Drawing to be kept at site:

One copy of the drawings furnished to the contractor shall be kept by the contractor on the site
and the same shall at all reasonable time be available for inspection and use by the Engineer-
in-Charge and the Engineer-in-Charge’s representative and by any other persons authorised
by the Engineer-in-Charge in writing.
80 B.I.S. [I.S.I.] books and APSS to be kept at site:

A complete set of Indian Standard specification referred to in “Technical
Specifications” and A.P.S.S. shall be kept at site for reference.
81 Site Order Book:

An order book shall be kept at the site of the work. As far as possible, all orders
regarding the work are to be entered in this book. All entries shall be signed and dated by the
Department Officer in direct charge of the work and by the contractor or by his representative.
In important cases, the Executive Engineer or the Superintending Engineer will countersign
the entries, which have been made. The order book shall not be removed from the work,
except with the written permission of the Executive Engineer.
82 Variations by way of modification, omissions or additions:

For all modifications, omissions from or additions to the drawings and specifications,
the Executive Engineer will issue revised plans, or written instructions, or both and no
modification, omission or addition shall be made unless so authorized and directed by the
Executive Engineer in writing.

The Executive Engineer shall have the privilege of ordering modifications, omission or
additions at any time before the completion of the work and such orders shall not operate to
annual those portions of the specifications with which said changes do not conflict.
Engineer-in-Charge’s Decision:
It shall be accepted as in separable part of the contract that in matters regarding materials,
workmanship, removal of improper work, interpretation of the contract drawings and contract
specification, mode of the procedure and the carrying out o the work, the decision of the
Engineer-in-Charge, which shall be given in writing, shall be binding on the contractor.
83 Income tax:
a) During the currency of the contract deduction of income tax at 2.00% + Surcharge as
in force shall be made from the gross value of each bill of the contract, the contract value of
which is in excess of Rs.20,000/- for deduction of tax at rates lower than 2.00% procedure
stipulated under section 194-C(4) of Income Tax Act, 1961 shall be followed.
b) Income Tax clearance certificate should be furnished before the payment of final bill.
Other wise final payment will be with held.
c) The contractor’s staff, personnel and labour will be liable to pay personnel income
taxes in respect of their salaries and wages as are chargeable under the laws and regulations
for the time being in force, and the contractor shall perform such duties in regard to such
deductions thereof as may be imposed on him by such laws and regulations.
84 Goods & Services Tax :

i. The Contractor shall comply to the provisions of GST and
related charging mechanism procedures of GST Act.
ii. The Contractor has to mention the GST number of TTD in the
tax invoice to be issued to TTD. After that the same has to be
uploaded properly in the monthly/ Quarterly returns to be filed
by the Contractor. If the said amount is not recorded in the
GST 2A, TTD shall recover the amounts from the Contractor
from time to time.
iii. The rates included in BOQ (Schedule-A) are exclusive of
GST.
iv. The percentage quoted by the contractor is exclusive of
Goods and Service Tax (GST) but inclusive of all other taxes
on all materials that the contractor will have to purchase for
performance of this contract.
v. The contractor must have an active/ valid registration number
with the GST authorities within the State of Andhra Pradesh
and shall provide copy of registration to TTD and the
applicable GST shall be paid by the contractor to the
department concerned. If in case not already registered shall
undertake by affidavit to cause registered before Price bid
finalisation and letter of acceptance, for entering of contract
agreement and for any such default not only forfeiture of EMD,
but also be made liable for other civil and penal
consequences.
vi. The contractor will submit regular Invoice/ Bill fulfilling all
conditions of GST amended from time to time clearly
indicating GST registration number, GST classification, rate
and amount of GST and shall produce proof of deposit of GST
in respect of preceding bills received from TTD to the TTD so
as to claim the GST amount of the current bill from TTD. The
contractor shall produce documental evidence that GST
amount in respect of the preceding bills is remitted to the
Government and reflected in GST portal.

vii.Estimate is prepared based on SOR rates / quotation rates for
materials, labour charges, machinery hire charges etc., which
are basis prices only (excluding GST). In case of open tenders
where the bidders have to quote individual item rates by them,
the Bidders / Tenderers shall quote rates excluding GST only,
but including all other taxes.
viii.The GST liability is as per the rates of tax applicable (if the
contract is not exempted from GST concerned), as per of the
G.O.Ms.No.58, Finance (WR.I), Dept., dt:08-05-2018 and
other relevant GOs / Circulars / Clarifications / amendments
etc., being issued from time to time by the Government of
Andhra Pradesh/ GOI. The contractors are requested to
ascertain themselves regarding the applicability of GST and
the prevailing rates thereof, while tendering and more so while
making the payment of GST to the department. In this regard,
TTD will not undertake any responsibility whatsoever.
ix. The service provider / contractor is liable to pay GST which
can be deducted at source under Sec.51-GST Act, 2017 on
every respective bill payment made by client which includes all
components as per Sec.15(2)-GST Act, 2017.
x. It is the responsibility of the contractor to pay the applicable
GST in time and TTD will not be responsible in the regard.
Any delay in payment of GST by the tenderer for whatsoever
reasons, the responsibility lies on the tenderer and any
penalties, interest levied in this regard shall be borne by the
tenderer only and such penalties, interest will not be paid by
TTD. Even, if the contractor pays any extra amount towards
GST than the applicable GST, the payment from TTD will be
limited to the applicable GST only. There shall not be any
excess payments to the agency on account of GST and para
(8) of G.O.Ms.No. 58 Finance (WR.I) Dept., dt. 08-05-2018
specifies that the tax liability under GST shall be taken into
consideration at the time of invoicing and payment there on as
per the terms and conditions of the agreement between the
contractor and TTD. Department shall ensure that there shall
not be any excess payments to the contractor.
xi. The contractor shall pay the applicable GST and shall satisfy
TTD w.r.t GST claims.
xii.All the rules as per GST ACT2017 and its amendments and
all Notifications/ Government Orders (GOs) issued from time
to time by the Govt. of India (GOI) and Govt. of Andhra
Pradesh with regard to GST are applicable.
xiii.Revenue Department, Govt. of Andhra Pradesh, has issued
a notification on tax deductions at source of section 51 of GST
Act and the guidelines for deduction and deposits of TDS w.e.f
01-10-2018 vide GO MS No.482 Revenue (Commercial
Taxes-II) Dept. Date 24-09-2018. As per the present
guidelines GST at 2% (CGST at 1% and SGST at 1%) for
intrastate or 2% at IGST for interstate transactions will be
deducted on the taxable amount payable and necessary TDS
certificate will be issued. Any amendments in this regard
issued from time to time will apply.
xiv.As per clause 60 of APSS, the contractor is bound to
produce as required by the employer all invoices, receipts,
bills, accounts, vouchers, licenses, permissions etc.,
compliance of labour Laws applicable if any, safety and
standard certificates applicable if any and produce all the
above and also any exemption from GST for GST/CGST/IGST

availed by and or available to him for GST in so far as the
works contract concerned with TAN & respective Registration
particulars, seigniorage, NAC, Labour Cess etc., to even any
component or any part of the contract works in so far as the
works contract concerned.
xv.The deposits (EMD/FSD) of the work will be released only
when the contractor produces the documental evidence that
GST in respect of final bill received is remitted to the
Government and reflected in GST portal.
xvi.During course of contract, if the contractor claims any
exemptions towards GST, the same must be intimated to the
Employer and to the extent GST (Works Contract) will not be
paid separately.
(xvii) The TTD will pay GST (Works Contract) at the applicable rates from time to time and
as per the provisions of the agreements. The bidders are advised to quote their most
competitive rates duly considering the input tax credit due to payment of GST on
materials, machinery, services etc., for due fulfilment of the contract.
85 Supply of construction materials:

i) The contractor has to make his own arrangements for procurements, supply and use of
construction materials.
ii) All materials so procured should confirm to the relevant specifications indicated in the
bidding documents.
iii) The contractor shall follow all regulations of the Department/Government of India in
respect of import licenses etc., of the procurement of the materials is through imports and he
shall be responsible for the payment of applicable duties and taxes, port clearances, inland
transportation etc.
iv) The contractor shall make his own arrangements for adequate storage of the materials.
86 The tenderer should work out his percentage without reference being made to the
Public Works Department current schedule of rates or to the estimate rates.
87 Once the contractor buys the tender schedules, he will not be permitted to return the
tender schedules. He has to compulsorily submit his tender duly fulfilling all the tender
conditions after buying the tender schedules. If a contractor does not tender for the work,
suitable action will be initiated.
88 The TTD reserves the right to engage the services of the consultants during the
course of the work, for Engineering or Architectural services and the contractor is bound to
carryout such instructions as may be given by consultants from time to time.
89 Preliminary specifications of APSS shall apply to all agreements entered by the

contractor with an inseparable condition of the contract. The tenderer is expected to examine
closely the relevant specifications of the APSS and the special specifications of ISS before
submitting the unit tender rates.
90 All the items of work including materials and workmanship should be executed as per
relevant A.P.D.S.S. and I.S.I. code. If there are any variation between the above two
specifications, the decision of the Executive Engineer is final and binding on the contract.
91 Scaffolding and gangways will have to be arranged by the contractor at his own
whenever they are considered desirable or necessary by the Engineer-in-Charge of the work
to facilitate the work.
92 PATENT RIGHT: In the event of any claim or demand being made or action being
brought against the TTD for infringement of letter of patent, registration for infringement of
design or trade mark in respect of any machines, plant, work materials or things or method of
using or working of such machine, plant work materials or things belonging to the contractor
shall indemnify the owner against all costs and expenses arising from or incurred by reason of
any such claim provided that the owner shall notify the contractor immediately any claim is
made and that the contractor shall be at liberty, if he so desires with the assistance of the
owner if required but at the contractor’s expenses, to conduct all negotiations for the
settlement of same or any litigation that may arise there from and provided that no such
machine, plant, works materials or things shall be used by the owner for any purpose or any
manner other than that for which they have been supplied by the contractor and specified
under his contract.
93 ASSISTANCE IN PROCUREMENT OF PROPERTIES, PERMITS, LICENCES OR

OTHER FACILITIES ETC.
94 The Engineer in charge of work on request by the contractor will if in his opinion the
request is reasonable and is in the interest of the work and its progress assist the contractor in
procurement of necessary licenses for obtaining necessary plant machinery or materials not
available locally.
95 The TTD will also assist the contractor in securing priorities for deliveries transport
etc., where such are needed. The TTD will not however be responsible for the non-availability
of any of the above facilities or delay in this behalf and for claims either in cost or time on
account of such failures or delays and the contractor is not entitled for any claim against the
owner.
96 In case of contradiction between the clauses included in this specification and the clauses
of PS to APSS, the former will prevail over the latter and is binding on the tenderer .
FORMATS OF SECURITIES
PROFORMA
BANK GUARANTEE FOR EARNEST MONEY DEPOSIT
WHEREAS ……………………………………………………….. (Name of the Contractor) (here in after

called “the Tenderer”) has submitted his tender response to NIT No………………………. dated:
…………………… for the work “ …………………………………………………………
……………………………………..” (Name of work) (hereinafter called “the tender”).
KNOWN ALL MEN by these present that we ……………………………..………………………

………………………………….……………. (Name and Address of Bank) ……………………………….
(hereinafter called “the Bank” are bound unto ……………………… / (Executive Officer, TTDs,
Tirupati.) in the sum of * ……………………………………………………
…………………………………………………………………………….. for which payment will and truly to
be made to the said Department, the Bank binds itself, his successors and assigns by these presents.
SEALED with the Common Seal of the Bank this …………….. day of ……………..200………
THE CONDITIONS of this obligation are:-

1. If after Tender opening the tenderer withdraws or modifies his
Bid during the period of bid validity specified in the Form of
Tender.
2. If the Tenderer having been notified of the acceptance of his
bid by the Department during the period of validity.
3. fails or refuses to execute the Form of Agreement in
accordance with the Instructions to Tenderers, if required; or
4. fails or refuses to furnish the balance EMD and additional
performance Security in accordance with the instructions of
Tenderers.
We undertake to pay to the Department up to the above amount upon receipt of his first
written demand, without the Department having to substantiate his demand, provided
that in his demand the Department will note the amount claimed by him is due to him
owning to the occurrence of one or both of the two conditions, specifying the occurred
condition or conditions.
This Guarantee will remain in force up to and including the date** …………………… after
the dead line for submission of Tenders as such deadline is stated in the Instructions to
Tenders or as it may be extended by the Department, notice of which extension(s) to the
Bank is hereby waived. Any demand in respect of this Guarantee should reach the Bank
not later than the above date.
DATE………………. SIGNATURE OF THE BANK ……………………..
WITNESS……………….. SEAL………………………………………………..
--------------------------------------------------------------------------------------------------------
(Signature, Name and Address)
--------------------------------------------------------------------------------------------------------
* The Tenderer should insert the amount of the EMD in words and figures denominated
in Indian Rupee. This figure should be the same as shown in the NIT.
** 6 months for the deadline date for submission of Tender. Date should be inserted by
the Department before the Tender documents are issued.
PROFORMA
BANK GUARANTEE FOR BALANCE “E.M.D.”
______________________________________________ (name & address of Department)

______________________________________________
WHEREAS_____________________________________________________ ________
_______________________________________________________________________ _____
________________________(name and address of Contractor) (hereinafter called “the Contractor”)
has undertaken, in pursuance of Contract No. ________ dated: ____________ to execute the work of
_________________ [name of work];
AND WHEREAS it has been stipulated by you in the said Contract that the Contractor shall
furnish you with a Bank Guarantee by a Schedule bank for the sum specified therein as balance
EMD / EMD for compliance with his obligations in accordance with the Contract;
AND WHEREAS we have agreed to give the Contractor such a Bank Guarantee;
NOW THEREFORE we hereby affirm that we are the Guarantor and responsible to you, on
behalf of the Contractor, up to a total of _____________________ [amount of guarantee]
_________________________________ [in words], such sum being payable and we undertake to
pay you, upon your first written demand and without cavil or argument, any sum or sums within the
limits of ________________________ [amount of guarantee] as aforesaid without your needing to
prove or to show grounds or reasons for your demand for the sum specified therein.
We hereby waive the necessity of your demanding the said debt from the Contractor before
presenting us with the demand.
We further agree that no change or addition to or other modification of the terms of the
Contract or of the Works to be performed thereunder or of any of the contract documents which may
be made between you and the Contractor shall in any way release us from any liability under this
guarantee, and we hereby waive notice of any such change, addition or modification.
This guarantee shall be valid upto ……………………….. i.e., until 28 days from the date of
expiry of the Defects Liability period.
Signature & seal of the Guarantor_____________________

Name of Bank_____________________________________
Address__________________________________________
Date_____________________________________________
FORM OF SOLVENCY CERTIFICATES BY MANDAL REVENUE OFFICER

ANNEXURE – I (A).
I, ______________________________________ Mandal Revenue Officer, of

_________________________________________ do hereby certify, on being satisfied by the
Examination of Revenue and other records and local enquiries that ______________
________________________________ [here the name and address of the contractor should be
mentioned] is solvent to the extent of Rs._______________ [Rupees _______
__________________________________________________________________________].
Date :
Place: MANDAL REVENUE OFFICER
SEAL OF THE OFFICE
ANNEXURE – I (B).
FORM OF SOLVENCY CERTIFICATE BY BANKS
I, ______________________________________________ Managing Director / Manager /

General Manager / Agent of _________________________________________ Bank Limited do
hereby certify that a __________________________________________
_______________________ [here the Names and addresses of the contractor] to be solvent to the
extent of Rs.__________________ [Rupees __________________________
________________________________] as disclosed by the information and record which are
available with the aforesaid bank.
For the ___________________________ Bank

Date:
Place:Signature of Bank Manager
[Authorised to Sign]
BILL OF QUANTITIES
AND
PRICE BID
Name of work: Providing base structure for erection of temporary

lighting along with connecting cables & street lighting at Sri
Kodanda Rama swamy vari Kalyanavedika in Vontimitta, Kadapa
district.
BILL OF QUANTITIES
PREAMBLE
1. The Bill of Quantities shall be read in conjunction with the instructions to Tenderers,
General and Special conditions of Contract Technical Specifications and Drawings.
2 The quantities given in the Bill of Quantities are estimated and provisional and are
given to provide common basis for tendering. The quantities here given are those upon which
the lump sum tender cost of the work is based but they are subject to alterations, omissions,
deductions or additions as provided for in the conditions of this contract and do not necessarily
show the actual quantities of work to be done. The basis of payment will be actual quantities
of work ordered and carried out as measured by the Contractor and verified by the Engineer
and valued at the estimate rate quoted in the Bill of Quantities where applicable, and
otherwise at such rates and prices as the Engineer-in-Charge may fix within the terms of
Contract.
3 The estimate rates in the Bill of Quantities shall, except in so-far as it is otherwise
provided under the Contract include cost of all constructional material, labour, machinery,
transportation, erection, maintenance, profit, taxes and duties together with all general risks,
liabilities and obligations set out or implied in the Contract.
4 The plans enclosed with the tender are liable to be altered during execution of work as
per necessity of site conditions. The Tender percentage quoted by the tenderer shall hold
good for execution of work even with altered plans. -DELETED
5. The whole cost of complying with the provisions of the Contract shall be included in the
estimated rates for items provided in the Bill of Quantities and where no items are provided in
the Bill of Quantities, their cost shall be deemed to be distributed among the estimate rates
entered for the related items of work.
6. General directions and descriptions of work and materials are not necessarily repeated
nor summarised in the Bill of Quantities. References to the relevant sections of the Contract
documentation shall be made before entering estimate rate against each item in the Bill of
Quantities.
7. The method of measurements of completed work for payment shall be in accordance

with the relevant B.I.S. Codes & A. P. S. Specifications.
8. All items of work are to be executed as per the drawings / specifications supplied with
the contract documents.
If there is any contradiction between the drawings and the text of the specifications,
the later shall prevail.
9. The quoted tender percentage shall also include the work of any kind necessary for
the due and satisfactory construction, completion and maintenance of the works according to
the drawings and these specifications and further drawings and orders that may be issued by
the Engineer-in-Charge from time to time. The quoted tender percentage shall include
compliance by the Contractor with all the general conditions of contract, whether specifically
mentioned or not in the various clauses of these specifications, all materials, machinery, plant,
equipment, tools, fuel, water, strutting, timbering, transport, offices, stores, workshop staff,
labour and the provision of proper and sufficient protective works, diversions, temporary
fencing and lighting. It shall also include safety of workers, first aid equipments suitable
accommodation for the staff and workmen, with adequate sanitary arrangements, the effecting
and maintenance of all insurances, the payment of all wages, salaries, fees, royalties / Taxes,
duties or other charges arising out of the execution of works and the regular clearance of
rubbish, reinstatement and clearing-up of the site as may be required on completion of works
safety of the public and protection of the works and adjoining land. The work of Building in
quality control / assurance shall be deemed to be covered in the quoted percentage. -
DELETED
10. The Contractor shall ensure that, the quoted tender rate shall cover all stages of work
such as setting out, selection of materials, selection of construction methods, selection of
equipment and plant, deployment of personnel and supervisory staff, quality control testing
etc. The work quality assurance shall be deemed to be covered in the tender rate.
11. a) The special attention of the tenderer is drawn to the conditions in the tender notices
wherein reference has been made to the Andhra Pradesh Standard Specifications [APSS] and
the Standard preliminary specifications containing therein. These preliminary specifications
shall apply to the agreement to be entered into between the contractor and the Government of
Andhra Pradesh and shall form an in-separable condition of the contract along with the
estimate. All these documents taken together shall be deemed to form one contract and shall
be complimentary to another.
b) The tenderer shall examine, closely the A.P.S.S. / MORTH and also the standard
preliminary specifications contained therein and sign the Superintending Engineer’s office
copy of the APSS / MORTH and its addenda volume in token of such study before submitting
his overall tender percentage which shall be for finished work in-situ. He shall also carefully
study the drawings and additional specifications and all the documents, which form part of the
agreement to be entered into by the successful tenderer. The APSS / MORTH and other
documents connected with contract such as estimate plans, specifications, can be seen on all
working days in the office of the concerned Superintending Engineer’s of TTD, Tirupati.
12. The tenderers attention is directed to requirements for materials under the clause
‘materials and workmanship’ in the preliminary specifications of APSS. Materials conforming
to the Bureau of Indian Standards specifications, APSS etc., shall be used on the work and
the tenderers shall quote his overall tender percentage accordingly.
13. The tenderer has to do his own testing of materials and satisfy himself that they
conform to the specifications of respective I.S.I. Codes before tendering.
14. The contractor shall himself procure the required construction materials of approved
quality including the earth for formation of embankment and water from quarries / sources of
his choice. All such quarries / sources of materials required for the work shall be got approved
by the Engineer-in-Charge in writing well before their use of the work.
15. The contractor shall himself procure the steel, cement, Bitumen, Blasting materials,
sand, metal, soils, etc., and such other materials required for the work well in advance. The
contractor has to bear the cost of materials for conveyance. The department will not take any
responsibility for fluctuations in market in cost of the materials, transportation and for loss of
materials etc.- - DELETED
16. The tenderer’s particular attention is drawn to the sections and clauses in the A.P.
standard specification dealing with
a) Test, inspection and rejection of defective materials and work.
b) Carriage
c) Construction plant
d) Water and lighting
e) Cleaning up during the progress and for delivery.
f) Accidents - DELETED
g) Delays
h) Particulars of payments.
The contractor should closely peruse all the specification clauses, which govern the
tender rate he is tendering.
17. The defect liability period of contract is 60 (SIXTY) months and the quoted rate shall
include the cost associated in rectification of defects during this period, which include
materials, labour etc., complete
18. The estimate rates for items shown in the Schedule “A” include all construction
materials. No escalation in rates will be paid unless specified in the tender document. The
tenderer has to quote rate for individual items considering all the aspects of the tender to
complete the finished item of work.
19. If there is any contradiction between APSS / MORTH and B.I.S. specifications, listed
and detailed technical specifications, the latter shall prevail.
20. In case of a job for which specifications are not available with the Schedule or in
APSS / MORTH or B.I.S. code and are required to be prescribed, such work shall be carried
out in accordance with the written instructions of the Engineer-in-charge. - DELETED
21. The contractor should quote his tender rate keeping in view of the above aspects.
22. Additions and alternations by the Tenderer in the Schedule of quantities will disqualify
the tender.
23. In the case of discrepancies between the written description of the item in the
Schedule “A” and the detailed description in the specification of the same item, the latter shall
be adopted.
24. The Unit rates noted below are those governing payment of extras or deductions for
omissions according to the conditions or the contract as set-forth in the preliminary
specifications of the A.P. standard specifications and other conditions of specification of this
contract.
25. It is to be expressly understood that the measured work is to be taken according to

the actual quantities when in place and finished according to the drawings or as may be
ordered from time to time by the Executive Engineer and the cost calculated by measurement
or weight at their respective rates without any additional charge for any necessary or
contingent works connected works connected herewith. The Percentage Excess or less on
ECV quoted are for works in situ and complete in every respect. -
DELETED
26. For all items of work in excess of the quantities indicated the rates payable for such
excess quantities will be tendered rates i.e., estimate rates.
27.1 For all items of work, intermediate payment will be made provisionally as per relevant
clause. Full-accepted agreement rates will be paid only after all the items of works are
completed.
27.2 The contractor is bound to execute all supplemental works that are found essential
incidental and inevitable during execution of main work.
28. The payment of rates for supplement items of work will be regulated as under.
28.1 Supplemental items directly deductible from similar items in the original agreement.
The rates shall be derived by adding to or subtracting from the agreement rate of such similar
item the cost of the difference in the quantity of materials labour between the new items and
similar items in the agreement worked out with reference to the schedule of rates adopted in
the sanctioned estimate with which the tenders are compared.
28.2 a) Similar items but the rates of which cannot be directly deducted from the original
agreement.
b) Purely new items which do not correspond to any item in the agreement.
28.3 The rate of all such items shall be estimated rates.
29 Entrustment of Additional Items.

a. Where ever additional items not contingent on the main work and outside the scope of
original agreement are to be entrusted to the original contractor dispensing with tenders and if
the value of such items exceeds the limits upto which the officer is empowered to entrust
works initially to contractor without calling for tenders approval of next higher authority shall be
obtained. Entrustment of all such items on nomination shall be rates not exceeding the
estimate rates.
b. Entrustment of supplement items contingent on the main work will be authorised by the
officers upto the monetary limits upto which they themselves are competent to accept items in
the original agreement so long as the total amounts upto which they are competent to accept
in an original agreement rates for such items shall be worked in accordance with the
procedure prescribed in GO Ms.No.1493 PWD, dated:25.10.1971 and as amended in Govt.
Memo number 544 cod 72-22 dt:6.7.1973.
c. Entrustment of either the additional supplemental items shall be further subject to the
provisions under para 176(b) of APWD Code Viz., the items shall not be ordered by an officer
on his own responsibility if the revised estimate or deviation statement providing for the same
requires the sanction of higher authority.
Note: It may be noted that the term estimate rate used above means the rate in the
sanctioned estimate with which the tender’s compared or if no such rate is available in the
estimate the rate derived will be with reference to the schedule of rates adopted in the
sanctioned estimate with which tenders are compared.
SCHEDULE – A
SCHEDULE OF RATES AND APPROXIMATE QUANTITIES
The quantities here given are those up to which the lumpsum tender cost of the work is
based, but they are subject to alterations, omissions, deductions or additions as provided for
in the conditions of this contract and not so necessarily show the actual quantities of work to
be done. The Unit rates noted below are those governing, payment for extras of deductions or
omissions according to the conditions of the contract as set forth in the preliminary
specifications of the A.P. Detailed Standard Specifications and other conditions Specifications
of this contract.
It is to be expressly understood that the measured work is to be taken net (not with standing
any custom or practice to the contrary ) according to the actual quantities when in place and
finished according to the drawings or as may be ordered from time to time by the Chief
Engineer / Superintending Engineer / Executive Engineer concerned and the cost calculated
by measurement or weight, at the respective prices, without any additional charges for any
necessary or contingent works connected therewith. The rates quoted are for works is Site
and complete in every respect.
SCHEDULE
NIT. No. : 36 / SE(Elec) / TTD / TPT / 2022-23
Name of Work :: Providing base structure for erection of temporary lighting along with
connecting cables & street lighting at Sri Kodanda Rama swamy vari Kalyanavedika in
Vontimitta, Kadapa district.
Schedule down load start date : 24-11-2022 at 5.00 PM

Down load end date : 09-12-2022 at 1.00 PM
Last date for bid submission : 09-12-2022 at 3.00 PM
Tender opening date : 09-12-2022 at 3.01 PM
EMD at the time of Tender : Rs 80,500-00
EMD at the time of Agreement : 1.5% of ECV / TCV whichever is higher
Time for completion : 3 Months
Form of Agreement : L.S
S. Estimat Item Detailed Work Type Item Short APSS / Rate UOM Amount
N e Specification (upto 200 Description Morth Cl. (INR) (upto 50 (INR) (upto
o Quantit Description characters) (upto 100 Number (upto 2 Characte 2 Decimals)
y (only Characters (upto 200 Decimal rs)
Figures ) Characte s)
) rs)
1 264 Supply and Supply and Supply and NA 144.26 Kg 38084.64
fixing of fixing of fixing of
fabricated M.S fabricated fabricated
clamps made M.S clamps M.S clamps
out of various made out of made out of
various various
sizes of (25mm sizes sizes
x 3mm, 25mm
x 6mm etc.) MS
flat with
necessary
holes on either
side with
suitable MS
bolts and nuts
and painting 2
coats of enamel
black paint over
one coat of red
oxide suitable
for fixing of
PVC pipes,
Conduit pipes
etc., on
Trusses /
Channels etc.
including all
labour charges
etc., complete.
2 13 Supply, Supply, Supply, NA 138026. Each 1794344.50
Installation, Installation, Installation, 50
Testing and Testing and Testing and
Commissioning Commission Commission
ing of free ing of free
of free standing
standing standing
floor mounted floor floor
dust and mounted mounted
vermin proof dust and dust and
compartmentali vermin proof vermin proof
sed cubical
panel outdoor
type control
pillar box of
size 1250mm
(W) x
1200mm(H) x
400mm (D)
made out of
CRCA sheet,
required
hardware, duly
painted by two
coats of zinc /
red oxide
primer followed
by Powder
coated / epoxy /
PU painted with
phosphatisation
in grey or
required shade
after rinsing.
The box should
be mounted on
40x40x6mm
MS angle with
stand legs at 4
corners at a
length of
600mm each of
40x40x6mm
MS angle with
necessary
welding two
coats of enamel
black paint over
one coat of red-
oxide. The pillar
box should be
fixed in ground
with cement
concrete using
20mm(1:3:6).
0 0 The panel The panel The panel NA 0.00 NA 0.00
having PU / having PU / having PU /
Neoprene Neoprene Neoprene
rubber gasket rubber rubber
gasket of gasket of
of not less than
not less than not less than
3mm thickness, 3mm 3mm
separate thickness thickness
detachable,
gland plate M.S
base channel,
hinged door
with locking
arrangement
for equipment /
switchgear.
Thickness of
sheet shall not
be less than
1.6mm up to
600mm length /
width of any
compartment
and be of
2.0mm above
600mm. Load
bearing
structure shall
be of 2.0mm
thick sheet
supported by
base M.S
channel if
required. Side
walls and cable
alley
compartments
having bolted
type doors with
detachable
extension type
structure (only
outer area on
all sides shall
be measured
and panel to be
fabricated from
CPRI approved
fabricator).
0 0 a) Incoming: Incoming Incoming NA 0.00 NA 0.00
Supply and
fixing of 250A,
4 Pole Change
Over Switch On
Load as per
IS:13947 open
type with all
accessories
etc., complete.
Makes: L&T /
Havells /
Standard / Indo
Asian / C&S/
Socomec - 1
No.
0 0 b) Out Goings: Outgoing Outgoing NA 0.00 NA 0.00
Supply and
fixing of 125A,
3 Pole MCCB
Adjustable,
Confirms to IEC
60947-2 and IS
13947-Part
1&2 having
Breaking
Capacity 25KA
with thermal
magnetic
release. Make:
Legrand -
DPX3 /
Schneider-Acti9
/ Hager -
Novello+ /
Siemens /
Havells
STADx / L&T -
Newrag / Indo
Asian (Opti
Pro) with all
necessary
spreader links
& accessories
on suitable
support- 4 Nos.
0 0 c) Supply and Supply and Supply and NA 0.00 NA 0.00
fixing of fixing of fixing of
Electrolytic Electrolytic Electrolytic
grade copper grade grade
bus bar of size copper bus copper bus
bar bar
1" x 1/2"
vertical &
horizontal from
COS to busbar
chamber with
necessary SMC
/ DMC type
insulator, high
tensile nuts and
bolts spring
washers in
existing panel
including
bending, cutting
in required
shape and size
and colour
coding with
heat shrinkable
PVC sleeves -
4 Nos.
0 0 d) The MCCBs The MCCBs The MCCBs NA 0.00 NA 0.00
should connect should should
to the bus bars connect to connect to
with 2 run of 16 the bus bars the bus bars
Sq.mm FRLS
copper wire of
makes:
Finolex / RR
Kabel /
Havells /
Polycab / L&T /
KEI with
necessary
copper lugs
and crimping
etc., complete.
0 0 e) Supply and Supply and Supply and NA 0.00 NA 0.00
Fixing of Fixing of Fixing of
240/220 V, LED 240/220 V, 240/220 V,
(22.5 mm dia ) LED LED
Pilot lamp with
integral circuit,
terminal block,
including
connection etc.
as required
(R,Y,B) - 2 sets
0 0 f) An earthing An earthing An earthing NA 0.00 NA 0.00
terminal should terminal terminal
be provided to should should
the box.
3 47 Fabrication, Fabrication, Fabrication, NA 22683.2 Each 1066110.40
Transportation Transportati Transportati 0
and supply of on and on and
hot-dip supply of supply of
hot-dip hot-dip
galvanized
galvanized galvanized
Octogonal Pole Octogonal Octogonal
with BSEN -
10025 grade S Pole Pole

355 JO steel
plate for shaft,
IS 2062 for
base plate with
door opening
arrangement,
including the
supply of
suitable boards
with bakelite
sheet as per IS
specification
suitable to
withstand the
wind speed of
180 KMPH for
9 Mtrs height
Pole having
dimensions
Bottom 155
mm,. Top
70mm with
3mm thick,
base plate 260
x 260 x 16mm
and 4 Nos of
M24 x 750 long
'J' bolts along
with template.
0 0 Makes: Bajaj / Makes Makes NA 0.00 NA 0.00
Valmont /
Laasma /
Transrail /
Utkarsh/
Skipper
4 69 Foundation and Foundation Foundation NA 8888.95 Each 613337.55
erection and erection and erection
charges with charges with charges with
special T&P, for special T&P, special T&P,
/ for for
9.00Mtrs
9.00Mtrs / 9.00Mtrs /
10Mtrs long 10Mtrs long 10Mtrs long
Octagonal /
Conical pole
duly erecting on
base plate duly
providing 4 Nos
foundation bolts
with nuts with
providing of
0.60Mtr x
0.60Mtrs x 1.40
Mtr size M20 cc
work vibrated
concreting
mixing with
necessary steel
(15kgs)
reinforcement
and curing for 7
days as
directed by the
field engineers
during
execution
including
excavation of
Earth/BT all
labour charges
and cost and
conveyance of
materials
etc.complete.
5 5 Supply and Supply and Supply and NA 25218.0 Each 126090.20
fixing of fixing of fixing of 4
suitable out suitable out suitable out
door type door type door type
piller feeder piller feeder piller
feeder
box box
box made with
14 SWG CRCA
sheet after 7
tank process
including S & F
of Legrand /
Schnieder /
L&T make 40-
63A FP MCB, 9
Nos SP
MCB's,din
chanel, bus
bars, 6 Sqmm 3
core copper
cable for
internal wiring ,
contactor,
connectors and
provision for
energy meter
etc., complete
for finished item
of work
6 3 Design, Design, Design, NA 39287.1 Each 117861.36
Fabrication, Fabrication, Fabrication, 2
Supply, Supply, Supply,
Installation and Installation Installation
Commissioning and and
Commission Commission
of Outdoor type ing of ing of
timer box of Outdoor Outdoor
size 600mm(W) type timer type timer

x 600mm(H) x box box
300mm(D) and
made with
14SWG CRCA
sheet steel
cleaning with 7
tank process
and painting
with powder
coating. The
box shall be
made by
provide rubber
beeding, door
knobs etc., and
the front door
with double leaf
arrangement
with hinges and
locking
arrangement.
Suitable heat
Dissipation / Air
/ Ventilation
ducts with
inside wire
mesh shall be
provide to the
panel. The box
base shall be
mounted on
40x40x6mm
MS angle with
stand legs at 4
corners at a
length of
700mm each of
40x40x6mm
MS angle with
necessary
welding and the
angles shall be
painted with
two coats of
enamel black
paint over one
coat of red-
oxide. The
timer box legs
should be fixed
in ground of
size 400mm
depth by using
20mm HBG
metal in 1:3:6
ratio.
0 0 A 9 Ply - 18 A 9 Ply - 18 A 9 Ply - 18 NA 0.00 NA 0.00
mm thick mm thick mm thick
plywood sheet plywood plywood
of size 0.50 m x sheet of size sheet of size
0.50m to fix
inside the box
and the
following shall
be supply and
fix firmly on the
ply wood sheet
and giving
necessary
connections
between
Isolator -
contactor -
timer - out
going MCBs
etc., with
suitable size of
PVC copper
wires /bus links
and suitable
holes to be
made at bottom
sheet of the
box for
incoming /
outgoing cables
and install the
box at site as
directed during
execution by
the site
Engineer.
0 0 a) Incoming: Incoming Incoming NA 0.00 NA 0.00
63A FP Isolator
- 1 No.
0 0 b) Out Goings: Outgoing Outgoing NA 0.00 NA 0.00
40A 4-pole
MCB - 2 Nos.
0 0 c) LED LED LED NA 0.00 NA 0.00
indicator lamps Indicator Indicator
- 3 Nos.
0 0 d) ML-4 3 ML-4 3 pole ML-4 3 pole NA 0.00 NA 0.00
Pole, 415 V
Power
Contactor
(L&T) - 1 No.
0 0 e) Toggle / 6 Toggle / Toggle / NA 0.00 NA 0.00
6Amps 6Amps
Amps 2 Way
Switch and
giving
connections.- 1
No.
0 0 f) Digital Time Digital Time Digital Time NA 0.00 NA 0.00
Switch (L & T) switch switch
- 1 No.
0 0 g) An earthing An earthing An earthing NA 0.00 NA 0.00
terminal should terminal terminal
be provide to should should
the box.
0 0 h) Danger Danger Danger NA 0.00 NA 0.00
name plate -1 Name Name
No.
0 0 i) The ratings of The ratings The ratings NA 0.00 NA 0.00
switches, of switches of switches
feeder name,
bus bar / cable
chamber etc.,
shall be
indicate on
panel with
stickering
letters as
directed during
execution.
fixing of thermo fixing of fixing of
plastic pole box thermo thermo
of size plastic pole plastic pole
210x310x116m box box
m of Hensel /
Sintex make of
IP 65 protection
for single stem
street light
fitting and the
box should be
fixed at the site
as directed by
the site
engineer. A
6mm thick
hylum sheet
with 4 Nos of
brass bolts,
nuts and
washers should
be supply and
fix firmly inside
the box.
8 1645 Supply and Supply and Supply and NA 269.81 Rmt 443837.45
transportatio transportatio
transportation n of 16 n of 16
of 16 Sq.mm 4 Sq.mm 4 Sq.mm 4
core LT XLPE core core
insulated,
1100V grade
armoured
Aluminium UG
cable as per
specification
confirming to
IS:7098 (Part-
I) / 1554-1.
0 0 Grade-A: Makes Makes NA 0.00 NA 0.00
Make: Torent /
Universal /
Unistar /
Havells / KEI /
Gloster /
Polycab / RR
Kabel / Finolex.
transportation transportatio transportatio
of 25 Sq.mm 3 n of 25 n of 25
1/2 core LT Sq.mm 3 1/2 Sq.mm 3 1/2
core core
XLPE
insulated,
1100V grade
armoured
Aluminium UG
cable as per
specification
confirming to
IS:7098 (Part-
I) / 1554-1.
Make: Torent /
Universal /
Unistar /
Havells / KEI /
Gloster /
Polycab / RR
Kabel / Finolex.
0 transportation transportatio transportatio
core core
XLPE
insulated,
1100V grade
armoured
Aluminium UG
cable as per
specification
confirming to
IS:7098 (Part-
I) / 1554-1.
Make: Torent /
Universal /
Unistar /
Havells / KEI /
Gloster /
Polycab / RR
Kabel / Finolex.
core core
XLPE
insulated,
1100V grade
armoured
Aluminium UG
cable as per
specification
confirming to
IS:7098 (Part-
I) / 1554-1.
Make: Torent /
Universal /
Unistar /
Havells / KEI /
Gloster /
Polycab / RR
Kabel / Finolex.
of 120 Sq.mm 3 n of 120 n of 120
core core
XLPE
insulated,
1100V grade
armoured
Aluminium UG
cable as per
specification
confirming to
IS:7098 (Part-
I) / 1554-1.
Make: Torent /
Universal /
Unistar /
Havells / KEI /
Gloster /
Polycab / RR
Kabel / Finolex.
1 3085 Laying of U.G Laying of Laying of NA 25.79 Rmt 79562.15

3 cables upto 50 U.G cables U.G cables
Sq,mm and
back filling of
trench including
labour charges
etc., complete.
1 1080 Laying of U.G Laying of Laying of NA 52.91 Rmt 57142.80
4 cables size U.G cables U.G cables
from 70 Sq.mm
to 150 sq.mm
and back filling
of trench
including labour
charges
etc.,complete.
1 250 Supply, Laying Supply, Supply, NA 209.39 Rmt 52347.50
5 and Laying and Laying and
Transportation Transportati Transportati
of Outer dia on of Outer on of Outer
and dia dia
78mm
inner dia
63mm,
6Kg/Sq.Cm
(PE- 100
grade) double
walled
corrugated
HDPE duct
made as per
specification
BSEN - 500
86/IS 14930
Part-II.
0 0 Make : DURA Makes Makes NA 0.00 NA 0.00
LINE (Dura
Guard) or its
equivalent
make.
1 250 Supply, Laying Supply, Supply, NA 340.89 Rmt 85222.50
6 and Laying and Laying and
Transportation Transportati Transportati
of Outer dia on of Outer on of Outer
and dia dia
120mm
inner dia
103.5mm,
6Kg/Sq.Cm
(PE- 100
grade) double
walled
corrugated
HDPE duct
made as per
specification
BSEN - 500
86/IS 14930
Part-II.
0 0 Make : DURA Makes Makes NA 0.00 NA 0.00
LINE (Dura
Guard) or its
equivalent
make.
1 60 Supply of 50 Supply of 50 Supply of 50 NA 663.19 Rmt 39791.40
7 mm dia G.I. mm dia G.I. mm dia G.I.
pipes of "B" pipes pipes
class of ISI
marked and
approved by
the department
including cost
and
conveyance
and all other
incidental
charges etc.,
and properties
and weight as
per IS 1239
marked. Make:
Jindal /
Appollo / TATA.
1 30 Supply of 80 Supply of 80 Supply of 80 NA 1201.67 Rmt 36050.10
8 mm dia G.I. mm dia G.I. mm dia G.I.
pipes of "B" pipes pipes
class of ISI
marked and
approved by
the department
including cost
and
conveyance
and all other
incidental
charges etc.,
and properties
and weight as
per IS 1239
marked. Make:
Jindal /
Appollo / TATA.
9 fixing of LT fixing of LT fixing of LT
cable route cable route cable route
indicators indicators indicators
made out of
cast iron fixed
to one meter
long 1''x1''x1/4''
MS angle 4''
bent at one
end buried in
the ground and
the other end
fixed with G.I.
bolts and nuts
to the cable
route indicators
as directed
during
execution.
0 making end making end making end
termination with termination termination
heavy
Alluminium lugs
(pin / ring type)
up to 16 Sq.mm
cable as per IS
specification
duly crimped
with crimping
tool, PVC tape
etc., complete.
Make: Dowels /
Jainson /
Comet.
heavy
Alluminium lugs
(pin / ring type)
for 25 Sq.mm
cable as per IS
specification
duly crimped
with crimping
tool, PVC tape
etc., complete.
Make: Dowels /
Jainson /
Comet.
heavy
Alluminium lugs
(pin / ring type)
for 50 Sq.mm
cable as per IS
specification
duly crimped
with crimping
tool, PVC tape
etc., complete.
Make: Dowels /
Jainson /
Comet.
heavy
Alluminium lugs
(pin / ring type)
for 95 Sq.mm
cable as per IS
specification
duly crimped
with crimping
tool, PVC tape
etc., complete.
Make: Dowels /
Jainson /
Comet.
heavy
Alluminium lugs
(pin / ring type)
for 120 Sq.mm
cable as per IS
specification
duly crimped
with crimping
tool, PVC tape
etc., complete.
Make: Dowels /
Jainson /
Comet.
5 making one making one making one
end termination end end
with heavy duty termination termination
single
compression
brass gland as
per BS
6121:2005, IP
66 complete,
SIBG type,
heavy duty
Alluminium lugs
duly crimped
with crimping
tool, PVC tape
etc upto 16
Sq.mm with
brass washers
of Armoured
PVC insulated
& PVC
sheathed /
XLPE
aluminium
conductor cable
of 1100 volt
grade as
required of
size. Make:
Dowels / Comet
/ SMI
single
compression
brass gland as
per BS
6121:2005, IP
66 complete,
SIBG type,
heavy duty
Alluminium lugs
duly crimped
with crimping
tool, PVC tape
etc for 25
Sq.mm with
brass washers
of Armoured
PVC insulated
& PVC
sheathed /
XLPE
aluminium
conductor cable
of 1100 volt
grade as
required of
size. Make:
Dowels / Comet
/ SMI
single
compression
brass gland as
per BS
6121:2005, IP
66 complete,
SIBG type,
heavy duty
Alluminium lugs
duly crimped
with crimping
tool, PVC tape
etc for 50
Sq.mm with
brass washers
of Armoured
PVC insulated
& PVC
sheathed /
XLPE
aluminium
conductor cable
of 1100 volt
grade as
required of
size. Make:
Dowels / Comet
/ SMI
single
compression
brass gland as
per BS
6121:2005, IP
66 complete,
SIBG type,
heavy duty
Alluminium lugs
duly crimped
with crimping
tool, PVC tape
etc for 95
Sq.mm with
brass washers
of Armoured
PVC insulated
& PVC
sheathed /
XLPE
aluminium
conductor cable
of 1100 volt
grade as
required of
size. Make:
Dowels / Comet
/ SMI
single
compression
brass gland as
per BS
6121:2005, IP
66 complete,
SIBG type,
heavy duty
Alluminium lugs
duly crimped
with crimping
tool, PVC tape
etc for 120
Sq.mm with
brass washers
of Armoured
PVC insulated
& PVC
sheathed /
XLPE
aluminium
conductor cable
of 1100 volt
grade as
required of
size. Make:
Dowels / Comet
/ SMI
0 fabrication of fabrication fabrication
M.S angle of of M.S angle of M.S angle
size 35mm x
35mm x 6mm
having length of
0.23mtr with 2
coats of black
paint over one
coat of red
oxide and
grouting and
fixing the angle
firmly on the
wall duly cutting
the angle for 1"
length (for
gripping) at one
end to a depth
of 4" with neat
cement packing
and plastering.
2 Nos. of
slotted
(adjustable)
holes with
10mm dia are
to be provided
for fixing of
given UG
Cables with
suitable MS
clamps
(excluding the
cost of MS
clamps) etc.,
including all
labour charges
etc., complete.
3 12 Providing of Providing of Providing of NA 6371.26 Each 76455.12
1 Independent Independent Independent
Chemical Chemical Chemical
Earthing after Earthing Earthing
excavating an
earth pit of
size1.5 m X 0.9
m X 2.05
m(Top 1.50 m
X 0.90 m X
0.9m & bottom
1.20 m X 0.90
m X 1.15 m)
with the
following
specification:-
0 0 (a) The Earth The Earth The Earth NA 0.00 NA 0.00
Electrodes, Electrodes, Electrodes,
40mm dia, wall 40mm dia, 40mm dia,
thickness wall wall
thickness thickness
3.25mm,
terminal Size
25x8 mm,
terminal hole
dia 12 mm, 2
meter long,
galvanized,
including 1 bag
(25Kg to a bag)
of Earth Life
Compound, as
per IS 3043,
Base Metal: IS
marked
branded mild
steel pipes.
0 0 Makes: Makes Makes NA 0.00 NA 0.00
Potential /
Shake Hands /
Mars / Tirumala
/ Arshlok
earthing.
0 0 b) The Earth The Earth The Earth NA 0.00 NA 0.00
Electrode shall Electrode Electrode
be inserted into shall be shall be
the ground for inserted inserted
1.75 Mtrs.
Below the
inspection
chamber
bottom 300mm
all around this
Earth Electrode
shall be
covered with
25 Kgs. Of
Earth Life
Compound
0 0 (c) The The The NA 0.00 NA 0.00
excavated gap excavated excavated
shall be back gap shall be gap shall be
filled with back filled back filled
excavated
earth, and shall
be properly
consolidated
with water.
0 0 (d) The top The top 0.25 The top 0.25 NA 0.00 NA 0.00
0.25 m of Earth m of Earth m of Earth
pipe shall be pipe shall be pipe shall be
exposed into exposed exposed
inspection
chamber of
Hume pipe .
The all around
inspection
chamber shall
be provided
with 18" dia
hume pipe.
Earth
connections
shall be given
to the Earth
Electrodes with
bolts, nuts &
washers.
0 0 (e) A 65 mm A 65 mm dia A 65 mm dia NA 0.00 NA 0.00

dia PVC PVC conduit PVC conduit
conduit is to be is to be is to be
embedded embedded embedded
through hume
pipe at one
side, to lay the
Earth from the
Earth bus to the
Electrode
through the
PVC conduit
and after laying
the Earth, the
pit entry PVC
conduit is to be
sealed with
Bitumen
compound.
0 0 (f) Necessary Necessary Necessary NA 0.00 NA 0.00
Meggar testing Meggar Meggar
is to be done in testing is to testing is to
the presence of be done be done
the concerned
Engineers, and
the reading
should be as
per IE
standards.
3 300 Supply and run Supply and Supply and NA 116.47 Rmt 34941.00
2 of ' 8 ' SWG GI run of ' 8 ' run of ' 8 '
wire for earth SWG GI SWG GI
electrode to wire wire
required places
buried in
ground at not
less than 0.5
mtrs below the
ground level
after excavation
of trench and
filling with 6"
sand all around
the earth strip
and refilling
etc., and giving
necessary
connections
with 3/8" x 2"
GI, Bolts, Nuts
and Washers
wherever joints
has to be done,
the strip has to
be either
riveted (or)
bolted (or) gas
welding neatly
and all labour
charges etc.,
complete.
3 75 Cutting open Cutting Cutting NA 138.31 Sq. Mtr 10373.25
3 BT road open BT open BT
surface (As well road surface road surface
as Asphalt
concrete up to
75 mm thick)
including water
bound
macadam.
3 10 Cutting open Cutting open Cutting open NA 3502.98 Cu. Mtr 35029.80
4 cement cement cement
concrete road
3 80 Cement Cement Cement NA 5146.68 Cu. Mtr 411734.40
5 concrete using concrete concrete
20mm HBG using using
metal in CC 20mm HBG 20mm HBG
metal metal
1:3:6 laid in
Layers of not
more than
15cms thick
well compacted
including curing
cost and
conveyance of
materials etc.,
complete
3 10 Plastering in Plastering in Plastering in NA 249.03 Sq. Mtr 2490.30
6 CM (1:6) with CM (1:6) CM (1:6)
12mm thick with 12mm with 12mm
using river sand thick thick
including
curing,
conveyance of
materials etc.,
3 2350 Earth Work Earth Work Earth Work NA 270.81 Cu. Mtr 636403.50
7 excavation for excavation excavation
trench for for trench for trench
laying of U.G.
Cable in
ordinary Soils,
manual means
to the required
width and depth
and depositing
the same on
bank as
directed during
execution etc.,
complete .
3 0 Manufacture, Manufacture Manufacture NA 0.00 NA 0.00
8 supply and , supply and , supply and
delivery of delivery of delivery of
R.C.C. Socket R.C.C. R.C.C.
Socket Socket
and Spigot
pipes
conforming to
B.I.S 458/ 2003
(Rate per meter
of effective
length). NP-2
CLASS
a 50 350 mm dia 350 mm dia 350 mm dia NA 692.66 Rmt 34633.00
b 50 400 mm dia 400 mm dia 400 mm dia NA 762.95 Rmt 38147.50
9 fabrication of fabrication fabrication
M.S angle of of M.S angle of M.S angle
size 35mm x
35mm x 6mm
having lengh of
1.2 mtrs with 2
coats of black
paint over one
coat of red
oxide and
grouting and
fixing the angle
firmly on the
wall duly cutting
the angle for 1"
length (for
gripping). 2
Nos. of slotted
(adjustable)
holes with
10mm dia are
to be provided
for fixing of
given UG
Cables with
suitable MS
clamps
(excluding the
cost of MS
clamps) etc.,
including all
labour charges
etc., complete.
0 Fixing of 120W Fixing of Fixing of
LED Day light 120W LED 120W LED
Day light Day light
Integral IP 66
street light /
Road light
fitting with
presure die
cast aluminium
body suitable
for mounting to
the existing
poles with
50mm to 60mm
outer dia
bracket
(Adustable
stem pipe) with
suitable
capacity of
isolation
constant
current driver.
The luminaire
shall be with
lense for
distribution of
lighting and
suitable to
operate on
230V, 50Hz AC
supply as per
following
specification.
0 0 Make: Philips/ Makes Makes NA 0.00 NA 0.00
Osram/
Havells/
Crompton
greaves /GE/
Orkus
0 0 1. Output output output NA 0.00 NA 0.00
Lumens :
12000 Lumens
+/-5%
0 0 2. IP grade : IP IP grade IP grade NA 0.00 NA 0.00
66
0 0 3. Material for material for material for NA 0.00 NA 0.00
glass: glass glass
toughened
glass
0 0 4. Material for material for material for NA 0.00 NA 0.00
LED engine: LED LED
metal core
PCB
0 0 5. Working working working NA 0.00 NA 0.00
temperature: 0 temperature temperature
C to 50 degree
C
0 0 6. Working working working NA 0.00 NA 0.00
humidity : humidity humidity
10% to 90%
relative
humidity
0 0 7. Working life: working life working life NA 0.00 NA 0.00
> 50000
hours
0 0 8. LED make: LED Make LED Make NA 0.00 NA 0.00
NICHIA
(Japan) /
OSRAM
(German) /
PHILIPS
LIMITED /
CREE (USA)
/ BRIDGELUX
(USA) / SEOL /
LEDNIM
0 0 9. LED LED LED NA 0.00 NA 0.00
efficiency: efficiency efficiency
>135 lm/w
0 0 10. Luminaire Luminaire Luminaire NA 0.00 NA 0.00
efficacy: 100 efficacy efficacy
Lumens/W + / -
5%
0 0 11. Total total system total system NA 0.00 NA 0.00
system
wattage : 120W
+/-5%
0 0 12. CCT: CCT CCT NA 0.00 NA 0.00
5500K-6500K
0 0 13. CRI : >70 CRI CRI NA 0.00 NA 0.00
0 0 14. Input Input Input NA 0.00 NA 0.00
voltage and voltage voltage
frequency:230-
240V AC, 50
Hz +/- 3 Hz
0 0 15. Operating operating operating NA 0.00 NA 0.00
voltage: votage votage
120/140V-270V
AC universal
Electronic
Driver
0 0 16. Power power factor power factor NA 0.00 NA 0.00
factor: >0.95
0 0 17. Driver Driver Driver NA 0.00 NA 0.00
efficiency:
>90%
0 0 18. THD : < THD THD NA 0.00 NA 0.00
10%
0 0 19. IEC / IS IES/IS IES/IS NA 0.00 NA 0.00
Applicable for Applicable Applicable
Luminaries:
IEC 60529
0 0 Warranty: 5 Warranty Warranty NA 0.00 NA 0.00
years
4 32 Fabrication, Fabrication, Fabrication, NA 2294.51 Each 73424.32
1 Transportation Transportati Transportati
and supply of on and on and
1.50 Mtr Length supply supply
Single Arm
Bracket made
with MS
galvanized
40mm / 50mm
dia Pipe.
0 0 Make: Bajaj / makes makes NA 0.00 NA 0.00
Valmont /
Laasma /
Transrail /
Utkarsh/
Skipper
0 0 Note: (1) The The above The above NA 0.00 NA 0.00
above rates are rates are rates are
basic prices basic prices basic prices
excluding GST
and applicable
GST will be
reimbursed /
paid as per
actuals on
production of
proof
0 0 (2) The bidders The bidders The bidders NA 0.00 NA 0.00
are requested are are
to quote the requested to requested to
Tender quote the quote the
Tender Tender
percentage
percentage percentage
excluding GST. excluding excluding
GST GST
0 0 (3) Statutory Statutory Statutory NA 0.00 NA 0.00
deductions will deductions deductions
be made as per will be made will be made
norms, if as per as per
norms norms
applicable. Any
modalities
imposed on
GST by the
Government
from time to
time, the same
will be
implemented
0 0 (Rupees NA NA NA 0.00 Total :
Eighty Lakh 80,45,796.
forty five 86
thousand
seven
hundred
ninety six and
paise eighty
six only)
PRICE BID
NIT No. 36/SE(Elec)/TTD/TPT/2022-23
Name of work: Providing base structure for erection of temporary lighting along with
connecting cables & street lighting at Sri Kodanda Rama swamy vari Kalyanavedika
in Vontimitta, Kadapa district.
ESTIMATED CONTRACT VALUE (IN FIGURES & WORDS): Rs 80,45,796.86 (Rupees

Eighty Lakh forty five thousand seven hundred ninety six and paise
eighty six only)
I / We ………..……………………………………………... do hereby express my
willingness to execute the aforesaid work as per the conditions, standards,
specifications, rules, regulations, etc., stipulated in the tender documents.
a. at an overall tender percentage of ………….……..

EXCESS (in figures)
………………………………………….(in words) EXCESS
OVER the estimated value.
( OR )
b. at an overall tender percentage of …………….…..

LESS (in figures)…………………….……………………...
(in words) LESS THAN THE estimated value.
( OR )
c. at ESTIMATE VALUE.
BILL OF QUANTITIES
Part-II
Details of Maximum amount reimbursable to the Contractor.
1) Towards GST : Applicable as per clause 84 of

Conditions of contract
NOTE:
1. The rates mentioned in Bill of Quantities (Part-I) are

including taxes if any, overhead charges and contractors
profit but excluding GST.
2. As the overhead charges include engaging technical
persons by the contractor, no reimbursement for the
personnel will be made separately.
3. If the contractor fails to employ technical persons, the
work will be suspended or department will engage
technical persons and recover the cost thereof from the
contractor.
Submitted:
Draft tender document for the subject work is submitted for kind perusal and
approval.
A.Venkateswarlu
Superintending Engineer (Elec)

NIT 36 Tender Document

Uploaded by

Copyright:

Available Formats

NIT 36 Tender Document

Uploaded by

Document Information

Copyright

Available Formats

Share this document

Share or Embed Document

Sharing Options

Did you find this document useful?

Is this content inappropriate?

Copyright:

Available Formats

NIT 36 Tender Document

Uploaded by

Copyright:

Available Formats

File No.

TTD-67024(31)/89/2022-DEE I SEC - TTD

Tirumala Tirupati Devasthanams :: Tirupati

STANDARD BID DOCUMENT

NO DETAILS Page No.

1. NOTICE INVITING TENDER (NIT)

E. Tender Opening and Evaluation.

À Checklist to Accompany the Tender

B) Time for completion.

E) Finishing the Contract

TIRUMALA TIRUPATI DEVASTHANAMS

1. DEPARTMENT NAME : TIRUMALA TIRUPATI DEVASTHANAMS

5. ESTIMATE CONTRACT : Rs 80,45,796-86

11 TRANSACTION FEE : Rs 2,849/- (0.03% of ECV + 18% GST)

Procedure for bid submission:

1.Bids shall be submitted online on www.apeprocurement.gov.in platform

General Terms & Conditions

1. Transaction fee: All the participating bidders shall pay a

2. All the participating bidders have to pay the E.M.D. of (@1% of

Name of Account holder: EO, TTD - EMD, TTD EMD Account

other accounts & EMD paid through Demand draft will be

The EMD online payment is to be made through e-procurement

The EMD Account details furnished is for obtaining Bank

3. The successful bidder has to pay the balance EMD @ 1.5% of

If, the tenderer submits 1% EMD in the form of BG at the time of

4. Class of contractor Eligible: Class-I Electrical contractors in

5. Any other condition regarding receipt of tenders in conventional

6. The successful bidder shall pay 0.04% of estimate contract value

8. As per the G.O.Ms 174, I&CAD (PW-REFORMS) Department dated

9. Tenders with an excess of above 5% of the estimated contract

value shall not be allowed to quote in online and the tender

10. Taxes & Duties.

(ii) The bidders are requested to quote the Tender percentage

(iii) Statutory deductions will be made as per norms, if applicable.

11. Single tender received in 1st call is liable for cancellation.

I AM/WE ARE professionally qualified an my/our qualifications are given below:

Name of members of technical staff proposed to be employed Qualification.

TENDERERS / CONTRACTOR’S CERTIFICATE.

DECLARATION OF THE TENDERER.

Address of the Tenderer :

Phone No.: Fax No.:

Name of work: Providing base structure for erection of temporary lighting

List out Principal Components of the work : SITC of Pillar boxes = 13

a. ECV Put to tender : Rs 80,45,796.86

2.2 Firms Ineligible to Tender:

Note: Near relatives include

financial years in Statement-III

j) the proposed methodology and program of construction, backed with equipment

(i) Satisfactorily completed as a PRIME CONTRACTOR, similar works of

Sl.No. Description of work Quantity

C. Each bidder should further demonstrate:

(i) Availability (either owned or leased or to be procured against mobilisation advance of

S.No. Equipment Type and Characteristics Minimum No. required.

(D) Bid capacity.

Available Bid Capacity : 2AN-B > Rs 80,45,796.86

No relaxation will be given to any of the qualification criteria.

Note: a) Sub-contractor’s experience, in his name will be taken in to account in

• Furnished false / fabricated particulars in the forms, statements and /

b) A tenderer submitting a Tender which the tender accepting authority

4. One Tender per Tenderer: