WORK ORDER - Local Job Work Receipt
WORK ORDER - Local Job Work Receipt
WORK ORDER - Local Job Work Receipt
CONTRACTOR DETAILS
Contractor Code 23104 Contact Person Mr Babu
Contractor Name R BABU Contact Address :
S/o Ramu,No 1/58,,
PAN No. BRIPB9235Q Parameswaramangalam, Vepparcharry,
GST No. 631501,Tamil Nadu,India
Tel. No.
Uam No :
Fax No.
Email
ITEM DETAILS
Line Item Code/ Description Work Area HSN/SAC Code UOM Quantity Unit Rate GST(%) Tax Amount Amount - INR
1 INV/2310/SICL/ T4-Floor 10 995454 SFT 9785.00 3.00 0.00 0.00 29355.00
Labour charges for fixing Steel Grills of
required pattern and size for
Windows/Ventilators, etc.,
( Rate per floor area of 9785 sft for
window, ventilator and balcony areas.
10th Floor )
SUB TOTAL 29355.00
ORDER SUB TOTAL 29355.00
GRAND TOTAL 29355.00
Amount in Words Rupees Twenty Nine Thousand Three Hundred Fifty Five Only
For STARWORTH
INFRASTRUCTURE &
CONSTRUCTION LTD.
(Authorized Signatory)
Terms & Conditions:
1. Work shall be carried out as per instruction and direction of PIC/EIC. ALL AS PER APPROVED SAMPLES.
2. Above said vendor shall hereby be called as sub-contractor.
3. Rates are inclusive of all tools & machineries required to carry out the work.
4. Payment Terms:
a. After completion of fixing at site subject to Certification / recommendation from PIC in all respective RA bills, Same will be payable after
duly certification by PIC
c. Retention amount @ 5% of the gross bill value to be deducted from each RA bill and will be released after the completion of defect liability
period of 12 months. This will be forfeited incase the sub contractor stop the work before completion of the assigned work.
d. The estimated starting date of the work ..............2019 & estimated ending date of the work ......................2019:
e. The area for measurement will be the area within all outer vertical and harizontal frames
f. Hold fast / supporting MS sections to fix the frame in the wall, will not be measured for billing. However the cost of such materials will be
included in the cost analysis of the grill.
g. The rates shall include one coat of primer.
h. Any damages & mis match in right angles etc shall be rectified by the supplier at his own cost.
5. Taxes:
•GST will be payable extra as applicable.
•No tax Claims will be paid other than the appropriate tax charged in the Invoice.
•Applicable deduction towards Income tax will be made.
6. Based on the sub contractor performance, further Blocks will be awarded /considered. Employer has every right to decrease your scope of
works in case of non performance and the contractor shall have no claims on foreclosing of the whole contract or in part.
7. Water, Electricity & Labor accommodation etc. will be provided by SICL.
8. Representative of the contractor to visit the site personally till the completion of the work is awarded to monitor.
9. Running Account Bills are to be submitted before 5th of every month and payments shall be released against running bills as per actual
after the certification by the Project in charge to effect payment
10. No escalation in rate will be allowed till completion of the project. Work to be carried out as per detailed specification and method
mentioned any deviation from the same/delay in work cannot be entertained and it may lead to penalty.
11. Liquidity Damages: For any delay in execution of the project, liquidated damages shall be charges, sum equal to 0.5% of contract value
for each week or part of a week the contractor is in default. If delay is in any part of work, LD will be applicable for that portion of work only.
The total LD will be limited to 5 % of total CV. No idle charges will be paid for any reason whatsoever.
12. Time of Completion: TIME IS ESSENCE OF THIS CONTRACT, The entire scope of work shall be completed as per the schedule
intimated to the sub-contractor and amended from time to time. Contractor will have to adhere to all schedules as intimated at site.
13. The quantities mentioned in the BOQ are only approximate and may vary to any extent depending upon work and site condition, which
shall be duly complied by the sub-contractor. Tools required for the work shall be brought by you.
14. Workmen compensation policy/insurance for all workers is in the scope of Sub contractor, copy of the same is provided to SICL as and
when required.
a. If sub contractor fails to take the WC policy then SICL will insure all workmen on your behalf and recover the premium.
b. Sub-contractor shall indemnify SICL in respect of all claims, damages, compensation and expenses payable in consequence of any
accident or injury sustained by any workman in the employment of Sub-contractor.
15. ESI & PF for the workers is in the scope of Sub Contractor and the proof same to be produced along with the bill, if the contractor fails to
produce, SICL will deduct ESI & PF shall be applicable to all Workmen drawing Rs.15,000/month or less
• 1.75% of the gross wages paid to all the workmen is deducted from bills.
• 12% of the basic wages paid to all workmen is deducted from the bills.
16. Workmen compensation policy shall be applicable to all workmen drawing above Rs.15, 000/month recovery at Rs.25/month/head (or) at
the current rate.
17. Any damage to company's assets & wastage of materials will not be allowed to sub contractor and such expenses will be recovered from
bills/security deposit of the sub contractor.
18. You are liable to pay all wages due to your work men. Contractor has to declare the wages of his workmen in the approved format of
SICL. Proof of payment made should be submitted every month with signature of work men.
19. SAFETY:
a. The sub-contractor is responsible for the safety for his staff/labor.
b. Safety gadgets like helmets, safety belts, shoes, jackets etc., shall be arranged by SICL on returnable basis and the cost recovered from
the sub-contractor, if it is not returned in good reusable condition.
20. Medical/ Hospital expenses will not be paid for non-fatal injuries by SICL in case the workmen at the time of accident,
I) was under the influence of Alcohol/drugs.
II) Has violated any order/rule framed for securing the safety of workers.
III) Has willfully removed/ not wearing safety gadgets providing for safety.
21. SICL reserves the right to terminate the contract by giving 7 days clear notice in writing in the event of the performance of the sub-
contractor being found unsatisfactory. If the sub contractor leaves the work incomplete, company has every right to complete at their risk &
cost.
22.All disputes and differences of any kind whatsoever arising out or in connection with the contract shall be referred to MD of SICL for
settlement.
23. The court of Chennai alone shall have exclusive jurisdiction in all disputes arising out of this contract.
24. For further clarification/instruction you requested to attend all meetings arranged at site.
25. Contact Persons @ DAE Project: -
i. Mr. Nachiappan Balaji -+91 9880054719 ( VP )