Government of West Bengal Government of West Bengal Government of West Bengal Government of West Bengal
Government of West Bengal Government of West Bengal Government of West Bengal Government of West Bengal
Government of West Bengal Government of West Bengal Government of West Bengal Government of West Bengal
ELECTRONIC NOTICE INVITING TENDER REFERENCE NO. WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023 OF THE
SUPERINTENDING ENGINEER, NORTHERN CIRCLE, SOCIAL SECTOR, PUBLIC WORKS DIRECTORATE.
The Superintending Engineer, Northern Circle, Social Sector, Public Works Directorate, invites PERCENTAGE RATE
e -Tender for the work detailed in the table below. (Submission of Bid through online).
Rs. 5000.00/set
mentioned in Sl.
3,89,510.00
No.-3 page-2 of
(Online)
56
NB: -i) Intending Tenderers will not have to pay the cost of tender documents for the purpose of participating in e-tendering, but the
successful L1 (Lowest) Bidder will have to pay the cost of tender documents of 3 (three) sets @ price mentioned in the list of
scheme of NIT during purchase of tender documents for execution of agreement as per notification no. 199-CRC/ 2M-10/ 2012
dt. 21.12.2012 of the Secretary, P.W.D. CRC Branch, Govt. of West Bengal.
In case of any contractor (L1) expressed his / her willingness to have extra copy of the standard contract forms, only one spare
copy of standard contract form may on payment of prescribed price be supplied to a contractor or firm of contactors, eligible to
tender in a specific work on receipt of written requisition well in advance for the same.
ii) In case of the works in the open tenders an Earnest Money amounting to 2% ( two percent) of the Estimated Value of work for
which tender has been called for, shall have to be deposited either by Net Banking (any listed bank) or through RTGS/NEFT as per
Page 1 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
Memorandum No. 3975-F(Y), Dt.- 28.07.2016 of Secretary to the Government of West Bengal, Finance Department, by all
intending Tenderers.
As per G.O. No. 430(3)-W(C)/1M-208/15 Dt 31.08.2015 of the Joint Secretary, P.W. Department in concurrence of
G.O. No. 6417-F(Y) dated 26-08-2015 of the Principal Secretary to the Govt. of West Bengal, Finance Department,
Audit Branch three State Government enterprises viz. Mackintosh Burn Limited, Westinghouse Saxby Framer
Limited and Britannia Engineering Limited have been given exemption from deposit of earnest money for
participating in Government tenders, subject to the condition that they will furnish security deposit if selected in a
tender.
iii) Contractors intending to participate in the bid for works value exceeding Rs. 25.00 Crore may also furnish Earnest
Money Deposit (EMD) in the form of Bank guarantee issued by any Bank which is authorized to conduct
Government business in West Bengal by Reserve Bank of India as notified by State Government from time to time or
any other Bank which has been authorized by the State Government, as per notification no. 55-A/PW/O/2D-13/10
dated 29.01.2015.
iv) Enlistment of Contractors has been abolished as per Govt. order no. 71/SPW/2014 dated 03.03.2014 and G.O. no.
1177-F(Y) Dated:- 28.02.2014.
v) Introduction of penal measures to the Contractors who are participating in the tender process as well as selected for
executing Public works for their false declaration or forgery or falsification of records submitted or failure to execute
committed contract or for their failure to perform contractual obligations and there by resulting delay for execution of
faulty works as per Memorandum No. 547-(C)/1M-387/15 Dated: 16/11/2015 of The Joint Secretary to the
Government of West Bengal, PWD. Details guidelines are annexed with Special Terms & Conditions as a part of.
1. In the event of e-Filling, intending bidder may download the tender document from the website:
https://wbtenders.gov.in directly with the help of Digital Signature Certificate & earnest money may be
submitted either by Net Banking (any listed bank) through ICICI Bank Payment Gateway or through
RTGS/NEFT in favour of the concerned Executive Engineer, Social Sector, P.W. Directorate (Details of
which has been narrated in “Instruction to Bidders) .
Tender document may be downloaded from website & submission of Technical Bid/Financial Bid as per Tender
time schedule stated in Sl. No. 12 (Date & Time Schedule).
The documents submitted by the bidders should be indexed and also should be according to his /
their Firm name.
2. Earnest Money: The amount of Earnest Money is to be submitted online .At the time of uploading the tender
/ quotation, the intending tenderer / quotationer should select the tender to bid and initiate payment of pre-
defined EMD for that tender by selecting from either of the following payment modes:
i) Net banking (any of the banks listed in the ICICI Bank Payment gateway) in case of payment through ICICI
Bank Payment Gateway.
ii) RTGS/NEFT in case of offline payment through bank account in any Bank.
with his / her tender / quotation as per Memorandum No. 3975-F(Y) dated: - 28.07.2016 of Secretary to the
Government of West Bengal, Finance Department. The L1 bidder shall make the Formal Agreement after
getting the Letter of Acceptance (LOA) issued by the Tender Inviting Authority. Failure to make the Formal
Agreement within the time period as prescribed in the Letter of Acceptance (LOA) for the purpose, may be
construed as an attempt to disturb the tendering process and will be dealt with accordingly in a legal manner as
deemed fit including blacklisting the bidder.
i) As per order no. 04-A/PW/O/10C-02/14 Dated:- 18.03.2015 of the Principal Secretary, PWD,
(Accounts Branch), Government of West Bengal, Credential certificate issued by the Executive
Engineer or equivalent or competent authority of a State / Central Government., State / Central
Government undertaking, Statutory / Autonomous bodies constituted under the Central / State statute,
on the executed value of completed / running work of similar nature of work with allied works like
Sanitary & Plumbing, Electrical works etc. will be taken as credential as follows:
Page 2 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
ii) Intending tenderers should produce credentials of 2(two) similar nature of completed work, each of
the minimum value of 30% of the estimated amount put to tender during last 5(five) years prior to the
date of issue of the tender notice; or,
iii) Intending tenderers should produce credentials of one single running work of similar nature which
has been completed to the extent of 80% or more and value of which is not less than the desired value
at (i) above;
In case of running works, only those tenderers who will submit the Certificate of satisfactory running
work from the concerned Executive Engineer, or equivalent competent authority will be eligible for
the tender. In the required certificate it should be clearly stated that the work is in progress
satisfactorily and also that no penal action has been initiated against the executed agency, i.e., the
tenderer.
The credential should be supported by Work Order, Price Schedule or BOQ of Work and
Completion Certificate mentioning the Date of Commencement and Date of Completion as per
Work Order Actual Date of Completion issued by the competent authority not below the rank of
Executive Engineer in their office letter pad containing proper Office Address, Phone/Fax no.
and email ID. The Completion Certificate should indicate the value of the work (equal to booked
expenditure) [Non Statutory Documents].
N.B. Estimated amount put to Tender, Tendered Amount, Actual date of completion of the Project & detail
Address for communication must be indicated in the Credential Certificate.
ii) The prospective bidders will have in their full time engagement experienced technical personnel, the
minimum being one Civil Engineering Degree holder and one Civil Engineering Diploma holder
(Authenticated documents in respect of qualification and documents of appointment / engagement into
the firm will have to be furnished for Technical-Evaluation). [Non Statutory Documents]
iii) PAN Card, Professional Tax deposit Challan for the year 2022-2023, 15-digit Goods and Services
Taxpayer Identification Number (GSTIN) under GST Act 2017, Income Tax return for the last 5 years
etc. are to be accompanied with the Technical Bid document. [Non Statutory Documents]
iv) The prospective bidders or any of their constituent partner(s) should not have abandoned more than
Page 3 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
one work. Not more than one of their contracts should have been rescinded during the last 3 (three)
years from the date of publishing of this NIT. Such abandonment or rescission will be considered as
disqualification towards eligibility (a declaration in this respect through Affidavit will have to be
furnished by the prospective bidders without which the technical bid will be treated as non-
responsive. Neither prospective bidder nor any of constituent partner(s) should have been debarred to
participate in tender(s) by the P.W. & P.W. (Roads) Department during the last 5 (five) years prior to
the date of this NIT. Such debarment will be considered as disqualification towards eligibility. (A
declaration in this respect has to be furnished by the prospective bidders as per prescribed format
without which the Technical Bid shall be treated non-responsive).
v) The Bidder’s Net Worth for the last year calculated on the basis of capital, profit and free reserve
available to the firm should be positive.
vi) The available Bid Capacity (to be calculated on the basis of prescribed format) of the prospective
applicant at the expected time of bidding should be more than the Estimated amount put to tender.
vii) In case of Proprietorship and Partnership Firms and Company the Tax Audited Report in 3CD/3CB
Form supported with Income Tax return are to be furnished along with balance sheet and profit and
loss account and all schedules forming the part of Balance Sheet and Profit & Loss Account. Tax
Audited report, Balance Sheet and Profit & Loss Account including all schedules forming the part of
Balance Sheet and Profit & Loss Account should be in favour of applicant. [Non Statutory
Documents]
viii) The prospective bidders should own or arrange through lease hold agreement (as the case may be) the
required plant and machineries of prescribed specifications as shown and mentioned in format
[Section- B, Form- IV]. For both cases conclusive proof of ownership [such as Tax invoice, Way Bill,
Delivery Challan, incorporation in the Balance Sheet as fixed asset etc. during the last 3(three) years]
for each plant and machinery in working condition will have to be submitted.
An affidavit of appropriate value duly notarized should be submitted mentioning
Present location of installation of the said main Plant and machinery , as mentioned, in specified
format, should also be enclosed. If the machineries is already engaged in the other works, then name
of client along with his contact number and Email address should be furnished in the declaration by
the intended tenderer duly countersigned by the client, with tentative date of release of such Plant and
Machineries mentioning present location (working place) where the same are presently engaged. If
necessary, authority/ tender evaluation committee may inspect Plant and Machineries physically or
call for the original documents as proof of Ownership in favour of owner / lessor of the same. Plant &
Machineries should be owned or arranged through lease hold agreement (wherever mentioned) by the
Applicant. Scanned Copy of necessary lease deed should also be submitted. [Non Statutory
Documents]
ix) Registered Unemployed Engineers’ Co-operative Societies/ Unemployed Labour Co.- Op. Societies
are required to furnish valid Bye Law, Current Audit Report(i.e. 2020-2021), Certificate of
Registration and professional tax deposit challan for the Financial Year 2022-2023, PAN Card, GST
Registration Certificate with latest return along with other relevant supporting papers. [Non Statutory
Documents]
x) Joint Ventures will not be allowed for works upto 25.00 crores. For work more than 25.00 crores in
case of a joint venture, Lead Member of such joint venture will be required to meet 60% of required
Bid Capacity and each of the Joint Venture members will be required to meet at least 30% of
requirement of BID Capacity. Bid Capacity of all the members in total should be at least 100% of
required Bid Capacity.
xi) The Bidder must have valid Electrical Contractors License with Electrical Supervisors having
certificate of competency from Directorate of Electricity, Govt. of W.B. / competent authority
of other Govt. as applicable or equivalent National Supervisors’ Certificate of Competency. (Self-
attested scan copy of documents of appointment / engagement regarding Electrical Supervisor are
required to be submitted as Non statutory Documents)
xii) A prospective bidder shall be allowed to participate in the particular Job either in the capacity of
individual or as a partner of a firm. If found to have applied severally for a single job, all his
applications will be rejected for that job, without assigning any reason thereof.
Page 4 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
xiii) A prospective bidder (including his participation in partnership) will be allowed to participate in more
than one work provided the bid capacity permits and the bidder is capable to arrange and deploy
separate set of required machineries for multiple works and complete the work in specified time.
xiv) A partnership firm will have to furnish the registered partnership deed and a company will have to
furnish the Article of Association and Memorandum. [Non Statutory Documents]
Where an individual person holds a digital certificate in his/her own name duly issued to him / her by
the company or the firm of which he / she happens to be a director or partner, such individual person,
either belonging to an appropriate cadre officer of the company or an authorized partner of a firm,
having a registered power of attorney empowered by the Board or by the firm, shall invariably upload
a copy of registered power of attorney showing clear authorization in his / her favour, to upload such
tender. The power of attorney shall have to be registered in accordance with the provisions of the
Registration Act.1908. as per G.O. no. 09-W(C)/1M-286/15 dated:-23.09.2015 of the Principal
Secretary to the Govt. of West Bengal, Public Works Department.
xv) Partnership Firm, Company Limited Firm, Private Company Limited Firm
shall be registered by the respective competent authority from the Registrar
of Firms, Society, Non-Trading Corporation, Registrar of Companies etc. &
copy of Registration Certificate (with allotment of Registration No.) will have
to be submitted, otherwise the Technical Bid will not be considered for
qualification & Financial Bid shall not be opened [Non Statutory Documents].
xvi) An undertaking should be given stating thereby that the firm has not been debarred or penalized for
any reasons out of work by any Government Department during the last 5 (five) years prior to the date
of this NIT.
4. The successful bidder will have to establish field testing laboratory equipped with requisite
instruments in conformity with relevant code of practice and technical staff according to the
requirements of works to be executed. The executing agency will have to produce satisfactory test
report of all the materials of the work as well as on samples collection jointly by him and concerned
authority of the Engineer-in-Charge from all completed items of works as per relevant codes of
practice at his own cost from any Govt. approved / Govt. testing laboratory outside the jurisdiction of
the SE/NC/SS/PWDTE during execution of works. The successful bidder will have to bring all requisite plants
and mechanical equipments and / or technical personnel and / or laboratory and field testing machineries and
equipments for all the items of work as per BOQ and / or as per relevant IRC /IS codes of practice and / or as
per direction of the Engineer-In-Charge and / or as per relevant PWD Schedule of Rates at the time of
execution of work at site even if upon technical evaluation he is declared as “qualified” without having all the
requisite plants and mechanical equipments and / or technical personnel and / or laboratory and field testing
machineries and equipments at the time of submission of tender.
5. The executing agency (successful bidder) may not get a running payment unless the gross amount
of running bill is 50(fifty) lakh or 30% of the tendered amount whichever is less. Provisions in
Clause(s) 7, 8, & 9 contained in W.B. Form No. 2911 (ii) so far as they relate to quantum and
frequencies of payment are to be treated as superseded. The payment will be made as and when
fund is available from the concerned source. No claim whatsoever for delay in payment, if any,
will be entertained. Financial sanction will be governed vide memo no. GO 2122011144ES
Dated:- 22.09.2022 of School Education Department . Govt. of West Bengal. Retention money
towards performance Security amount to 10% (ten percent) of the value of the work will be
deducted from the running account bill of the tender as per prevailing order. No interest will be paid
on security deposit.
6. Tax Invoice(s) needs to be issued by the supplier for raising claim under the contract showing
separately the tax charged in accordance with the provisions of GST Act 2017 for (a) procurement
of Goods and Services and (b) works related contract involving supply of goods and services by
contractor including procurement under rule 47(C).
7. Constructional Labour Welfare Cess @ 1(one) % of cost of construction will be deducted from the bills
of the contractors on all contracts awarded on or after 01.11.2006 in pursuance with G.O. No.
599A/4M-28/06 dated 27.09.2006.Vat, Royalty & all other Statutory levy/ Cess will have to be borne by
the contractor & the rate in the schedule of rates are inclusive of all the taxes & Cess stated above.
Page 5 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
Successful Tenderers will be required to obtain valid Registration Certificate & Labour License
from respective Regional Labour Offices where construction work by them are proposed to be
carried out as per Clauses u/s 7 of West Bengal Building & other Construction Works’ Act, 1996
and u/s 12 of Contract Labour Act.
(a) Employees’ Provident Fund and Miscellaneous Provisions Act, 1952 and Employees State
Insurance Act, 1948 should be strictly adhered to wherever such Acts become applicable.
(b) Minimum wages to the workers shall be paid according to the rates notified and/or revised
by the State Government from time to time under the Minimum Wages Act, 1948 in
respect of scheduled employments, within the specified time as per law. Payment of
bonus, wherever applicable, has to be made.
(c) Adequate safety and welfare measures must be provided as per the provisions of the
Building and other Construction Workers’ (Regulation of Employment & Conditions of
Service) Act, 1996 read with West Bengal Building and Other Construction Workers
(Regulation of Employment and Conditions of Service) Rules, 2004.
(d) All liabilities arising out of engagement of workers are required to be duly met before
submission of bills for payment.
If there is any violation of one or all the relevant above criteria during execution of the job, it
will render the concerned agencies ineligible for the work then and there or at any subsequent stage as
may be found convenient.
10. Agencies shall have to arrange required land for installation of Plant & Machineries, (specified for each
awarded work, storing of materials, labour shed, laboratory etc. at their own cost and responsibility nearest
to the work site. The agencies have to submit declaration that they will install all machineries on the
working site within 10 (Ten) days from the date of issue of work order from this end positively with
application of Tender.
11. Bids shall remain valid for a period not less than 120 (One Hundred Twenty) days from the last date
of submission of Financial Bid / Sealed Bid. In case of inadvertent typographical mistake found in the
specified schedule of rates / BOQ, the same will be treated to be so corrected as to conform with the
relevant schedule of rates prevailing at the time of floating of tender and / or technically sanctioned
estimate. No claim whatsoever for such inadvertent typographical mistake will be entertained.
12. All materials required for the proposed scheme as mentioned in the Sl including bitumen (all grade),
bitumen emulsion, cement & steel will have be of specified grade & approved brand in conformity with
relevant code of practice (latest revision) & manufactured accordingly & will have to be procured &
supplied by the agency at his/ their own cost including all taxes. Authenticated evidence for purchase of
bitumen, bitumen emulsion, cement and steel are to be submitted along with challan and test certificate.
In the event of further testing opted by the Engineer-in-Charge, such testing from any Government
Page 6 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
approved/ Govt. outside the jurisdiction of SE/NC/SS/PWDTE Testing Laboratory will have to be
conducted by the agency at his/their own cost. Only 60/70(VG 30) grade paving bitumen of I.O.C.L/
B.P.C.L/ H.P.C.L (from nearest depot) will be permitted as Straight run Bitumen.
Steel reinforcement to be procured from any of the producers should be tested (physical test and chemical
test) as per required frequencies and as per relevant code of BUREAU OF INDIAN STANDARD by the
procuring authority from the laboratory / institution with proper testing infrastructure (preferably NABL
accredited), approved by the Procuring authority / Engineer in Charge of the works. Cost of such testing
will be borne by the producers / suppliers from whom the department is going to procure the steel
reinforcement. The test result (both physical & chemical) should conform to IS-1786-(latest revision) or IS-
432 (latest revision) whichever is applicable.
For all buildings with pile / raft foundations and for all bridges the reinforcement steel should be procured
as per PWD SOR Vol-I, II & III with effect from 01.11.2017 with Upto date CORRIGENDA &
ADDENDA PWD SOR Vol-I, II & III. (Date of Technical Sanction)
Cement to be used should satisfy all criteria as per relevant IS codes of practice. Cement manufactured from
mini plants shall not be used in any case.
5 Closing date and time of download of Tender Document 20.05.2022 up to 2.00 P.M.
(online).
6 Closing date and time of Bid submission (Technical and 20.05.2022 up to 2.00 P.M.
Financial) (online).
7 Date and time of opening of Technical Proposals (online). 25.05.2022 after 3.00 P.M. at
the Office of the Superintending
Engineer, Northern Circle, SS, PWDte.,
P.W.D. Inspection Bungalow (Annex
Building), 2nd Floor, Kutchery Road,
Venus More, Siliguri, Dist.- Darjeeling,
PIN – 734001.
8 Date and time of uploading of list of Technically qualified Will be notified later on.
bidders.(online)
9 Date of uploading of final list of technically qualified bidders Will be notified later on.
after disposal of appeals, if any.
10 Date and time of opening of Financial Proposal (online). Will be notified later on.
Page 7 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
13. Clause 25 of. 2911(ii) is modified vide notification No. 8182-F(Y) dt. 26.09.2012 of Finance
Department, Govt. of West Bengal, as follows :
“Except where otherwise provided in the contract all question and disputes relating to the meaning of the
specifications, designs, drawings and instructions herein before mentioned and as to the quality of
workmanship or materials used on the work or as to any other question, claim, right, matter or thing
whatsoever, in any way arising out of relating to the contracts designs, drawings, specifications, estimate,
instructions, orders or these conditions or otherwise concerning the works, or the executions or failure to
execute the same, whether arising during the progress of the work, or after the completion or abandonment
thereof shall be dealt with as mentioned hereinafter;
If the contractor considers any work demanded of him to be outside the requirements of the contract, or
disputes any drawings, record or decision given in writing by the Engineer-in-Charge on any matter in
connection with or arising out of the contract or carrying out of the work, to be unacceptable, he shall
promptly within 15 days request the Chairman of the Dispute Redressal Committee in writing for written
instruction or decision. Thereupon, the Dispute Redressal Committee shall give its written instructions or
decision within a period of three months from the date of receipt of the contractor’s letter.
The Dispute Redressal Committee in each of the works Departments shall be constituted with the
following officials as members-
This provision will be applicable irrespective of the value of the works to which the dispute may relate.
14. The Bidder, at the Bidder’s own responsibility and risk is encouraged to visit and examine the site of works and its
surroundings and obtain all information that may be necessary for preparing the Bid and entering into a contract for
the work as mentioned in the Notice inviting Tender, the cost of visiting the site shall be at the Bidder’s own expense.
Issuance of Letter of Acceptance / Work Order may be delayed and / or work may be financially restricted upto the
limit of existing Administrative Approval until receipt of Revised Administrative Approval from the competent
authority(in applicable cases). Also issuance of Letter of Acceptance / Work Order may be delayed and / or work
may be restricted in some stretches till necessary land for the same is made available and / or encroachments are
removed (in applicable cases). No claim, whatsoever, for such delay in issuance of Letter of Acceptance / Work
Order and / or restriction of work will be entertained. Intending bidders may keep these criteria in mind while
participating in tender and / or while quoting their rates.
15. Prospective applicants are advised to note carefully the minimum qualification criteria as mentioned in the
‘Instructions to Bidders’ before bidding.
16. There will be a “Defect Liability Period” of 05 [Five] year for the original works from the date of completion and
the security deposit will be released phase wise as detailed below. Prospective bidders will have to execute the
work in such manner so that appropriate service level for the stipulated stretch(s)/length of the road under
improvement is to be maintained during stipulated contractual period till completion and a period of 05 [Five]
year from the date of successful completion of the work to the entire satisfaction of Engineer-in-Charge. If any
defect/damage is found during the period as mentioned above, the contractor will make the same good at his own
expense up to the specification at par with the instant project work, or on default, the Engineer-in-Charge may
cause the same to be made good by other agency and deduct the expense (of which the certificate the Engineer-in-
Charge shall be final) from any sums that may be then, or at any time thereafter become due to the contract or
Page 8 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
from his security deposit, or the proceeds of the sale thereof, or of sufficient portion thereof. Refund of Security
Deposit will only be made on the pro-rata basis.
However, for repair and maintenance nature of bituminous road work or combination thereof the Defect Liability
period would be considered as 1 (one) year. And in case of Original Works where bituminous thickness is less
than 40 mm, the Defect Liability period is 1 (one) year from the date of completion as per memo no. 2014-E-in-
C/2015 dated 06-11-2015 of the Engineer-in-Chief & Ex-Officio Secretary, Public Works Department, Govt. Of
West Bengal.
Explanation:
The word ‘work’ means and includes road work, bridge work, building work, sanitary and plumbing work,
electrical work and / or any other work contemplated within the scope and ambit of the contract. For
(i) The work of patch repair or patch maintenance in nature combination thereof, the Defect
Page 9 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
Liability Period of the work shall be three months from the actual date of completion of
the work.
(ii) Through Bituminous Surfacing work with bituminous thickness less than 40mm. Repair
& Rehabilitation of any road / bridge / culvert / building/ Sanitary & Plumbing work, the
Defect Liability Period of the work shall be one year from the actual date of completion
of the work;
(iii) Extension of building / bridge/ culvert, Construction of new flexible pavement up to
bituminous level which has been designed for a period of 3 years or more, Widening and
strengthening of flexible pavement designed for a period of 3 years or more,
Improvement of riding quality/ Strengthening of flexible pavement designed for a period
of 3 years or more; Providing only mastic asphalt layer over existing bituminous surface
without providing bituminous profile corrective course / bituminous base course, the
Defect Liability Period of the work shall be three years from the actual date to
completion of the work;
(iv) Construction of new building / new bridge / new culvert, Reconstruction of building /
bridge / culvert including construction of approach roads for / bridge/ culvert,
Construction of ridge pavement, Reconstruction of ridge pavement, Construction of new
flexible pavement covered by mastic work which has been designed for a period of 5
years or more, Improvement of riding quality / Strengthening of flexible pavement
covered by mastic work which has been designed for a period of 5 years or more, the
Defect Liability Period of the work shall be five years from the actual date of
completion of the work;
In cases of Refunding and Releasing of 100% Security Deposit held with the Government, arising out from
works contract, Security Deposit will be released after issuance of Completion Certificate on submission of
unconditional BANK GUARANTEE by the Contractor for the Security Deposit subject to the following conditions:
1. The Bank Guarantee will be issued by a Scheduled Commercial Bank in favour of the Engineer -In-Charge of
the concern work, PWD, Government of West Bengal on behalf of the contractor.
2. The Bank Guarantee will remain valid for the Defect liability period/Security period as per contract of the work.
3. The Bank Guarantee will be submitted as per Format attached in Annexure –I. The Engineer-In-Charge should
obtain confirmation of the Bank Guarantee directly from the Bank before its acceptance.
4. The Bank Guarantee, now pledged in the form of Security Deposit will be released to the contractor in the
following manner, if not forfeited under conditions of contract-
(Vide NOTIFICATION No. 5951-PW / L&A / 2M-175 / 2017 Dated: 02.11.2017)
(a) For work with three months Defect Liability Period:
i. Full amount shall be refunded to the contractor on expiry of three months from the actual date of
completion of the work.
(b) For work with one years Defect Liability Period:
i. Full amount shall be refunded to the contractor on expiry of one years from the actual date of
completion of the work .
(c) For work with three years Defect Liability Period:
i. 30% of the same shall be refunded to the contractor on expiry of two years from the actual date of
completion of the work .
ii. The balance 70% of the same shall be refunded to the contractor on expiry of three years from the
actual date of completion of the work .
(d) For work with five years Defect Liability Period:
i. No amount same shall be refunded to the contractor for the first 3 years from the
actual date of completion of the work .
ii. 30% of the same shall be refunded to the contractor on expiry of four years from the actual date of
completion of the work .
iii. The balance70% of the same shall be refunded to the contractor on expiry of four years from the
actual date of completion of the work .
Page 10 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
WHEREAFTER, in cases for those contractors, who will not intend to opt for the provisions laid down
hereinabove for refund of security deposit, this Department's earlier Notification no. 177-CRC/2M-57/2008
dt.12/07/2012 details of which are as stated earlier, shall be in force in the manner provided in the earlier aforesaid
Notification.
17. In case of Ascertaining Authority at any stage of tender process or execution of work necessary registered
irrevocable power of attorney is to be produced. Power of Attorney holders are not allowed to sign Tender
Documents unless otherwise approved by Government.
18. All intending bidders are requested to be present in the office of the Superintending Engineer, Northern Circle,
Social Sector, P.W. Directorate during opening of the Tender to observe the tender opening procedure.
19. No CONDITIONAL/ INCOMPLETE TENDER will be accepted under any circumstances.
20. Requirement of Principal Machineries which must be possessed by own/ Lease Hold agreement(as
the case may be) are as shown and mentioned in Section – B, Form – IV.
Original documents in support of own / lease possession of the aforesaid machineries are to be furnished if
required by the Tender Inviting Authority.
21. In the event of acceptance of lowest tendered rate no multiple minimum rates will be considered by the
Department.
22. The Superintending Engineer, Northern Circle, Social Sector , P.W. Directorate reserves the right to cancel the
N.I.T. due to unavoidable circumstances and no claim in this respect will be entertained.
23. During the scrutiny, if it comes to the notice of the tender inviting authority that the credential(s) and/or any
other paper(s) of any bidder are incorrect/ manufactured/ fabricated, that tender will be out rightly rejected and
further penal action may be taken against him as per rule.
24. In case there is any objection regarding prequalifying an agency, that should be lodged to the Chairman of the
Bid Evaluation Committee i.e. The Superintending Engineer, Northern Circle, Social Sector, P.W.Dte. within 48
hours from the date and time of publication of list of qualified agencies and beyond that time schedule no
objection will be entertained by the Bid Evaluation Committee.
25. Before issuance of LOA/ work order, the tender inviting authority may verify the credentials & other documents
of the lowest tenderer if found necessary. After verification, if it is found that such documents submitted by the
lowest tenderer are either manufactured or false, in that case LOA/work order will not be issued in favour of that
tenderer under any circumstances and further penal action may be taken against him as per rule.
26. If any discrepancy arises between two similar clauses on different notifications, the clause as stated in later
notification will supersede former one in following sequence:-
In case of inadvertent typographical mistake in the BOQ / Schedule of works/ Price Schedule/rates /elsewhere, the
same may be treated to be so corrected as to conform with the relevant schedule of rates and or technically
sanctioned estimate.
i) The Superintending Engineer, Northern Circle, Social Sector, P.W.Dte. – Chairperson & Convenor.
ii) The concerned Executive Engineer North Bengal/ Malda / Cooch Behar Division, Social Sector, P.W.Dte.
under whom the work tendered for will be executed.
iii) T.A. to Superintending Engineer, Northern Circle, Social Sector, P.W.Dte.
iv) Divisional Accounts Officer / Divisional Accountant.
The Bid Evaluation Committee will do the technical and financial evaluation of the bidders for different type of
works and make recommendation to the tender accepting authority. The bidders will have to meet all the
minimum criteria regarding:-
Page 11 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
a) Financial Capacity
b) Technical Capability comprising of personnel and plant & equipment capability
c) Experience / Credential
The eligibility of a bidder will be ascertained on the basis of his digitally signed documents in support of the
minimum criteria as mentioned in a, b, c above with the help of his DSC and the declaration executed through
prescribed affidavit in non-judicial stamp paper of appropriate value duly notarized. If any document submitted
by a bidder is either manufactured or false, in such case the eligibility of the bidder/ tenderer will be out rightly
rejected at any stage without any prejudice and further penal action may be taken against him as per rule.
28. The Bid Evaluation Committee reserves the right to ignore minor deficiencies at their discretion in case of first
call and no challenge whatsoever against such decision of the said committee/ authority will be entertained. In
case of second and subsequent calls, the Bid Evaluation Committee reserves the right to ignore some
deficiencies at their discretion and no challenge whatsoever against such decision of the said committee will be
entertained.
29. Bidders should upload their documents from original copies. Uploading Photocopy & illegible copies will not be
accepted.
30. Each work will be awarded against specific set of machineries as indicated in Sl. No. 20 of this NIT & section B
(Form-IV).
INSTRUCTION TO BIDDERS
SECTION – A
2. Registration of Contractor
Any contractor willing to take part in the process of e-Tendering will have to be enrolled &
registered with the Government e-Procurement system; through logging on to
https://wbtenders.gov.in (the web portal of public works department) the contractor is to click on
the link for e-Tendering site as given on the web portal.
4. The contractor can search & download NIT & Tender Documents electronically from computer
once he logs on to the website mentioned in Clause 2 using the Digital Signature Certificate. This
is the only mode of collection of Tender Documents.
Page 12 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
6. Submission of Tenders.
General process of submission : Tenders are to be submitted online through the website stated in
Cl. 2 in two folders at a time for each work, one in Technical Proposal & the other is Financial
Proposal before the prescribed date & time using the Digital Signature Certificate (DSC). The
documents are to be uploaded virus scanned copy duly Digitally Signed. The documents will get
encrypted (transformed into non readable formats).
A. Technical proposal
The Technical proposal should contain scanned copies of the following in further two covers
(folders):
v. Tax Audited Report in 3CD/3CB Form supported with Income Tax return along with Balance
Sheet & Profit & Loss A/c for the last five years (year just preceding the current Financial Year
will be considered as year-I)
vi. Bye laws are to be submitted by the Registered labour Co-Op (S) & Engineers’ Co.-Opt.(S)
vii. List of machineries possessed by own/ lease along with authenticated copy of invoice, challan &
waybill Ref.:- Cl. No. 3(viii) & 20 of this NIT (Section –B, Form IV) and an affidavit of
appropriate value duly notarized should be submitted with mentioning the present status and
location of installation of main plant and machineries.
viii. List of laboratory Instrument along with authenticated Invoice & Challan.(Ref.:- Cl. No.4 of NIT)
ix. List of Technical staffs along with structure & organization (Section – B, Form – III). Identity
proof, Qualification proof of Technical Staff and Declaration of engagement from the both
ends on regards to this e-NIT are to be submitted.
x. Electrical Supervisory competency certificate from Directorate of Electricity, Govt. of
W.B. competent authority of other Govt. as applicable.
Page 13 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
Valid Electrical S.C.C Part No. 1,2,3,4,5,6A,6B,7A,7B,10,11 & 12 issued by the
Licensing Board, Govt. of West Bengal or competent authority of other Govt. as applicable.
The agency should have submit credential in respect of similar nature of Electrical works.
In case of Association with an Electrical agency, the Bidder must have Memorandum of
Understanding with an Electrical agency which is duly notarized in non judicial stamp
paper. All liabilities regarding electrical works will be vested upon the bidder. M.O.U. of
electrical agency and the bidder must be submitted along with the technical bid.
In a composite NIeT to facilitate Joint Venture for building works for works less
than Rs. 25 Crore such that for works worth value less than Rs.25 Crore and which are
predominantly civil work in nature with electrical components less than 25% of the
estimated amount put to tender, the Civil contractor may be allowed to submit an
agreement in non-judicial stamp paper of requisite value with an electrical contractor for
execution of the electrical components of the work. In that case, the electrical contractor
will have to qualify for all requirements set forth in the NIT for electrical works
including credential, electrical supervisor’s certificate of competency (SCC) etc. The
Civil contractor will have to qualify for all requirements set forth in the NIT including
requisite credential for Civil component of such works but excluding credential and SCC
requirements for electrical works. However, the onus and full responsibility for execution
of the total work (Civil & Electrical) will be on the civil contractor who will execute the
agreement with the Department. Payment will also be made to the civil contractor only.
(Vide memorandum No. 311-W(C)/1M-132/15 Date: 28/03/2018 pf P.W.D, works Branch,
Govt. of West Bengal ) (NOT REQUIRED FOR THIS TENDER)
xi. As per order no. 04-A/PW/O/10C-02/14 Dated:- 18.03.2015 of the Principal Secretary, PWD, (Accounts
Branch), Government of West Bengal, Credential certificate issued by the Executive Engineer or equivalent
or competent authority of a State / Central Government., State / Central Government undertaking, Statutory
/ Autonomous bodies constituted under the Central / State statute, on the executed value of completed /
running work will be taken as credential (Ref. Cl. No. 3(i) of this NIT).
Scanned copy of Original Credential Certificate (supported by Work order, Price Schedule or BOQ)
during the last 5(five) years prior to the date of issue of this NIT is to be furnished.
Note:- Failure of submission of any of the above mentioned documents (as stated in A1 & A2)
will render the tender liable to be summarily rejected for both statutory & non statutory cover.
Page 14 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
viii. While evaluation the committee may summon the bidders(s) & seek clarification /
information or additional documents or original hard copy of any of the documents
already submitted & if these are not produced within the stipulated time frame, their
proposals will be liable for rejection.
Click the check boxes beside the necessary documents in the My Document list and then click the tab
“Submit Non Statutory Documents’ to send the selected documents to Non-Statutory Folder. Next Click
the tab “Click to Encrypt and upload” and then click the “Technical” Folder to upload the Technical
Documents.
Page 15 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
P/L AND BALANCE Profit and Loss and Balance Sheet (with Annexure
SHEET 2020-2021
P/L AND BALANCE Profit and Loss and Balance Sheet (with Annexure
SHEET 2019-2020
P/L AND BALANCE Profit and Loss and Balance Sheet (with Annexure
SHEET 2018-2019
P/L AND BALANCE Profit and Loss and Balance Sheet (with Annexure
SHEET 2017-2018
P/L AND BALANCE Profit and Loss and Balance Sheet (with Annexure
SHEET 2016-2017
F. MANPOWER TECHNICAL List of Technical Staffs Along with Structures and
PERSONNEL Organization (As per NIT). – Form no. III.
TECHNICAL List of Technical Staffs Along with structures and
PERSONNEL Organization (As per NIT). – Form no. III.
ON CONTACT
C. Financial proposal
i. The financial proposal should contain the following documents in one cover (folder) i.e.
Bill of Quantities (BOQ). The contractor is to quote the rate (percentage Excess/ Less/ At
par) online through computer in the space marked for quoting rate in the BOQ.
ii. Only downloaded copies of the above documents are to be uploaded virus scanned &
Digitally Signed by the contractor.
7. Financial capacity of a bidder will be judged on the basis of net worth and available bid capacity as
mentioned in the N.I.T. to be derived from the information furnished in Form-I & II (Section-B) i.e.,
Application (for Pre-qualification) & Financial Statement.
The audited Balance sheet for the last five years, net worth, bid capacity etc. are to be submitted
which must demonstrate the soundness of Bidder’s financial position, showing long term
profitability including an estimated financial projection for the next two years.
9. REJECTION OF BID
The Employer (tender accepting authority) reserves the right to accept or reject any Bid and to cancel the
Bidding processes and reject all Bids at any time prior to the award of Contract without thereby incurring
any liability to the affected Bidder or Bidders or any obligation to inform the affected Bidder or Bidders
of the ground for Employer’s (tender accepting authority) action.
Page 16 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
10. AWARD OF CONTRACT
(i) The Bidder whose Bid has been accepted will be notified by the Tender Inviting & Accepting Authority
through Letter of Acceptance.
(ii) The Letter of Acceptance will constitute the formation of the Contract. Issuance of LOA / work order
may be delayed due to non-receipt of clear site for the work and no claim, whatsoever, for delay in
issuance of LOA/ Work order will be entertained.
(iii) The Agreement in W.B.F.No.-2911(ii) will incorporate all necessary documents e.g. N.I.T., all addenda-
corrigendum, special terms & conditions (Section –C), different filled-up forms (Section –B), B.O.Q., for
the works under this N.I.eT. is based upon the schedule of rates of Public Works Department for Building
Works(vol-I), Sanitary & Plumbing Works(vol-II) and Road & Bridge Works(vol-III) w.e.f. 01.11.2017 including
all up to date Addenda & Corrigendum and for Electrical Works as applicable (Date of Technical Sanction), at
the time of floating of NIT, and the same will be constituted between the Tender Accepting Authority
and the successful Bidder.
Superintending Engineer,
Northern Circle, Social Sector, P.W.Dte.
Copy forwarded to the Office of the Sub-Divisional Information & Cultural Officer , Dept of I & CA., Mainak
Tourist Lodge Annexe Building, Hill Cart Road Mallaguri, Pradhan Nagar, Siliguri, for information with the
request to wide publication.
Superintending Engineer,
Northern Circle, Social Sector, P.W.Dte.
Page 17 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
Memo No:19-1-15/68-C Dated: 22.04.2022.
Copy forwarded for information and wide circulation through his office NOTICE BOARD to :-.
1. The Chief Engineer, Social Sector, P.W.Dte. New Sectt. Building, Kolkata – 700001
2. The Chief Engineer, North Zone, P.W.Dte. , PWD Campus, Jalpaiguri.
3. The Sabhadhipati, Zilla Parishad, Malda District.
4. The Joint Secretary, School Education Department, Planning & Budget Branch Govt. Of West Bengal, 5th
floor, Bikash Bhavan, Salt Lake, Kolkatta-91.
5. The Superintending Engineer, Southern Circle / South West Circle/ Project Circle, Social Sector, P.W.Dte.
6. The Superintending Engineer, Northern Electrical Circle, Malda. This is to inform that the electrical works
has not been incorporated in this tender.
7. The Executive Engineer, North Bengal Division / Raigunj Division / Malda District, Social Sector, P.W.Dte.
8. The District Magistrate, Malda District.
9. The Principal DIET, Malda District
10. The T.A. to Superintending Engineer, Northern Circle, Social Sector, P.W.Dte.
11. The Estimator, Northern Circle, Social Sector, P.W.Dte.
12. Contractor’s association, Malda District.
13. The Secretary, Contractors Association, Kolkata.
14. The Secretary, Labour Co-operative Society / Engineers Co. Operative Society, Malda District
15. Notice Board of this office.
Superintending Engineer,
Northern Circle, Social Sector, P.W.Dte.
Page 18 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
SECTION – B
FORM –I
PRE-QUALIFICATION APPLICATION
To
The Superintending Engineer
Northern Circle, Social Sector, P.W.Dte.
Ref: - Tender
for______________________________________________________________________________
________________________________________ (Name of work) ____________________________
______________________________________________________________________________________
______________________________________________________________________________________
____
• N.I.T.No.: ……….(Sl. No. ………..) of 2022-2023 of Superintending Engineer, Northern Circle,
Social Sector, P.W.Dte.
Dear Sir,
Having examined the Statutory, Non statutory & NIT documents, I /we hereby submit all the necessary information and
relevant documents for evaluation.
We are interested in bidding for the work(s) given in Enclosure to this letter.
We understand that:
(a) Tender Inviting & Accepting Authority/Engineer-in-Charge can amend the scope & value of the
contract bid under this project.
(b) Tender Inviting & Accepting Authority/Engineer-in-Charge reserve the right to reject any
application without assigning any reason.
Enclo: - e-Filing:-
1. Statutory Documents
2. Non Statutory Documents
Date: -
__________________________________
Signature, name and designation
of Authorised Signatory
For and on behalf of
___________________
(Name of the Applicant)
Page 19 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
SECTION – B
Form – II
FINANCIAL STATEMENT
N.I.e.T. No. ______Sl No._____OF 2022-2023 OF THE SUPERINTENDING ENGINEER, NORTHERN CIRCLE, SOCIAL SECTOR, P.W.DTE.
Name of Bidder:
1. The Bidder’s Net Worth for the last year calculated on the basis of capital, profit and free reserve available to the
firm should be positive.
2. Bidders, who meet the minimum qualification criteria, will be qualified only if their available bid capacity at the
expected time of bidding is more than the total estimated cost of the works. The available bid capacity will be
calculated as under:
A = Maximum value of engineering works in respect of Projects executed in any one year during the last five
years (updated to the price level of the year indicated in table below under note) taking into account the
completed as well as works in progress. The projects include turnkey projects / Item rate contract /
Construction works.
N = Number of years (i.e.,_______ year) prescribed for completion of the works for which Bids are invited.
B = Financial Liability of the bidder to be incurred for existing commitments and on-going works during the
period of the subject contract.
A table containing value of Engineering Works in respect to Projects (Turnkey projects / Item rate contract /
Construction works) undertaken by the Bidder during the last 5 years is as follows:
Value of Engineering
Sl. No. Year Works undertaken w.r.t.
Projects (Rs. In Crores)
1. Year - 5
2. Year - 4
3. Year - 3
4. Year - 2
5. Year - 1
ii) Maximum value of projects that have been undertaken during the F.Y. _____________ out of the last 5
years and value thereof is Rs.___________ Crores (Rupees______________________________________).
Further, value updated to the price level of the year indicated in Table is as follows:
Page 20 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
Table indicating the factor for the year for updation to the price level is indicated as under
iii) Net worth for the last year Rs._________________of ___________________(name of the company)
(The Bidder’s Net Worth for the last year calculated on the basis of capital, profit and free reserve available
to the firm should be positive.)
__________________________________ _________________________________________
Signature, name and designation Signature of authorized signatory of the
of Authorised Signatory Statutory Auditors firm
Name of the Statutory Auditor’s firm:
For and on behalf of Seal of the audit firm:
_______________________________ (Signature, name and designation and
(Name of the Applicant) Membership No. of authorized Signatory)
Page 21 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
3. A table containing value of all the existing commitments and on-going working to be completed
during the next 180 days (prescribed time for completion of the works for which Bids are invited) is
as follows:
Note: Please enclose copy of work order & up-to-date work progress certificate from the concerned Executive
Engineer.
__________________________________
Signature, name and designation
of Authorised Signatory
________________________________
(Name of the Applicant)
Note:
1. All the documents to be submitted in support of “Financial Statement” must be duly signed and sealed by
the applicant/bidder and authenticated by Statutory Auditor’s firm.
2. In case of a Joint Venture, Lead Member of such joint venture will be required to meet 60% of required Bid
Capacity and each of the Joint Venture members will be required to meet at least 30% of requirement of BID
Capacity. Bid Capacity of all the members in total should be at least 100% of required Bid Capacity.
Page 22 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
AFFIDAVIT – “X”
(To be furnished in Non – Judicial Stamp paper of appropriate value duly notarized)
N.I.e.T. No. ______Sl No._____OF 2022-2023 OF THE SUPERINTENDING ENGINEER, NORTHERN CIRCLE,
SOCIAL SECTOR, P.W.DTE.
Date________________
______________________________
Signature, name and designation
of Authorised Signatory
For and on behalf of
________________________________
(Name of the Applicant)
Page 23 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
AFFIDAVIT – “Y”
(To be furnished in Non – Judicial Stamp paper of a ppropriate value duly notarized)
1. I, the under-signed do certify that all the statements made in the attached documents are true and correct. In
case of any information submitted is proved to be false or concealed, the application may be rejected and no
objection/claim will be raised by the under-signed.
2. The under-signed also hereby certifies that neither our firm _____________________________
____________________________ nor any of its constituent partners had been debarred to participate in
tender by any directorate of Public Works Department during the last 5(five) years prior to the date of this
NIT.
3. The under-signed also hereby certifies that neither our firm _____________________________
____________________________ nor any of its constituent partners have failed to executed more than one
works contract under any directorate of Public Works Department and that neither our firm
______________________________________________ nor any of its constituent partners was terminated
by any sub-rule under clause 3 of Tender Form no. 2911 and that neither our firm
___________________________________________________ nor any of its constituent partners was
terminated under any clause of standard Bidding Documents by the Engineer-in-Charge/ Employer during
last 3(three) years.
4. Certified that I have access to or have available liquid assets (aggregate of working capital, cash-in-hand,
uncommitted Bank Guarantees) and/or credit facilities not less than 10% of the estimated cost put to tender.
In this respect, I have attached necessary documents with this application. The under-signed would authorize
and request any Bank, person, Firm or Corporation to furnish pertinent information as deemed necessary
and/or as requested by the Department to verify this statement.
5. The under-signed understands and agrees that further qualifying information may be requested and agrees to
furnish any such information at the request of the Department.
6. Certified that I have applied in the tender vide NIeT no _____ of 2022-2023, Sl. no. ________in the capacity
of individual/ as a partner of a firm & I have not applied severally for the same job.
7. The under-signed also hereby certifies that the Bid shall remain valid for a period not less than 120 (One
Hundred twenty) days, after the dead line date for Bid submission.
8. I, the under-signed, declare that all the statements made in the attached documents in respect of mode of
ownership of machineries are true and correct.
9. Certified that required specified machineries for the works under this NIT will be installed at the working site
within 10(Ten) days from the date of issue of Work Order.
10. I / we do hereby certify that I shall bring all requisite technical personnel and /or plants/ testing machineries /
equipments for all the items of works as per relevant IRC / IS codes of practice and as per BOQ and as per
direction of the Engineer-In-Charge at the time of execution of work at site even if upon Technical evaluation
I am declared as “qualified” without having all the requisite technical personnel and /or plants/ testing
machineries / equipments at the time of submission of tender.
11. I, the under-signed do certify that all the statements made in the attached documents are true and correct. If
any declaration submitted is found / ascertain to be incorrect / fabricated / misrepresented / fraudulent etc.
accordingly tender will be liable to be cancelled / terminated immediately & I / my firm / company shall also
be liable to prosecuted under section 197, 199 & 200 of Indian Penal Code, 1860 along with section-71 &
Page 24 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
section-73 of Indian Information & Technology Act 2008 & any other applicable law for the time being in
force in addition to forfeiture of Earnest Money / Security Deposit.
Date________________
________________________________
Signature, name and designation
of Authorised Signatory
For and on behalf of
________________________________
(Name of the Applicant)
Page 25 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
SECTION - B
FORM- III
Telephone No. :
Fax No.
E mail I.D. :
Page 26 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
SECTION –B
FORM – IV
_______________________________
Signature, name and designation
of Authorised Signatory
For and on behalf of
_______________________________
(Name of the Applicant)
Page 27 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
SECTION - B
FORM – IV (contd...)
G. CONTRACTOR’S EQUIPMENT
Whereas it is entirely the responsibility of the Contractor to deploy sufficient plant and mechanical
equipment to ensure compliance with his obligations under the Contract, the following list is an indicative
list of the minimum essential basic holding of plant and mechanical equipment which the bidder must own
or where mentioned in the following list arrange through lease hold agreement.
Minimum No. & capacity For NIT
Sl. Bidders’ Scheme Sl.
TYPE OF EQUIPMENT
No. Capacity Responsibility No.
No.
Tilting / Reversible Drum concrete mixer 1 Minimum 230-280 ltr Own/Lease I
1.
with Hopper (7/10 cft )capacity
For each item of equipment the applicant should attach copies of:-
(i) Document showing proof of full payment,
(ii) Receipt of Delivery,
(iii) Way Bill & Road Challan from Factory to delivery spot, are to be furnished.
Note: - 1) For leased plant & Machineries (wherever applicable), registered/notarized agreement is to be
submitted. The agreement should mention existing commitments and on-going works taken up with those
plants / machineries. More than one commitment with same plant / machineries will not be considered as
eligible.
2) Date of completion of existing commitment with the plant / machineries should be mentioned in
Page 28 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
the registered agreement including present location (working place) where the same are presently engaged.
3) As per order no. 293-W(C)/1M-24/15 Dated:- 15.06.2015 of the Principal Secretary, PWD,
(Works Branch), Government of West Bengal, Initially for Concrete batching and mixing plant, Concrete
mixer with integral weigh batching facility maximum age of the plants, machineries will be 5 years as on the
date of publication of NIT. It may be extended upto 7 years after getting fit certificate from the manufacturer
and this certificate should be produced at the time of submission of bid. All other machineries and equipments
should be in running condition. All plants, machineries and equipments will be verified by the competent
authority before execution of the work.
Superintending Engineer,
Northern Circle, Social Sector, P.W.Dte.
SECTION – B
FORM – V
EXPERIENCE PROFILE
D.1 LIST OF PROJECTS COMPLETED THAT ARE SIMILAR IN NATURE TO THE WORKS HAVING MORE
st nd rd
THAN 40% IN RESPECT OF 1 CALL, 30% IN RESPECT OF 2 CALL AND 20% IN RESPECT OF 3
AND SUBSEQUENT CALLS AS MENTION IN CLAUSE NO 3(i) OF NIT OF THE PROJECT COST
EXECUTED DURING THE LAST FIVE YEARS.
Name of
Name, Consulting Contract Percenta Original Original Date Actual Actual Reasons for
Name of Employer Location & Engineer price in ge of Date of of Date of Date of delay in
nature of responsible Indian Participa start of completion starting completi completion
work for Rs. tion of work of work the work on of (if any)
supervision company work
Page 29 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
SECTION – C
C.1 General :
Unless otherwise stipulated all the works are to be done as per general conditions and
general specifications as mentioned either in—
(i) ‘Departmental Schedule’, which means the Public Works Department Schedule of
Rates for Building Works (Volume – I), Sanitary & Plumbing Works (Volume – II), Road
& Bridge Works (Volume – III) and Electrical Works and Carriage etc. in different
district of West Bengal for the working area effecting from 01.11.2017, with up-to-date
addenda and corrigenda (Date of Technical Sanction), if any, issued by the Superintending
Engineer, Planning & Monitoring Circle, P.W.Dte & Convener of the Combined
Schedule Committee of PWD and Chief Enginner(HQ), P.W.Dte & Chairman of the
Combined Schedule Committee of PWD or in
(ii) Latest edition (5th Revision) of the book of name ‘Specification for Road and Bridge
Works’ of the M.O.R.T. & H., Surface Transport (Roads Wing), Government of India,
published by Indian Roads Congress, New Delhi and “Specification for Rural Road” by
Ministry of Rural Development (MORD), for the specification of various works.
For general conditions and general specifications of items of works including supply
and carriage works provided in this BOQ, not appearing in the aforesaid specification
books, relevant Public Works Department Schedule of Rates for Building Works
(Volume – I), Sanitary & Plumbing works (Volume – II) and Road & Bridge Works
(Volume – III) including Materials, Labour & Carriage in force with up-to-date addenda
and corrigenda, if any, issued from competent authority as applicable for the working
area of concerned Circle at the time of submission of tender for the working area will be
considered. Also relevant specifications and criteria as provided in the relevant IS or
IRC code of Practice may be followed where current PWD SOR is silent about the detail.
Page 30 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
must see that all damages to any property which, in the opinion of the Engineer-in-
Charge are due to the negligence of the contractor are promptly rectified by the
contractor at his own cost and expenses and according to the direction and satisfaction
of the Engineer-in-Charge.
C.5 Transportation arrangement :
The contractor will arrange for all means of transport including railways wagons
required for carriage and supply of materials and also the materials required for the
construction work. The Department may however, at their own discretion grant
necessary certificates, if required, for booking of railways wagons etc. But, in case of
failure of the department to help the contractor in this respect, the contractor will have
to arrange at his own initiative so that progress of work is not hampered and no claim
whatsoever on this ground will be entertained under any circumstances. If railways
facilities are not available, the contractor will have to depend on transport of materials
by road as necessary to complete the work without claiming any extra payment from
department in this regard. The contractor must consider this aspect while quoting rate.
C.6 Contractor’s Site Office :
The contractor will have to set up an office adjacent to the work as may be approved by
the Engineer-in-Charge where all directions and notice of any kind whatsoever, which
the Engineer-in-Charge or his representative may desire to give to the contractor in
connection with the contract, may be left or sent by post to such office or delivered to
the contractor’s authorised agent or representative. For such intimation to the
contractor’s site office, it will be deemed to the sufficient enough to be served upon the
contractor.
C.7 Incidental and other charges :
The cost of all materials, hire charges of Tools and plants, labour,
Corporation/Municipal Fees for water supply, Royalty or road materials (if any),
electricity and other charges of Municipalities or statutory local bodies, ferry charges,
Toll charges, loading and unloading charges, handling chargers, overhead
charges etc. will be deemed to have been covered by the rates quoted by the contractor
inclusive of Sales Tax (Central and/or State), Income Tax, Octroi Duty/Terminal Tax,
Turnover Tax, VAT etc., all other charges for the execution of the specified work,
including supply of materials and related carriage, complete or finished in all respect
up to the entire satisfaction of the Engineer-in-charge of the work. No extra claim in
this regard beyond the specified rate as per work schedule in this respect will be
entertained.
C.8 Authorised Representative of Contractor :
The contractor should not assign the agreement or sublet any portion of the work. The
contractor, may however, appoint and authorised representatives in respect of one or
more of the following purposes only.
b) To give requisition for Departmental materials, Tools & Plants etc., to receive the
same and sign hand receipts thereof.
c) To attend measurements when taken by the Departmental Officers and sign the
records of such measurements which will be taken as accepted by the contractor.
The selection of the authorised representatives will be subject to the prior approval of
the Engineer-in-Charge concerned and the contractor will in writing seek such
approval of the Engineer-in-Charge giving therein the name of work, Tender No., the
Name, Address and the attested specimen signature of the representative he wants to
appoint and the specific purposes as specified here-in-above, which the representative
will be authorised for. Even after first approval, the Engineer-in-Charge may issue at
Page 31 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
any subsequent date, revised directions about such authorised representatives and the
contractor will be bound to abide by such directions. The Engineer-in-Charge will not
be bound to assign any reason for his revised directions. Any notice correspondence
etc. issued to the authorised representative or left at his address, will be deemed to
have been issued to the contractor.
C.9 Power of Attorney :
The Provision of the power of attorney, if any, must be subject to the approval of the
Department. Otherwise the Department will not be bound to take cognizance of such of
attorney.
C.10 Extension of time :
For cogent reasons over which the contractor will have no control and which will retard
the progress, extension of time for the period lost will be granted on receipt of
application from the contractor before the expiry date of contract. No claim whatsoever
for idle labour, additional establishment, enhanced cost of materials and labour and
hire charges of tools & plants etc. will be entertained under any circumstances. The
contractor should consider the above factor while quoting his rate. Applications for
such extension of time should be submitted by the contractor in the manner indicated
in Clause-5 of the printed form of W.B.F. No.2911 (ii).
C.11 Contractor’s Godown :
The contractor must provide suitable godowns for cement and other materials at the
site of work. The cement godown should be sufficient in capacity and it must be water
tight with either an elevated floor with proper ventilation arrangement underneath the
floor or if solid raised flooring is made, cement is to be stored on bamboo or timber
dunnage to the satisfaction of the Engineer-in-Charge. No separate payment will be
made for these godowns or for the store yard. Any cement, which is found at the time of
use to have been damaged, shall be rejected and must immediately to removed from
the site by the contractor as per directed of the Engineer-in-Charge.
C.12 Arrangement of Land :
The contractor will arrange land for installation of his Plants and Machineries, his
godown, store yard, labour camp etc. at his own cost for the execution of the work.
Departmental land, if available and if applied for, may be spared for the purpose on
usual charges as fixed by the Competent Authority.
C.13 Use of Government Land :
Before using any space in Government land for any purpose whatsoever, approval of
the Engineer-in-charge will be required. Departmental land, if available and if applied
for, may be spared for the purpose on usual charges as fixed by the Competent
Authority. The contractor will have to make his own arrangements for storage of tools,
plants, equipments; materials etc. of adequate capacity and will clear and remove on
completion of work and will also remove the shed, huts etc. which he might have
erected in Government land. If after such use, the contractor fails to clear the land,
Department will arrange to remove those installations and adequate recovery will be
made from the dues of the contractor.
C.14 Work Order Book :
The contractor will within seven days of receipt of the order to take up the work, supply
at his own cost one Work Order Book to Sub-Divisional Officer/Assistant Engineer
Concerned, who is authorized to receive and keep in custody the Work Order Book on
behalf of the Engineer-in-Charge. The Work Order Book will be kept at the site of work
under the custody of Sub-Divisional Officer/Assistant Engineer or his authorised
representative. The Work Order Book should have machine numbered pages in
triplicate. Directions or instructions from Departmental officers to be issued to the
Contractor will be entered (in triplicate) in the Work Order Book (except when such
directions or instructions are given by separate letters). The contractor or his
authorised representatives should regularly note the entries made in the Work Order
Book and also record thereon the actions taken or being taken by him for complying
the said directions or instructions on any relevant points relating to the work. The
contractor or his authorised representative may take away the triplicate pages of the
Page 32 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
Work Order Book for his own record and guidance.
Cases of supplementary items or of claims may not be entertained unless supported by
entries in the Work Order Book or any written order from the Tender Accepting
Authority.
The first page of the Work Order Book shall contain the following particulars:
a) Name of the Work
b) Reference to contract number
c) Contractual rate in percentage
d) Date of opening of the Work Order Book
e) Name and address of the Contractor
f) Signature of the Contractor
g) Name & address of the Authorized representative (if any)
h) Specific purpose for which the contractor’s representatives is authorized to act
on behalf of the Contractor.
i) Signature of the authorized representative duly attested by the Contractor.
j) Signature of the Sub-Divisional Officer/Assistant Engineer concerned.
k) Date of actual completion of work.
l) Date of recording final measurement.
Entries in (k) & (l) above shall be filled in on completion of the work and before the
Work Order Book is recorded in the office of the Sub-Divisional Officer/Assistant
Engineer.
Page 33 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
if so directed by the Engineer-in-Charge and the rates will be fixed in the manner as
stated below: -
(a) Rates of Supplementary items will be analyzed in the 1st instant as far as possible
from the rates of the allied items of works appearing in the tender schedule.
(b) Rate of supplementary items will be analyzed to the maximum extent possible from
the rates of allied items of works appearing in the P.W. Department Schedule of
Rates of probable items of work forming part of the tender document. Rates of SOR
for the working area at the time of floating of N.I.T. will be applicable.
(c) In Case, additional items do not appear in the above Public Works Department
Schedule of Rates, such items for the works will be paid at the rates entered in the
Public Works Department Schedule of Rates for the working area at the time
floating of N.I.T.
(d) If the rates of the supplementary items cannot be computed even after application
of clauses stated above, the same will be determined by analysis from market rates
of material, labour and carriage cost prevailing at the time of execution of such
items of work. Profit and overhead charges (both together) at 10% (Ten percent) will
be allowed only. In that case the contractual percentage will not be applicable.
Page 34 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
for work shall also have to be borne by the Contractor without any extra claim from the
department.
C.21 Drawings :
All works should be carried out in conformity with the drawings supplied by this
Department. The Contractor will have to carry out all the works according to the
Departmental General Arrangement Drawing and Detail Working Drawings to be
supplied by the Department from time to time.
b) The Contractor will save and indemnify the department from and against all claims,
demands, suit and proceedings for or on account of infringement of any patent, rights,
design, trade mark of name of other protected right in respect of any constructional
plant, machine, work, materials, thing or process used for or in connection with works
or temporary works or any of them.
Page 35 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
Laboratory Equipments:
1. Balances
i) 7 Kg to 10 Kg capacity, semi-self indicating type-accuracy 10 gm.
ii) 500 gm. Capasity. Semi-self indicating type-accuracy 1 gm.
iii) Pan balance-5 kg. capacity-accuracy 10 gms.
2. Ovens-electrically operated, thermostatically controlled upto 110˚C- sensitivity 1˚C.
3. Sieves: as per IS 460-1962.
i. I.S. serves-450 mm internal dia, of sizes 100 mm, 88 mm, 63 mm, 50 mm, 40
mm, 25 mm, 20 mm, 12.5 mm, 10 mm, 6.3 mm, 4.75 mm, complete with lid
and pan.
ii. I.S. sieves-200 mm internal dia (brass frame) consisting of 2.36 mm, 1.18 mm,
600 microns, 425 microns, 300 microns, 212 microns, 150 microns, 90
microns,75 microns, with lid and pan.
4. Sieve shaker capable of 200 mm and 300 mm dia sieves, manually operated with
timing switch assembly.
5. Equipment for slump test- slump cone, steel plate, tamping rod, steel scale, scoop.
6. Dial gauges, 25 mm travel-0.01mm/ division least count- 2nos.
7. 100 tonnes compression testing machine, electrical- cum mabually operated.
8. Graduated measuring cylinders 200 ml capacity- 3 nos.
9. Enamel trays (for efflorescence test for bricks).
i. 300 mm x 250 mm – 2 nos.
ii. Circular plates of 250 mm dia – 4 nos.
10. Cube Mould 12 nos.
11. Compression testing machine
12. Others as per requirement.
Page 36 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
C.30 Compliance of different Acts :
The contractor shall comply with the provisions of the Apprentices Act, 1961, Minimum
Wages Act, 1848. Contact Labour (Regulation and Abolition) Act 1970 and the rules
and orders issued hereunder from time to time. If he fails to do so, Engineer-in-Charge
or Superintending Engineer of the concern Circle of P.W. (Roads) Directorate may at his
discretions, take necessary measure over the contract.
The Contractor shall also make himself responsible for any pecuniary liabilities arising
out on account of any violation of the provision of the said Act(s). The Contractor must
obtain necessary certificate and license from the concerned Registering Office under
the Contract Labour (Regulation & Abolition) Act, 1970.
The contractor shall be bound to furnish the Engineer-In-Charge all the returns,
particulars or date as are called for from time to time in connection with
implementation of the provisions of the above Acts and Rules and timely submission of
the same, failing which the contractor will be liable for breach of contract and the
Engineer-in-Charge may at his discretion take necessary measures over the contract.
(d) ensure that all lights provided by the Contractor shall be screened so as not to
interfere with any signal light of the railways or with any traffic or signal lights of any
local or other authority.
Page 37 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
C.34 Setting out of the work :
The contractor shall be responsible for the true and perfect setting out of the work and
for the correctness of the position, levels, dimensions and alignments of all parts of
work, if any rectification or adjustment becomes necessary the contractor shall have to
do the same at his own cost according to the direction of the Engineer-in-Charge.
During progress of works, if any, error appears or arises in respect of position, level,
dimensions or alignment of any part of the work contractor shall at his own cost rectify
such defects to the satisfaction of the Engineer-in-Charge. Any setting out that may be
done or checked by either of them shall not in any way relieve the contractor from their
responsibility for correctness and rectification thereof.
Page 38 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
C.40 Implied elements of work in items :
Except of such items as are included in the Specific Priced Schedule of probable items
and approximate quantities no separate charges will be paid for traffic control
measures, shoring, shuttering, dewatering, curing etc. and the rates of respective items
or works are deemed to be inclusive of the same.
C.46.1. Rate quoted will be inclusive of clearing site including removal of surplus (both
serviceable & unserviceable) earth, rubbish, materials etc. as per direction of the
Engineer-in-Charge.
C.46.2. Rate quoted will be inclusive of West Bengal Sales Tax, Income Tax Octroi and
all other duties, if any.
C.46.3. Display board (Informatory) of size 150cm X 90cm is to be provided at starting
and end chainage of the work-site with aluminum plate hoisted on steel tubular pipe/
angle post to a height of 1.5 Meter at the cost of the contractor including fitting, fixing,
painting, lettering etc. complete as per direction of Engineer-in-Charge.
C.46.4.The Contractor is to display caution board maintaining I.R.C. norms at his own
cost as per direction of Engineer-in-Charge.
C.46.5. Deep excavation of trenches left out for days should be avoided.
C.46.6. Labour welfare Cess will be deducted @ 1(one) % of gross bill value as per rule.
C.46.7. The whole work will have to be executed as per Departmental drawings
available in this connection at the tendered rate.
C.46.8. Income Tax will be deducted from each bill of the contractor as per applicable
rate and rules in force.
Page 39 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
C.46.9. In accordance with the West Bengal Taxation Laws (amendment) Ordinance,
1993 amending the West Bengal Finance (Sales Tax) Act, 1994 necessary S.T / VAT
will be deducted as per rate in force from the bill in addition to other deduction as per
extent rules.
C.49 Arbitration :
As mentioned in Cl. 13 of NIT
SECTION – D
General
These Special Conditions of Contract supplement the preamble and General Instructions,
General Conditions of Contract, Bill of Quantities and basic rates and Technical Specifications
and tender drawings enclosed thereto, and shall be considered as part of the Tender Papers.
Where the provisions of these Special Conditions of Contract are at variance with General
Conditions of Contract, the provisions of these Special Conditions of Contract shall prevail.
The several documents forming the tender are to be taken as mutually complementary to one
another. Detailed drawings shall be followed in preference to small-scale drawings and figured
dimensions in preference to scaled dimensions.
If there are varying or conflicting provisions in the documents forming part of the contract, the
Engineer-in-Charge shall be the deciding authority with regard to the intentions of the
provisions and his decision shall be final and binding on the contractor.
The Employer reserve the right to exclude any of the Schedule items on reasons of the rates not
being reasonable or subsequent change of design for evaluation of tender and deciding the
contract.
The Contractor may be required to carry out any additional or alteration work other than the
specified in the schedule of work / bill of quantities as and when required, by the ‘Employer’
within the completion period of the project.
Scope of Work
The works to be governed by this contract shall cover designing and transportation upto
destination, safe custody at site, insurance, erection, testing and commissioning of the
following:
i) Main Switchgear panel connecting cables of both incoming and outgoing feeders
etc.
Page 40 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
ii) Laying of L.T underground cables from Switch Room to various buildings,
feeder pillar boxes, street light poles, etc.
The works to be undertaken by the Contractor will inter alias include the following:
vii) All other earthwork and masonry works required to be done concerning the
electrical works.
Drawings
Contractors shall prepare all the detailed design and working drawings and submit them
to the Employer for approval within 15 days from the date of award of contract.
The electrical layout, clearly indicating the electrical clearances, cable run layout with
schematic diagram shall be furnished in triplicate for approval.
Execution of work
All the works i.e. power panels, distribution boards, equipment layout, conduits layout,
electrical wiring, street lighting, cable laying, earthing etc. have to be done as per approved
drawings and directions given at site by the Engineer-in-Charge.
Page 41 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
Period of Completion
Completion period is very important in this case. Normally no extension of time will be
given, however, because delay if any, in the construction of building suitable extension will
be considered.No price variation shall be admissible on the contract rate for any item
during the entire period of contract including extended periods. The Contractor shall not
have any claim whatsoever in this regard except statutory variation of duties and taxes
imposed by Govt. of India.
Insurance Coverage
The Contractor shall within 15 days from the date of commencement of the work insure all
the works and materials with any nationalized Insurance Company for the full amount of
the contract at his own cost against loss or damage by fire, storm, tempest, lightning,
floods, earthquake, air craft or anything dropped there from, aenal objects, nots, civil
commotion and other such usual risks.
All erection work shall be of the best quality to the entire satisfaction of the Employer. The
Contractor shall ensure that the equipment and services under the scope of this contract
whether manufactured or performed within the Contractor’s premises or at his
subordinate’s premises or at the work site or at any other place are strictly in accordance
with the provisions of this contract. For this purpose, the Contractor shall adopt
necessary quality assurance programme to control such activities at all stages.
Inspection
The inspection officer(s) for this contract shall be nominated by the Employer and notified
to the Contractor.
Page 42 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
The cost of the inspection will be on Employer’s account subject to any other provisions
contained hereunder or elsewhere in the contract. One week’s notice must be given by the
Contractor to the Inspecting Engineer to take up the inspection.
The Contractor shall provide without any extra cost of the Employer all materials,
equipment, tools, labour and maintenance of every kind which the Employer’s Inspecting
Engineer may consider necessary for any test and examination to be made at the
Contractor’s or the Sub-contractor’s premises and at site and shall pay all cost attended
thereon.
All the equipment and materials shall be tested / inspected by the Employer or its
authorized Inspecting Engineer and approved before they are installed / used in the
execution of the works covered in the contract. If the Contractor uses any equipment /
materials without the prior approval of Employer, those are liable to be rejected. The exact
positions of all switch boards, OPDs and all runs-of-mains, sub-mains and distribution
wiring to individual points including exact positions of all light fittings and switch-boards
shall be first worked on the buildings and shall have to be approved by the Engineer-in-
Charge before actual commencement work.
The Inspecting Engineer or his authorized representative shall have at all times access to
the Contractor’s premises and shall have the power to:
i) Inspect and examine the materials and workmanship of the work at any time
during the manufacture at the manufacturer’s premises or in the premises of
the Sub-Contractor or at the site of the erection.
ii) Reject any part of the work submitted by the Contractor as not being in
accordance with the Contractor.
iii) Reject the whole of the work including equipment tendered of inspection if after
the inspection of such portion as he may, in his discretion think fit, he is
satisfied that the same is unsatisfactory.
iv) Mark the rejected equipment with a rejection mark so that the same may be
easily identified.
Consequence of Rejection
On the equipment / assemblies being rejected by the Inspecting Officer of the Employer at
destination the Contractor shall replace such rejected equipment / assemblies of the work
forthwith but in any event not later than a period of 2(two) weeks in the case of minor
equipment and 4(four) weeks in the case of major equipment from the date of rejection.
The Contractor shall bear all the costs replacement including freight, etc. but without
Page 43 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
being entitled to any extra time on this account. The decision as to whether the
equipment is to be classified as Minor or Major for the purpose of this clause shall be that
of the Engineer and it is not questionable.
Installation
All works connected with and inclusive of installation and erection under this contract
shall be done in accordance with the standard and established methods of
installation and erection of electrical equipment and shall comply with relevant
Indian Electricity Rules, National Electrical Code, BIS Codes of Specifications and
Standards. The work shall also be strictly in accordance with the instructions /
recommendations of the manufacturers. The equipment shall be leveled carefully
before being fixed finally in position. All fragile and sensitive equipment shall be
protected adequately and handled carefully during installation and erection.
Commissioning Tests
As soon as the installations are ready for commissioning / sub-station, the Contractor
shall arrange for all the tests / inspection as required by the relevant ISS and / or IE
Rules and advise the Employer and others concerned. Employer shall depute their
Inspecting Officer for witnessing the tests and to carry out inspection independently and
also jointly with other concerned agencies wherever necessary and only after the
installation passes the required tests and inspection, it should be commissioned /
energized.
The Contractor shall take full responsibility for these tests. For site sites the Employer
where possible, may permit the Contractor for the purpose of testing, the use of any
instruments / apparatus and electric power which the Employer can conveniently work
not complying with the specifications, the Employer at their discretion ask the Contractor
to pay the cost of providing the additional energy required. The Contractor shall provide
all apparatus and energy, which may be required for drying out the equipment in a
manner approved by the Employer. If, by reasons of the Contractor failing to comply with
any of the provisions of this clause, any of the said tests are to be repeated the Contractor
shall pay all fees and expenses in connection therewith.
Visual inspection, shall include checks for satisfactory workmanship, all connections,
painting, plastering, cleanliness of all fittings etc. and compliance with Indian Electricity
Rules.
The ammeters, voltmeters, and energy-meters shall be checked for their calibration, scale,
accuracy, etc. for compliance with the specified requirement.
Page 44 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
iv) Routine tests are to be carried out on presence of Engineer-in-Charge and Test
Certificates are to be submitted.
All cables shall be tested at manufacturer’s works in compliance with relevant standards.
All cables and connections after erection shall be tested as required by the Employer for:
i) Pressure Test.
Earth resistance shall be measured separately for each earth electrode and when they are
connected together and to the equipment recorded.
Warranty
Contractor shall guarantee that all the equipment and the works executed under this
contract shall be free from all defects and faults in materials, design, workmanship and
manufacture and shall be of acceptable standards for the contracted work and in full
conformity to the technical specifications.
The Contractor’s liability in respect of any compliant defect and / or claim shall be limited
to the execution, installation and erection of replacement parts free of charge, or the repair
of defective parts only to the extent that such replacement or repairs are attributable to or
arise from faulty workmanship or design of material in the manufacture of the equipment
/ stores, and or negligence in any manner and also in the event of failure of the equipment
to perform as intended.
The Contractor shall, if required, replace, repair, execute and / or install the goods or such
portion thereof as in rejected by the Employer free of cost at site or at the option of the
Employer the Contractor shall pay to the Employer the value thereof and such other
expenditure and damage as may arise by reason of the breach of the conditions therein
specified.
If, any defect is not rectified satisfactorily within the above mentioned one month, the
Employer may proceed to do the work at Contractor’s risk and cost and without prejudice
to any other rights of the Contractor under this contract.
If the Contractor so desires, the replaced parts can be taken over by him or his
representative for disposal as he deems fit within a period of one month from the date of
replacement of goods / parts. At the expiry of this period, no claim whatsoever shall lie on
the Employer.
The Employer may, at their discretion recover the ground rent for the goods / parts which
have been rejected during the warranty period for the specified period of one month, if the
rejected materials are not taken over within that period one month, by the Contractor or
his representative.
The warranty herein contained shall not apply to any material which have been repaired or
altered by the Employer, or on their behalf in any without the consent of the Contractor so
Page 45 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
as to affect its strength, performance and reliability or to any defects to any part due to
misuse negligence or accidents and to items of normal wear and tear to be specifically
mentioned by the Contractor in his offer and got accepted by the Employer. The decision
of the Employer concerning Contractor’s liability and the amount if any payable, under
this warranty, shall be final and conclusive.
Indemnity Bond
The Contractor shall sign an Indemnity Bond before starting the work from any damages,
prosecution, other legal suits and claims arising out of any mishaps occurring at site due
to negligence, wrong practice, bad workmanship, faulty work, violation of safety rules and
regulations etc., for which the Contractor shall be solely responsible. The Indemnity Bond
shall be executed in the form prescribed by the Employer.
Mode of Payment
Measurement of Electrical works should be done by the competent officers of the Electrical
Wing P.W.D.in Measurement Book according to Priced Schedule and Agreement and the
said measurements as authenticated by the Executive Engineer Electrical Wing, P.W.D.
shall be forwarded to the Executive Engineer (Civil) P.W.Dte. for making necessary
payment.
Termination of above cables, including supply of suitable brass compression cable glands
for respective size of heavy duty type including solderless copper cable sockets (Dowell’s
make) and necessary anti oxide pest (Dowell’s make) required during cramping sockets by
suitable section of cramping dice and tools etc. mention may be made that beyond 120 sq.
mm size hydraulic type machine to be used for proper crimping of cable sockets. The
sockets must be tinned properly and should be cleaned before insinuating the conductors
applying anti-oxide pest for proper surface bondage.
Page 46 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
Wiring cable shall be manufactured under IS:694/1900 or BS:2004 for PVC insulated
sheathed/unsheathed with copper conductor stranded of 1.1 KV or 650 volts grade having
colour code as required for electrical use.
Cables are to be laid both inside and outside the buildings. Laying of cables shall be in
accordance with IS:1255. Inside the buildings, cables shall be laid in G.I pipes /
Polythene pipes of suitable sizes or open trench as required. Outside the buildings, the
cables shall be laid in the ground at a depth of 1 meter from the ground level along with
approved routes with necessary brick and G.I protection for vertical riser / road crossings.
Laying of cable includes excavation of earth i.e. making the required trench, placing the
cables in trenches, providing the necessary sand cushioning below and above the cables
and brick protection at top. Identification – tags shall be provided on the cables at regular
intervals where more than one cable is laid. After the laying of cables as approved by the
Engineer-in-Charge, the trenches shall be filled with shifted earth and well rammed to
bring the surface in level with the surroundings. Sand shall be of good quality river sand
and the bricks B class burnt. Sand and bricks shall be laid continuously on the cables to
cover the cables fully. Cable identification makers made of galvanized steel places
incorporating the information such as the line voltage, size of cables. Cable identification
no. shall be provided at intervals of 10 metres along with entire cable route in an approved
arrangement.
Wherever the cables are crossing the roads, drains, water / sewerage pipes or entering /
leaving the buildings the cables shall be laid in class B G.I. pipes of suitable size as
directed by the Engineer-in-Charge.
Straights through joints are not normally permitted. In case of unusually long distances of
cable, laying work straight through joints would be considered on permission only if the
kits of specified make are used. No extra payment will be permitted for such joints.
Service Meter Boards housing front operated SFUs, terminal blocks, fuse cut-outs, kWh
meters etc., shall be provided with suitable arrangements for locking and sealing front
door. Suitable cut-outs and glass windows in front of kWh meters shall be provided for
taking readings and for periodical watching meters working.
Page 47 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
PDB/EPDB, LDB/ELDB service meter boards and main switch boards shall be complete
with all the equipment such as MCCBs, MCBs, Isolators, SFUs, Fuse Cut-outs, kWh
meters etc. as indicated in the Schedule of Quantities for the incoming and outgoing
circuits, suitably rated copper bus bars, neutral link, internal wiring, phenolic phase
barriers wherever necessary, clearances between phases, phases-neutral and earth
maintained as per relevant IS and properly painted with anti-corrosive primers and finish
paints. Finish colour should be as per client’s choice.
Insulated or covered earthing conductors where used, shall have green insulation braiding
or covering as appropriate. Under as circumstance shall the colour green be used for other
than earthing conductor. In addition where it is required that cables of different colours be
used for-identification purposes; the following system shall be employed. Red, Yellow and
Blue colour for phases and black for neutral only.
The electric load of all lights, power outlets etc. shall be balanced across the three phases.
Distribution wiring in PVC conduit casing capping to light, fan, socket outlets, exhaust fan
points etc. shall be done in looping in system. In this system except at stopping points
such as at terminals of switches, ceiling-roses, etc, and in case of socket outlets at the
socket terminals. Intermediate wiring joint injunction boxes will not be permitted.
The maximum number of wires drawn in one PVC conduit shall not be greater than the
recommended number given in the table of IS. 732-1963, contractor must consult the
specification given above.
Sub-mains are considered for the wiring from PDB to power outlets LDBs and point
control switch boards. These may be by two-core PVCA cable/PVC insulated sheathed
copper conductor wires as considered in bill of quantities.
Page 48 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
POINT WIRING IN BUILDINGS
Wiring in the buildings shall be concealed/surface drawn. PVC conduits accessories, PVC
casing capping cables, ceiling-rose, switches etc. used in the wiring shall be of approved
makes. All writing to be done by stranded single core copper PVC cable of size 1.5 sq.mm
for phase and neutral and one sq.mm copper PVC cables for earth wire (Green colour). In
case of rewiring partially, the similar cables are to be used as existing.
Laying of conduits, conduit accessories and wiring in concealed and surface system shall
meet the requirements of IS-732; National Electrical Code and national Building Code.
The PVC and MS conduits shall conform to IS:9537 (part 1 and 3) and IS : 1653
respectively. Metal junction boxes/ PVC junction boxes shall be used with PVC/MS
conduits as the case may be conduit accessories such as junction boxes/pull boxes, outlet
boxes, bends. Sleeves etc shall conform to IS : 5133 Necessary GI pull wire of 14 SWG
shall be provided in the conduits from and end to the other as required for drawing
electrical wires.
PVC conduits/Alkathene pipes shall be laid as far possible in straight runs tied to the
reinforcement bars to prevent the getting dislocated during concreting. Where conduits are
required to be embedded in the walls, the walls shall be chased to the required depth and
conduits fixed in position by means or suitable pipe hoods at every 600mm distance in an
approved manner. The walls chased for conduit embedding shall be covered suitably by
the Electrical Contractor.
Preparing switch board covers, control switches for all lights, fans, call bells, exhaust fans,
ceiling roses, PVC insulated electrical wires bond wire etc. are parts of Schedules for point
wiring. Similarly, conduits laying covered under a separate schedule item include
providing and embedding Alkathene pipe/MS conduits in RCC roof slabs/beams, walls,
MS junction boxes, bends, outlet switch boxes with 3mm thick Phylum sheet, fixing brass
screws and cup washer etc. in running meter measurement. Switch-boards may be of
double teak-wood board with Phylum cover or MS with Phylum cover as the case may be.
Terminal/outlet/switch boxes shall be of MS sheet of not less than 1.5mm thick and
provided with 4/6/8 threaded holes depending upon the size of the box. The depth sf the
boxes shall not be less than 75mm and the centre cross sectional area in between from
100 to 750 Sq. cms. The boxes shall be provided with two coats of anti-corrosive paint and
the inside surface finished with suitable white paint. The front cover should be 3mm thick
coloured or white Phylum sheet and over size by 1 cm, all round shall be provided with
suitable brass screws & cup-washer for MS Board only.
Sheet Metal Connector Box (16 SWH) of the following sizes with 3mm white Phylum sheet
cover is to be used:
a) 6” x 4” x 2.1/2”
b) 7” x 4” x 2.1/r
c) 8” x 6” x 2.1/2”
d) 4” x 4” x 2.1/2”
Page 49 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
In case of surface wiring by casing capping, the double T.W. Switch Board and Junction
Box of the following sizes (with 3mm thick white Phylum sheet cover fixing by four Nos.
brass wooden screw with Cup-washer) are permitted:
T- x 4” x 2” / 8” x 6” x 2” / 8” x 10” x 2” / 8” x 12” x 2”
Various sizes of wires viz. 1, 1.5, 2.5, 4 and 6 sq. mm which required to be used in the
wiring of building shall be of stranded flat twin/single core copper conductors, PVC
insulated & sheathed 1100 volt grade conforming to relevant IS-specification.
The number of cables/wires drawn in various sizes of conduits shall not exceed the
following limit.
1.5 Sq.mm 6 10 -
2.5 Sq.mm 4 18 -
4.0 Sq.mm 3 6 -
6.0 Sq.mm 2 14 8
a) For light, fan, call bell and Stranded 1.5 Sq.mm single core
Page 50 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
d) For air-conditioners, in-coming power supply cable will be of 7/0.36mm
stranded size (phase and neutral) and of earth 2.5 sq.mm (3/0.036 mm)
stranded single core copper cable from separate way of PDB.
Similar to Box/Rail Type with Fluorescent light Fittings with Opal acrylic diffuser.
Page 51 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
Compact Fluorescent Type Light Fittings
Compact fluorescent fitting with 2 x 11 Watts lamps, holders, stainless steel reflector with
housing and OPEC acrylic diffuses etc. of SIGMA’ search light make.
Control switches for lights, fans, call bells, exhaust fans etc. shall be of rating 6 Amps, 230
Voil, Piano-type flush mounted, cream colour conforming to relevant Indian Standards.
Ceiling roses also shall be of 6 Amps, rating 230 V. cream colour deluxe conforming to the
relevant IS – Specification Switches of 16 Amps capacity and associated 16A socket would
also required to pro’ ided facility of connection of power load upto 1 KW. Alternatively,
Industrial type plug-socket board may be used in specific cases. Cable used for power load
should be of suitable capacity.
After successful completion of the work., the final drawings/Blue Print Plan showing the
details circuit diagrams and fittings, fixtures are to be submitted along with the final bill.
EARTHING
All non-current carrying metal parts of the electrical installations such as switch gears, LT
panel, distribution boards, power plugs exhaust fans, air conditions, cable glands, MS
conduits, switch boxes etc. shall be bounded together suitably and connected to earth-
stations in accordance with the requirements of Indian Electricity Rules and IS : 3043.
All earth stations shall be of the same type similar to one illustrated in IS : 3403, using
pipe electrode of galvanized steel Class B having 65mm dia and a length of 3.04 meter
buried vertically in the ground and providing layers of charcoal/coke and salt as
necessary. The top end of the pipe electrode shall have suitable arrangements for making
connections of earth wire/flats in the manner approved by the Engineer-in-Charge. The
earth stations snail be located at least 2 M away from the buildings and not less than 6M
apart. Nearby earth stations (at least two) shall be interconnected with suitable size GI flat.
i) For building wiring the earth lead will be drawn from earth electrode to earth
bus-bar by 19/10 GL stranded wire and from earth bar to PDB & SWG GI wire &
from PDB to, SDB & LDB etc. by No. 10 SWG GI wire. For Power plug and 6 Amp
plug, either by 1 Sq. mm stranded copper/16 SWG G.I wire as the case may be
which will be mentioned in B.O.Q.
ii) Double connections shall be made for medium voltage supply (251 to 650V).
iii) All earth wires and flats from one end to the other shall be continuous and
without any joints and so laid to protect them against mechanical damage.
Page 52 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
If the required earth resistively is not obtained with the earth-pits, additional pits shall be
made for improving the system resistively. The rates payable for additional pits shall be
same as the rates quoted in the tender.
Earthing Schedule includes supply of all required material, digging pits, providing charcoal
/ cake and salt, filling up the pits (providing cement concrete chamber with cover for
substation earthing only for laying of earth wires / flat making connection with proper
fasteners, finishing machinery work that have been disturbed for electrical works, testing
etc.
Erection of Poles:
Erection of single street tubular pole of length, as given below with or without sole plate &
cap etc. in cement concrete foundation (proportion and dimension indicated below) as to
G.S having 600 x 600 x 150mm thick cement concrete (4:2:1) base block below sole
plate/Pole with hard Jhama metal including CC (6:3:1) muffing of 0.3 Mt (3ft) dia and 0.3
Mt (1 ft) above ground level including 3 mm (1/8”) thick neat cemented finish and
providing G.I earth bolt after making drilled hole etc. on pole & carrage of pole upto 1.6km
from store depot to work site including filling up the excavated earth pit with shifted soil
and ramming properly.
___________________________________________________________________
___________________________________________________________________
___________________________________________________________________
___________________________________________________________________
Erection of H – pole (D.P.) structure with 9 Mt long steel tubular poles (0.9 Mt. to 1.5 Mt.
apart) in cement concrete (6:3:1) foundations (as to similar dimension in item 1.2 (above)
including 600 x 600 x 150mm (2’ x 2’ x 6”) thick cement concrete (4:2:1) base block below
sole plate / pole with hard jhama meta including cement concrete (6:3:1) muffing 300mm
(1 ft.) dia and 300mm above ground level neatly cemented finish 3mm (1/8”) thick and
providing galvanised MS channels, cross arms and cross bracing made out of galvanised,
angle, flats etc. anti-climbing devices, ‘Danger’ board & earth bolt etc. “as per IS code of
practice”.
Extension items 1 & 2 above, for providing cement concrete (6:2:1) base block (around the
pole) dimension 0.60 x 0.60 x 0.76 mt. (2” x 2” 2’.6”) above ground level, neatly cemented
finish (3mm thick) at the base of pole (in lieu of cement concrete muffing) including S & F
looping cable box 25cm x 25cm 10cm (10” x 10” x 4”) made of C.I & including providing
drilled hole in pole suitable for Alkathene/polythene pipe entry as directed for street light
wiring.
Page 53 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
Painting of Steel Tubular Pole of lengths and no. of coats of paints as given below with
ready mixed paint/primer of approval make brand including preparation of surface by
sand paper/ emery paper, cleaning etc. for receiving fresh coat of paint.
Painting block letters or digits within a circle/square as required with “Black Japan” paint
of approved make & brand the size of letters and digits.
Painting of Steel Tubular pole of lengths and no. of coats of paint as given below with ready
mixed paint/primer of approved make & brand including preparation of surface by sand-
paper/emery paper, cleaning etc. for receiving fresh coat of paint.
Painting of any steel /iron surface with no of coats of paints as given below with ready
mixed paint/primer of approved make and brand including preparation of surface by sand
paper, cleaning etc. for receiving fresh coat of paint.
The Schedule item of street light poles include manufacture of stepped poles, excavation of
pits, making concrete foundations, erection of poles, filling up of pits satisfactorily, fixing
of light fixing on poles, connection with suitable weather proof insulated wires, earthing,
testing and commissioning at the locations decided by the Engineer-in-Charge. The pole
shall as per the sketch enclosed.
The poles shall be manufactured out of steel tubes conforming to IS: 2713 as shown in the
drawing. There shall be a base plate of MS of size 220 x 200 x 6mm welded to the bottom
of the pole and one MS rod of 19/20mm dia and 300m iong inserted across the and welded
at a height of 600mm from the base plate and both of them coated with bituminous paint.
The cable terminal arrangement shall be built in within the MS sleeve loop box as per in
the sketch. Water light 2 ram thick MS box shall have locking arrangement to house two
sets of terminals for incoming and looping connections and one re-wireable fuse fitting
with 6 Amps fuse on 6mm thick phylum base & properly insulated to withstand weather
conditions.
The poles shall be erected properly with cement concrete foundations as per P.W.D
(ELECT) specification-Necessary change of the concrete shall be done as per relevant
procedures. Two P.V.C pipe of not less than 30mm dis. With gland and bends shall be
provided in the foundation for cables entry into terminal box. Electrical connection
between the terminal box and the light fitting shall be made by means of 2.5mm single
core, PVC insulated copper cable of 1100V grade.
Page 54 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
v) NEC – 1985 – National Electrical Code for hospital and Operation Theatre.
vi) IS: 3480 – Flexible Steel Conduits for Electrical Wiring
vii) IS: 2667 – Fittings for rigid Steel Conduits for Electrical Wiring
viii) IS: 3837 – Accessories for rigid Steel Conduits for Electrical Wiring
ix) IS: 9537 Part-Hi- 1983-PVC Conduits for Electrical Wiring
x) IS: 694 – 1977 – Specifications for PVC insulated Cable for working voltage
upto and including 1100 Volts
xi) IS: 8130-1984 – Specification for Conduits for insulated Electrical Cable and
Flexible Cords
xii) IS-5563 – Electrical Power Connectors
xiii) IS: 3854-19S8 – Flush type Switches
xiv) IS: 1293-198S – Pin Sockets
xv) IS: 6538 – 1971 – 3 pin piano top
xvi) IS: 371 – 1979- Ceiling Roses
xvii) IS: 374-1979-Ceiling Fan
References, information and certificates from the respective clients certifying suitability,
technical knowledge or capability of the applicant should be signed by an officer not below
the rank of Executive Engineer or equivalent.
The applicant may furnish any additional information which he thinks is necessary to
establish his capabilities for successful completion of work. The applicants are however,
advised not to furnish superfluous information. No information shall be entertained after
submission of short-listing documents unless it is called for by the Client.
The contractor shall be responsible to obtain necessary approval from the respective
Authorities for Fire Detection and Alarm System. Contractor shall ensure that their sub-
suppliers are from Purchaser’s list of approved vendors only. In case of any deviation,
contractor shall obtain prior approval for the same from the Purchaser and shall submit
copies of such letters for approval along with inspection call.
Strict implementation of Directions for preventive measures needs to be taken to control air
pollution. Vide Memo no.: 1M-21/2017/06-R/W(N) Dated:- 16.06.2017 of the Joint Secretary
to the Govt. of WB(Projects & Coordination) Public Works Department.
Page 55 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023
c) Applying water prior to leveling or any other earth moving activity to keep the soil
moist throughout the process.
d) Limiting vehicle speeds to 15 mph on the work site.
e) Cleaning wheels and undercarriage of haul trucks prior to leaving construction site.
f) Applying and maintaining dust suppressant on haul routes.
g) Applying a cover or screen to stockpiles and stabilize stockpiles at completion of
activity by water and maintain a dust palliative to all outer surfaces of the
stockpiles.
h) Stabilizing surface soils where loaders, support equipment and vehicles should
operate by using water and maintain surface soils in a stabilized condition where
loaders, support equipment and vehicles will operate.
i) Stabilizing adjacent disturbed soils following paving activities with immediate
landscaping activity pr installation of vegetative or rock cover.
j) Maintaining dust control during working hours and clean track at the end of the
work shift/ day.
k) Stabilizing sloping surfaces using soil binders until vegetation or ground cover can
effectively stabilize the slope.
l) Disposal of debris in consultation with the local authorities following proper
environmental management practice.
m) During construction work, including cutting of marbles, ambient noise level should
not exceed more than 65 Db(a).
Practices to be discarded:-
A consolidated report regarding compliance of the directions i.e. preventive measures to be taken
and practice to be discarded, may please be furnished to this office for onward submission to the
Principal Secretary, Department of Environment.
Necessary instruction may be given to the Superintending Engineers and Executive Engineers
under his jurisdiction for taking necessary action in this regard.
Superintending Engineer,
Northern Circle, Social Sector, P.W.Dte.
Page 56 of 56 of
WB PWD/SS/SE/NC/NIT- 01 (e)/ 2022-2023