AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED

PROJECT NAME AND NUMBER: DIA6024/2019/RFP

TITLE OF PROJECT: DESIGN AND CONSTRUCT THE WEATHER PROTECTION STRUCTURE

NEC 3: ENGINEERING AND CONSTRUCTION CONTRACT (ECC)

Between AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED

Applicable at KING SHAKA INTERNATIONAL AIRPORT

(Registration Number: 1993/004149/30)

and [DRAFTING NOTE: INSERT CONTRATOR NAME]

(Registration Number: ___________________)

for DESIGN AND CONSTRUCT THE WEATHER PROTECTION

STRUCTURE

Contents: No of pages

Part C1 Agreements & Contract Data [●]

Part C2 Pricing Data [●]

Part C3 Scope of Works [●]

Part C4 Site Information [●]

Part C1: Agreements and Contract Data

C1.1: Form of Offer and Acceptance
OFFER

The Employer, identified in the Acceptance signature block, has solicited offers to enter into a contract for
the procurement of DESIGN AND CONSTRUCT THE WEATHER PROTECTION STRUCTURE
:

The tenderer, identified in the Offer signature block, has examined the documents listed in the Tender Data
and addenda thereto as listed in the Returnable Schedules, and by submitting this Offer has accepted the
Conditions of Tender.

By the representative of the tenderer, deemed to be duly authorised, signing this part of this Form of Offer
and Acceptance the tenderer offers to perform all of the obligations and liabilities of the Contractor under
the contract including compliance with all its terms and conditions according to their true intent and meaning
for an amount to be determined in accordance with the conditions of contract identified in the Contract Data.

THE OFFERED TOTAL OF THE PRICES INCLUSIVE OF VAT IS:

(in words)
………………………………………………………………………………………….................................... Rands;

(in figures) R…………………………………………..

THE OFFERED PRICES ARE AS STATED IN THE PRICING SCHEDULE

This Offer may be accepted by the Employer by signing the Acceptance part of this Form of Offer and
Acceptance and returning one copy of this document including the Schedule of Deviations (if any) to the
tenderer before the end of the period of validity stated in the Tender Data, or other period as agreed,
whereupon the tenderer becomes the party named as the Contractor in the conditions of contract identified
in the Contract Data.

Signature(s)

Name(s)

Capacity

For the
Bidder:

(Insert name and address of

Name & organisation)
signature of Date
witness
ACCEPTANCE

By signing this part of this Form of Offer and Acceptance, the Employer identified below accepts the tenderer’s
Offer. In consideration thereof, the Employer shall pay the Contractor the amount due in accordance with the
conditions of contract identified in the Contract Data. Acceptance of the tenderer’s Offer shall form an
agreement between the Employer and the tenderer upon the terms and conditions contained in this agreement
and in the contract that is the subject of this agreement.

The terms of the contract, are contained in:

Part C1 Agreements and Contract Data, (which includes this Form of Offer and Acceptance)

Part C2 Pricing Data

Part C3 Scope of Work: Works Information

Part C4 Site Information

and drawings and documents (or parts thereof), which may be incorporated by reference into the above listed
Parts.

Deviations from and amendments to the documents listed in the Tender Data and any addenda thereto listed in
the Returnable Schedules as well as any changes to the terms of the Offer agreed by the tenderer and the
Employer during this process of offer and acceptance, are contained in the Schedule of Deviations attached to
and forming part of this Form of Offer and Acceptance. No amendments to or deviations from said documents
are valid unless contained in this Schedule.

The tenderer shall within two weeks of receiving a completed copy of this agreement, including the Schedule of
Deviations (if any), contact the Employer’s agent (whose details are given in the Contract Data) to arrange the
delivery of any securities, bonds, guarantees, proof of insurance and any other documentation to be provided in
terms of the conditions of contract identified in the Contract Data. Failure to fulfil any of these obligations in
accordance with those terms shall constitute a repudiation of this agreement.

Notwithstanding anything contained herein, this agreement comes into effect on the date when the tenderer
receives one fully completed original copy of this document, including the Schedule of Deviations (if any).
Unless the tenderer (now Contractor) within five working days of the date of such receipt notifies the Employer
in writing of any reason why he cannot accept the contents of this agreement, this agreement shall constitute a
binding contract between the Parties.

Signature(s)

Name(s)

Capacity
for the
Employer

(Insert name and address of

Name & organisation)
signature of Date
witness
Schedule of Deviations

1 Subject . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
Details . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
...........................................................................
...........................................................................
...........................................................................
2 Subject . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
Details . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
...........................................................................
...........................................................................
...........................................................................
3 Subject . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
Details . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
...........................................................................
...........................................................................
...........................................................................

By the duly authorised representatives signing this agreement, the Employer and the Tenderer agree to and
accept the foregoing schedule of deviations as the only deviations from and amendments to the documents
listed in the Tender Data and addenda thereto as listed in the returnable schedules, as well as any
confirmation, clarification or changes to the terms of the offer agreed by the Tenderer and the Employer during
this process of offer and acceptance.

It is expressly agreed that no other matter whether in writing, oral communication or implied during the period
between the issue of the tender documents and the receipt by the tenderer of a completed signed copy of this
Agreement shall have any meaning or effect in the contract between the parties arising from this agreement.

For the Employer For the Bidder

Signature (s)

Name (s)

Capacity

Name and Airports Company South Africa SOC

Address Limited

LAMERCY DRIVE

Name & (Insert name and address of (Insert name and address of organisation)
Signature of organisation)
witness

Date
Part C1.2a Contract Data
Part one – Data provided by the Employer
The Conditions of contract are selected from the NEC3 Engineering and Construction Contract, April 2013.

Each item of data given below is cross-referenced to the NEC3 Engineering Construction Contract which
requires it.

Clause Statement Data

1 General

The conditions of contract are the

core clauses and the clauses for
Main Option

Main Option B: Priced contract with Bill of Quantities

Dispute resolution Option W1: Dispute resolution procedure

Secondary Options (incorporating X2: Changes in the law

amendments) X7: Delay damages
X13: Performance Bond
X16: Retention
X18: Limitation of liability
Z: Additional conditions of contract
of the NEC3 Engineering and Construction Contract, April
2013

10.1 The Employer is (Name) Airports Company South Africa SOC Limited, KING SHAKA
INTERNATIONAL AIRPORT

Address Airports Company South Africa SOC Limited

Po box 57701 la mercy 4407

Telephone 032 436 6000

Fax 0860 665 5274

10.1 The Project Manager is:

Mzokhona Dlamini
 Address KING SHAKA INTERNATIONAL AIRPORT
LA MERCY

Telephone 032 436 6567

E-mail address Procurement3.KSIA@airports.co.za

10.1 The Supervisor is Siphiwe MsimangoXX

Address KING SHAKA INTERNATIONL AIRPORT

LA MERCY
4407Xx
Telephone
Fax
Email

11.2 The works are DESIGN AND CONSTRUCT THE WEATHER PROTECTION
STRUCTURE [DESCRIBE THE WORKS]

11.2 The following matters will be • Availability of As Built information

included in the Risk Register • Access to Site
• Site Constraints and Constructability
•

11.2 The Works Information is in Part C3 ‘Scope of Works’ section of this contract

11.2 The Site Information is in Part C4 ‘Works Information’ section of this contract

11.2 The boundary of the site is Xx

12.2 The law of the contract is the law the Republic of South Africa
of

13.1 The language of this contract is English

13.3 The period of reply is Seven (7) days

3 Time

31.2 The starting date is XX

11.2 The completion date is XX

30.1 The access date is XX

31.1 The Contractor submits a first Within two weeks of the contract date XX
(preliminary) programme with the
tender by the tender closing date

32.2 The Contractor submits revised Four (4) weeks

programmes at intervals no
longer than

35.1 The Employer is not willing to The Employer and Others will have access to the works
take over the works before the during construction or prior to completion. Such access by
completion date the Employer and Others shall not relieve the Contractor from
liability for the completion of the works in accordance with the
Works Information and in terms of this contract.

4 Testing and Defects

42.2 The defects date is Twelve (12) months after Completion of the whole of the
works

43.2 The defects correction period is Two (2) weeks

5 Payment

50.1 The assessment interval is Ends and starts at 12h00 on the 25th day of each successive
month XX (XX) weeks

50.1 The currency of this contract is South African Rand

the

51.2 The period within which payment Four (4) weeks

is made is

51.4 The interest rate is The prime lending rate of the Nedbank Bank. as determined
from time to time

6 Compensation events

60.1 The weather measurements to be the cumulative rainfall (mm)

recorded for each calendar month the number of days with rainfall more than 10 mm
are the number of days with minimum air temperature less than 0
degrees Celsius

60.1 The place where weather is to be At the Construction Site Office and the records to be kept on
recorded (on the Site) is site in a file clearly marked for this purpose

60.1 Assumed values for the ten-year Month Days Month Days
return weather data for each January 1 July 4
weather measurement for each February 1 August 3
calendar month are March 2 September 2
April 2 October 2
May 3 November 2
June 3 December 1

7 Title No data required for this section of the conditions of contract

8 Risks and Insurance

84.1 The Employer provides these Refer to the Insurance Clauses which is attached at the end
insurances of the Contract Data

84.2 The Contractor provides the The Insurance Clauses which is attached at the end of the
insurance stated in Contract Data. The insurances are in the joint names of the
Parties and provide cover for events which are at the
Contractor’s risk from the starting date until the Defects
Certificate or a termination certificate has been issued.

The minimum limit of indemnity As prescribed by the Compensation for Occupational Injuries
for insurance in respect of death and Diseases Act No. 130 of 1993
of or bodily injury to employees of
the Contractor arising out of and
in the course of their employment
in connection with this contract for
any one event is:

9 Termination No data required for this section of the conditions of contract

10 Data for Main Options

B Priced contract with Bill of [include if applicable]

Quantities

11 Data for Option W1

W1.1 The Adjudicator is The person appointed jointly by the parties from the list of
adjudicators contained below

W1.2 The Adjudicator nominating body The current Chairman of Johannesburg Advocate’s Bar
is Council

W1.4 The tribunal is Arbitration

W1.4 If the tribunal is arbitration, the The arbitration procedure is set out in The Rules for the
arbitration procedure is Conduct of Arbitrations 2013 Edition, 7th Edition, published by
The Association of Arbitrators, (Southern Africa)

W1.4 The place where arbitration is to Johannesburg, South Africa.

be held is

W1.4 The person or organisation who The Arbitrator is the person selected by the Parties as and
will choose an arbitrator when a dispute arises in terms of the relevant Z Clause, from
the Panel of Arbitrators provided under the relevant Z clause
if the arbitration procedure does not state who selects an
arbitrator. The Arbitrator nominating body is the Chairman of
the Johannesburg Advocates Bar Council.

12 Data for Secondary Option

Clauses

X7 Delay Damages
 Delay damages of the works are Amount per day is 0.05%, to the maximum of 10% of the
Contract value

X13 Performance bond

X13.1 The amount of the performance 10% of the contract value. Pro-forma draft of a performance
bond is bond to be used is attached to this contract.

X16 Retention

X16.1 The retention percentage is 5% of the Contract value.

X18 Limitation of Liability

X18.1 The Contractor’s liability to the Nil - Neither Party is liable to the other for any consequential
Employer for indirect or or indirect loss, including but not limited to loss of profit, loss
consequential loss is limited to of income or loss of revenue

X18.2 For any one event, the The total of the Prices
Contractor’s liability to the
Employer for loss of or damage to
the Employer’s property is limited
to

X18.3 The Contractor’s total liability to The total of the Prices

the
Employer for defects due to his
design
which are not listed on the
Defects Certificate is limited to

X18.4 The Contractor’s total liability to The Contractor’s total direct liability to the Employer for all
the Employer for all matters matters arising under or in connection with this contract, other
arising under or in connection than the excluded matters, is limited to the total of the Prices
with this contract, other than and applies in contract, tort or delict and otherwise to the
excluded matters, is limited to extent allowed under the law of the contract.

The e excluded matters are amounts payable by the

Contractor as stated in this contract for

- Loss of or damage to the Employer’s property,

- Delay damages,
- Defects liability,
- Insurance liability to the extent of the Contractor’s risks
- loss of or damage to property (other than the works, Plant
and Materials),
- death of or injury to a person;
- damage to third party property; and
- infringement of an intellectual property right
Z The Additional conditions of Z1 – Z20
contract are

Amendments to the Core Clauses

Z1 Interpretation of the law

Z1.1 Add to core clause 12.3:

Any extension, concession, waiver or relaxation of any action stated in this contract by the Parties,
the Project Manager, the Supervisor, or the Adjudicator does not constitute a waiver of rights, and
does not give rise to an estoppel unless the Parties agree otherwise and confirm such agreement
in writing.

Z2 Providing the Works:

Z2.1 Delete core clause 20.1 and replace with the following:
The Contractor provides the works in accordance with the Works Information and warrants that
the results of the Works, when complete, shall be fit for their intended purpose

Z3 Other responsibilities:

Add the following at the end of core clause 27:

Z3.1 The Contractor shall have satisfied himself, prior to the Contract Date, as to the completeness,
sufficiency and accuracy of all information and drawings provided to him as at the Contract Date

Z3.2 The Contractor shall be responsible for the correct setting out of the Works in accordance with the
original points, lines and levels stated in the Works Information or notified by the Project Manager,
Supervisor or the Employer. Any errors in the positioning of the Works shall be rectified by the
Contractor at the Contractor’s own costs.

Z4 Extending the defects date:

Add the following as a new core clause 46:

Z4.1 If the Employer cannot use the works due to a Defect, which arises after Completion and before
the defects date, the defects date is delayed by a period equal to that during which the Employer,
due to a Defect, is unable to use the works

Z4.2 If part of the works is replaced due to a Defect arising after Completion and before the defects
date, the defects date for the part of the works which is replaced is delayed by a period equal to
that between Completion and the date by when the part has been replaced

Z4.3 The Project Manager notifies the Contractor of the change to a defect date when the delay occurs.
The period between Completion and an extended defects date does not exceed twice the period
between Completion and the defects date stated in the Contract Data

Z5 Termination

Z5.1 Add the following to core clause 91.1, at the second main bullet, fifth sub-bullet point, after
the words “assets or”: “business rescue proceedings are initiated or steps are taken to initiate
business recue proceedings”.

Amendment to the Secondary Option Clauses

Z6 Performance Bond
Z6.1 Amend the first sentence of clause X13.1 to read as follows:
The Contractor gives the Employer an unconditional, on-demand performance bond, provided by
a bank which the Project Manager and the Employer have accepted, for the amount stated in the
Contract Data and in the form set out in Annexure C.ii of this Contract Data.

Z6.2 Add the following new clause as Option X13.2:

The Contractor ensures that the performance bond is valid and enforceable until the end of the
contract period. If the terms of the performance bond specify its expiry date and the end of the
contract period does not coincide with such expiry date, four weeks prior to the said expiry date,
the Contractor extends the validity of the performance bond until the end of the contract period. If
the Contractor fails to so extend the validity of the performance bond, the Employer may claim the
full amount of the performance bond and retain the proceeds as cash security

Z7 Limitation of liability:

Insert the following new clause as Option X18.6:

Z7.1 The Employer's liability to the Contractor for the Contractor's indirect or consequential loss is
limited to R0.00

Z7.2 Notwithstanding any other clause in this contract, any proceeds received from any insurances or
any proceeds which would have been received from any insurances but for the conduct of the
Contractor shall be excluded from the calculation of the limitations of liability listed in the contract

Additional Z Clauses

Z8 Cession, delegation and assignment

Z8.1 The Contractor shall not cede, delegate or assign any of its rights or obligations to any person
without the written consent of the Employer, which consent shall not be unreasonably withheld.
This clause shall be binding on the liquidator/business rescue practitioner /trustee (whether
provisional or not) of the Contractor

Z8.2 The Employer may cede and delegate its rights and obligations under this contract to any person
or entity

Z9 Joint and several liability

Z9.1 If the Contractor constitutes a joint venture, consortium or other unincorporated grouping of two or
more persons, these persons are deemed to be jointly and severally liable to the Employer for the
performance of the Contract.

Z9.2 The Contractor shall, within 1 week of the Contract Date, notify the Project Manager and the
Employer of the key person who has the authority to bind the Contractor on their behalf.

Z9.3 The Contractor does not materially alter the composition of the joint venture, consortium or other
unincorporated grouping of two or more persons without prior written consent of the Employer.

Z10 Ethics

Z10.1 The Contractor undertakes:

Z10.1.1 not to give any offer, payment, consideration, or benefit of any kind, which constitutes or could be
construed as an illegal or corrupt practice, either directly or indirectly, as an inducement or reward
for the award or in execution of this contract;
Z10.1.2 to comply with all laws, regulations or policies relating to the prevention and combating of bribery,
corruption and money laundering to which it or the Employer is subject, including but not limited to
the Prevention and Combating of Corrupt Activities Act, 12 of 2004.

Z10.2 The Contractor’s breach of this clause constitutes grounds for terminating the Contractor’s
obligation to Provide the Works or taking any other action as appropriate against the Contractor
(including civil or criminal action). However, lawful inducements and rewards shall not constitute
grounds for termination.

Z10.3 If the Contractor is found guilty by a competent court, administrative or regulatory body of
participating in illegal or corrupt practices, including but not limited to the making of offers (directly
or indirectly), payments, gifts, gratuity, commission or benefits of any kind, which are in any way
whatsoever in connection with the contract with the Employer, the Employer shall be entitled to
terminate the contract in accordance with the procedures stated in core clause 92.2. the amount
due on termination is A1.

Z11 Confidentiality

Z11.1 All information obtained in terms of this contract or arising from the implementation of this contract
shall be treated as confidential by the Contractor and shall not be used or divulged or published to
any person not being a party to this contract, without the prior written consent of the Project
Manager or the Employer, which consent shall not be unreasonably withheld.

Z11.2 If the Contractor is uncertain about whether any such information is confidential, it is to be
regarded as such until otherwise notified by the Project Manager.

Z11.3 This undertaking shall not apply to –

Z11.3.1 Information disclosed to the employees of the Contractor for the purposes of the implementation
of this agreement. The Contractor undertakes to procure that its employees are aware of the
confidential nature of the information so disclosed and that they comply with the provisions of this
clause;

Z11.3.2 Information which the Contractor is required by law to disclose, provided that the Contractor
notifies the Employer prior to disclosure so as to enable the Employer to take the appropriate
action to protect such information. The Contractor may disclose such information only to the
extent required by law and shall use reasonable efforts to obtain assurances that confidential
treatment will be afforded to the information so disclosed;

Z11.3.3 Information which at the time of disclosure or thereafter, without default on the part of the
Contractor, enters the public domain or to information which was already in the possession of the
Contractor at the time of disclosure (evidenced by written records in existence at that time);

Z11.4 The taking of images (whether photographs, video footage or otherwise) of the works or any
portion thereof, in the course of Providing the Works and after Completion, requires the prior
written consent of the Project Manager. All rights in and to all such images vests exclusively in
the Employer

Z11.5 The Contractor ensures that all his Subcontractors abide by the undertakings in this clause.

Z12 Employer’s Step-in rights

Z12.1 If the Contractor defaults by failing to comply with his obligations and fails to remedy such default
within 2 weeks of the notification of the default by the Project Manager, the Employer, without
prejudice to his other rights, powers and remedies under the contract, may remedy the default
either himself or procure a third party (including any subcontractor or supplier of the Contractor) to
do so on his behalf. The reasonable costs of such remedial works shall be borne by the
Contractor

Z12.2 The Contractor co-operates with the Employer and facilitates and permits the use of all required
information, materials and other matter (including but not limited to documents and all other
drawings, CAD materials, data, software, models, plans, designs, programs, diagrams,
evaluations, materials, specifications, schedules, reports, calculations, manuals or other
documents or recorded information (electronic or otherwise) which have been or are at any time
prepared by or on behalf of the Contractor under the contract or otherwise for and/or in connection
with the works) and generally does all things required by the Project Manager to achieve this end.

Z13 Liens and Encumbrances

Z13.1 The Contractor keeps the Equipment used to Provide the Services free of all liens and other
encumbrances at all times. The Contractor, vis-a-vis the Employer, waives all and any liens which
he may from time to time have, or become entitled to over such Equipment and any part thereof
and procures that his Subcontractors similarly, vis-a-vis the Employer, waive all liens they may
have or become entitled to over such Equipment from time to time

Z14 Intellectual Property

Z14.1 Intellectual Property (“IP”) rights means all rights in and to any patent, design, copyright, trade
mark, trade name, trade secret or other intellectual or industrial property right relating to the
Works.

Z14.2 IP rights remain vested in the originator and shall not be used for any reason whatsoever other
than carrying out the works.

Z14.3 The Contractor gives the Employer an irrevocable, transferrable, non-exclusive, royalty free
licence to use and copy all IP related to the works for the purposes of constructing, repairing,
demolishing, operating and maintaining the works

Z14.4 The written approval of the Contractor is to be obtained before the Contractor's IP made available
to any third party which approval will not be unreasonably withheld or delayed. Prior to making any
Contractor's IP available to any third party the Employer shall obtain a written confidentiality
undertaking from any such third party on terms no less onerous than the terms the Employer
would use to protect its IP

Z14.5 The Contractor shall indemnify and hold the Employer harmless against and from any claim
alleging an infringement of IP rights (“the claim”), which arises out of or in relation to:

Z14.5.1 the Contractor’s design, manufacture, construction or execution of the Works

Z14.5.2 the use of the Contractor’s Equipment, or

Z14.5.3 the proper use of the Works.

Z14.6 The Employer shall, at the request and cost of the Contractor, assist in contesting the claim and
the Contractor may (at its cost) conduct negotiations for the settlement of the claim, and any
litigation or arbitration which may arise from it.

Z16 Dispute resolution:

Z16.1 Appointment of the
Adjudicator

An Adjudicator is appointed Panel of Adjudicators

when a dispute arises, from
the Panel of Adjudicators Name Location Contact details
below. The referring party (phone & e mail)
nominates an Adjudicator, Adv. Ghandi Badela Gauteng +27 11 282 3700
which nomination is either ghandi@badela.co.za
accepted or rejected by the Mr. Errol Tate Pr. Durban +27 11 262 4001
other party. In the instance of a Eng. Errol.tate@mweb.co.za
rejection of the nominated Adv. Saleem Ebrahim Gauteng +27 11 535-1800
Adjudicator, the referring Party salimebrahim@mweb.co.za
refers the appointment Mr. Sebe Msutwana Gauteng +27 11 442 8555
deadlock to the Chairman of Pr. Eng. sebe@civilprojects.co.za
the Johannesburg Bar Council, Mr. Sam Amod Gauteng sam@samamod.com
who appoints an Adjudicator
listed in the Panel of Adv. Sias Ryneke Gauteng 083 653 2281
Adjudicators below SC reyneke@duma.nokwe.co.z
a
The Parties appoint the Mr. Emeka Ogbugo Pretoria +27 12 349 2027
Adjudicator under the NEC3 (Quantity Surveyor) emeka@gosiame.co.za
Adjudicator’s Contract, April
2013

Z16.2 Appointment of the

Arbitrator

An Arbitrator is appointed Panel of Arbitrators

when a dispute arises from the
Panel of Arbitrators below. The Name Location Contact details
referring party nominates an (phone & e mail)
Arbitrator, which nomination is Adv. Ghandi Badela Gauteng +27 11 282 3700
either accepted or rejected by ghandi@badela.co.za
the other party. In the instance Mr. Errol Tate Pr. Durban +27 11 262 4001
of a rejection of the nominated Eng. Errol.tate@mweb.co.za
Arbitrator, the referring Party Adv. Saleem Ebrahim Gauteng +27 11 535-1800
refers the appointment salimebrahim@mweb.co.za
deadlock to the Chairman of Mr. Sebe Msutwana Gauteng +27 11 442 8555
the Johannesburg Bar Council, Pr. Eng. sebe@civilprojects.co.za
who appoints an Arbitrator Mr. Sam Amod Gauteng sam@samamod.com
listed in the Panel of
Arbitrators below Adv. Sias Ryneke Gauteng 083 653 2281
SC reyneke@duma.nokwe.co.z
a
Mr. Emeka Ogbugo Pretoria +27 12 349 2027
(Quantity Surveyor) emeka@gosiame.co.za

Z17 Notification of a compensation event

Z17.1 Delete “eight weeks” in clause 61.3 and replace with “four weeks”. Delete the words “unless the
event arises from the Project Manager or the Supervisor giving an instruction, issuing a certificate,
changing an earlier decision or correcting an assumption.

Z18 BBBEE Certificate

Z18.1 The Contractor shall be expected to annually present a compliant BEE Certificate. Failure to do
adhere to these requirements shall be considered a material breach of the conditions of this
Contract, the sanction for which may be a cancellation of this Contract.

Z19 Communication

Z19.1 Add a new Core Clause 14.5 and 14.6 to read as follows:
The Project Manager requires the written consent of the Employer if an action will result in a
change to the design, scope, and Works information that is 5% or more

Z19.2 The Project Manager requires the written consent of the Employer if an action will result in the
Completion Date being extended by more than 30 days.

Z20 Delegation

As stipulated by Section 37(2) of the Occupational Health and Safety Act No. 85 of 1993 as
amended the Contractor agrees to the following:

Z20.1 As part of this contract the Contractor acknowledge that it (mandatory) is an employer in its own
right with duties as prescribed in the Occupational Health and Safety Act No 85 of 1993 as
amended and agree to ensure that all work being performed, or Equipment, Plant and Materials
being used, are in accordance with the provisions of the said Act, and in particular with regard to
the Construction Regulations
PART C1.2b CONTRACT DATA
PART TWO – DATA PROVIDED BY THE CONTRACTOR

Clause Statement Data

10.1 The Contractor is (Name):

Address:

Telephone No.
Fax No.

11.2 The working areas are Only the Site Area. See C4 ‘Site Information’

24.1 The Contractor’s Key people are: CV’s to be appended to Tender Schedule

Name:

Job:

Responsibility:

Qualifications:

Experience:

Name:

Job:

Responsibility:

Qualifications:

Experience:

Name:

Job:

Responsibility:

Qualifications:

Experience:
 Name:

Job:

Responsibility:

Qualifications:

Experience:

11.2 The completion date is XX

11.2 The following matters will be • Existing Services

included in the Risk Register • Access to Site
• Delay in supply of material and/or equipment
• Progress of the works against the program
• Travelling public and ACSA stakeholders

11.2 The Works Information is in Part C3 ‘Scope of Works’ section of this contract

31.1 The programme identified in the XX

Part C1: Agreements and Contract Data
C1.3: Form of Guarantee

PRO FORMA FOR PERFORMANCE BOND

PERFORMANCE BOND
[TO BE REPLICATED ON BANK’S LETTERHEAD]
Brief description of contract……………………………………………………………………..

Name and address of Beneficiary.......................................................................................................

…………………………………………………….. (whom the contract defines as the Contractor).

We, the undersigned ................................................... and..................................... in our capacities as

Guarantor’s...........……………….. of …………….. (Registration Number: ….) (hereinafter called “the Bank”)
have been informed that …………………………… hereinafter called the ‘Principal’) is your Contractor under such
contract, which requires him to obtain an irrevocable, unconditional performance security.

At the request of the Principal, we …………………………………..(name of bank) hereby irrevocably undertake to

pay you, the Employer, any sum or sums not exceeding in total the amount of ………………………………(the
“Guaranteed Amount”) upon receipt by us of your first written demand stating that such an amount (or lesser
amount) as may be claimed is due and payable to the Employer.

This guarantee constitute an irrevocable, unconditional, non-negotiable and non-transferable undertaking to pay
in accordance with the above, subject to the proviso that this Letter will not be interpreted as extending the
Bank’s liability to anything more than the Guaranteed Amount.

Notwithstanding anything to the contrary herein contained, the Bank’s obligation shall be construed as principal
and not as accessory to the contract and shall not be delayed or discharged by the fact that a dispute exists
between the Employer and the Contractor.

We undertake to pay you such Guaranteed Amount upon receipt by us, within such period of 14 days, of your
first written demand stating that such an amount (or lesser amount) as may be claimed is due and payable to the
Employer.

The guarantee shall be governed by and construed in accordance with the laws of the Republic of South Africa

Signed at ______________________________ on ____________________20….

For:
Registration Number:

Name & Position

As witnesses:

1. ______________________________

2. ______________________________
PART C1: AGREEMENTS AND CONTRACT DATA
[EACH AIRPORT TO CONFIRM WITH SAFETY DEPARTMENTS WHETHER THERE IS
ADDITIONAL SAFETY DOCUMENTATION TO BE ATTACHED THAT CONTRACTOR
SHOULD BE AWARE OF]
C1.4: OCCUPATIONAL HEALTH AND SAFETY AGREEMENT

OCCUPATIONAL HEALTH AND SAFETY AGREEMENT

AGREEMENT IN TERMS OF SECTION 37(2) OF THE OCCUPATIONAL HEALTH & SAFETY ACT (ACT 85 Of
1993) & CONSTRUCTION REGULATION 5.1(k)

OBJECTIVES

To assist Airport Company South Africa (ACSA) in order to comply with the requirements of:
1. The Occupational Health & Safety (Act 85 of 1993)and its regulations and
2. The Compensation for Occupational Injuries & Diseases Act (Act 130 of 1993) also known as the (COID
Act).

To this end an Agreement must be concluded before any contractor/ subcontracted work may commence

The parties to this Agreement are:

Name of Organisation:

AIRPORTS COMPANY SOUTH AFRICA

KING SHAKA INTERNATIONL AIRPORT XXX AIRPORT
Physical Address:
Airport Company South Africa

LA MERCY 4407XXX

Hereinafter referred to as “Client”

Name of organisation:

Physical Address

Hereinafter referred to as “the Mandatary/ Principal Contractor”

MANDATORY’S MAIN SCOPE OF WORK

GENERAL INFORMATION FORMING PART OF THIS AGREEMENT

1. The Occupational Health & Safety Act comprises of SECTION 1-50 and all unrepealed
REGULATIONS promulgated in terms of the former Machinery and Occupational Safety Act No.6 of
1983 as amended as well as other REGULATIONS which may be promulgated in terms of the Act
and other relevant Acts pertaining to the job in hand.
2. “Mandatary” is defined as including as agent, a principal contractor or a contractor for work, but
WITHOUT DEROGATING FROM HIS/HER STATUS IN HIS/HER RIGHT AS AN EMPLOYER or
user of the plant
3. Section 37 of the Occupational Health & Safety Act potentially punishes Employers (PRINCIPAL
CONTRACTOR) for unlawful acts or omissions of Mandataries (CONTRACTORS) save where a
Written Agreement between the parties has been concluded containing arrangements and
procedures to ensure compliance with the said Act BY THE MANDATARY.
4. All documents attached or refer to in the above Agreement form an integral part of the Agreement.
5. To perform in terms of this agreement Mandataries must be familiar and conversant with the relevant
provisions of the Occupational Health & Safety Act 85 of 1993 (OHS Act) and applicable
Regulations.
6. Mandatories who utilise the services of their own Mandatories (contractors) must conclude a similar
Written Agreement with them.
7. Be advised that this Agreement places the onus on the Mandatary to contact the CLIENT in the
event of inability to perform as per this Agreement.
8. This Agreement shall be binding for all work the Mandatary undertakes for the client.
9. All documentation according to the Safety checklist including a copy of the written Construction
Manager appointment in terms of construction regulation 8, must be submitted 7 days before work
commences.

THE UNDERTAKING

The Mandatary undertakes to comply with:

INSURANCE

1. The Mandatary warrants that all their employees and/or their contractor’s employees if any are
covered in terms of the COID Act, which shall remain in force whilst any such employees are present
on the Client’s premises. A letter is required prior commencing any work on site confirming that the
Principal contractor or contractor is in good standing with the Compensation Fund or Licensed
Insurer.
2. The Mandatary warrants that they are in possession of the following insurance cover, which cover
shall remain in force whilst they and /or their employees are present on the Client’s premises, or
which shall remain in force for that duration of their contractual relationship with the Client, whichever
period is the longest.
a. Public Liability Insurance Cover as required by the Subcontract Agreement.
b. Any other Insurance cover that will adequately makes provision for any possible losses and/or
claims arising from their and /or their Subcontractors and/or their respective employee’s acts
and/or omissions on the Client’s premises.

COMPLIANCE WITH THE OCCUPATIONAL HEALTH & SAFETY

ACT 85 OF 1993

The Mandatary undertakes to ensure that they and/or their subcontractors if any and/or their
respective employees will at all times comply with the following conditions:
 1. All work performed by the Mandatary on the Client’s premises must be performed under the
close supervision of the Mandatary’s employees who are to be trained to understand the hazards
associated with any work that the Mandatary performs on the Client’s premises.
2. The Mandatary shall be assigned the responsibility in terms of Section 16(1) of the OHSAct 85 of
1993, if the Mandatary assigns any duty in terms of Section 16(2), a copy of such written
assignment shall immediately be forwarded to the Client.
3. The Mandatary shall ensure that he/she familiarise himself/herself with the requirements of the
OHSAct 85 of 1993 and that s/he and his/her employees and any of his subcontractors comply
with the requirements.
4. The Mandatary shall ensure that a baseline risk assessment is performed by a competent person
before commencement of any work in the Client’s premises. A baseline risk assessment
document will include identification of hazards and risk, analysis and evaluation of the risks and
hazards identified, a documented plan and safe work procedures to mitigate, reduce or control
the risks identified, and a monitoring and review plan of the risks and hazards.
5. The Mandatary shall appoint competent persons who shall be trained on any Occupational
Health & Safety aspect pertaining to them or to the work that is to be performed.
6. The Mandatary shall ensure that discipline regarding Occupational Health & Safety shall be
strictly enforced.
7. Any personal protective equipment required shall be issued by the Mandatary to his/her
employees and shall be worn at all times.
8. Written safe working practices/procedures and precautionary measures shall be made available
and enforced and all employees shall be made conversant with the contents of these practises.
9. No unsafe equipment/machinery and/or articles shall be used by the Mandatary or contractor on
the Client’s premises.
10. All incidents/accidents referred to in OHSAct shall be reported by the Mandatary to the Provincial
Director: Department of Labour as well as to the Client.
11. No user shall be made by the Mandatary and/or their employees and or their subcontractors of
any of the Client’s machinery/article/substance/plant/personal protective equipment without prior
written approval.
12. The Mandatary shall ensure that work for which the issuing of permit is required shall not be
performed prior to the obtaining of a duty completed approved permit.
13. The Mandatary shall ensure that no alcohol or any other intoxicating substance shall be allowed
on the Client’s premises. Anyone suspected to be under the influence of alcohol or any other
intoxicating substance shall not be allowed on the premises. Anyone found on the premises
suspected to be under the influence of alcohol or any other intoxicating substance shall be
escorted off the said premises immediately.
14. Full participation by the Mandatary shall be given to the employees of the Client if and when they
inquire into Occupational Health & Safety.

FURTHER UNDERTAKING

1. Only a duly authorised representative appointed in terms of Section 16.2 of the OHS Act is eligible to
sign this agreement on behalf of the Mandatary. The signing power of this representative must be
designated in writing by the Chief Executive Officer of the Mandatary. A copy of this letter must be
made available to the Client.
2. The Mandatary confirms that he has been informed that he must report to the Client’s management,
in writing anything he/she deems to be unhealthy and /or unsafe. He has versed his employees in
this regard.
3. The Mandatary warrants that he/she shall not endanger the health & safety of the Client’s employees
and other persons in any way whilst performing work on the Client’s premises.
4. The Mandatary understands that no work may commence on the Client’s premises until this
procedure is duly completed, signed and received by the Client.
5. Non-compliance with any of the above clauses may lead to an immediate cancellation of the
contract.

ACCEPTANCE BY MANDATARY
In terms of section 37(2) of the Occupational Health & Safety Act 85 of 1993 and section 5.1(k) of the
Construction Regulations 2014,

I ………………………………….a duly authorised 16.2 Appointee acting for and on behalf of

………………………………………………..(company name) undertake to ensure that the requirements and the
provision of the OHSAct 85 of 1993 and its regulations are complied with.

Mandatary – WCA/ Federated Employers Mutual No……………………………….

Expiry date …………………………………………………………………………………….

________________________________________ _______
SIGNATURE ON BEHALF OF MANDATARY DATE
(Warrant his authority to sign)

_________________________________________ _______________
SIGNATURE ON BEHALF OF THE CLIENT DATE
AIRPORT COMPANY SOUTH AFRICA
PART C1: AGREEMENTS AND CONTRACT DATA
C1.5: ACSA INSURANCE CLAUSES

INSURANCE CLAUSES FOR CAPEX PROJECTS

[DRAFTING NOTE: ENSURE THAT CORRECTLY DATED INSURANCE SCHEDULE ATTACHED –

NOKULUNGA MASIZA IS THE CUSTODIAN]

The insurance clauses in this document should be extracted and attached to tender documents and to contracts.

SECTION A: DEFINITIONS

Landside refers to:

• Areas of the airport before the security points, and

• The restricted area beyond the security points but, within the perimeter of gatehouses, passenger
terminals and cargo buildings

Airside refers to:

• The Apron / manoeuvring areas

• Area within the airside boundary/perimeter fence, excluding the internal areas of the passenger
terminals, perimeter gatehouses and cargo building.

SECTION B: INSURANCE CLAUSES

1. Insurance requirements for contracts with a value below R50million on the LANDSIDE

1.1 Contract Works

• With regards to contract works claims, the contractor/consultant is responsible for a deductible (excess)
of R250 000.
• Contractors / consultants may re-insure the deductible

1.2 Public Liability

• In the event of a claim against the contractor / consultant for 3rd party property damage the contractor /
consultant will be responsible for a deductible (excess) of R275 000
• In the event of a claim against the contractor / consultant for removal of lateral support, the contractor /
consultant will be responsible for a deductible (excess) of R500 000
• Contractors / consultants may re-insure the deductibles

1.3 Professional Indemnity

• All consultants are responsible for Professional Indemnity cover of R5million

• Contractors who have a material design element, excluding typical P & G related work, as part of their
scope, are responsible for Professional Indemnity cover of R5million
• In the event of a claim above R5million, the ACSA PI cover will kick in for the amount in excess of R5m.
• Proof of cover in the form of a certificate of insurance should be provided to ACSA before a contract is
signed between ACSA and the contractor and/or consultant.
2. Insurance requirements for contracts below R50million on the AIRSIDE
2.1 Contract Works

• With regards to contract works claims, the contractor / consutant is responsible for a deductible (excess)
of R250 000.
• Contractors / consultants may re-insure the deductible

2.2 Public Liability

• In the event of a claim brought against the contractor / consultant for 3rd party property damage the
contractor / consultant will be responsible for a deductible (excess) of R525 000
• In the event of a claim brought against the contractor / consultant for removal of lateral support, the
contractor / consultant will be responsible for a deductible (excess) of R750 000
• In the event of a claim brought against the contractor / consultant for damage to aircraft, the contractor /
consultant will be responsible for a deductible (excess) of R750 000
• Contractors / consultants may re-insure the deductibles

2.3 Professional Indemnity

• All consultants are responsible for Professional Indemnity cover of R5million

• Contractors who have a material design element, excluding typical P & G related work, as part of their
scope, are responsible for a Professional Indemnity cover of R5million.
• In the event of a claim above R5million, the ACSA PI cover will kick in for the amount in excess of
R5million.
• Proof of cover in the form of a certificate of insurance should be provided to ACSA before a contract is
signed between ACSA and the contractor and/or consultant.

3. Insurance requirements for contracts with a value above R50 million on the LANDSIDE

• Contracts with a value of more R50 million are not automatically covered under the construction policies.
A separate quote is provided by insurers per contract.

3.1 Contract Works

With regards to contract works claims, the contractor / consultant is responsible for the following deductibles:

• All Civil Work and Earthworks – R300 000 deductible (excess)

• All other claims – R300 000 deductible (excess)
• Other property insured – R700 000 deductible (excess)
• Contractors / consultants may re-insure the deductibles

3.2 Public Liability

• In the event of a claim brought against the contractor / consultant for 3rd party property damage the
contractor / consultant will be responsible for a deductible (excess) of R275 000
• In the event of a claim brought against the contractor / consultant for removal of lateral support, the
contractor / consultant will be responsible for a deductible (excess) of R500 000
• Contractors / consultants may re-insure the deductibles

3.3 Professional Indemnity

• All consultants are responsible for Professional Indemnity cover of R10million

 • Contractors who have a material design element, excluding typical P & G related work, as part of their
scope, are responsible for a Professional Indemnity cover of R10million
• In the event of a claim above R10million, the ACSA PI cover will kick in for the amount in excess of
R10m
• Proof of cover in the form of a certificate of insurance should be provided to ACSA before a contract is
signed between ACSA and the contractor and/or consultant.

4. Insurance requirements for contracts with a value above R50 million on the AIRSIDE

• Contracts with a value of more R50 million are not automatically covered under the construction policies.
A separate quote is provided by insurers per contract.

4.1 Contract Works

With regards to contract works claims, the contractor / consultant is responsible for the following deductibles:

• All Civil Work and Earthworks excluding Runways – R300 000 deductible (excess)
• Runway Rehabilitation – R300 000 deductible (excess)
• New Runway Construction – R700 000 deductible (excess)
• All other claims – R300 000 deductible (excess)
• Other property insured – R700 000 deductible (excess)
• Contractors / consultants may re-insure the deductibles

4.2 Public Liability

• In the event of a claim brought against the contractor / consultant for 3 rd party property damage the
contractor / consultant will be responsible for a deductible (excess) of R1 025 000
• In the event of a claim brought against the contractor / consultant for removal of lateral support, the
contractor / consultant will be responsible for a deductible (excess) of R1 250 000
• In the event of a claim for damage to aircraft, the contractor / consultant will be responsible for a
deductible (excess) of R1 250 000
• Contractors / consultants may re-insure the deductibles

4.3 Professional Indemnity

• All consultants are responsible for Professional Indemnity cover of R10million

• Contractors who have a material design element, excluding typical P & G related work, as part of their
scope, are responsible for a Professional Indemnity cover of R10million
• In the event of a claim above R10million, the ACSA PI cover will kick in for the amount in excess of
R10m
• Proof of cover in the form of a certificate of insurance should be provided to ACSA before a contract is
signed between ACSA and the contractor and/or consultant.
PART C2: PRICING DATA

Develop Pricing Data (Pricing Assumptions, Pricing Schedules, Bills of Quantities etc, as relevant) using
guidance provided in the CIDB Compiler guidance note for Component document: C2 – Pricing Data
(http://www.cidb.org.za/procurement/procurement_toolbox/overview/contract_sec/default.aspx)
.

PRICING SCHEDULES / BILL OF QUANTITIES SBD3

C2.3 DETAILED BREAKDOWN OF COSTS TO SUPPORT THE PRICED BILL OF QUANTITIES

Detailed breakdown of cost to be inserted here.

Price Schedule

No: Price
Quantity
Description Rates Unit Price
(Hours)

1 Designing of the canopy structure or similar proposed structure and construction supervision.
Provide breakdown of costing as an attachment (To include the number of hours, rate per individual
and other related costs)

Quantity Price
Description Rates Unit Price
(Hours)
2 Other related professional costs
(please specify)

Construction WORKS

3.1 R
Cost of material (civil works) Provide bill of quantities, attach detailed breakdown
3.2 R
Cost of material (structural works) Provide bill of quantities, attach detailed breakdown

Other costs

4.1 R
Safety file

4.2 R
Site establishment
4.3 R20 000
Permit costs (to be paid on a proven costs)

Any Other cost please list below (Provide detailed breakdown)

22
Total Excluding VAT R
23
VAT R
24
Total Including VAT R
PART 3: SCOPE OF WORK

Document reference Title No of

pages

This cover page 1

C3.1 Employer’s Works Information

C3.2 Contractor’s Works Information1

1 Insert at award stage or delete if not applicable. Delete this note once a selection is made.

Page 29 of 45
Revision 1 Nov 2015
 Total number of pages

Develop Scope of Work using guidance provided. Note that this document is merely a guideline of what to
include in the scope of work. The contract manager will be required to apply his / her mind and delete or add
any information required, depending on the nature of the works. Where the contract requires information to
be included in the scope of works, the relevant heading will contain a footnote indicating that the information
is compulsory. Complete this document by replacing the guidance notes in [square brackets] with the
relevant information. When the document is complete, delete this note and ALL footnotes.

For further guidance refer to guidance notes on CIDB website:

http://www.cidb.org.za/procurement/procurement_toolbox/overview/contract_sec/default.aspx

.
PART C3
SERVICE INFORMATION (SCOPE / SPECIFICATIONS)

C3 SCOPE OF WORKS

1. PURPOSE
The Aim of this tender is to appoint a reputable service provider for the design and construction of the weather protection
structure such as the canopy between the Avis car rentals to the terminal building. The team shall include the Architect,
Structural Engineer and the contractor.

2. SCOPE OF WORK
2.1. Description of the Work / Services:
The project scope includes the following:
Design and construct the canopy structure or similar approved structure that will be able to protect passengers from
adverse weather conditions. The scope will entail design including conceptual designs by the Architect (proposals to be
submitted to ACSA with different canopy arrangement or equivalent shelter structure. The agreed structure will have to
be designed and signed off by a registered Engineer. This project will further include procurement of material and
construction supervision (EPCM model).
Design is to address the following deliverables: -
a. Less obstruction to Avis rental’s advertisements or interference with their parking
b. Less obstructing structural members on passengers’ walkways
c. For Ease maintenance, specification to match the existing airport structures
d. Provision of access to designated smoking area

The project stages will be as follows:

Stage 1: Inception

Page 30 of 45
Revision 1 Nov 2015
The first step on appointment is an in-depth discussion to ascertain the requirements of the project. A visit to site will
then be required to do an analysis and possible solutions to the problem. This will include consideration of issues such
as the views, orientation, access, and the surrounding buildings.

A design brief will then be agreed upon, and an outline concept will be formulated based on the project requirements,
design requirements, the contextual issues stemming from the site analysis.

Stage 2: Concept Design

Based on the architectural brief developed from the discussions above and site analysis in Stage 1, an initial concept
design will be prepared and submitted to ACSA for review. This will show the intended weather protection structure or
concept based on the scope requirements, as well as the planning relationships and proposed layout and contextual
issues stemming from the site such as views, orientation and access. It will also show the proposed intended concept
and form of the structure.
After review and comments on the initial concept, the design will be further developed to show the proposed materials as
well as the technical and functional characteristics of the design. These will include sections through the structure, more
detailed dimensioned sketch plans illustrating the positioning of the structure in relation to the surrounding buildings. As
the sketch plans form the basis of the entire project, this may be a back-and-forth process until all parties involved are
entirely satisfied with the outcome.

Stage 3: Design Development

The design development stage will commence once the final concept design, along with estimated price based on this,
are approved.

The plans will then be further developed based on the approved concept design, with any further changes that may be
required, as well as the input from the consultants. In the case of the input from the structural engineer, this will include
the specifications of the foundations, member size designs and the roof design. The design development will include
details of the construction systems and materials to be used.
After any further changes are made, the final set of design development plans are produced.

Stage 4: Construction Documentation

The service provider will be expected to design, procure materials and construct. The proposal is to comprise of a priced
Bill of Quantities of the proposed solutions.

Stage 5: Construction phase

Contract Administration
The architectural /professional service provided for this stage comprises of the administration of the construction work.
This includes administering the handover of the site to the contractor; the issuing of construction documentation; initiating
and/or checking sub-contract design and documentation as appropriate; regularly inspecting the works for conformity to
the design and contract documentation; issuing the practical completion certificate; and submitting handover documents
to ACSA.

Page 31 of 45
Revision 1 Nov 2015
TABLE OF CONTENTS
Clause number and description Page

Part 3: Scope of Work.................................................................................................................................... 291

C3.1: Employer’s works Information .................................................................................................................. 2

1. Description of the works ............................................................................................................................ 2

2. Contract Management ............................................................................................................................. 23

3. Engineering and design of the works ...................................................................................................... 45

4. Procurement ............................................................................................................................................ 56

5. Construction ............................................................................................................................................. 68

6. Plant and Materials standards and workmanship .................................................................................. 811

2. List of drawings .................................................................................................................................... 1013

C3.2 Contractor’s Works Information ....................................................................................................... 1114

Page 1 of 45
Revision 1 Nov 2015
C3.1: EMPLOYER’S WORKS INFORMATION

1. Description of the works

[provide a general description of the works, including the general arrangements and location
drawings. Sufficient information should be included so as to enable the tenderer to determine
whether they have the resources and capability to carry out the work]

Description of the Work / Services:

The project scope includes the following:
Design and construct the canopy structure or similar approved structure that will be able to protect passengers from
adverse weather conditions. The scope will entail design including conceptual designs by the Architect (proposals to be
submitted to ACSA with different canopy arrangement or equivalent shelter structure. The agreed structure will have to
be designed and signed off by a registered Engineer. This project will further include procurement of material and
construction supervision (EPCM model).
Design is to address the following deliverables: -
e. Less obstruction to Avis rental’s advertisements or interference with their parking
f. Less obstructing structural members on passengers’ walkways
g. For Ease maintenance, specification to match the existing airport structures
h. Provision of access to designated smoking area

2. Interpretation and terminology

[If necessary, include any definitions in addition to those used in the conditions of contract which are
required only for the purpose of making the Works Information easier to draft and read. Also list
abbreviations used and provide a full interpretation of each one, as illustrated below]
The following abbreviations are used in this Works Information:
Abbreviation Meaning given to the abbreviation

ACSA Airports Company South Africa SOC Limited

3. Contract Management

Management meetings2

Risk reduction meetings are to be held monthly during pre-installation, installation and project close
out phase. Meetings will be minuted and distributed within a week. Supervisor attendance is
required.

Health and safety risk management

2 The information in this section is required by the contract. Do not delete.

Page 2 of 45
Revision 1 Nov 2015
 The Contractor shall comply with the health and safety requirements contained in Part C.1.2 of the “Works
Information

Environmental constraints and management

The contractor must take into consideration passenger traffic at the arrivals area especially during peak hour

operations. Work is to be scheduled to avoid peak hour operation times.

Quality assurance requirements

Within the period stated in the Contact Data, the Contractor submits his complete quality
control and assurance system (with all quality control and assurance
procedures and manuals) for review and acceptance by the Employer. The
manual includes pro-forma checklists for all requirements of the Contractor’s
quality control and assurance program and those called for in the Scope.

Acceptance by the Employer of the Contractor’s quality assurance programme, quality plans
and/or inspection and/or test plans, or of those of his Subcontractors will not
relieve the Contractor of his obligation to provide services which meet the
requirements of the Contract.

Programming

The contractor is to make provision of 4 weeks from date of contract signing for the acquiring of
permits on site.

The Contractor’s Personnel

[state any additional constraining requirements on Contractor’s Personnel that are not
already stated in other sections of the Works Information or the conditions of contract. For
example, the Employer may require the Contractor to submit an organogram showing its
people and their lines of authority / communication, particularly where the Contractor is a
Joint Venture]
Insurance provided by the Employer

[add any insurance related information, requirements or other issues not dealt with in core
clause 87.1. as well as the details of ACSA personnel to whom insurance-related queries
should be addressed]
Provision of bonds and guarantees

Page 3 of 45
Revision 1 Nov 2015
 Without limitation to the Employer’s rights under the Contract, the Employer may withhold
payment of amounts due to the Contractor until the bond or guarantee required
in terms of this contract has been received and accepted by the person notified
to the Contractor by the Project Manager to receive and accept such bond or
guarantee. Such withholding of payment due to the Contractor does not affect
the Employer’s right to termination stated in this contract.

[add any other requirements]

Records of Defined Cost, payments & assessments of compensation events to be kept by the
Contractor

[include any constraint imposed in regard to format and filing of the records, and whether
access for the Project Manager shall be provided in hard copy or electronically. Also detail
how other documentation should be treated]
Training workshops and technology transfer

[in this section, describe –

the Contractor ‘s requirements in relation to training workshops and technology transfer;

the frequency of on job training workshops;

obligation for technology transfer being included as part of the contract on Completion of the
works (if any)]

4. Engineering and design of the works

Employer’s design

[where the design is primarily done by the Employer, describe the Employer’s design in
sufficient detail so as to indicate the standard of performance required to the Contractor]
[where the design responsibility lies with the Contractor –
describe the Employer’s specification which the Contractor must observe when designing
the works;

detail any particulars which must be taken into account by the Contractor in his design]

Parts of the works which the Contractor is to design3

[provide details as to the Contractor’s design obligations as required by core clause 21.1]
Procedure for submission and acceptance of Contractor’s design

[specify the extent of detail (the particulars) of the Contractor’s design which is to be
submitted to the Project Manager for his acceptance and state requirements for drawings to
be prepared by the Contractor]
3 The information in this section is required by the contract. Do not delete.

Page 4 of 45
Revision 1 Nov 2015
 Use of Contractor’s design

[detail any purposes, in addition to those provided for in core clause 22.1, for which the
Contractor’s design may be used. Also list any limitations or exceptions applicable]
Equipment required to be included in the works4

[core clause 11.2(7) defines Equipment as “items provided by the contractor and used by
him to provide the works and which the Works Information does not require him to include in
the works.” Detail the equipment to be included in the works in this section]
As-built drawings, operating manuals and maintenance schedules

[in this section, describe any requirements applicable to as-built drawings, operating
manuals and maintenance schedules]
5. Procurement

[the definition of Disallowed Cost in Options C D and E makes reference to the Works Information in
relation to procurement procedures. Use this section to include any such procedures to be able to
administer this procedure, as well as any constraints on procurement procedures as may be required
by Options A & B]
Personnel:

Minimum requirements of people employed on the Site

[specify any constraints in relation to people employed to carry out the Works]

Subcontracting

Preferred subcontractors

[in this section the Employer may list subcontractors or suppliers with which the
Contractor is required to enter into subcontracts]
Limitations on subcontracting

The Contractor may not subcontract more than 20% of the Works.

[state any additional requirements or restrictions]

Plant and Materials

Plant & Materials provided “free issue” by the Employer

[state requirements as to collection, delivery, storage, inspection, care and

control of plant and Materials. Always include the requirements that “all other
Plant and Materials are to be provided by the Contractor”]
Contractor’s procurement of Plant and Materials

[specify any requirements applicable to the Contractor’s procurement of Plant

and Materials]
Tests and inspections before delivery5

4 The information in this section is required by the contract. Do not delete.

Page 5 of 45
Revision 1 Nov 2015
 [specify any requirements here for any tests and inspections as required by core clauses 40
and 41]
Marking Plant and Materials outside the Working Areas6

[state how the Contractor is to “mark” Plant and Materials which is outside the Working
Areas if they are to be paid for before delivery to the Working Areas, as required by core
clauses 70.1 and 71.1]
Contractor’s Equipment (including temporary works)

[state any requirements that may be specific to the type of works being performed]
6. Construction

[this section deals with the requirements, facilities, services and rules applicable to the Contractor in
carrying out the work on the Site during the construction and maintenance period. Complete
accordingly]
Temporary works, Site services & construction constraints

Employer’s Site entry and security control, permits, and Site regulations

[add project-specific requirements in this section]

Restrictions to access on Site, roads, walkways and barricades

[add project-specific requirements in this section]

People restrictions on Site; hours of work, conduct and records

[add project-specific requirements in this section]

Title to materials from demolition and excavation7

[core clause 73.2 states that the Contractor has title to materials from
excavation and demolition only as stated in the Works Information. Complete
accordingly]
Contractor’s Equipment

[state how records are to be kept of Equipment on Site]

Equipment provided by the Employer

[Provide details of equipment made available for use by the employer and set
out conditions relating thereto]
Site services and facilities provided by the Employer8

[State the site services and facilities Employer will provide e.g. power, water,
waste disposal, ablutions, fire protection, lighting etc, as required by core clause
25.2 and state that “the Contractor shall provide everything else necessary for
Providing the Works”]

5 The information in this section is required by the contract. Do not delete. If it does not apply, delete the notes
in italics and substitute the words ‘Not applicable’.
6 The information in this section is required by the contract. Do not delete. If it does not apply, delete the notes

in italics and substitute the words ‘Not applicable’.

7 The information in this section is required by the contract. Do not delete. If it does not apply to the works,

delete the notes in italics and substitute the words ‘Not applicable’.
8 The information in this section is required by the contract. Do not delete. If it does not apply, delete the notes

in italics and substitute the words ‘Not applicable’, but ALWAYS state “the Contractor shall provide everything
else necessary for Providing the Works”.

Page 6 of 45
Revision 1 Nov 2015
 Facilities provided by the Contractor

[in this section –

The facilities the Contractor is to provide e.g. Site accommodation, laboratories,
storage, vehicles and office equipment etc;

The requirements for such facilities; and

what happens to these facilities upon completion of the contract]

Existing premises, inspection of adjoining properties and checking work of Others

[provide details of the project-specific requirements]

setting out of the works

[state requirements for the setting out of the works]

site conditions and requirements

[in this section, state any requirements related to –

Excavations and associated water control

Underground services, other existing services, cable and pipe trenches and
covers

Control of noise, dust, water and waste

Construction requirements

[In this section, specify any additional requirements related to –

Sequences of construction or installation

Hook ups to existing works]

Completion, testing, commissioning and correction of Defects

Work to be done by the Completion Date9

[core clause 11.2(2) defines Completion as when the Contractor has done all
the work which the Works Information states he is to do by the Completion
Date]
All work is to be done by the Contractor shall be completed by the Completion
Date, save for the following: [list project-specific exceptions and
state by when the work should be completed]

9 The information in this section is required by the contract. Do not delete.

Page 7 of 45
Revision 1 Nov 2015
 The Project Manager cannot certify Completion until all the work except that
listed above has been completed and is also free of Defects which
would have, in his opinion, prevented the Employer from using the
works and Others from doing their work.

Use of the works before Completion has been certified10

[core clause 35.2 provides that the Employer may use any part of the works
before Completion has been certified but if he does so he takes over the part of
the works except if the use is for a reason stated in the Works Information. The
reasons referred to in core clause 35.2 are stated in this section]
Materials facilities and samples for tests and inspections

[state the materials, facilities and samples for tests and inspections the
Contractor and the Employer are to provide in terms of core clause 40.2]
Commissioning

[requirements and procedure relating to commissioning would be stated here, or

attached to an annexure referred to in this section]
Start-up procedures required to put the works into operation

[complete accordingly]
Take over procedures

[complete accordingly]
Access given by the Employer for correction of Defects11

[core clause 43.4 requires that the Project Manager arranges for the Employer
to allow the Contractor access to and use of a part of the works which has been
taken over if needed to correct a Defect. After the works have been put into
operation, the Employer may require the Contractor to undertake certain
procedures before such access can be granted (for example barricading a
motorway or in a nuclear power station). Include these here]
Performance tests after Completion

[in this section, state the procedures for carrying out such tests]
Operational maintenance after Completion

[state any applicable requirements here]

7. Plant and Materials standards and workmanship

[this section of the Works Information contains all the specifications for the permanent works.
Provide the relevant details and requirements under the following headings:]
Investigation, survey and Site clearance

Building works

10 The information in this section is required by the contract. Do not delete. If it does not apply, delete the notes
in italics and substitute the words ‘Not applicable’.
11 The information in this section is required by the contract. Do not delete. If it does not apply, delete the notes

in italics and substitute the words ‘Not applicable’.

Page 8 of 45
Revision 1 Nov 2015
 [this section comprises of the specifications provided by the Employer, the list of
standardised specifications applicable to the works and variations to the standardised
specifications]
Civil engineering and structural works

[this section comprises of the specifications provided by the Employer, the list of
standardised specifications applicable to the works and variations to the standardised
specifications]
Electrical & mechanical engineering works

[these specifications are usually project specific and developed by the Employer to suit his
operations. Either include these specifications here, or refer to them in attached Annexure]
Process control and IT works

[these specifications are usually project specific and developed by the Employer to suit his
operations. Either include these specifications here, or refer to them in attached Annexure]
[any additional information as required by ACSA]

Page 9 of 45
Revision 1 Nov 2015
8. List of drawings

1.1. Drawings issued by the Employer

[This is the list of drawings issued by the Employer at or before the Contract Date and which
apply to this contract]

Drawing number Revision Title

Page 10 of 45
Revision 1 Nov 2015
C3.2 CONTRACTOR’S WORKS INFORMATION

[This section of the Works Information will always be project-specific depending on the nature of the works.
In this section, include information such as the Contractor’s design and Plant and Materials specifications
and schedules etc]

11
PART C4: SITE INFORMATION

Document reference Title No of

pages

This cover page 1

C4 Site Information

Total number of pages

For additional guidance notes go to

http://www.cidb.org.za/procurement/procurement_toolbox/overview/contract_sec/default.aspx
Develop Site Information for engineering and construction works contract only using guidance provided in
the Compiler guidance note for Component document: C4 – Site Information

12
Core clause 11.2(16) states

“Site Information is information which describes the Site and its surroundings and is in the documents which
the Contract Data states it is in.”

In Contract Data, reference has been made to this Part 4 of the contract for the location of Site Information.

Delete this note and others given in boxes like this one at final draft stage.

The compiler of this document should first consult the ECC3 Guidance Notes pages 23 and 24. Further
notes are given under each heading below.
Site Information is information about the Site at the time of tender upon which the tendering contractor bases
his prices. It is fixed and does not include anything about what happens on the Site after award; that is
Works Information.
Site Information does not include weather data; that is included in the Contract Data.
If the Contractor subsequently encounters conditions which are different to those described here, he may be
entitled to notify a compensation event.

Description of the Site and its surroundings

General description
Provide a general description of the Site and its location. Reference would probably be made to a drawing
showing the Site and its surroundings and the boundaries of the site as required by the Contract Data. It is
particularly important that details of surrounding buildings be provided where crane operation is likely to be
affected, or the works involve deep foundations adjacent to existing buildings.

Existing buildings, structures, and plant & machinery on the Site

If the works have interfaces or hook up points with existing facilities or comprise refurbishment of existing
facilities, provide full details of these so that the tendering contractor can plan his design and construction to
integrate with them as the Works Information requires. As built drawings of the existing facilities usually
provide the necessary information; such drawings can be listed here stating where they are located for the
Contractor’s use.

Subsoil information
Provide details of geotechnical reports, borehole records and test results for parts of the Site where
earthworks are required by this contract. These details may be referenced as an Annexure to this document
where they are extensive.

Hidden services
Provide details about and drawings showing hidden services and underground structures. If accurate details
are not available state what assumptions are to be made by the Contractor concerning such services.

Other reports and publicly available information

13
This subsection may refer to mapping, hydro-graphic data, hydrological information, shipping movements,
tides and published papers or Geological Surveys that the tendering contractor may need to be able to
decide his method of working and programme and prepare any designs for which he would be responsible.

14